W911WN-18-R-7051_Porta_Johns_Combined_Synopsis.docx

Solicitation Number: W911WN‐18‐R-7051 Request for Quote (RFQ)

This is a combined synopsis/solicitation for commercial supplies prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued.

This solicitation is being issued in compliance with the Robert T. Stafford Disaster Relief and Emergency Assistance Act and the resultant contract will be awarded to a contractor residing in the affected area.

This solicitation document and incorporated provisions and clauses are those in effect through the Federal Acquisition Regulation (FAR) and Department of Defense FAR Supplement (DFARS).

This acquisition is SET ASIDE 100% for Small Business. A Firm-Fixed Price contract will be awarded. NAICS CODE: 562991

SIZE STANDARD: $7.5M

FAR 52.212‐1, Instructions to Offerors – Commercial, does apply to this acquisition with no addenda to the provision.

Offerors must include a completed copy of FAR 52.212‐3, Offeror Representations and Certifications – Commercial Items, with its offer. This provision is included in Section I of this combined synopsis/solicitation.

FAR 52.212‐4, Contract Terms and Conditions – Commercial Items, does apply to this acquisition with no addenda to the provision.

FAR 52.212‐5, Contract Terms and Conditions Required to Implement Statutes or Executive Orders – Commercial Items, applies to this acquisition. The specific clauses required are detailed in Section I of this combined synopsis/solicitation.

Offers for this solicitation are due on December 3, 2017 by 2:00 pm local time Email all offers to avery.c.moore@usace.army.mil

PERFORMANCE WORK STATEMENT (PWS)

LATRINE AND HAND WASH STATIONS

PORT OF PONCE AND FORT ALLEN

PUERTO RICO

PART 1 GENERAL

1.1 PROJECT LOCATION

This project requires performance at two separate geographical locations. The first location, is Fort Allen. This location requires (2) latrine units and (1) hand washing station be placed in the general area of Carr 149 Fort Allen, Juana Díaz, Puerto Rico 00795 with the specific location to be determined by the on-site personnel. The second location is in the vicinity of Port of Ponce, Compania De Comercio y Exportacion de Puerto Rico, Warehouse 2, Port of Ponce, Puerto Rico, requires (6) latrine units and (3) hand washing stations. The exact location will be determined by the on-site personnel.

1.2 SCHEDULE

The units are to be installed and ready for occupancy within 4-5 days of award of the contract.

1.3 CONTRACTOR SUBMITTALS

A. Latrine unit Details All units shall be in good repair with no broken parts. The door shall be able to be securely latched from both the inside and outside of the unit. The units shall have a separate “urinal” attachment or be molded in a similar fashion; each unit shall have one devise to hold a roll of paper with storage for at least one extra roll. Each unit shall have a seat and a lid that closes securely. All vents shall be equipped with screens to prevent flies. Units shall be equipped with battery operated lights for use after dark. Batteries shall be provided by the contractor.

B. Hand Washing station details.

The unit shall be in good repair with no broken parts. It shall be equipped with a device controlled by the person needing water to control the amount and volume of water. Each unit shall be equipped with a minimum of 20 gallons of fresh water. The unit shall have a self-contained catch basin of at least 110% of the capacity of the supply water. Waste water will be collected and at no time will it be discharged on the ground. The unit shall be equipped with a soap dispenser with enough capacity to last between each cleaning.

1.4 CODE REQUIREMENTS

All work under this contract, including the latrine and hand washing unit, shall be completed in accordance with all Local, State, and Federal Codes and/or Regulations. Federal codes include: International Building Code (IBC, 2015), International Plumbing Code (IPC, 2015), International Mechanical Code (IMC, 2015), National Electrical Code (NEC, 2008), International Energy Conservation Code (IECC, 2015), National Fire Protection Association 101 Life Safety Code (NFPA 101, 2015), NFPA 70 (2017).

1.5 Permits

The Contractor shall identify and obtain all permits, to include transportation permits, and inspections that are required for installation. The Contractor shall be responsible for obtaining necessary permits associated with placing and installing the unit and utility installation. The cost of permits is included in basic installation.

PART 2 Cleaning

2.1 Latrine

Each unit shall be cleaned on Monday, Wednesday and Friday of each week. Cleaning will be accomplished as per industry standards, but as a minimum shall include removal of waste, restocking of materials and sanitization by a disinfectant solution.

2.2 Occupancy of the unit shall not constitute a valid reason to not service the unit unless said occupancy exceeds 20 minutes.

2.3 Hand Washing Station

Each unit shall be cleaned on the same schedule as the latrine; Monday, Wednesday and Friday of each week. Cleaning will be accomplished as per industry standards, but as a minimum shall include removal of waste water, restocking of soap and sanitization by a disinfectant solution. Unit will be wiped down to remove surface dirt and soap scum at each cleaning.

PART 3 EXECUTION

3.1 GENERAL SITE WORK & LEVELING

Certify that the gradation meets the requirements. The contractor shall clean away all grass, roots, sod, topsoil, loose dirt, rocks, vegetative material or other debris at the base of the units and ensure the units are level.

3.2 ANCHORING/STRAPPING

The Contractor is responsible for the required local, and country inspection of the unit and other equipment. The unit shall be double blocked, leveled, anchored and strapped according to the manufacturer’s recommendations. This includes meeting all Federal, State and Local Codes for this type of structure.

3.4 Service Period

The base service period will be for four (4) months with one (1) month optional extension periods. The base period shall begin on the date of final acceptance of unit. The Contractor will be required to remove the unit at the end of the contract.

3.5 WARRANTY

The Contractor shall identify a single point of contact that the customer can call for warranted items.

3.6 CLEANUP

Remove construction debris, waste materials, packaging material and the like from the work site at the completion of install.

3.7 RESTORATION OF AREA

Upon completion of the service period the Contractor shall disconnect per local code and remove all debris.

---- End of Section ----

INSTRUCTIONS TO OFFEROR

QUOTES DUE DATE/LOCAL TIME: December 3, 2017

REQUEST FOR INFORMATION, EXTENSIONS, OR QUESTIONS DUE: December 2, 2017

POINT OF CONTACT: MAJ Avery C. Moore, avery.c.moore@usace.army.mil

Quotes will be accepted via “EMAIL ONLY”; NO fax, mail, express mail, or hand carry. No exceptions.

Subject line of email must include the solicitation number.

For additional help contact your local Procurement Technical Assistance Centers (PTAC). Centers were created by Congress to assist businesses seeking to compete on federal contracts. Services are generally free; however, a small fee may be charged for certain services. Please use website http://www.aptac-us.org/new/ to contact a center near your business to assist you in the preparation for a federal contract, registering in SAM or other required systems.

SYSTEM FOR AWARD MANAGEMENT (SAM) is REQUIRED to receive an award on all federal government contracts. Therefore, contractors are encouraged to begin this process sooner rather than later. If already registered, please ensure your registration is ACTIVE. The website to register with SAM is: www.sam.gov.

DATA UNIVERSAL NUMBERING SYSTEM (DUNS) is REQUIRED. Dun & Bradstreet (D&B) provides a DUNS Number, a unique nine digit identification number, for each physical location of your business. DUNS Number assignment is FREE for all businesses required to register with the US Federal government for contracts or grants in the System for Award Management (SAM see below). Click here to request your D-U-N-S Number via the Web. If one does not exist for your business location, it can be created within 1 business day. The website to obtain your DUNS number:

http://fedgov.dnb.com/webform For technical difficulties, contact govt@dnb.com

ONLINE REPRESENTATIONS AND CERTIFICATIONS APPLICATIONS (ORCA) is REQUIRED. Allows contractors to complete a one-time certification and representations for your use on any solicitation. The website to complete ORCA is available at the System for Award Manager (SAM): www.sam.gov. The information previously maintained in CCR, FedReg and ORCA now is contained within the Entity Management area in SAM. Legacy EPLS information resides in the Performance Information area of SAM.

ATTENTION TO OFFEROR(s)/CONTRACTOR(s): On July 14, 2014, Small Business Administration (SBA) increased the monetary-based industry size standards to account for inflation. You must update your Representations (Reps) and Certifications (Certs) for the impacted North American Industry Classification System (NAICS) codes identified with an exclamation point "!" next to the "Small Business" value in the System for Award Management (SAM). Please log into SAM, review, and resubmit your registration to apply the new size standard.

CONTRACTING OFFICERS STATEMENT

Only a warranted Contracting Officer (either a Procuring Contracting Officer (PCO), or an Administrative Contracting Officer (ACO), acting within their delegated limits, has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

CLIN SCHEDULE

Portable Toilets

Funded Amt:

This lease is for six portable toilets, to include delivery, set-up, and maintenance required for full operation at Compania De Comercio y Exportacion de Puerto Rico, Warehouse 2, Port of Ponce, Puerto Rico as described in the Performance Work Statement.

Portable Hand Washing Stations

This lease is for three portable hand washing stations, to include delivery, set-up, and maintenance required for full operation at Compania De Comercio y Exportacion de Puerto Rico, Warehouse 2, Port of Ponce, Puerto Rico as described in the Performance Work Statement.

Portable Toilets

This lease is for six portable toilets, to include delivery, set-up, and maintenance required for full operation at Carr 149 Fort Allen Juana Díaz, Puerto Rico 00795 as described in the Performance Work Statement.

Portable Hand Washing Stations

This lease is for three portable hand washing stations, to include delivery, set-up, and maintenance required for full operation at Carr 149 Fort Allen Juana Díaz, Puerto Rico 00795 as described in the Performance Work Statement.

CLAUSES INCORPORATED BY REFERENCE

Service and Construction Contracts 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service MAY 2008 and Construction Contracts

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

AUG 2011

JUL 2013

DEC 2013

SEP 2011

NOV 2011

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation MAY 2016 Support

252.213-7000 Notice to Prospective Suppliers on Use of Past Performance Information Retrieval System--Statistical Reporting in Past Performance Evaluations

JUN 2015

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7001 Buy American And Balance Of Payments Program-- Basic (Dec 2016)

DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

JUN 2013

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

1. Price

2. Technical capability of the item to meet Government’s requirement

3. Past Performance

Factor 1: Price

The Government will award a contract resulting from this solicitation to the lowest priced proposal that is technically acceptable and that is fair and reasonable to the Government within the competitive range. Prices will be evaluated for fairness and reasonableness through a price analysis that compares the offered prices against each other and against an independent government estimate.

Factor 2: Technical

Technical capability will be assessed against the contractor’s ability to deliver the requested items, in the correct quantities, and at a reasonable date and time from contract award, and to provide any maintenance required in the Performance Work Statement. Offerors will demonstrate technical ability by: Submitting pictures of their requested equipment per the PWS.

Factor 3: Past Performance

For an offer to be eligible for award, it must have either a satisfactory or neutral past performance in Federal Awardee Performance and Integrity Information System (FAPIIS). This database provides past performance results. Results will be considered for within the 3 years limit (48 C.F.R §42.1503). If an action was terminated for default or cause; offerors will be given a negative rating. Offerors with a negative rating are encouraged to provide information on problems encountered on the identified contracts and the offeror’s corrective actions. The government will consider this information, as well as information obtained from any other sources, when evaluating the offeror’s past performance. Offerors with no negative actions in their history will be given a satisfactory rating. Offerors with no relevant performance history will be given a neutral rating.

(b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017) ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). “Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) ) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended. Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) ) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service- connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) ch individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs

. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ business concern.

] is, [

] is not a small

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ not a veteran-owned small business concern.

] is

(3) ) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [

] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ disadvantaged business concern as defined in 13 CFR 124.1002.

] is not, a small

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ owned small business concern.

] is not a women-

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women- owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [

] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [

] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:

.] Each

WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) ) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

] is not an EDWOSB concern, has provided all the required documents to the WOSB

Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture:

.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women- owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [

] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

] is not a HUBZone small business concern listed, on the date of this representation, on the

List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture:

.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.) [The offeror shall check the category in which its ownership falls]:

Black American.

Hispanic American.

Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal).

Individual/concern, other than one of the preceding.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

] has, [

] has not, participated in a previous contract or subcontract subject to the Equal

Opportunity clause of this solicitation; and

] has, [

] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

] has developed and has on file, [

] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or

] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American – Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements— Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.:

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act'':

Canadian or Israeli End Products:

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.- made or designated country end product as defined in the clause of this solicitation entitled “Trade Agreements.”

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals--

(1) [

] Are, [

] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(2) [

] Have, [

] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and

(3) [

] Are, [

] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and

(4) [

] Have, [

] have not, within a three-year period preceding this offer, been notified of any delinquent

Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(i) ) Taxes are considered delinquent if both of the following criteria apply:

(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) Examples.

(A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights.

(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines…