W9124B22Q0006 Amendment 01.pdf

0011755188

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See Summary of Changes

1. CONTRACT ID CODE PAGE OF PAGES

J 1 7

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 14-Jul-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9124B22Q0006

X 9B. DATED (SEE ITEM 11)

29-Jun-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

14-Jul-2022

CODE

MICC - FORT IRWIN

PO BOX 105095 ISSUING OFFICE

FORT IRWIN CA 92310-5095

W9124B 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9124B22Q0006

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

SOLICITATION/CONTRACT FORM

The required response date/time has changed from 21-Jul-2022 10:00 AM to 26-Jul-2022 10:00 AM.

The following have been added by full text:

Question and Answer (Q&A)

Question 1: Could you provide the measurement for the SACON Panels?

Answer 1: The measurements for each panel are listed in Attachment 1 - Keyed Wall Panel Specifications. The height for each panel is no less than eight (8) feet, which was not listed in the attachment.

Question 2: What is the final destination of the block @ Ft Irwin? In the main cantonment area by range control or down range at the building site.

Answer 2: The materials will be delivered to the main cantonment area by Range Control (Bldg. 6100) as specified in Attachment 2. The Government will be responsible for transporting and assembling the materials at the three designated site locations within the training area.

Question 3: Do you have a building design? Reason for asking is the steel channel for the top must be made per the building layout.

Answer 3: The customer does not have a specific building design. The vendor must provide sufficient steel channels that are interchangeable and able to connect to all the SACON panels listed in Attachment 1 of the solicitation in at least two different configurations.

Question 4: Is the delivery time of 60 days negotiable? We cannot make this much SACON in that period of time not to mention get it shipped to site.

Answer 4. The delivery date was changed for 60 days to 180 days (6 Months) to reflect industry standard.

Attachment 1 – Keyed Wall Panel Specifications

The unit quantities will be split in three separate piles in a linear line as indicated on the map (Attachment 2). Each pile will consist of the following materials:

Attachment 2 – Delivery & Drop Off Location

Three (3) piles of the materials will be dropped off across from the Range Operations:

Bldg. 6100 Barstow Road Fort Irwin, CA 92310

The following have been modified:

STATEMENT OF WORK

REQUIREMENT / SPECIFICATIONS

for

SACON PANELS

SCOPE: The contractor shall provide Shock Absorbing Concrete (SACON) panels designed to assemble a multi-functional Urban Counter Improvised Explosive Devices objective footprint comprised to support a sub-objective configurations capable of supporting conventional, SOF, individual, collective, C-IED training and Joint Live Fire Exercises in the simultaneous commitment of all forces on a single footprint urban objective.

REQUIREMENT / SPECIFICATIONS:

1. The SACON concrete panels shall be made of bullet absorbing material capable of absorbing the impact of 5.56mm, 9mm, .45 caliber and up to 7.62mm ammunition from internal and external angles with minimal damage.

2. Sub-objective configured panels must be able to absorb inside and outside fires of 1,000 rounds of 5.56mm, 9mm, 7.62mm and .45 caliber ammunition from internal and external fire before maintenance to repair/replace panels as needed or before the safety threshold is exceeded. Damaged and worn out areas shall be easily repaired/replaced.

3. SACON concrete panels must be able to prevent ricochet of rounds fired to the maximum extent possible.

4. SACON concrete panels shall be able to withstand 75+ MPH winds and associated sand storms.

5. SACON concrete panels shall be able to withstand 20-135 º (degrees) Fahrenheit temperatures.

6. SACON concrete panels shall be able to withstand humidity levels from 0% to 100%.

7. SACON concrete panels must be capable of absorbing the concussive and explosive blast of high explosive hand grenades.

8. SACON concrete panels (each) must be no less than twenty-four (24) inches thick.

9. The contractor shall ensure that the product(s) used to develop the panels meets the same standard of protections provided by SACON® material.

10. The contractor shall ensure that the SACON concrete panels are modular and capable of multiple configurations (i.e. levels, number of rooms, fake walls, doorways) so that the overall footprint can be modified to meet training Units scenario requirements.

11. The contractor shall ensure that the materials will be non-combustible or fire retardant in the most hazardous conditions of atmosphere, pressure, and temperature to be expected in their use.

NOTE: The contractor will not use “nonpermanent” fire retardant additives to achieve fire retardation.

Description and Dimension of SACON Concrete Panels.

12. Purchase and delivery of materials to the assigned location inside of the Fort Irwin cantonment area. The COR will coordinate with the Contractor on the drop off location prior to the delivery of materials. The Government will not be responsible for damages or recovery. Contractors shall be required to provide means of downloading materials at the designated site.

13. SITE LOCATION. See delivery location

14. Line Items for Contract – Keyed Wall Panel Specifications:

Line Item Description Qty CLIN 0001 Keyed Wall Panel, D - Corner 36

CLIN 0002 Keyed Wall Panel, AA - Straight 99 CLIN 0003 Keyed Wall Panel, A - Straight 297

CLIN 0004 Keyed Wall Panel, ADR - Door (Right) 45 CLIN 0005 Keyed Wall Panel, ADL - Door (Left) 45

CLIN 0006 Keyed Wall Panel, INT L - Interior Corner (Left) 27 CLIN 0007 Keyed Wall Panel, INT R - Interior Corner (Right) 27

15. DELIVERABLES.

15.1. Contractor shall provide C-Channel or other metal to be used to secure the top of keyed SACON units. The SACON units must be keyed in a safe manner using no less than two (2) bolts or similar (SIM). Keyed panels must interlock or overlap for complete bullet containment.

15.2. Contractor shall only deliver and download materials at the designated site. The total quantities for each line item will be divided in three (3) piles. Contractor shall separate each pile within the designated site.

16. SHIPPING.

16.1. The COR will notify the Contractor 14 days prior to making changes to the delivery date or delivery site.

16.2. Shipping address: Bldg. 6100 Barstow Road Fort Irwin, CA 92310. See Attachment 02

52.211-8 TIME OF DELIVERY (JUN 1997)

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

Within Days 180 days

After Date of Award

Item No. Quantity of Contract See Line Items for details

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

Within Days

After Date

Item No. Quantity of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

(End of Summary of Changes)