AMEND-0001_W9126G19B0001.pdf

W45VAK82546889 018130

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Unrestricted Procurement for Texas City Channel, Texas, Main Channel in Galveston County, Texas, Pipeline Dredging is hereby amended as follows:

Continued on Page 2.

1. CONTRACT ID CODE PAGE OF PAGES

J 1

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W9126G19B0001

X 9B. DATED (SEE ITEM 11)

25-Oct-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

CODE 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

US Army Corps of Engineers Galveston Disrict 2000 Fort Point Road, PO Box 1229 Galveston, Texas 77553-1229

X

M3ODXMAN

Typewritten Text 14-Nov-2018

M3ODXMAN

Typewritten Text

W9126G19B0001

A0001-2

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

1. The specifications for Solicitation No. W9126G18B0001, Texas City Channel, Texas, Main Channel, in Galveston County, Texas, Pipeline Dredging, are hereby amended as follows:

THE BID DUE DATE IS HEREBY RESCHEDULED FOR 27 NOVEMBER 2018 AT 2:00 P.M.

LOCAL TIME.

a) Specifications.

(1) SECTION 00 11 00.00 45, BID SCHEDULE – The enclosed SECTION 00 11 00.00 45 entitled BID SCHEDULE supersedes that issued with this Solicitation.

(2) SECTION 00 21 00 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS – The enclosed section 00 21 00 entitled BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS, supersedes that issued with this solicitation.

(3) SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS, STANDARD – The enclosed SECTION 00 73 00.01 45, entitled SPECIAL CONTRACT REQUIREMENTS, STANDARD, supersedes that issued with this Solicitation.

(4) SECTION 35 20 23.16 45, PIPELINE DREDGING – The enclosed SECTION 35 20 23.16 45, entitled PIPELINE DREDGING, supersedes that issued with this Solicitation.

(5) SECTION 35 20 23.16 45, PIPELINE DREDGING, APPENDIX I - QUANTITY

SUMMARY TABLE –The enclosed SECTION 35 20 23.16 45, entitled PIPELINE DREDGING, APPENDIX I – QUANTITY SUMMARY TABLE, supersedes that issued with this Solicitation.

b) Drawings.

(1) NONE

2. This amendment shall be attached to and become a part of the solicitation.

5 Encls:

1. SECTION 00 11 00.00 45, BID SCHEDULE

2. SECTION 00 21 00 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

3. SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS

4. SECTION 35 20 23.16 45, PIPELINE DREDGING

5. SECTION 35 20 23.16 45, PIPELINE DREDGING, APPENDIX 1- QUANTITY SUMMA5RY

TABLE

SWG FILE NO.:GALV 308-385 SOLICITATION NO.:W9126G19B0001

Section 00 21 00 - Page 1

Section 00 21 00 - Instructions, Conditions and Notices to Offerors

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $5,000,000 and $10,000,000.

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON THE FEDERAL BUSINESS

OPPORTUNITIES WEBSITE ((FBO) (far 5.102(a)(1)

After solicitation issuance, contractors may register to be placed on a plan holders list, view and/or download this solicitation and all amendments at the Federal Business Opportunities (FBO) website at http://www.fbo.gov/

Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the FBO website daily (using the above link) for amendments to the solicitation. You must be registered in the System for Award Management (SAM) to receive a government contract award. You may register with the SAM at https://www.sam.gov

1.3 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (18 MAR 2013) (UAI

31.105-100) In accordance with FAR 31.105(d)(2)(i)(b), equipment ownership and operating cost shall be determined using EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule.

1.4 TECHNICAL INFORMATION DREDGING (FAR 14.211)

(a) For technical information regarding the plans and specifications submit questions in PROJNET, see paragraph 1.10 of this section for details.

(b) The Contractor [ ] shall [ X ] shall not be permitted to use self-propelled hopper dredges to perform the work specified herein.

1.5 PREAWARD INFORMATION DREDGING (FAR 9.105-1)

The apparent low bidder shall submit within (1) working day after Bid Opening, the following information:

(a) A statement as to whether he is now or ever has been engaged in performing dredging of [ X ] deep or [ ] shallow draft channels.

(b) A list of key personnel available for the current project and their qualifications.

(c) A copy of the bidder's latest financial statement, including the names of banks or other financial institutions with which the bidder conducts business. If the financial statement is more than 60 days old, a certificate should be attached stating that the financial condition is substantially the same, or if not the same, the changes that have taken place. Such statement will be treated as confidential.

(d) A list of present commitments, including the dollar value thereof, name of office under which the work is being performed, the scheduled completion date of each, days ahead or behind schedule and the name of the dredge(s) to be used on the job.

(e) Name and location of the firm's dredging plant to perform the work under this contract, the date this plant will commence work, and the plants capability to perform the work as required by the specifications.

(f) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within (1) working day after Bid Opening.

Section 00 21 00 - Page 2

1.6 DISPOSAL OF EXCAVATED MATERIAL

The following owners in the vicinity of the work to be accomplished under this Invitation for Bids are known to desire fill material:

NAME ADDRESS

If any of the areas owned by the above-listed owners are proposed to be utilized by the Contractor in the performance of the work, the provision for use of alternate areas DREDGING: PLACEMENT OF EXCAVATED MATERIAL of the specifications will be applicable.

1.7 BIDDER'S QUALIFICATIONS (FAR 9.105-1)

Before a bid is considered for award, the bidder may be requested by the Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

1.8 CAUTIONS & REMINDERS TO BIDDERS (FAR 52.214-18)

All information required by the terms of the solicitation must be furnished.

MISTAKES OR OMISSIONS CAN BE COSTLY. Important items for you to check are included in but not limited to, those listed below. This checklist is furnished only to assist you in submitting a proper offer. Check as you read.

Have you acknowledged all amendments?

Have you completed SECTION 00 45 00, REPRESENTATIONS &

CERTIFICATIONS portion of the solicitation package?

Is your offer properly signed?

If a bid guarantee is required, is it included with your offer?

(A late bid guarantee is treated the same as a late offer).

Is your bid guarantee in the proper amount? Bid guarantee shall be in the amount of 20 percent of the amount of the offer, or $3 million, whichever is less.

If your bid guarantee is in the form of a bid bond, is the bond properly signed by both the bidder and surety and are all required seals affixed?

Is the name in which you submitted the offer the same as your bid bond?

If required have you entered a unit price for each item? (The solicitation will specifically state when this is necessary).

Are decimals in unit prices in the proper places? Are your figures legible?

Are the extensions of your unit prices, and your total offer price correct?

Are all erasures or corrections initialed by the person signing the offer?

I have not restricted my offer by altering the provisions of the solicitation.

REMINDER TO BIDDERS

REMINDER #1 - Acknowledge all Amendments on the reverse side of SF 1442, Item 19, Solicitation, Offer, and Award.

Section 00 21 00 - Page 3

REMINDER #2 - The Contracting Officer signing this contract is the Primary Contracting Officer. However, any Contracting Officer assigned to the Galveston District may take formal action. See Section entitled "Specific Project Requirements".

1.9 SPECIAL INSTRUCTIONS PERTAINING TO ELECTRONIC BID SUBMISSION: (FAR 14.302

& 14.304)

Bids and a copy of the SF24 Bid Bond must be delivered via the AMRDEC website, not later than the response date and time indicated in the solicitation. If the AMRDEC website is NOT accessible, mailed or hand carried bids or amendments to bids will be accepted, see Paragraph 1.10, Special Instructions Pertaining to Hand-Carried Bids/Offers.

Original copies of the Bid Bond shall be submitted to USACE, Galveston District, ATTN: Lucille Smith, 2000 Fort Point Road, Galveston, Texas 77550- 1229, on or before the bid due date.

SENDING FILES:

The AMRDEC SAFE application can be accessed via https://safe.amrdec.army.mil/safe .

• Proceed as Guest - Select this option if you do not have a CAC.

After selecting one of the options above, the page will be redirected to the package upload form. Fill in all the required input fields:

• Your Name - Your name;

• Your Email address - Your email address;

• Confirm Your Email Address - Re-enter your email address;

• Description of File(s) - Enter a description for the package; including solicitation number and bid opening date/time.

• File(s) - Click the "Browse" button to select your file(s). You may add up to 25 files per package, so long as the total file size does not exceed 2GB;

• Deletion Date - Select a date for the package to be deleted from SAFE.

The maximum (which is also the default) is two weeks (14 days) from today;

• Provide an email address to give access to - Enter ALL of the following email addresses here and click "Add"”

• curtis.cole@usace.army.mil

• maria.e.rodriguez@usace.army.mil

• lucille.r.smith@usace.army.mil

• william.bondurant@usace.army.mil

• Grant access to these people - This is the list of people you have granted access to the package. To remove a recipient, highlight their name and click the "Remove" button;

https://safe.amrdec.army.mil/safe mailto:curtis.cole@usace.army.mil mailto:maria.e.rodriguez@usace.army.mil mailto:lucille.r.smith@usace.army.mil mailto:william.bondurant@usace.army.mil

Section 00 21 00 - Page 4

• Caveats - Default is "None";

• Encrypt email message when possible - Attempt to encrypt the package's notification email to each recipient;

• Notify me when files are downloaded - You (the sender) will receive a notification via email when a recipient downloads the package;

• Require CAC for pickup – Require the recipient to be logged in with a valid US DoD-issued CAC to download the file(s). Recipients without a CAC will not be able to download the package.

Clicking the "Submit" button will upload the files and submit the package.

Guest users will need to check their email to verify their email address before the recipients will be notified.

1.10 SPECIAL INSTRUCTIONS PERTAINING TO HAND-CARRIED BIDS/OFFERS:

Hand-carried Bids/Offers must be delivered to: the Contract Specialist or Contracting Officer located at the US Army Corps of Engineers, Jadwin Building, 2000 Fort Point Road, Galveston District, Galveston, TX 77550. Not Later than the Due Date and Time. Bids/Offers will only be accepted by contracting personnel. Guards are not authorized to accept Bids/Offers on behalf of the Government.

Galveston District has a security gate located on Fort Point Rd and requires all occupants of the vehicle to have a valid driver’s license for entry.

Parking is limited. Firearms are not permitted on the installation. Offerors are cautioned to allow sufficient time for travelling over the causeway or ferry. Neither will constitute Government-caused delay.

Offerors are also cautioned that Galveston is an island that, during Spring Break and the Summer Season, can have traffic slowdowns and congestion because the District is collocated with the Bolivar Ferry traffic waiting to board and can delay access to the District Office.

(End of Clause)

1.11 BIDDER INQUIRY – PROJNET (FAR 14.211)

1. Prospective Offerors should submit questions concerning this solicitation via Bidder Inquiry in ProjNet at www.projnet.org/projnet .

A. To submit and review bid inquiry items, bidders will need to be a current registered user or self-register into the system. To self-register, go to the aforementioned web page and click on the BID tab. Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

***Please Note: Offerors shall only submit one question per inquiry.

Inquiries containing multiple questions may be rejected.

B. From this page, you may view all bidder inquiries or add inquiry.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

http://www.projnet.org/projnet

Section 00 21 00 - Page 5

D. The Solicitation Number is: W9126G19B0001 The Bidder Inquiry Key is: 3R45D4-2G84E6

2. The Bidder Inquiry System will be unavailable for new inquires fifteen

(15) calendar days prior to offer submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

1.12 CONSTRUCTION WAGE RATE REQUIREMENTS (FAR 52.222-6)

Paragraph entitled CONSTRUCTION WAGE RATE REQUIREMENTS of (CONTRACT CLAUSES - Section 00 72 00, FAR 52.222-6) is applicable to this solicitation. Wage Rates will be incorporated by amendment, if they are not included in this solicitation.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-18 Commercial and Government Entity Code

Maintenance

JUL 2016

52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and

Withdrawals of Bids

NOV 1999

52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-

Construction

AUG 1996

52.214-34 Submission Of Offers In The English Language

APR 1991

52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.215-20 Requirements for Certified Cost or

Pricing Data or Information Other Than Certified Cost or Pricing Data

OCT 2010

52.216-1 Type Of Contract APR 1984 52.217-5 Evaluation Of Options JUL 1990 52.232-14 Notice Of Availability Of Progress

Payments Exclusively For Small Business Concerns

APR 1984

52.232-38 Submission of Electronic Funds Transfer Information with Offer

JUL 2013

CLAUSES INCORPORATED BY FULL TEXT

Section 00 21 00 - Page 6

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 60 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

Section 00 21 00 - Page 7

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

Galveston County 28.9%

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

Section 00 21 00 - Page 8

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is SMSA Galveston County, Texas.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY

2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at

FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison

Section 00 21 00 - Page 9 table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the Contracting Officer, US Army Corps of Engineers, Galveston District, PO Box 1229, Galveston, Texas 77553-1229, submitting the protest at SWF-protest@usace.army.mil .

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Mr. Ralph E. Steiner Address: US Army Corps of Engineers, Galveston District, Galveston Resident Office, 2000 Fort Point Road, Galveston, Texas 77553 Telephone: 409-766-3907 mailto:SWF-protest@usace.army.mil mailto:SWF-protest@usace.army.mil

Section 00 21 00 - Page 10

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available.

The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer.

In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ http://farsite.hill.af.mil/

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 11 00.00 45

BID SCHEDULE

PART 1 GENERAL

1.1 BID SCHEDULE

1.1.1 Schedule No. 1

1.1.2 Option No. 1

1.1.3 Option No. 2

1.2 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

-- End of Section Table of Contents --

DOCUMENT 00 11 00.00 45 Page 1

(TO ACCOMPANY AMENDMENT NO. 0001 TO SOLICITATION NO. W9126G19B0001)

SECTION 00 11 00.00 45

BID SCHEDULE

AMENDMENT NO. 0001

PART 1 GENERAL

1.1 BID SCHEDULE

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.1 Schedule No. 1

Item No. Description Estimated Quantity

Unit Unit Price Estimated Amount

SCHEDULE NO. 1

0001 Mobilization and Demobilization 1 JOB SUM $___________

0002 Pipeline Management, SPPA 3, 4, 5

1 JOB SUM $___________

0003 Dredging -- Texas City Main Channel, Section Nos. 2-3

351,000 C.Y. $_________ $___________

TOTAL SCHEDULE NO. 1 $___________

NOTE: Completion time stated in SECTION 00 73 00.01 45 SPECIAL CONTRACT REQUIREMENTS, STANDARD is for Schedule No. 1 work.

DOCUMENT 00 11 00.00 45 Page 2

BID SCHEDULE (CONT'D)

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.2 Option No. 1

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 1

0004 Dredging -- Texas City Main Channel, Section No. 1

79,000 C.Y. $_________ $___________

TOTAL OPTION NO. 1 $___________

TOTAL SCHEDULE NO. 1 AND OPTION NO. 1 $___________

NOTE FOR OPTION NO. 1: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. An additional time of 9 calendar days will be added to this Contract for completion of this Option.

DOCUMENT 00 11 00.00 45 Page 3

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.3 Option No. 2

Item No. Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 2

0005 Dredging -- Texas City Main Channel, Section No. 4

149,000 C.Y. $_________ $___________

TOTAL OPTION NO. 2 $___________

TOTAL SCHEDULE NO. 1 AND OPTIONS NOS. 1 AND 2 $___________

NOTE FOR OPTION NO. 2: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. An additional time of 10 calendar days will be added to this Contract for completion of this Option.

DOCUMENT 00 11 00.00 45 Page 4

(TO BE ATTACHED TO STANDARD FORM 1442)

1.2 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

-- End of Document --

DOCUMENT 00 11 00.00 45 Page 5

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section Table of Contents --

DOCUMENT 00 73 00.01 45 Page 1

SECTION 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD

AMENDMENT NO. 0001

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed;

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use no later than 50(AM#1)46 calendar days after the date the Contractor receives the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $3,519.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by survey.

(b) Weather Conditions. Under ordinary conditions, the mean tidal range is about 1.5 feet. The height of tide is largely dependent on the force, direction, and duration of the wind. Strong northerly winds may depress the water surface as much as, and in some instances more than 2 feet below Mean Lower Low Water (MLLW), while southerly winds may raise the water surface as much as, and in some instances more than 4 feet above MLLW.

(c) Transportation Facilities. The immediate vicinity is served by railroad, highway, and deep and shallow draft channels. The work site is accessible by water via the Gulf Intracoastal Waterway, the Texas City Ship Channel or via highway or railway.

DOCUMENT 00 73 00.01 45 Page 2

(d) Other Information. Channel traffic consists of deep draft ships, small boats of various sizes, fishing vessels, ferries, tugs and tows consisting of a tug and one or more barges. Traffic will interfere with dredging operations to some extent.

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

(a) This special contract requirement does not apply to terminations.

See 52.249-5000, Basis for Settlement of Proposals, and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the con-tractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VI. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply.

For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

NOTE: A copy of EP 1110-1-8, "CONSTRUCTION EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE," is available at the following website:

http://www.publications.usace.army.mil/USACEPublications/EngineerPamphlets.aspx.

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Document --

DOCUMENT 00 73 00.01 45 Page 3

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 23.16 45

PIPELINE DREDGING

PART 1 GENERAL

1.1 SUMMARY

1.2 MEASUREMENT AND PAYMENT

1.3 WORK COVERED BY CONTRACT PRICE

1.3.1 Existing Conditions

1.4 REFERENCES

1.5 SUBMITTALS

1.6 MATERIAL TO BE REMOVED

1.6.1 Debris Within the Dredging Limits

1.7 EASEMENTS

1.8 UTILITIES ACROSS THE LIMITS OF DREDGING

1.8.1 Known Pipeline/Utility Crossings

1.9 ORDER OF WORK

1.9.1 Dredging Options

1.10 OBSTRUCTION OF CHANNEL

1.11 TEMPORARY REMOVAL OF AIDS TO NAVIGATION

1.12 NOTIFICATION PRIOR TO COMMENCEMENT OF DREDGING OPERATIONS

1.13 SIGNAL LIGHTS

1.14 PLANT

1.14.1 General Requirements

1.14.2 Capacity

1.14.3 Inspectors (Government Agents) Transportation

1.15 INSPECTION

1.15.1 Equipment

1.15.2 Transportation

1.16 QUANTITY SURVEYS

1.17 FINAL EXAMINATION AND ACCEPTANCE

1.17.1 Acceptance

1.18 SHOALS

1.19 UNANTICIPATED SHOALING

1.20 VARIATIONS IN ESTIMATED QUANTITIES - DREDGING

1.21 CONTINUITY OF WORK

PART 2 PRODUCTS

2.1 BRIDGE-TO-BRIDGE RADIOTELEPHONE EQUIPMENT

2.2 LOOKOUTS AND RADIO COMMUNICATIONS

PART 3 EXECUTION

3.1 ESTIMATED QUANTITY OF MATERIAL

3.1.1 Quantity Summary

3.1.2 Required Dredging Prism

3.1.3 Allowable Overdepth

3.1.4 Side And End Slopes

3.1.5 Excessive Dredging

3.2 AREAS TO BE DREDGED

SECTION 35 20 23.16 45 Page 1

3.3 CONDUCT OF DREDGING WORK

3.3.1 Pre-Operations Safety Coordination Meeting

3.3.2 Protection of Existing Waterways

3.3.3 Adjacent Property and Structures

3.4 PLACEMENT OF EXCAVATED MATERIAL

3.4.1 General

3.4.1.1 Misplaced Material

3.4.1.2 Placement Operations Inspection

3.4.1.3 Placement Area Drainage

3.4.1.4 Maintenance of Existing Dike

3.4.2 Placement Area

3.4.2.1 Shoal Point Placement Area (SPPA) 3, 4, 5

3.5 PRESERVATION OF PUBLIC AND PRIVATE PROPERTY

3.5.1 Damages

3.5.2 Accountability and Restoration

3.6 ALTERNATE PLACEMENT AREA(S) PROPOSED BY CONTRACTOR WITH BID AFTER

AWARD OF CONTRACT

3.6.1 Data Submittal

3.7 METHOD OF PLACEMENT

3.7.1 Pipeline Route

3.8 DISPOSAL IN PLACEMENT AREA

3.8.1 Utilities within the Placement Area

3.8.2 Unauthorized Placement of Material

3.8.3 Debris Disposal

3.9 DREDGE PIPELINES

3.9.1 Submerged Pipeline

3.9.2 Submerged Pipeline Lighting Requirements

3.9.3 Floating Pipeline

3.9.4 Pipeline Leaks

3.9.5 Magnetometer Survey Report

3.10 HOUSTON-GALVESTON VESSEL TRAFFIC SERVICE AREA

3.10.1 General

3.10.2 Report Changes

3.10.3 Vessel Traffic Service Location

3.10.4 Communications

3.10.5 Operations

3.11 WORK IN THE VICINITY OF OTHER GOVERNMENT CONTRACTORS

3.12 DREDGING AND DREDGE RELATED MARINE WORK (CESWG)

3.13 AUTOMATIC IDENTIFICATION SYSTEM

3.14 DREDGE PLANT INSTRUMENTATION

ATTACHMENTS:

Appendix 1 - QUANTITY SUMMARY TABLE

Appendix 1 - QUANTITY SUMMARY TABLE

-- End of Section Table of Contents --

SECTION 35 20 23.16 45 Page 2

SECTION 35 20 23.16 45

PIPELINE DREDGING

AMENDMENT NO. 0001

PART 1 GENERAL

1.1 SUMMARY

The work in this Section consists of furnishing plant, labor, materials, and equipment and performing the operations necessary for the removal of materials to the required dimensions shown, satisfactory disposal thereof, and other operations incidental thereto.

1.2 MEASUREMENT AND PAYMENT

Measurement and payment for pipeline dredging will be paid for in accordance with provisions of the SECTION 01 22 00.10 MEASUREMENT AND

PAYMENT.

1.3 WORK COVERED BY CONTRACT PRICE

Base bids on the quantity of dredging indicated. If the total quantity of dredging varies from that specified as the basis for bidding, the Contract price will be adjusted in accordance with the CONTRACT CLAUSE entitled CHANGES. The dredging conditions specified and indicated describe conditions which are known. However, the Contractor is responsible for other conditions encountered which are not unusual when compared to the conditions recognized in the dredging business as usual in dredging activities such as those required under this Contract. The Contract price for dredging will include the cost of removal and placement of the material as specified in the Paragraphs: CHARACTER OF MATERIAL and PLACEMENT OF EXCAVATED MATERIAL. The Contract price for dredging will include the costs for maintenance of dikes and ditches necessary to confine the material within the areas shown.

1.3.1 Existing Conditions

The drawings already prepared as specified in the CONTRACT CLAUSES Paragraph entitled CONTRACT DRAWINGS AND SPECIFICATIONS represent conditions existing as of the date of their preparation using average existing conditions. However, to reflect anticipated shoaling occurring between the dates of preparation of the drawings and the dates of the "before-dredging" sections, the estimated dredging quantities stated in the Bid Schedule have been adjusted accordingly. The depths and elevations shown will be verified and corrected by fathometer soundings taken by the Government before dredging. The Government will normally use a frequency of 200 kHz to conduct hydrographic surveys. If the surveys indicate the presence of fluff in the channel, a frequency of 40 kHz will be used. Determination of quantities removed and the deductions made from them to determine quantities by in-place measurement to be paid for in the area specified, after having once been made will not be reopened, except on evidence of collusion, fraud, or obvious error.

SECTION 35 20 23.16 45 Page 3

1.4 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.5 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with SECTION 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Notification Prior To Commencement of Dredging Operations ; G

Indicate commencement of dredging operations, and location of dredge(s).

Temporary Removal of Aids To Navigation ; G

SD-02 Shop Drawings

Submerged Pipeline ; G

Indicate pipeline location and installation details as outlined in the Subparagraph: Submerged Dredge Pipeline.

Pipeline Route ; G

A detailed pipeline diagram for each Placement Area detailing the pipeline route and anchor locations are to be submitted prior to commencing work on this project.

SD-06 Test Reports

Magnetometer Survey Report ; G

Report to be be submitted as specified.

1.6 MATERIAL TO BE REMOVED

The material to be removed is shoals which have accumulated over a period of time. However, some virgin material may be encountered in allowable overdepth, or side slope dredging. Bidders are expected to examine the worksite and the records of previous dredging, which are available in the Galveston Resident Office and after investigation decide for themselves the character of materials.

1.6.1 Debris Within the Dredging Limits

Debris including but not limited to, metal bands, pallets, pieces of

SECTION 35 20 23.16 45 Page 4 broken cable, rope, stumps, and broken piles may be encountered. The Government has no knowledge of existing wrecks, wreckage, or other material of that size or character as to require the use of explosives or special or additional plant for its economical removal. Debris removed from the dredged area is to be removed from the water. Disposal is to be the responsibility of the Contractor and disposal is to be outside the limits of Government property. If the actual conditions differ from those stated or shown, an adjustment in Contract price or time of completion, or both, will be made in accordance with the CONTRACT CLAUSE entitled

DIFFERING SITE CONDITIONS.

1.7 EASEMENTS

Permits authorizing the laying of shore pipe, and for placement of dredge material in the Placement Area(s), are on file and available for examination in the Galveston Resident Office of the U.S. Army Corps of Engineers, Jadwin Building, 2000 Fort Point Road, Galveston, Texas. The instruments authorizing the laying of shore pipelines may contain certain restrictions relative to specific route, location, and general use of the land. These instruments form a part of these specifications and the Contractor is to strictly comply with the terms thereof.

1.8 UTILITIES ACROSS THE LIMITS OF DREDGING

It is the Contractor's responsibility to investigate the location of utility crossings. The Contractor is to take precautions against damages which can result from dredging operations in the vicinity of the utility crossings. If damage occurs as a result of dredging operations, the Contractor will be required to suspend dredging until the damage is repaired and approved. Costs of these repairs and downtime of the dredge and attendant plant is to be at the Contractor's expense.

1.8.1 Known Pipeline/Utility Crossings

There are pipelines and or utilities which are within the work limits.

The following list of pipeline/utility crossings may not be all inclusive. It shall be the Contractor's responsibility to review all contract documents and ensure all utility/pipeline crossings are identified. Furthermore, the Contractors shall perform due diligence and ensure the work area has been cleared of pipeline crossing or known pipeline crossings are identified in the field prior to commencing dredging in the particular reach. The Contractor shall submit evidence to the COR attesting to the Contractor's efforts in locating utility/pipeline crossings. The following known pipeline/utilities cross the area(s) to be dredged:

Approximate Station

Permit No. Description Owner

13+600 22929 One 24-inch pipeline

Manta Ray Gathering, Co.

EVERY EFFORT HAS BEEN MADE TO GIVE ALL PERTINENT DETAILS ON THE LOCATION

OF PIPELINES/UTILITIES. THE DATA FURNISHED ON THE PLANS ARE BELIEVED TO

BE SUBSTANTIALLY CORRECT. HOWEVER, THE EXACT LOCATIONS MAY VARY FROM THAT

SHOWN: THEREFORE THE CONTRACTOR IS TO COOPERATE WITH THE RESPECTIVE

SECTION 35 20 23.16 45 Page 5

OWNERS TO ESTABLISH THE ACTUAL POSITION OF THE PIPELINES/UTILITIES. THE

U.S. ARMY CORPS OF ENGINEERS PERMITS OF THE RESPECTIVE PIPELINES AND

PREVIOUS SURVEYS ARE AVAILABLE IN THE GALVESTON RESIDENT OFFICE .

THE FOLLOWING IS FURNISHED FOR INFORMATION ON VERIFYING PIPELINE LOCATION

OWNERSHIPS:

Lonestar Notification Center 1-800-545-6005 or online at www.Lonestar811.com

Texas 811 (Dig-Tess) 1-800-344-8377

1.9 ORDER OF WORK

The Contractor may commence dredging in the order desired. The Government reserves the right to change the order of work at any time.

1.9.1 Dredging Options

The Government will award Dredging Options as specified. ]

1.10 OBSTRUCTION OF CHANNEL

The Government will not undertake to keep the Channel free from vessels or other obstructions, except to the extent of applicable regulations, if any, as may be prescribed by the Secretary of the Army, in accordance with the provisions of Section 7 of the River and Harbor Act approved 8 August 1917. The Contractor will be required to conduct the work using a method that will obstruct navigation as little as possible, and if the Contractor's plant does obstruct the Channel and makes passage of vessels difficult or endangers them, the plant is to be promptly moved on the approach of a vessel as far as may be necessary to afford a practicable passage. Upon completion of the work, promptly remove plant, including ranges, buoys, piles, and other marks placed under this Contract.

1.11 TEMPORARY REMOVAL OF AIDS TO NAVIGATION

The temporary removal or changes in locations of channel markers may be required to facilitate dredging operations. Notify the Contracting Officer at least 21 days prior to the date that the removal or change in location of channel markers will be required so the U.S. Coast Guard can perform the work and so navigation interests may be informed sufficiently in advance of the proposed removal or change in location.

The Contractor is not to remove, change the location of, obstruct, willfully damage, make fast to, or interfere with aids to navigation.

Indicate temporary removal or changes in locations of channel markers required to facilitate dredging operations.

1.12 NOTIFICATION PRIOR TO COMMENCEMENT OF DREDGING OPERATIONS

Notify the Resident Engineer, Galveston Resident Office, in writing, at least 10days prior to commencement of dredging operations, the location or locations at which a dredge or dredges will be placed on the work. This information is required in addition to the progress charts and schedule provided for in the CONTRACT CLAUSE entitled SCHEDULE FOR CONSTRUCTION

CONTRACTS.

SECTION 35 20 23.16 45 Page 6

1.13 SIGNAL LIGHTS

Display signal lights and conduct operations in accordance with the General Regulations of the Department of the Army and of the U.S. Coast Guard governing the:

i) lights and day signals to be displayed by towing vessels with tows on which no signals can be displayed, vessels working on wrecks, dredges, and vessels engaged in laying cables or pipe or in submarine or bank protection operations;

ii) lights to be displayed on dredge pipe lines;

iii) day signals to be displayed by vessels of more than 65 feet in length moored or anchored in a fairway or channel;

iv) and the passing by other vessels of floating plant working in navigable channels as set forth in United States Coast Guard publication entitled Navigation Rules and Regulations Handbook. Web site location:

http://www.navcen.uscg.gov/?pageName=navRuleChanges

1.14 PLANT

1.14.1 General Requirements

Keep the necessary dredge equipment and attendant plant on the job to meet the requirements of the work. The dredge equipment and attendant plant is to be in satisfactory operating condition and capable of safely and efficiently performing the work as set forth in specifications and be subject to inspection by the Contracting Officer's representative at all times.

1.14.2 Capacity

No reduction in the capacity of the dredge equipment and attendant plant employed to execute the work is to be made except by written direction of the Contracting Officer. The measure of the "Capacity of the Dredge and Attendant Plant" is to be its actual performance on the work to which these specifications apply.

1.14.3 Inspectors (Government Agents) Transportation

At the request of the Government within 15 minutes after arriving on site, throughout the Contract period, transportation shall be furnished throughout the Contract period, for the exclusive use of the Government: a motorboat, minimum 18 feet in length, with enclosed cabin, a minimum of a 50 horsepower motor and equipped with safety equipment as required by EM 385-1-1 . Furnish a boat operator, fuel, oil, and maintenance for the motorboat throughout the Contract period. Assume full responsibility for the storage and security of the motorboat when not in use by the Government employees. There will be no separate payment for these items and the cost will be distributed throughout the existing bid items.

Equipment which fails to perform because of insufficient power or other mechanical deficiencies are to be replaced and inexperienced operators unable to operate the equipment is to be replaced within 12 hours after the Contractor is directed to do. No smoking is to be allowed inside the cabin and operator's space while occupied by Government personnel. No

SECTION 35 20 23.16 45 Page 7

Smoking signs are to be posted. If the Contractor refuses, neglects, or delays compliance with these requirements, the specific facilities may be furnished and maintained by the Contracting Officer, and the cost thereof will be deducted from the…