Attachment 1 - Synopsis_Solicitiation Revision 20251118.pdf

Agency/Office: MICC – Fort Drum

Location: MICC – Fort Drum

Title: FY23-28 General Construction Services Blanket Purchase Agreement (BPA)

This synopsis is for informational purposes only. This is not a request for quote (RFQ) or a promise to issue a future RFQ. It shall not be construed as a commitment by the Government to contract for any service. The U.S.

Government is not seeking quotes at this time and will not accept unsolicited proposals in response to this synopsis.

Responses in any form are not offers and the Government is under no obligation to award a contract because of this announcement. No funds are available to pay for preparation of responses to this announcement. Any information submitted by respondents to this technical description is strictly voluntary. Not responding to this announcement does not preclude participation in any future RFQ, if any is issued.

The Mission and Installation Contracting Command (MICC) Fort Drum, NY is seeking to identify multiple Small Businesses with the interest and resources to enter into a Blanket Purchase Agreement (BPA) for General Construction Services under North American Industry Classification System (NAICS) Code 236220 Commercial and Institutional Building Construction. The small business size standard for this industry is $45 million in average annual revenue. The Product Service Code is Z2QA Repair or Alteration of Real Property (Public or Private).

MICC-Fort Drum anticipates procuring construction projects valued between the Micro-purchase Threshold and the Simplified Acquisition Threshold. on a competitive basis through the BPA for General Construction Services.

Construction projects under the BPA would include but not be limited to the following: Provide all necessary resources, management, personnel, materials, supervision, transportation, supplies, and all equipment, except Government Furnished Property (GFP) to facilitate all phases of work in connection with various general construction projects on Fort Drum, NY. This would include new work, additions, alterations and maintenance and repair of real property facilities and structures. Insurance is required for these types of projects; and information on required insurance amounts will be included in the Statement of Work.

The total estimated value of BPA construction projects is $15,000,000.00 with an estimated 35 projects each fiscal year with an average value of $75,000.00. Contractors with a BPA must be capable of obtaining the payment bonds required for construction projects valued between $35,000.00 and the Simplified Acquisition Threshold.

Contractors unable to meet this bonding requirement will not be considered for issuance of a BPA. Where site visits are offered and attended, the prime BPA Contractor must represent themselves (subcontractors cannot represent a prime contractor on site visits or in response to any request for information or quote). BPA contractors shall comply with FAR 52.222-6 Construction Wage Rate Requirements (formerly Davis-Bacon Act). Each project will be competitively procured, and the Government will incorporate the most current Davis Bacon wage determination in effect at time of award. Davis Bacon wage determinations are located at https://sam.gov/content/wage-determinations.

In accordance with FAR Part 36.211 Distribution of Advance Notices and Solicitations, contractors are required to submit requests for equitable adjustment as a result of change orders to the issuing Contracting Officer. Contractors are required to acknowledge the change order within 30 days and are to submit their request for adjustment which includes all supporting documents as soon as possible, but not later than the required completion date of the contract. In the table below is the agency’s past performance, for the period of three fiscal years, regarding the time required to definitize equitable adjustments for change orders under construction contracts.

Time to definitize after receipt of an adequate change order definitization proposal under construction contracts

Number of change order proposals definitized under construction contracts

30 days or less 1 31 to 60 days 1 61 to 90 days 0 91 to 180 days 0

181 to 365 days 0

366 or more days 0 Table 1. Change Order Definitization

When establishing these BPAs, the Government will consider price and socio-economic status. BPAs will be evaluated annually and may remain in place for up to five (5) years. Annual review of BPAs will be performed to determine whether the Government is receiving fair and reasonable pricing, usage, and participation, which may result in either continuing the BPA or early discontinuation. Early discontinuation may result if the Government no longer has a requirement for the general construction services provided by the Contractor. MICC-Fort Drum anticipates a maximum of 10 contractors holding a BPA for general construction services. A list of interested vendors will be maintained.

The Contractor must be registered in Wide Area Work Flow (WAWF) for contract payment. To register and access WAWF, go to https://piee.eb.mil/. As prescribed in DFARS 252.204-7007, interested parties must be registered with the System for Award Management (SAM) under NAICS Code 236220. Representations and Certifications must also be on record. SAM registration is free and done through the website at https://www.sam.gov.

Per the authority of FAR Clause 52.219.3(c) Notice of HUBZone Set-Aside or Sole-Source Award, this procurement will be 100% set aside for Historically Underutilized Business (HUB) Zone small businesses.

Instructions to Interested Parties: If your small business organization has the potential capacity to perform these general construction services and is interested in being considered for inclusion in this general construction service BPA, respond electronically to the point of contact information below. Responses must reference “FY23-28 General Construction Services Blanket Purchase Agreement (BPA)” in the subject field, be in Portable Document Format (PDF), submitted electronically to Lyndsie Hall, lyndsie.j.hall.civ@army.mil, with a courtesy copy to SSG Dugaue, kyle.r.dugaue.mil@army.mil and include the following:

1) UEI Number

2) CAGE Code

3) Tax ID Number

4) POC’s name, physical address, email address, and telephone number

5) Website address

6) Small business size, socioeconomic categories, and type of ownership for the organization

7) Capability Statement

8) Letter from surety confirming your organization’s bonding capability

9) Completed provision representations/certifications of this synopsis

Additionally, your small business organization must complete the representations included in this synopsis’ provisions in https://www.SAM.gov.

Telephone inquiries will not be accepted or acknowledged, and no feedback or evaluations will be provided to companies regarding their submissions. Vendors who meet the requirements of this solicitation will be notified of their inclusion onto the interested vendors list for this General Construction Services BPA.

Provisions Incorporated by Reference

52.204-22 Alternative Line Item Proposal JAN 2017 52.236-28 Preparation of Proposals—Construction OCT 1997 252.204-7008 Compliance With Safeguarding Covered Defense Information Controls OCT 2016

Provisions Incorporated by Full Text

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2022)

http://www.sam.gov/ mailto:lyndsie.j.hall.civ@army.mil, mailto:kyle.r.dugaue.mil@army.mil

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $45,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph

(d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(D) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

XX (i) 52.204-17, Ownership or Control of Offeror.

XX (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

XX (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the

It [ ] will, [ ] will not facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

It [ ] does, [ ] does not it [ ] does, [ ] does not provide

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representations.

(1) The Offeror represents that covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ] does, [ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address:

https://www.acquisition.gov

(End of clause)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2021)

Substitute the following paragraphs (b), (d) and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at FAR 52.204-7, System for Award Management, is included in this solicitation, paragraph

(e) of this provision applies.

(2) If the provision at FAR 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) Paragraph (e) applies.

(ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.204-7016, Covered Defense Telecommunications Equipment or Services--Representation. Applies to all solicitations.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

http://www.acquisition.gov/

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer:

(i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

(ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

(iii) 252.225-7020, Trade Agreements Certificate.

Use with Alternate I.

(iv) 252.225-7031, Secondary Arab Boycott of Israel.

(v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

Use with Alternate I.

Use with Alternate II.

Use with Alternate III.

Use with Alternate IV.

Use with Alternate V.

(vi) 252.226-7002, Representation for Demonstration Project for Contractors Employing Persons with Disabilities.

(vii) 252.232-7015, Performance-Based Payments--Representation.

(e) The Offeror has completed the annual representations and certifications electronically via the SAM website at https://www.acquisition.gov/. After reviewing the SAM database information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [Offeror to insert changes, identifying change by provision number, title, date ]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS provision No.

Title

Date

Change

Any changes provided by the Offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Clauses Incorporated by Reference

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity MAY 2014 52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal Transactions JUN 2020 52.204-7 System for Award Management OCT 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance OCT 2018 52.204-19 Incorporation by Reference of Representations and Certifications. DEC 2014 52.204-27 Prohibition on a ByteDance Covered Application JUN 2023 52.211-5 Material Requirements AUG 2000

52.213-4 Terms and Conditions--Simplified Acquisitions (Other Than Commercial Products and Commercial Services) DEC 2022 52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation MAY 2018 52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations MAY 2014 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for Construction APR 2015 52.222-54 Employment Eligibility Verification MAY 2022 52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving JUN 2020 52.223-19 Compliance with Environmental Management Systems MAY 2011 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-13 Alternative Payment Protections JUL 2000 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 Progress Payments NOV 2021 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed Price) (Short Form) APR 1984 52.249-10 Default (Fixed-Price Construction) APR 1984 52.249-14 Excusable Delays APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD Officials SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting DEC 2019 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support MAY 2016 252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7020 NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.223-7003 Changes In Place Of Performance--Ammunition And Explosives DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Alt I Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials - Alternate I SEP 2014 252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports DEC 2018 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7005 Airfield Safety Precautions DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items DEC 2022 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations OCT 2010 252.247-7023 Transportation of Supplies by Sea FEB 2019

5152.209-4000 DOD LEVEL I ANTITERRORISM (AT) STANDARDS FEB 2009

Clauses Incorporated by Full Text

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within (**to be specified with each BPA Call**) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than (**to be specified with each BPA Call**). The time stated for completion shall include final cleanup of the premises.

52.219-3 NOTICE OF HUBZONE SET-ASIDE OR SOLE-SOURCE AWARD (OCT 2022)

(a) Definition. "HUBZone small business concern,'' as used in this clause, means a small business concern, certified by the Small Business Administration (SBA), that appears on the List of Qualified HUBZone Small Business Concerns maintained by the SBA (13 CFR 126.103).

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside, or awarded on a sole-source basis to, HUBZone small business concerns;

(2) Part or parts of a multiple-award contract that have been set aside for HUBZone small business concerns;

(3) Orders set aside for HUBZone small business concerns under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F); and

(4) Orders issued directly to HUBZone small business concerns under multiple-award contracts as described in

19.504(c)(1)(ii).

(c) General.

(1) Offers are solicited only from HUBZone small business concerns. Offers received from concerns that are not HUBZone small business concerns will not be considered.

(2) Any award resulting from this solicitation will be made to a HUBZone small business concern.

(d) Joint venture. A joint venture may be considered a HUBZone concern if--

(1) At least one party to the joint venture is a HUBZone small business concern and complies with 13 CFR 126.616(c); and

(2) Each party to the joint venture qualifies as small under the size standard for the solicitation, or the protege is small under the size standard for the solicitation in a joint venture comprised of a mentor and protege with an approved mentor-protege agreement under the SBA mentor-protege program.

(e) A HUBZone joint venture agrees that, in the performance of the contract, at least 40 percent of the aggregate work performed by the joint venture shall be completed by the HUBZone small business parties to the joint venture.

Work performed by the HUBZone small business party or parties to the joint venture must be more than administrative functions.

52.219-14 LIMITATIONS ON SUBCONTRACTING (OCT 2022) DEVIATION 2021-O0008

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that--

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to--

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are--

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are--

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for--

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding certain other direct costs and certain work performed outside the United States (see paragraph (e)(1)(i)), to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract;

(i) Other direct costs, to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service. Examples include airline travel, work performed by a transportation or disposal entity under a contract assigned the environmental remediation NAICS code 562910), cloud computing services, or mass media purchases.

(ii) Work performed outside the United States on awards made pursuant to the Foreign Assistance Act of 1961, or work performed outside the United States required to be performed by a local contractor.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause--

By the end of the base term of the contract and then by the end of each subsequent option period; or

X By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph

(e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protege and its mentor approved by the Small Business Administration, the small business protege shall perform at least 40 percent of the work performed by the joint venture. Work performed by the small business protege in the joint venture must be more than administrative functions.

(2) In an 8(a) joint venture, the 8(a) participant(s) shall perform at least 40 percent of the work performed by the joint venture. Work performed by the 8(a) participants in the joint venture must be more than administrative functions.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial product (as defined in paragraph (1) of the definition of "commercial product" at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless…