W9127820R0023 AM01.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE 4. REQUISITION/PURCHASE 5. PROJECT NO. (If applicable)

W91278-20-R-0023-0001 21 FEB 2020 MEF20045

6. ISSUED BY CODE 7. ADMINISTERED BY(If other than item 6)

CODE

Corps of Engineers 109 St. Joseph St.

Mobile, AL 36602

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP code) 9A. AMENDMENT OF SOLICITATION

NO.

W91278-20-R-0023

9B. DATED (SEE ITEM 11)

7 FEB 2020

10A. MODIFICATION OF

CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority)

THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b)

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible)

The subject solicitation for: TWO PHASE DESIGN & CONSTRUCTION OF COMMERCIAL GATE, TYNDALL AFB, FL

Is modified in the following: REFER TO THE ENCLOSED REVISED SPECIFICATIONS FOR AMENDMENT NO. 0001

Except as provided herein, all terms and conditions of the document reference in item 9A or 10A, as Heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICE (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

BY

(Signature of contracting officer)

16C. DATE SIGNED

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)

PREVIOUS EDITION UNUSABLE Prescribed by GSA

TWO-PHASE DESIGN & CONSTRUCTION OF COMMERCIAL GATE W9127820R0023

TYNDALL AIR FORCE BASE, FLORIDA MEF20045

SF 30 Page 2 W91278-20-R-0023-0001

PART I - REVISIONS MADE BY ADDED AND/OR REPLACEMENT PARAGRAPHS/PAGES/SECTIONS

The items listed below are to be replaced by the corresponding added and/or revised paragraphs/pages or sections. Added and/or revised paragraphs/pages or sections are indicated by a note in bottom right hand corner of each paragraph or page. Added sections are hereby made a part of the contract and are to be inserted in the specification in the proper numerical/alphabetical sequence.

Within the specifications, deletions from the specifications are indicated by strikethrough, e.g.: deletions are marked with strikethrough and additions to the specifications including revisions/substitutions are indicated in bold, italic and underlined, e.g.: additions are indicated thus.

Corresponding Added or Revised Paragraph SECTION Page, and/or Section

00 70 00 Revised clause 52.211-12 as indicated herein.

Encl as stated:

Revised pages of the specifications as indicated in Part I.

TWO-PHASE DESIGN & CONSTRUCTION OF COMMERCIAL GATE W9127820R0023

TYNDALL AIR FORCE BASE, FLORIDA MEF20045

SECTION 00 70 00 – PAGE 1

REVISED BY AMENDMENT NO. W91278-20-R-0023-0001

SECTION 00 70 00

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $4,569.00 to be determined in Phase Two for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(NOTE: The remainder of the section is unchanged by amendment.)