Solicitation Amendment W911PT26QA0970001 SF 30.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form Continuation

The following changes have been made:

INFORMATION FROM TO

Response Due Time

04:00 PM 01:00 PM

Response Due Date

07 Jul 2026 16 Sep 2026

Miscellaneous text in this section has been modified from:

STATEMENT OF WORK (SOW)

FOR

Water Strainer Inspection and Cleaning

AT

Watervliet Arsenal

Buildings 40,110, 120, 125, 130, 135, Back Flow 4 (Siberia)

Project #: 26PW018

Installation Management, Public Works Division

Facilities Engineering (TAWV-IMP-F)

GENERAL

1.1 SUMMARY OF WORK

1.1.1 Project Description

a. This Statement of Work (SOW) defines the effort required for the cleaning and inspection of seven water meter strainers.

W911PT26QA0970001

1.1.2 Location of Work

a. The exact location will be shown by the Contracting Officer.

1.1.3 Period of Performance

a. The contractor shall be required to (i) commence work under this contract within 7 calendar days after the date the contractor receives notice to proceed, (ii) prosecute the work diligently, and (iii) complete the entire work ready for use not later than [30] calendar days after notice to proceed was given. The time stated for completion shall include final cleanup of the premises.

1.1.4 Hours of Operation

a. Normal duty hours are 7:00 AM through 4:00 PM, Monday through Thursday, and 7:

00 AM through 3:00 PM on Fridays. Federal holidays are non-work days. If a federal holiday falls on a Saturday or Sunday, the preceding Friday or following Monday is a work holiday.

1.2 SUBMITTALS

1.2.1 General Submittal Requirements

a. The contractor shall provide submittal documents via e-mail to the Contracting Officer for review and approval. Provide all physical (non-document) submittals (including but not limited to material swatches, samples, etc.) directly to the Contracting Officer for review and approval. All submittals require government approval unless otherwise explicitly stated.

b. The contractor shall reference APPENDIX A "Consolidated List of Submittals" for the complete list of required submittals.

1.2.2 Contractor Safety Plan

a. The contractor shall submit a safety plan which is specific to the work activity being performed under the scope of this project for Government review and approval.

1.2.3 Lockout / Tagout (LOTO) Acknowledgement

a. The Contractor shall sign and submit a "Lockout/Tagout (LOTO) Notification Acknowledgement Record" prior to working on or de-energizing any electrical equipment.

1.2.4 Asbestos Notification Acknowledgement Record

a. The contractor shall sign the "Asbestos Notification Acknowledgement Record" and submit this form to the Project COR prior to starting project work.

1.2.5 Project Schedule

a. The contractor shall create a project schedule and submit for Government review and approval.

b. The project schedule shall detail the phases of work and the overall timeline for the execution of the work. The contractor shall include delivery dates, appropriate milestones, and shall clearly detail any requirements for work performed outside of regular hours of operation.

1.3 GENERAL REQUIREMENTS

1.3.1 Watervliet Arsenal Information for Contractors (WAIC)

a. The contractor shall perform all work in strict conformance with Watervliet Arsenal Instructions for Contractors (WAIC). The contractor shall read and understand this document prior to submitting a proposal. The WAIC is publicly available at:

1.4 Utility Outage Requests and Utility Connection Requests

1.4.1 Schedule work to minimize outages. For utility outages and connections required during the execution of work that affect existing systems, coordinate schedule with COR.

Schedule utility outages and connections to minimize disruptions to the Government. No additional payment will be provided for utility outages and connections required to be performed outside the regular work hours.

a. The contractor shall notify the Contracting Specialist a minimum of two (2) business days before the contractor starts work. The contractor shall notify the COR a minimum of seven (7) business days before the shut-down of a utility or building service.

1.4.2 Safety Requirements

a. The contractor is required to provide the proper control of hazardous energy (lockout /tagout) per OSHA 29 CFR 1910.147.

b. The contractor shall inspect the project work site prior to starting work, and shall request a copy of the asbestos building inspection records to verify the location and description of known asbestos-containing materials.

1.5 ON-SITE PERMITS

1.5.1 Excavation (Dig Permit)

a. The clearance of buried utilities will be performed by the Government in advance of the Contractor performing subsurface work, unless otherwise explicitly stated.

b. The Contractor shall obtain a copy of the completed Utility Clearance Permit (WVA Form 420-2-E) from the COR prior to performing subsurface work. Verify existing utility locations indicated on contract drawings, within area of work.

1.5.2 Hot Work and Confined Space

a. Obtain permit for welding, burning, use of flame, or entry into confined space from WVA Fire Department by calling (518)266-5990 each day the permit is to be used.

1.6 APPLICABLE DOCUMENTS

1.6.1 Drawings

a. Water Meter Pit Locations

1.7.1 Specifications

a. UFGS 33 61 13.19 - Valves, Piping and Equipment in Valve Manholes

b. UFGS 33 11 00 - WATER UTILITY DISTRIBUTION PIPING

1.8.1 References

a. The following references accompany this Statement of Work and are a part thereof.

i. Watervliet Arsenal Instructions for Contractors (WAIC).

ii. NFPA 70 - National Electric Code (NEC).

1.7 CONTRACTOR EQUIPMENT

1.7.1 Equipment Identification

a. The contractor shall create and affix a label to all large equipment, dumpsters, and other mobilized property, which is weather-resistant (laminated, or within a see-thru label hanger), securely affixed to the equipment or visible through a window, and which clearly displays the General Contractor's:

i. Company Name, POC Name (first, last), POC phone number, Project Number.

1.7.2 Waste Dumpster

a. The contractor shall place any waste dumpsters in a manner that does not interfere with thru-traffic.

b. Place waste dumpsters with a minimum of 33' clearance from any building. The final location shall be coordinated with, and approved by the COR before any dumpsters are mobilized.

c. Cover all waste dumpsters when not in use, and before the end of each work shift.

The cover shall be weather-tight.

d. The Contractor shall submit all Bills of Lading and Weight Slips associated with the disposal of all construction and demolition (C&D) debris to the Contracting Officer on a monthly basis. The contractor shall provide this information within ten (10) days of disposal of the waste.

PART 2 PRODUCTS

2.1 GENERAL

All work shall be in strict accordance with product manufacturer's instructions and specifications, including but not limited to manufacturer guidance for storage, staging, application, installation, and disposal of the product.

2.1.1 Hazardous Materials

a. The contractor shall submit Safety Data Sheets (SDS) for all hazardous materials to be used.

2.1.2 Asbestos, Mercury, Lead, PCB

a. Unless otherwise stated, all materials for this project shall be new. All products shall not contain any asbestos, mercury, chromium/lead paint, Class I Freon, and Polychlorinated Biphenyls (PCB), and shall state such on the manufacturer's original packaging.

2.1.3 DoD Green Procurement Program

a. All construction materials shall meet the applicable requirements of the DoD Green Procurement Program, specifically recycled content products, environmentally preferable products and services, biobased products, energy-and water-efficient products, alternate fuel vehicles and alternative fuels, products using renewable energy, and alternatives to hazardous or toxic chemicals as found at .

2.1.4 Paint

a. To meet the Affirmative Procurement Program (Federal Government's Buy Recycled Requirements) all paint used in the project shall adhere to the below listed requirements of the Comprehensive Procurement Guideline for recovered materials. This applies only to interior latex paint, only if available at the time of the project.

i. Reprocessed Latex Paint (White, Off-White, Pastel Colors) shall contain 20% Post consumer content.

ii. Reprocessed Latex Paint (Grey, Brown Earth tones, and Other Dark Colors) shall contain 50-99% Post consumer content.

iii. Consolidated Latex Paint shall contain 100% Post consumer content.

PART 3 EXECUTION

3.1 ITEMS OF WORK

3.1.1 General Requirements

a. The Contractor shall furnish all labor, supervision, materials, supplies, transportation, tools, equipment, and other means necessary for performing and completing a water strainer inspection and cleaning.

b. The Contractor shall perform all services in a safe and workmanlike manner as per generally accepted industry standards, as well as coordinating all efforts with the COR and meeting with additional system personnel as appropriate.

3.1.2 Water meter pits/vaults are considered confined spaces. Contractors working in Watervliet Arsenal confined spaces must provide their own air monitoring devices, harnesses, tripods and all other safety services/devices.

a. In addition, proper entry procedure must be followed in accordance with OSHA and Watervliet Arsenal health standards for permit required confined spaces. The Fire Department rescue line shall be used for emergency contact on the installation for immediate rescue efforts to take place.

b. Contractors must use the Watervliet Arsenal Form 385-17-E (Confined Space entry permit) and provide that form to the COR. They must also notify the Fire Department of all actions during the confined space projects. They also must ensure emergency notification sheet is always complete and visible onsite.

3.1.3 Water Meter Strainer Cleaning and Inspection Verification

3.1.4 The Contractor shall develop, plan and execute inspection and cleaning of the (7x) potable water system strainers. Strainers are part of 8" Sensus OMNI Fireline Water Meter assemblies.

3.1.5 The Contractor shall inspect the strainer mesh for damage.

3.1.6 The Contractor shall provide a "Work Plan" to implement the water strainer inspection and cleaning, including steps and timeframe required for this work to be completed including a description of the specialized equipment being used. Contractor shall provide a detailed description of cleaning and inspection methods.

a. The Contractor shall provide notice to the COR every time they are onsite to include the location of all crews. The COR or their designated representative will periodically inspect the work and will always be available should issues arise. Contact numbers will be exchanged upon commencement of the work.

b. The Arsenal will aid the Contractor as required for the location of water main gate valves and curb-stops. However, the Arsenal will not provide to the Contractor an employee as a guide or assistance in the operation meter recalibration and inspection.

The Arsenal will also provide a map of the water system to locate the water meter pits.

3.1.7 The Contractor shall pump out valve vaults full of water to facilitate strainer servicing

3.1.8 The Contractor shall provide before and after cleaning pictures of the inside of each strainer.

3.1.9 The Contractor shall reassemble the strainer and confirm that it does not leak to the exterior at pressure.

3.1.10 Meter strainer cleaning and inspection report

3.1.11 The contractor shall provide a meter strainer inspection and cleaning report with the following information:

a. Before and after pictures of strainer internals

b. Meter number

c. Recommendations on additional maintenance (if any)

3.2 CLOSEOUT REQUIREMENTS

3.2.1 Construction and Demolition Debris

a. The Contractor shall submit copies of all Bills of Lading and Weight Slips associated with the disposal of construction and demolition (C&D) debris and/or recycled materials, under this scope of work. Submit documentation per Appendix A, "Consolidated List of Submittals".

3.2.2 Cleanup of Work Site

a. The contactor shall clean all work areas daily and remove all tools, equipment, debris, materials, and all waste from the premises.

b. The contractor shall remove all debris from any remote holding locations, to include any excavation and concrete equipment chute cleanout debris.

c. The contractor shall remove their equipment from Watervliet Arsenal premises within five (5) working days after completion of project work.

3.2.3 Restoration of Work Site

a. The contractor shall repair any items, building surfaces, equipment or miscellaneous items which were damaged during the execution of this SOW. Items that cannot be repaired to restore original function or aesthetics shall be replaced in kind by the Contractor at no additional charge to the Government.

3.2.4 Warranty

a. The contractor shall provide a [1] year warranty from the date of government acceptance on any newly installed parts and workmanship.

PART 4 APPENDICES

4.1 Consolidated List of Submittals

APPENDIX A: Consolidated List of Submittals

Line Item Submitted Submittal Needed By Submittal Reviewed By (Office)

1 Safety Data Sheets for Hazardous Materials

(SDS)

NLT 7 Calendar

Days After Award

Safety Office

2 Signed Contractor Asbestos Notification Form NLT 7 Calendar

Days After Award

Environmental Office

3 Signed Lockout/Tagout (LOTO) Notification

Acknowledgement Record

NLT 7 Calendar

Days After Award

Safety Office

4 Project Schedule COR

NLT 7 Calendar

Days After Award

5 Contractor Safety Plan NLT 7 Calendar

Days After Award

COR

6 Solid Waste Reporting Log, Bills of Lading, Dump Slips for C&D Debris and Recycled

Materials

NLT the 10th Day of the Following Month, and at Project

Completion.

Environmental Office

7 Meter strainer cleaning and inspection report NLT 7 Days After

Project Completion.

COR

Local Narratives:

A.__ NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS

(a) IMPORTANT DELIVERY/QUALITY REQUIREMENTS

(1) ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE

REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE

ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

(2) ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE

DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO

COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION

OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND

DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

(3) PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS

IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING

PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

(4) PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR

CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms "we" and "you", the term "we" means the government of the United States of America, and the term "you" means the contractor.

(b) WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

"Watervliet Arsenal Information for Contractors" document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address:

http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available."

POC - CONTRACT SPECIALIST/BUYER: Dana Gleeson

TELEPHONE NUMBER: 518-266-4604

E-MAIL ADDRESS: dana.m.gleeson.civ@army.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: ___________

VENDOR POC: ___________

POC PHONE: ___________

E-MAIL ADDRESS: ___________

W911PT26QA0970001

mailto:dana.m.gleeson.civ@army.mil

UEID NUMBER: ___________

CAGE CODE: ___________

TAX ID NUMBER: ___________

VENDOR FAX NUMBER: ___________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you. If we experience difficulties with e-mail, it will be data faxed.

(c) AWCF BULK FUND __X__ DOES ____ DOES NOT APPLY

(d) POSTERS:

(1) Contracts for Material, Supplies, Articles and Equipment Exceeding $15,000/Service Contract Labor Standards. Orders subject to these Acts require contractors to post WH Publication 1313, "Employee Rights on Government Contracts".

(2) Construction Orders. Orders for construction require contractors to post WH Publication 1321, "Employee Rights under the Davis Bacon" and the Office of Federal Contract Compliance poster on "Equal Employment Opportunity is the Law."

(3) These posters can be accessed electronically at http://www.dol.gov .

(4) Hard copies of the posters will be made available upon request to the contracting officer.

(e) PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the "my invoice" system.

You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

(f) RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor's responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.

usapa.army.mil/pdffiles/r360_1.pdf

C._1_ Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-Warren (WVA))

Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cumulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as "applicable contractors").

It is the contractor's responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S /Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.

watervliet.tacom.list.watesafety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

- Total Case Incidence Rate (TCIR)

- the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

- Days Away, Restricted, and/or Transfer Case Incident Rate (DART)

- Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

- OSHA Form 300A

Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

H._1_ SERVICES/CONSTRUCTION REQUIREMENTS

(a) SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to "JOB".

(b) WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the "Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won't be considered an excusable delay to contract performance as defined in the contract clause "Default". Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

(c) CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE OF WATERVLIET

ARSENAL TECHNOLOGY

(1) The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

(2) Any knowledge gained, as a result of my being permitted on Watervliet Arsenal's premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company's domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

(3) Definitions:

(a) CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components. It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

(b) CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used and/or useful in the manufacturing of cannon.

(c) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(d) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(e) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(f) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

(e) JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2026 to be closed is January 9 , 2026.th

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won't be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

(f) CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S.

citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause "Default" contained in the contract.

Therefore, offerors should consider the above contingencies during offer preparation.

(h) CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

A. Electronic Contracting

Electronic Bids/Proposals/Commercial Offers Required in Response to this Solicitation (June 2020)

(a) All Army Contracting Command - solicitations will be publicized on the SAM.gov website (https://sam.gov/). Any additional attachments, including Technical Data Packages, when available electronically, will be separate attachments or links embedded in the solicitation.

(b) Bids/Proposals must be submitted in electronic media. When submitting your bid/proposal electronically, the bid/proposal and any supplemental information (such as spreadsheets, backup data, technical information), can be submitted using any of the following electronic formats:

(1) Microsoft* Office Products (Watervliet can read Microsoft* Office 2007 and lower); Word, Excel, or PowerPoint. Spreadsheets must be sent in a format that includes all formulate macro and format information. Print image is not acceptable.

(2) Files in Adobe PDF (Portable Document Format). Scanners should be set to 300 dots per inch.

(3) Files in HTML (Hypertext Markup Language). HTML documents must not contain active links to live Internet sites or pages. All linked information must be contained within your electronic bid/offer and be accessible offline.

(4) Other electronic formats are not acceptable.

(c) Please select only one medium by which to transmit each bid/proposal.

(d) Timely receipt of offers/proposals:

(1) Your attention is called to the solicitation closing date and time on the solicitation is local time for the Army Contracting Command - Warren (WVA). Lateness rules for electronic submissions for bids are outlined in FAR 52.214-7, "Late Submissions, Modifications, and Withdrawal of Bids," for proposals in FAR 52.215-1, "Instructions to Offerors--Competitive Acquisition" or FAR 52.212-1, "Instructions to Offerors-Commercial Items." Pay particular attention to the applicable clause as it relates to the timing of submissions.

W911PT26QA0970001

https://sam.gov/)

(2) NOTE: There is no "expected" or "target" length of time for proposal submission; size and content may be factors, therefore offerors are strongly cautioned to submit their proposals allowing adequate time for submission.

(3) Solicitations may remain posted on the SAM.gov website after the solicitation closes. Even though the system may allow you to submit a proposal after the closing date/time, your proposal will be considered late and may not be considered for award.

(e) Security Note: If you choose to password-protect access to your bid/offer, you must provide the password to Watervliet Arsenal at least ten days prior to the opening/closing date. Contact the buyer identified in Clause 52.0000-4200, "Watervliet Arsenal Information/Requirements".

Passwords used only for the purpose of write protecting files need not be provided.

(f) Electronic bids/proposals must include, as minimum:

(1) E-mailed bids/proposals must include a signed SF 33 cover sheet, SF 1449 or SF 1442 (whichever is applicable) that can be scanned. If scanned, attach it to your e-mail offer (or first e-mail message if you are sending multiple e-mails due to length).

(2) All applicable fill-in provisions. For solicitations issued on an SF 33 or SF 1442, this would include Sections A, B, F, and K. For solicitations issued on an SF 1449, you must review the solicitation to ascertain where all of the required fill-ins are located since commercial acquisitions do not have designated sections.

(3) A statement of agreement to all the terms, conditions, and provisions of the solicitation.

(4) Any other information required by the solicitation.

(g) Please see FAR 14.406 for a description of the steps the Government shall take with regard to unreadable electronic bids received via the media described in paragraphs (b) above. See FAR 15.207(c) for a description of steps the government shall take with regard to unreadable proposals.

(h) Bidders/Offerors shall make every effort to ensure that their bid/proposal is virus-free. Bids /proposals (or portions thereof) submitted which DO reflect the presence of a virus, or which are otherwise rendered unreadable by damage in electronic transit, shall be treated as "unreadable" per paragraph (h) above. Use of any formats other than those listed above may result in the file being quarantined and will be considered by Watervliet Arsenal to be "unreadable" files.

Note (Macros): The virus scanning software used by our e-mail systems cannot always distinguish a macro from a virus. Therefore, sending a macro embedded in an email message or an email attachment may cause the email bid/offer to be quarantined. In that event paragraph (g) above applies.

*Registered trademark

C. REQUEST FOR QUOTE RESPONSES

ALL RESPONSES MUST BE ELECTRONIC. YOU MUST SUBMIT YOUR QUOTE RESPONSES

USING THE FOLLOWING METHODS:

(a) Email to: Contract Specialist: dana.m.gleeson.civ@army.mil

(b) Request for Quotes must be filled out completely and sent in its entirety to be considered responsive.

To:

Local Narratives:

A.__ NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS

(a) IMPORTANT DELIVERY/QUALITY REQUIREMENTS

(1) ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE

REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE

ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

(2) ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE

DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO

COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION

OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND

DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

W911PT26QA0970001

(3) PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS

IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING

PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

(4) PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR

CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms "we" and "you", the term "we" means the government of the United States of America, and the term "you" means the contractor.

(b) WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

"Watervliet Arsenal Information for Contractors" document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address:

http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available."

POC - CONTRACT SPECIALIST/BUYER: Dana Gleeson

TELEPHONE NUMBER: 518-266-4604

E-MAIL ADDRESS: dana.m.gleeson.civ@army.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: ___________

VENDOR POC: ___________

POC PHONE: ___________

E-MAIL ADDRESS: ___________

UEID NUMBER: ___________

CAGE CODE: ___________

TAX ID NUMBER: ___________

W911PT26QA0970001

VENDOR FAX NUMBER: ___________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you. If we experience difficulties with e-mail, it will be data faxed.

(c) AWCF BULK FUND __X__ DOES ____ DOES NOT APPLY

(d) POSTERS:

(1) Contracts for Material, Supplies, Articles and Equipment Exceeding $15,000/Service Contract Labor Standards. Orders subject to these Acts require contractors to post WH Publication 1313, "Employee Rights on Government Contracts".

(2) Construction Orders. Orders for construction require contractors to post WH Publication 1321, "Employee Rights under the Davis Bacon" and the Office of Federal Contract Compliance poster on "Equal Employment Opportunity is the Law."

(3) These posters can be accessed electronically at http://www.dol.gov .

(4) Hard copies of the posters will be made available upon request to the contracting officer.

(e) PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the "my invoice" system.

You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

(f) RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor's responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.

usapa.army.mil/pdffiles/r360_1.pdf

C._1_ Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-Warren (WVA))

Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cumulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as "applicable contractors").

It is the contractor's responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S /Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.

watervliet.tacom.list.watesafety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

- Total Case Incidence Rate (TCIR)

- the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

- Days Away, Restricted, and/or Transfer Case Incident Rate (DART)

- Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

- OSHA Form 300A

Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

H._1_ SERVICES/CONSTRUCTION REQUIREMENTS

(a) SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to "JOB".

(b) WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the "Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won't be considered an excusable delay to contract performance as defined in the contract clause "Default". Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

(c) CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE OF WATERVLIET

ARSENAL TECHNOLOGY

(1) The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

(2) Any knowledge gained, as a result of my being permitted on Watervliet Arsenal's premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company's domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

(3) Definitions:

(a) CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components. It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

(b) CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used and/or useful in the manufacturing of cannon.

(c) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(d) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(e) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(f) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

(e) JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2026 to be closed is January 9 , 2026.th

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won't be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

(f) CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S.

citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause "Default" contained in the contract.

Therefore, offerors should consider the above contingencies during offer preparation.

(h) CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

A. Electronic Contracting

Electronic Bids/Proposals/Commercial Offers Required in Response to this Solicitation (June 2020)

(a) All Army Contracting Command - solicitations will be publicized on the SAM.gov website (https://sam.gov/). Any additional attachments, including Technical Data Packages, when available electronically, will be separate attachments or links embedded in the solicitation.

(b) Bids/Proposals must be submitted in electronic media. When submitting your bid/proposal electronically, the bid/proposal and any supplemental information (such as spreadsheets, backup data, technical information), can be submitted using any of the following electronic formats:

(1) Microsoft* Office Products (Watervliet can read Microsoft* Office 2007 and lower); Word, Excel, or PowerPoint. Spreadsheets must be sent in a format that includes all formulate macro and format information. Print image is not acceptable.

(2) Files in Adobe PDF (Portable Document Format). Scanners should be set to 300 dots per inch.

(3) Files in HTML (Hypertext Markup Language). HTML documents must not contain active links to live Internet sites or pages. All linked information must be contained within your electronic bid/offer and be accessible offline.

(4) Other electronic formats are not acceptable.

(c) Please select only one medium by which to transmit each bid/proposal.

(d) Timely receipt of offers/proposals:

(1) Your attention is called to the solicitation closing date and time on the solicitation is local time for the Army Contracting Command - Warren (WVA). Lateness rules for electronic submissions for bids are outlined in FAR 52.214-7, "Late Submissions, Modifications, and Withdrawal of Bids," for proposals in FAR 52.215-1, "Instructions to Offerors--Competitive Acquisition" or FAR 52.212-1, "Instructions to Offerors-Commercial Items." Pay particular attention to the applicable clause as it relates to the timing of submissions.

(2) NOTE: There is no "expected" or "target" length of time for proposal submission; size and content may be factors, therefore offerors are strongly cautioned to submit their proposals allowing adequate time for submission.

(3) Solicitations may remain posted on the SAM.gov website after the solicitation closes. Even though the system may allow you to submit a proposal after the closing date/time, your proposal will be considered late and may not be considered for award.

W911PT26QA0970001

(e) Security Note: If you choose to password-protect access to your bid/offer, you must provide the password to…