W911RQ-17-R-0014.pdf

SEE ADDENDUM

(No Collect Calls)

W911RQ-17-R-0014 25-Aug-2017

b. TELEPHONE NUMBER

586-282-3548

8. OFFER DUE DATE/LOCAL TIME

12:00 PM 08 Sep 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W911RQ9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

TYLER WONSOWICZ

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ARMY CONTRACTING COMMAND-WARREN (DTA)

6501 E.11 MILE ROAD

WARREN MI 48397-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE W911RQ 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

RED RIVER ARMY DEPOT

DEBORAH WILLIAMS

100 JAMES CARLOW DRIVE

BLDG 551 SOUTH LOT

TEXARKANA TX 75507-5000

TEL: 903-334-1097 FAX:

FAX:

TEL: 586-282-6734

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

332710

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF64

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W911RQ-17-R-0014

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES ESTIMATED

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

0011 47 First Ordering Per-M870A1 Trailer REFUR

FFP

M870A1 Trailer Refurbishment is in accordance with Performance Work

Statement.

FOB: Destination

ESTIMATED

NET AMT

UNIT UNIT PRICE ESTIMATED AMOUNT

0012 47 Second Ordering Per-M870A1 Trailer REFUR

FFP

M870A1 Trailer Refurbishment is in accordance with Performance Work

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

0013 31 Third Ordering Per-M870A1 Trailer REFUR

FFP

M870A1 Trailer Refurbishment is in accordance with Performance Work

UNIT UNIT PRICE ESTIMATED AMOUNT

Data Items

FFP

The following Contract Line Item Numbers (CLIN) represents Contract Data

Requirements Lists (CDRL) for the Statement of Work (SOW).

CDRLs are to be NOT SEPARATELY PRICED. Proposals that are received with any priced CDRLs will not be eliminated from consideration for contact award.

However, any prices proposed for any CDRL in this solicitation will not be calculated into the offerors proposal. Only CLINs 0011, 0012, and 0013 will make up the total price.

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

A001 Repairable Item Inspection Report

FFP

Repairable Item Inspection Report is in accordance with CDRL A001 and

Performance Work Statement Sections 3.5 and 5. This CDRL is NOT

SEPARATELY PRICED, please DO NOT provide a price for this CLIN.

See Exhibit A

UNIT UNIT PRICE ESTIMATED AMOUNT

A002 Weekly Progress Report

FFP

Weekly Progress Report is in accordance with CDRL A002 and Performance Work

Statement Section 3.13. This CDRL is NOT SEPARATELY PRICED, please DO

NOT provide a price for this CLIN.

See Exhibit B

PERFORMANCE WORK STATEMENT

Performance Work Statement (PWS) – M870A1 Trailer Neck Pin Hole Repair

1. Introduction. Red River Army Depot (RRAD) is refurbishing a significant quantity of M870A1 40-Ton

Low-Bed Semi Trailers for various DoD components worldwide. As part of this process, RRAD needs to ensure all moving parts of the trailers are within-tolerance and operate as originally designed. Field observation and testing by RRAD and the Tank-Automotive Research, Development, and Engineering

Center (TARDEC) indicate some of these trailers may exhibit wear to moving parts within their

“gooseneck” assemblies, requiring precision machining to correct. Further testing by TARDEC has resulted in the approved repair process described herein, for performance by a qualified Contractor.

2. Scope. The Contractor shall retrieve M870A1 refurbishment candidate trailers from RRAD, disassemble the “gooseneck” assembly of each trailer including the link arms, and inspect the pins and all slots and holes for wear. When wear is found, the Contractor shall perform precision machining to bore and sleeve the holes, and fabricate new pins to ensure each trailer operates as originally designed. When all gooseneck repairs are complete, the Contractor shall return the trailers to RRAD.

3. Repair Tasks. Work shall only be performed where certain conditions are observed, as detailed in this section. The Contractor shall ensure all work is performed with the exact materials and to the tolerances described herein.

3.2. Work Location and Trailer Movement. The Contractor shall retrieve trailers from RRAD’s facility near

Texarkana, TX, repair the trailers at its facility, and return the trailers to RRAD when complete. RRAD will ensure each trailer is equipped with all required tires at the point of pickup, but the Contractor is hereby advised that the trailer may require special handling when being transported (e.g. supplemental lights, preparations for seized bearings). The Contractor is responsible for all transportation to and from RRAD.

3.3. Contractor must perform the work under this contract at a facility within a 250 mile radius of Red

River Army Depot.

3.4. Dismantling. The gooseneck assembly and link arms shall be disassembled on each incoming trailer to permit comprehensive and precise inspection of all wear surfaces.

3.5. Cataloging and Reporting. The Contractor shall catalog any damage found and the diameter of each hole before and after the repair process, and shall report the findings to the COR by submitting a

Repairable Item Inspection Report (CDRL A001) for each trailer.

3.6. Pin Tolerances and Composition. The Contractor shall inspect all pins for wear or distortion, and shall replace all pins found to be bent, cracked, crushed, or with wear surfaces that are out-of-round or reduced in diameter by 0.015in or more. Replacement pins shall be fabricated with ASTM A 572

Grade 55 – Grade 65 material.

3.7. Hole Tolerances. The Contractor shall inspect all holes in the gooseneck assembly and link arms, and determine if any distortion, abrasion, or ovality is present. If any abrasion or ovality is present, or if the diameter of the hole at any point is more than 0.015in larger than designed, the hole must be bored and sleeved to correct the issue. The bushings shall utilize SAE 4130 quench and Temper to 22-23 HRC and the Doubler shall utilize ASTM A 572 Grade 65. The Bushing and the Doubler is captured for reference in Figures one and two (Attachments 1).

3.8. Return Without Repair. If the conditions detailed in Paragraphs 3.5 and 3.6 are not found, the

Contractor shall notify the COR, reassemble the trailer using anti-seize compound on gooseneck wear surfaces, and return it to RRAD.

3.9. Extreme Damage. If the Contractor observes any condition that may render the trailer irreparable using the procedures described herein, the Contractor shall notify the COR immediately for further guidance.

3.10. Boring Technique and Tolerances. The Contractor shall use portable line boring machines or horizontal boring machines as required, and shall use precision methods to ensure all holes are properly aligned. Holes shall be machined to the extent they will accept a bushing with a minimum

0.125in wall thickness.

3.11. Bushing Tolerances and Composition. Bushings shall be machined such that their walls are no thinner than 0.125in, from SAE 4130 quench and temper to 22-23 HRC material, with a 0.002-0.003in interference fit. Doublers (the holes that contain the bushings themselves and are utilized throughout the trailer) requiring machining shall utilize ASTM A 572 Grade 65 material. Bushing interior diameters shall only allow 0.006-0.008in clearance for pins.

3.12. Reassembly. Bushings shall be installed into holes using a liquid nitrogen shrinking process. All bushing interiors, pins, and other gooseneck wear surfaces shall be lubricated with anti-seize compound during assembly.

3.13. The Contractor or their manager shall provide the COR a Weekly Progress Report (CDRL A002) to verify the project status, time delays, percent of overall completion, task completion status, adjusted completion date and any other issues directly related to the project completion.

4. Contracting Officer’s Representative. Work performed under this Contract will be supervised by a

Contracting Officer's Representative (COR). The COR is authorized to perform inspection and acceptance on the repaired trailers, but cannot authorize additional work or deviations from the performance standards.

The Contractor shall notify the COR and Contracting Officer immediately of any additional work required or hidden flaws uncovered when working on a trailer, and shall provide the COR and the Contracting

Officer with a description of the problem and an estimate for project completion. The Contractor shall not proceed with additional work without the consent of the Contracting Officer.

5. Inspection and Acceptance. Prior to acceptance by Red River Army Depot, the Contractor shall demonstrate for the Contracting Officer’s Representative (COR) that the trailer functions as originally designed, and shall demonstrate the gooseneck assembly across its full range of motion. The Contractor shall provide the COR with a full description of the services performed and any parts repaired or replaced for each trailer as part of the Repairable Item Inspection Report (CDRL A001).

6. Schedule. Contractor shall be provided a 14 day ramp up time period. During these 14 days the contractor shall not be required to complete any trailers. After the 14 day ramp up time has ended, a delivery order will be issued by Government. Once the delivery order is issued, Contractor shall pick up the first two trailers and transport to the Contractor's facility to be refurbished. The initial two trailers shall be completed and ready for delivery back to RRAD no more than 14 days after pickup by Contractor. After the initial two trailers are delivered back to RRAD the Contractor shall complete refurbishment of two trailers per week until the remaining trailers are finished.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0011 Origin Government Origin Government

0012 Origin Government Origin Government

0013 Origin Government Origin Government

0021 N/A N/A N/A Government

A001 N/A N/A N/A Government

A002 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0011 28 dys. ADC 2 RED RIVER ARMY DEPOT

DEBORAH WILLIAMS

100 JAMES CARLOW DRIVE

BLDG 551 SOUTH LOT

TEXARKANA TX 75507-5000

903-334-1097

W911RQ

0011 35 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 42 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 49 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 56 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 63 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 70 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 77 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 84 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 91 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 98 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 105 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 112 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 119 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 126 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 133 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 140 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 147 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 154 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 161 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 168 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 175 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 182 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0011 189 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0012 372 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 379 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 386 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 393 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 400 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 407 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 414 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 421 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 428 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 435 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 442 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 449 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 456 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 463 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 470 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 477 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 484 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 491 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 498 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 505 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 512 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 519 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 526 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0012 533 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0013 730 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 737 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 744 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 751 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 758 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 765 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 772 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 779 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 786 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 793 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 800 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 807 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 814 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 821 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 828 dys. ADC 2 (SAME AS PREVIOUS LOCATION)

0013 835 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0021 N/A N/A N/A N/A

A001 N/A N/A N/A N/A

A002 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984

52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(Sep 2006) -- Alternate I

OCT 1995

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.211-14 Notice Of Priority Rating For National Defense, Emergency

Preparedness, and Energy Program Use

APR 2008

52.211-17 Delivery of Excess Quantities SEP 1989

52.212-1 Instructions to Offerors--Commercial Items JAN 2017

52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017

52.216-21 Requirements OCT 1995

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-19 Child Labor -- Cooperation with Authorities and Remedies OCT 2016

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-35 Equal Opportunity for Veterans OCT 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014

52.222-37 Employment Reports on Veterans FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.232-11 Extras APR 1984

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.242-13 Bankruptcy JUL 1995

52.242-17 Government Delay Of Work APR 1984

52.245-1 Government Property JAN 2017

52.245-9 Use And Charges APR 2012

52.247-34 F.O.B. Destination NOV 1991

52.247-48 F.O.B. Destination--Evidence Of Shipment FEB 1999

52.247-55 F.O.B. Point For Delivery Of Government-Furnished

Property

JUN 2003

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

252.204-7006 Billing Instructions OCT 2005

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7011 Alternative Line Item Structure SEP 2011

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.208-7000 Intent To Furnish Precious Metals As Government--Furnished

Material

DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.211-7007 Reporting of Government-Furnished Property AUG 2012

252.215-7000 Pricing Adjustments DEC 2012

252.225-7001 Buy American And Balance Of Payments Program-- Basic

(Dec 2016)

DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016

252.225-7012 Preference For Certain Domestic Commodities DEC 2016

252.225-7013 Duty-Free Entry--Basic (May 2016) MAY 2016

252.225-7016 Restriction On Acquisition Of Ball and Roller Bearings JUN 2011

252.225-7021 Trade Agreements--Basic DEC 2016

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

252.225-7048 Export-Controlled Items JUN 2013

252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business

Concerns

SEP 2004

252.232-7010 Levies on Contract Payments DEC 2006

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012

252.245-7003 Contractor Property Management System Administration APR 2012

252.246-7003 Notification of Potential Safety Issues JUN 2013

252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

(a) Definitions. As used in this clause--

Internal confidentiality agreement or statement means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.

Subcontract means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.

(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.

(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form

312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information

Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing

Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the

Government determines that the Contractor is not in compliance with the provisions of this clause.

(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

(End of clause)

52.207-4 ECONOMIC PURCHASE QUANTITY--SUPPLIES (AUG 1987)

(a) Offerors are invited to state an opinion on whether the quantity(ies) of supplies on which bids, proposals or quotes are requested in this solicitation is (are) economically advantageous to the Government.

Each offeror who believes that acquisitions in different quantities would be more advantageous is invited to recommend an economic purchase quantity. If different quantities are recommended, a total and a unit price must be quoted for applicable items. An economic purchase quantity is that quantity at which a significant price break occurs. If there are significant price breaks at different quantity points, this information is desired as well.

OFFEROR RECOMMENDATIONS

PRICE

ITEM QUANTITY QUOTATION TOTAL

(c) The information requested in this provision is being solicited to avoid acquisitions in disadvantageous quantities and to assist the Government in developing a data base for future acquisitions of these items. However, the

Government reserves the right to amend or cancel the solicitation and resolicit with respect to any individual item in the event quotations received and the Government's requirements indicate that different quantities should be acquired.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-4020 ANTI-TERRORISM (AT) LEVEL I TRAINING REQUIREMENT (JUN 2012) (TACOM)

All contractor employees, including subcontractor employees, requiring access to Army installations, facilities, or controlled access areas shall complete AT Level I awareness training within 60 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever applies. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee to the COR (or to the contracting officer, if a COR is not assigned) within 60 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at https://atlevel1.dtic.mil/at.

52.211-4009 DELIVERIES TO RED RIVER ARMY DEPOT (RRAD) (Nov 2015)

Effective October 1, 2015 ALL Delivery Appointments must be made through CAS (Carrier Appointment System) at least 24 hours prior to desired delivery date. Carriers arriving without an appointment will experience delays. Carriers can register for CAS at https://eta.sddc.army.mil/ETASSOPortal/Default.aspx

GPS Address is 100 Armory Drive New Boston, TX 75570.

Automated directions 903-334-3060.

Temporarily, if you do not have access to CAS at this time, you may contact Timothy Hill @ 903-334- 1245 for assistance in making an appointment. At this time, 903-334-1242 is not being utilized for appointments.

Sensitive/TPS shipments, DODAAC SV3227 will load/unload at Bldg. 595 telephone number 903 334 3295, FAX Rep-ship for Classified material to 903 334 3620 or DSN 829-3620 or ddrt-repship@dla.mil.

DLA RRAD does not accept 1.4S shipments of any kind.

Effective 1 Aug 2015, prohibited items not allowed on depot: firearms, explosive, ammunition, propane over 20 LBS, fuel containers over 5 gallons, illegal knives.

Drivers must clear a NCIC Background check for entry onto the facility.

SW3227/W562RM do not accept USPS shipments.

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

https://www.acquisition.gov/ https://atlevel1.dtic.mil/at

The Evaluation will be conducted in accordance with FAR 12.6 (Streamlined Procedures for Evaluation and

Solicitation for Commercial Items). There are two factors (1) price and (2) technical acceptability. The Government intends to award a contract to the responsible offeror whose proposal (1) has the lowest total evaluated price; (2) is rated as Technically Acceptable.

In the first phase, offerors will have their proposals put in order of lowest evaluated to highest evaluated by proposed price which will be the total price for all ordering periods for all CLINs in the solicitation. The offeror with the lowest price will then be selected for a technical review (phase 2). The lowest price offeror in this phase will be evaluated for responsibility and so fourth, until a responsible offeror is determined.

The second phase will involve establishment of technical acceptability. An offer will be determined technically acceptable if the offeror owns or leases a facility within 250 miles of Red River Army Depot. An offeror is required to submit documentation that confirms the facility where the work will be conducted, is within this 250 mile limit.

Award will be made to the offer who submits the lowest priced proposal, is Technically Acceptable, and is determined to be responsible as defined in FAR 9.1.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means— https://www.sam.gov/portal

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance

Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a

State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974; and http://www.dol.gov/fairpayandsafeworkplaces

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the

FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of

``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

http://www.osha.gov/dcsp/osp/approved_state_plans.html

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act

(50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term

“successor” does not include new offices/divisions of the same company or a company that only changes its name.

The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least

51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal

Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies https://www.acquisition.gov/ by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-

3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ .

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United

States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a…