W911WN-16-T-8016-0001_Roof_Replacements_Amendment.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

RE: REMOVAL AND NEW REPLACEMENT OF THREE (3) ROOFS LOCATED ON THE OHIO RIVER AT 1. OPEKISKA LOCK AND DAM, FAIRMONT, WV 2. MORGANTOWN LOCK AND DAM, MORGANTOWN, WV. AND 3. POINT MARION LOCK AND DAM, DILLINER, PA.

The purpose of this amendment is to incorporate the latest Wage Determinations (PA160077) for Point Marion Lock & Dam, Dilliner, PA and (WV160042) for Morgantow n Lock & Dam, Morgantow n, WV that w ere revised on July 29, 2016.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 03-Aug-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911WN-16-T-8016

X 9B. DATED (SEE ITEM 11)

21-Jul-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

03-Aug-2016

CODE

U.S. ARMY ENGINEER DISTRICT, PITTSBURGH

ATTN CELRP-RC-P

W S MOORHEAD FEDERAL BUILDING

1000 LIBERTY AVENUE ROOM 2203

PITTSBURGH PA 15222-4186

W911WN 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

carole.householder@us.army.milEMAIL:412-395-7274TEL:

CAROLE M HOUSEHOLDER / CONTRACT SPECIALIST

W911WN-16-T-8016

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

ADDENDUM TO SECTION 00800

00800-1 WAGE RATES

The following schedules of wage rates contain rates applicable to all work under the contract:

For Opekiska L/D:

General Decision Number: WV160015 02/26/2016 WV15 Superseded General Decision Number: WV20150015 State: West Virginia Construction Type: Building County: Marion County in West Virginia.

http://www.wdol.gov/wdol/scafiles/davisbacon/WV15.dvb?v=3

For Morgantown L/D:

General Decision Number: WV160042 07/29/2016 WV42 Superseded General Decision Number: WV20150042 State: West Virginia Construction Type: Building County: Monongalia County in West Virginia.

http://www.wdol.gov/wdol/scafiles/davisbacon/WV42.dvb?v=4

For Point Marion L/D:

General Decision Number: PA160077 07/29/2016 PA77 Superseded General Decision Number: PA20150077 State: Pennsylvania Construction Type: Building County: Greene County in Pennsylvania.

http://www.wdol.gov/wdol/scafiles/davisbacon/PA77.dvb?v=9

00800-2 PAYMENT FOR PERFORMANCE AND PAYMENT BONDS

a. In order to ensure that sufficient funds have been set-aside for payment of performance and payment bond premiums, bidders shall insert in Bid Item No. 0001, an appropriate not-to-exceed dollar amount. Failure of bidders to insert a not-to-exceed dollar amount in Bid Item No. 0001 will cause the bid to be rejected as non-responsive.

b. The Contractor shall be reimbursed the actual bond costs only, as established by evidence of full payment to the surety, up to the dollar amount set forth in Bid Item No. 0001.

In no case will the Contractor be reimbursed an amount which exceeds the dollar amount set forth in Bid Item No. 0001.

c. The Government will reimburse only the Prime Contractor for actual paid bond premiums. The Government will not reimburse any subcontractor's paid bond premiums.

00800-3 REQUIRED INSURANCE

a. The Contractor shall procure and maintain during the entire period of his performance under this contract, the following minimum insurance. (See also the clause of the contract entitled "Insurance - Work on a Government Installation").

Type Bodily Injury Amount Property Damage

Comprehensive General Liability $500,000 Per Occurrence $100,000

Automobile Liability $200,000 Each Person ‐‐

$500,000 Per Occurrence $20,000

Workmen’s Compensation and As Legally Employer’s Liability Required by the State

b. The Contracting Officer will notify the Contractor of any noncompliance with the foregoing provisions. The Contractor shall, after receipt of such notice, immediately comply.

Such notice, when delivered to the Contractor or his representative at the site or mailed to the Contractor's address, will be deemed sufficient for the purpose. If the Contractor fails or refuses to comply promptly, the Contracting Officer may issue an order stopping all or part of the work until the Contractor complies. No part of the time lost due to any such stop orders shall be made the subject of a claim for extension of time or for excess costs or damages by the Contractor.

Compliance with the provisions of this article by subcontractors will be the responsibility of the Contractor.

c. Longshoreman and Harbor Worker's Insurance MAY be required for this work. Please consult with your insurance carrier and applicable statutes (33 USC 901, et. seq.).

00800-4 SAFETY AND HEALTH REQUIREMENTS MANUAL

A copy of the current US Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1 and its changes are available at http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1- 1.pdf . The Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

00800-5 WORK UNDER OTHER CONTRACTS

Attention is directed to the fact that other Contractors may be employed by the Government or by local interests at or in the vicinity of the work covered by these specifications. All Contractors shall have equal rights to the use of all roads and grounds so far as practicable and this Contractor shall cooperate with other Contractors so that the work may be performed with the maximum efficiency. Should a disagreement occur between Contractors as to the use of facilities or in other matters, the decision of the Contracting Officer shall govern.

00800-6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the clause entitled "Default (Fixed-Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. This delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

11 8 8 8 8 7 7 6 6 6 6 7

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more on the Contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to work days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the clause entitled, "Default (Fixed-Price Construction)".

d. The anticipated adverse weather work days listed above are based on days with precipitation greater than 0.1 inch and/or maximum temperature below 32 degrees F. The numbers shown represent the number of work days (not calendar days) normally expected to have these particular weather conditions based on historical data obtained from the "Climatography of the United States No. 20". The actual number of days will vary. This information is furnished for computation of possible time extensions due to weather delays and is not intended to imply that no work can be done on these days. The Contractor shall make his own determination of the effect of these conditions on his operations under this contract, and schedule his work accordingly.

00800-7 WORK PERFORMED BY CONTRACTOR

Within ten (10) days after award of the contract, the successful bidder will be required to furnish a description of the work which he intends to perform with his own organization, the percentage of the total work this represents, and the estimated cost thereof.

00800-8 COPYING, DISSEMINATION OR DISTRIBUTION OF INFORMATION.

Those who disseminate information contained on this CD-ROM or in the solicitations and/or drawings must ensure that the recipients have a legitimate need for the information and maintain a record of each recipient. Legitimate need means recognized business entities seeking to do business, or having business, with the Government as prime contractors, subcontractors or suppliers. You shall maintain a record of the following information on each recipient: Business name and address, DUNS Number and IRS Tax ID Number, and name and telephone number of person receiving the information.

(End of Summary of Changes)