SF1449_W9124D17T0064.pdf

SEE ADDENDUM

(No Collect Calls)

W9124D-17-T-0064 15-Sep-2017

b. TELEPHONE NUMBER

502-624-6853

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 25 Sep 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9124D9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

KAREN E. KEYS

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

0010997760

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

MISSION AND INSTALLATION CONTRACTING CMD

MICC FORT KNOX

BLDG 1109B STE 373

199 6TH AVE

FORT KNOX KY 40121-5720

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE W22PES 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

W6CD DPW

W6CD DPW

DIRECTOR OF PUBLIC WORKS

CRP BLDG 2803 MOTOR PARK ROAD

FORT KNOX KY 40121-5000

TEL: 502-624-8638 FAX:

FAX:

TEL: 502-624-2153 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$15,000,000

NAICS:

811412

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA FAR (48 CFR) 53 212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W9124D-17-T-0064

Section SF 30 - BLOCK 14 CONTINUATION PAGE

The solicitation is for a firm fixed price contract for washer and dryer repair for the Directorate of Public Works, Fort Knox, KY for the period of 1 October 2017 through 30 September 2018 with four one-year option periods.

OFFEROR SHALL COMPLETE THE FOLLOWING INFORMATION

DUNS NUMBER: ___________________________

CAGE CODE: ___________________________

TAX ID NO: ___________________________

PHONE NO: ___________________________

POINT OF CONTACT: ___________________________

FAX NO: ___________________________

E-MAIL ADDRESS: ___________________________

PAYMENT TERMS: ___________________________

NOTES:

1. All offerors shall be registered in the System for Award Management (SAM) to be eligible for award of a contract. Offerors shall ensure SAM registration is active and shall not assume that CCR information automatically migrated to the SAM system. The official SAM website is https://www.sam.gov/portal/public/SAM/. Contractors are encouraged to complete SAM registration as soon as possible. The government may not delay award for the purpose of allowing a contractor time to register in SAM.

2. Offeror must submit any questions regarding this solicitation in writing to the contracting officer. Questions must be received by the contracting officer no later than 11:00 a.m. on 18 September 2017 to allow a written response prior to the quote due date. No remarks or written responses to questions by government personnel shall change or qualify any of the terms or conditions of this RFQ. The solicitation can only be changed by a formal written amendment issued by Mission and Installation Contracting Command (MICC)-Fort Knox, Kentucky. Questions concerning this RFQ shall emailed to karen.e.keys.civ@mail.mil. Please request acknowledgement of receipt of your email messages.

3. Offer/quoter shall mail quote package to MICC- Fort Knox, Bldg 1109B Ste 373, 199 6th Ave, Fort Knox, KY 40121-5720. Quote shall be submitted no later than the date and time specified for receipt (see Block 8 on the SF 1449 or the latest issued amendment). EMAILED OR FAXED QUOTE will not be accepted.

4. Quote packages shall be SEALED. Solicitation number shall be annotated on the outside of the quote package.

The quote package shall include a quote submitted in paper format; and an electronic duplicate of the original quote, submitted on CD or DVD (other types of media will not be accepted). The CD shall be prepared and finalized so as to be readable in any reader. “READ ONLY” is recommended. Submit copy in pdf format. SF 1449 Packages shall also contain the following:

- Offerors must complete blocks 17a, 17b, 30a, 30b and 30c on page 1, SF Form 1449 (for SF 1449 - See Attachment I) -Completed page 3 of the solicitation (Continuation Sheet) -Completed quote schedule-all CLIN(s) -Complete all representations and certifications included herein -Acknowledge amendments, if applicable mailto:karen.e.keys.civ@mail.mil

5. Contract line items numbers (CLINs) 0001 through 0008 shall be priced as per repair), likewise those for the option periods.

6. Quantities listed in this contract are estimates only, based on the best information currently available to the government. The contractor will be paid for actual services performed. The government will pay the contractor monthly for services performed during the preceding month, upon submission of proper invoices, the prices stipulated in this contract for services delivered and accepted, less any deductions provided for in the contract. The amount established in Contract Line Item Numbers (CLINs) 0004, 1004, 2004, 3004 and 4004 are estimated values and shall be used by all bidders in computing total contract price. The successful contractor shall not construe this amount as a firm obligation for payment.

7. AWARD. The award of any contract issued hereunder will be made in the aggregate to the lowest-priced responsive, responsible quoter. Failure to submit a quote on all items may render the quote non-responsive.

8. All times stated reflects Fort Knox, KY Local/Eastern Time.

BASE PERIOD ESTIMATED TOTAL AMOUNT FOR LINE ITEMS 0001 AND 0009 IS

FIRST OPTION ESTIMATED TOTAL AMOUNT FOR LINE ITEMS 1001 AND 1009 IS

SECOND OPTION ESTIMATED TOTAL AMOUNT FOR LINE ITEMS 2001 AND 2009 IS

THIRD OPTION ESTIMATED TOTAL AMOUNT FOR LINE ITEMS 3001 AND 3009 IS

FOURTH OPTION ESTIMATED TOTAL AMOUNT FOR LINE ITEMS 4001 AND 4009 IS

TOTAL ESTIMATED TOTAL AMOUNT FOR ALL YEARS, LINE ITEMS 0001 THRU 4009 IS

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 550 Each Repair Washer and Dryer

FFP

The contractor shall repair washers and dryers in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

Note: Each represents Per Repair FOB: Destination

PURCHASE REQUEST NUMBER: 0010997760

NET AMT

0002 100 Each Hook-Up Washer and Dryer

FFP

The contractor shall hook-up washers and dryers in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0003 100 Each Salvage

FFP

The contractor shall provide salvage in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0004 20,000 Job Parts

FFP

The contractor shall provide parts accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

For evaluation purposes only, each offeror shall use estimated line item cost of $20,000.00.

0005 900 Each Clean Dryer Vents

FFP

The contractor shall clean dryer vents in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0006 100 Each Repair Screen

FFP

The contractor shall provide screen repair in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0007 180 Each Repair Hi Efficiency Washer

FFP

The contractor shall provide hi efficiency washer repair in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0008 200 Each Assessment

FFP

The contractor shall provide assessment in accordance with performance work statement herein during the base period of 1 October 2017 through 30 September 2018.

0009 1 Each Contractor Manpower Reporting (CMR)

FFP

CMR as directed by the Secretary of the Army in accordance with paragraph 1.6.27 of performance work statement included herein for the base period 1 October 2017 through 30 October 2018.

Note: If there is no change, insert 0 or no charge (NC). Failure to insert a price will result in $0.00 being utilized for evaluation and award purposes.

1001 550 Each OPTION Repair Washer and Dryer

FFP

The contractor shall repair washers and dryers in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

1002 100 Each OPTION Hook-Up Washer and Dryer

FFP

The contractor shall hook-up washers and dryers in accordance with performance work statement herein during the first option of 1 October 2018 through 30 September 2019.

1003 100 Each OPTION Salvage

FFP

The contractor shall provide salvage in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

1004 20,000 Job OPTION Parts

FFP

The contractor shall provide parts in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

For evaluation purposes only, each offeror shall use estimated line item cost of $20,000.00.

1005 900 Each OPTION Clean Dryer Vents

FFP

The contractor shall clean dryer vents in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

1006 100 Each OPTION Repair Screen

FFP

The contractor shall provide screen repair in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

1007 180 Each OPTION Repair Hi Efficiency Washer

FFP

The contractor shall provide hi efficiency washer repair in accordance with performance work statement herein during the second period of 1 October 2018 through 30 September 2019.

1008 200 Each OPTION Assessment

FFP

The contractor shall provide assessment in accordance with performance work statement herein during the first option period of 1 October 2018 through 30 September 2019.

1009 1 Each OPTION Contractor Manpower Reporting

FFP

CMR as directed by the Secretary of the Army in accordance with paragraph 1.6.27 of performance work statement included herein for the first option period 1 October 2018 through 30 September 2019.

Note: If there is no change, insert 0 or no charge (NC). Failure to insert a price will result in $0.00 being utilized for evaluation and award purposes.

2001 550 Each OPTION Repair Washer and Dryer

FFP

The contractor shall repair washers and dryers in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

2002 100 Each OPTION Hook-Up Washer and Dryer

FFP

The contractor shall hook-up washers and dryers in accordance with performance work statement herein during the second option of 1 October 2019 through 30 September 2020.

2003 100 Each OPTION Salvage

FFP

The contractor shall provide salvage in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

2004 20,000 Job OPTION Parts

FFP

The contractor shall provide parts in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

For evaluation purposes only, each offeror shall use estimated line item cost of $20,000.00.

2005 900 Each OPTION Clean Dryer Vents

FFP

The contractor shall clean dryer vents in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

2006 100 Each OPTION Repair Screen

FFP

The contractor shall provide screen repair in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

2007 180 Each OPTION Repair Hi Efficiency Washer

FFP

The contractor shall provide hi efficiency washer repair in accordance with performance work statement herein during the second period of 1 October 2019 through 30 September 2020.

2008 200 Each OPTION Assessment

FFP

The contractor shall provide assessment in accordance with performance work statement herein during the second option period of 1 October 2019 through 30 September 2020.

2009 1 Each OPTION Contractor Manpower Reporting

FFP

CMR as directed by the Secretary of the Army in accordance with paragraph 1.6.27 of performance work statement included herein for the second option period 1 October 2019 through 30 September 2020.

Note: If there is no change, insert 0 or no charge (NC). Failure to insert a price will result in $0.00 being utilized for evaluation and award purposes.

3001 550 Each OPTION Repair Washer and Dryer

FFP

The contractor shall repair washers and dryers in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3002 100 Each OPTION Hook-Up Washer and Dryer

FFP

The contractor shall hook-up washers and dryers in accordance with performance work statement herein during the third option of 1 October 2020 through 30 September 2021.

3003 100 Each OPTION Salvage

FFP

The contractor shall provide salvage in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3004 20,000 Job OPTION Parts

FFP

The contractor shall provide parts in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

For evaluation purposes only, each offeror shall use estimated line item cost of $20,000.00.

3005 900 Each OPTION Clean Dryer Vents

FFP

The contractor shall clean dryer vents in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3006 100 Each OPTION Repair Screen

FFP

The contractor shall provide screen repair in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3007 180 Each OPTION Repair Hi Efficiency Washer

FFP

The contractor shall provide hi efficiency washer repair in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3008 200 Each OPTION Assessment

FFP

The contractor shall provide assessment in accordance with performance work statement herein during the third option period of 1 October 2020 through 30 September 2021.

3009 1 Each OPTION Contractor Manpower Reporting

FFP

CMR as directed by the Secretary of the Army in accordance with paragraph 1.6.27 of performance work statement included herein for the third option period 1 October 2020 through 30 September 2021.

Note: If there is no change, insert 0 or no charge (NC). Failure to insert a price will result in $0.00 being utilized for evaluation and award purposes.

4001 550 Each OPTION Repair Washer and Dryer

FFP

The contractor shall repair washers and dryers in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

4002 100 Each OPTION Hook-Up Washer and Dryer

FFP

The contractor shall hook-up washers and dryers in accordance with performance work statement herein during the fourth option of 1 October 2021 through 30 September 2022.

4003 100 Each OPTION Salvage

FFP

The contractor shall provide salvage in accordance with performance work statement herein during the fourth option period of 1 October 2020 through 30 September 2021.

4004 20,000 Job OPTION Parts

FFP

The contractor shall provide parts in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

For evaluation purposes only, each offeror shall use estimated line item cost of $20,000.00.

4005 900 Each OPTION Clean Dryer Vents

FFP

The contractor shall clean dryer vents in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

4006 100 Each OPTION Repair Screen

FFP

The contractor shall provide screen repair in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

4007 180 Each OPTION Repair Hi Efficiency Washer

FFP

The contractor shall provide hi efficiency washer repair in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

4008 200 Each OPTION Assessment

FFP

The contractor shall provide assessment in accordance with performance work statement herein during the fourth option period of 1 October 2021 through 30 September 2022.

4009 1 Each OPTION Contractor Manpower Reporting

FFP

CMR as directed by the Secretary of the Army in accordance with paragraph 1.6.27 of performance work statement included herein for the fourth option period 1 October 2021 through 30 September 2022.

Note: If there is no change, insert 0 or no charge (NC). Failure to insert a price will result in $0.00 being utilized for evaluation and award purposes.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government 1003 Destination Government Destination Government 1004 Destination Government Destination Government 1005 Destination Government Destination Government 1006 Destination Government Destination Government 1007 Destination Government Destination Government 1008 Destination Government Destination Government 1009 Destination Government Destination Government 2001 Destination Government Destination Government 2002 Destination Government Destination Government 2003 Destination Government Destination Government 2004 Destination Government Destination Government 2005 Destination Government Destination Government 2006 Destination Government Destination Government

2007 Destination Government Destination Government 2008 Destination Government Destination Government 2009 Destination Government Destination Government 3001 Destination Government Destination Government 3002 Destination Government Destination Government 3003 Destination Government Destination Government 3004 Destination Government Destination Government 3005 Destination Government Destination Government 3006 Destination Government Destination Government 3007 Destination Government Destination Government 3008 Destination Government Destination Government 3009 Destination Government Destination Government 4001 Destination Government Destination Government 4002 Destination Government Destination Government 4003 Destination Government Destination Government 4004 Destination Government Destination Government 4005 Destination Government Destination Government 4006 Destination Government Destination Government 4007 Destination Government Destination Government 4008 Destination Government Destination Government 4009 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 POP 01-OCT-2017 TO

30-SEP-2018

N/A W6CD DPW

W6CD DPW

DIRECTOR OF PUBLIC WORKS

CRP BLDG 2803 MOTOR PARK ROAD

FORT KNOX KY 40121-5000

502-624-8638

W22PES

0002 POP 01-OCT-2017 TO

30-SEP-2018

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0005 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0006 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0007 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0008 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0009 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 01-OCT-2018 TO

30-SEP-2019

N/A (SAME AS PREVIOUS LOCATION)

1002 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1003 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1004 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1005 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1006 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1007 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1008 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1009 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 01-OCT-2019 TO

30-SEP-2020

N/A (SAME AS PREVIOUS LOCATION)

2002 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2003 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2004 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2005 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2006 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2007 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2008 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2009 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

3001 POP 01-OCT-2020 TO

30-SEP-2021

N/A (SAME AS PREVIOUS LOCATION)

3002 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3003 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3004 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3005 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3006 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3007 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3008 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3009 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

4001 POP 01-OCT-2021 TO

30-SEP-2022

N/A (SAME AS PREVIOUS LOCATION)

4002 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4003 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4004 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4005 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4006 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4007 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4008 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4009 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.212-1 Instructions to Offerors--Commercial Items JAN 2017 52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.217-5 Evaluation Of Options JUL 1990 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.222-41 Service Contract Labor Standards MAY 2014 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.226-1 Utilization Of Indian Organizations And Indian-Owned Economic Enterprises

JUN 2000

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-1 Payments APR 1984 52.232-8 Discounts For Prompt Payment FEB 2002 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.237-2 Protection Of Government Buildings, Equipment, And Vegetation

APR 1984

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

SEP 2004

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or https://www.acquisition.gov/ https://www.sam.gov/portal confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

http://www.dol.gov/fairpayandsafeworkplaces

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

http://www.osha.gov/dcsp/osp/approved_state_plans.html

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ . [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that— https://www.acquisition.gov/

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of…