W911PT26QA022.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

calls)

Solicitation/Contract Form Continuation

FIBERGLASS ROVINGInstrument Name:

REQUEST FOR QUOTE RESPONSES

ALL RESPONSES MUST BE ELECTRONIC. YOU MUST SUBMIT YOUR QUOTE

RESPONSES USING THE FOLLOWING METHODS:

(a) Email to: giuseppe.tropiano.civ@army.mil

(b) Request for Quotes must be filled out completely and sent in its entirety to be considered responsive.

ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES

a. The contractor and all associated subcontractors' employees shall comply with applicable installation, facility, and area commander installation and facility access and local security policies and procedures (provided by the Government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the installation Provost Marshal Office, Director of Emergency Services, or Security Office. The contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9 "Personal Identity Verification of Contractor Personnel") as directed by DoD, HQDA, and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

b. For contractors requiring Common Access Card (CAC). Before CAC issuance, the contractor employee requires, at a minimum, a favorably adjudicated National Agency Check with Inquiries (NACI) or an equivalent or higher investigation in accordance with Army Directive 2014-05, The contractor employee will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DoD facility and access, via logon, to DoD networks on-site or remotely; (2) Remote access, via logon, to a DoD network using DoD-approved remote access procedures; or (3) Physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of six (6) months or more. At the discretion of the sponsoring activity, an initial CAC may be issued on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personal Management.

c. For contractors that do not require CAC, but require access to a DoD facility or installation.

Contractor and all associated sub-contractors employees shall comply with adjudication standards, and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190- 13), applicable installation, facility and area commander installation/facility access and local security policies and procedures elsewhere in Section C titled as paragraph - Access to the Detroit Arsenal; Identifying Contractor Employees; Non-disclosure Statement; for OCONUS locations, refer to the Status of Forces Agreement and other theater regulations.

W911PT26QA022

NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS

(a) IMPORTANT DELIVERY/QUALITY REQUIREMENTS:

(1) ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE

REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE

ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

(2) ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE

DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO

COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN

TERMINATION OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT

ELECTS TO EXTEND DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid.

They are not acceptable excuses for failing to meet the delivery after award).

(3) PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST

AS IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-

CONFORMING PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS

TO THE ARSENAL.

(4) PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR

CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms "we" and "you", the term "we" means the government of the United States of America, and the term "you" means the contractor.

(b) WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

"Watervliet Arsenal Information for Contractors" document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address: https://www.wva.army.mil/docs/librariesprovider6/default-document-library/waic.pdf?

sfvrsn=8b90f522_0

POC - CONTRACT SPECIALIST/BUYER: Giuseppe Tropiano

TELEPHONE NUMBER: 518-266-5094

E-MAIL ADDRESS: giuseppe.tropiano.civ@army.mil

W911PT26QA022

https://www.wva.army.mil/docs/librariesprovider6/default-document-library/waic.pdf?sfvrsn=8b90f522_0 https://www.wva.army.mil/docs/librariesprovider6/default-document-library/waic.pdf?sfvrsn=8b90f522_0

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: _________________________

VENDOR POC: __________________________

POC PHONE: ____________________________

E-MAIL ADDRESS (see note below): __________________________

DUNS NUMBER _______________________

CAGE CODE (if known) __________________

TAX ID NUMBER ________________________

VENDOR FAX NUMBER ________________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you. If we experience difficulties with e-mail, it will be data faxed.

(c) AWCF BULK FUND __ DOES _X___ DOES NOT APPLY

(d) POSTERS:

(1) Contracts for Material, Supplies, Articles and Equipment Exceeding $15,000/Service Contract Labor Standards. Orders subject to these Acts require contractors to post WH Publication 1313, "Employee Rights on Government Contracts".

(2) Construction Orders. Orders for construction require contractors to post WH Publication 1321, "Employee Rights under the Davis Bacon" and the Office of Federal Contract Compliance poster on "Equal Employment Opportunity is the Law."

(3) These posters can be accessed electronically at . http://www.dol.gov

(4) Hard copies of the posters will be made available upon request to the contracting officer.

(e) PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at using the "my invoice" https://wawf.eb.mil/ system. You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

(f) RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor's responsibility to be familiar with, and comply with the requirements of Chapter 7, page 22, paragraph 7-1, of AR 360-1 may be found at https://armypubs.army.mil/epubs/DR_pubs/DR_a/ARN30105-AR_360-1-000-WEB-1.pdf

DELIVERY INFORMATION

(a) Effective 1 March, 2020, all commercial carriers must request an appointment for delivery to Watervliet Arsenal through the Carrier Appointment System (CAS). Carriers can register for CAS at https://eta-teams.transport.mil/ In the event that a carrier is either unable to register for CAS, or if CAS is down, carriers must call the transportation desk at 518-266-5858 to schedule an appointment

Note(s):

i. Late/early arrivals may be rescheduled to the next available appointment date.

ii. This will not apply to small package carriers such as FEDEX, UPS, or DHL.

(b) NOTICE: NORMAL DELIVERY HOURS FOR RECEIPT OF SUPPLIES AT WATERVLIET

ARSENAL ARE AS FOLLOWS:

Monday through Thursday Business Hours: 6:30 A.M. EST to 3:30 P.M. EST

Friday Business Hours: Every other Friday from 6:30 A.M. EST to 2:00 P.M. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2026 to be closed is January 9, 2026.

BASED ON THE ABOVE, CONTRACTORS SHOULD CALL THE CONTRACT/PURCHASE

ORDER ADMINISTRATOR IN ADVANCE IF DELIVERY IS SCHEDULED FOR A FRIDAY TO

FIND OUT IF THE ARSENAL WILL BE OPEN FOR BUSINESS.

Also, when a federal holiday is normally observed on a Friday, the arsenal may be closed on the preceding Thursday. In these instances, please contact the contract/purchase order administrator in advance of delivery if Thursday delivery is anticipated to determine if the arsenal will be open for business.

THE ABOVE INFORMATION SHOULD BE NOTED WHEN SCHEDULING DELIVERIES AS

WATERVLIET ARSENAL WILL NOT BE LIABLE FOR ANY STORAGE, DEMURRAGE OR

SHIPPER LABOR COSTS INCURRED AS A RESULT OF CONTRACTOR ATTEMPTED

DELIVERIES ARRIVING DURING NON-BUSINESS HOURS.

(b) ITEM DESCRIPTION:

The material delivered hereon must be tagged or otherwise identified by placing the purchase order/contract number on the packing slip or it will be returned at the contractor's expense. If more than one item is involved, material must be segregated by item and must be tagged or otherwise identified by item number. National stock number, when applicable, must be shown on all vendor's documents, such as Bill of Lading, Notice of Shipment, delivery or packing slip, etc.

HQ-AMC LEVEL PROTEST PROCEDURES

Complete AMC Protest Procedures can be found at: http://www.amc.army.mil/Connect/Legal- Resources/

An agency protest may be filed with either the contracting officer or to HQAMC but not both following the procedures listed on the website above.

Disclosure of Unit Price Information

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices of the awardee in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such release prior to submission of initial proposals.

PROMPT PAYMENT NOTICE TO FAR 52.212-4

In accordance with the prompt payment regulations at 5 CFR 1315 referenced in FAR 52.212-4 Contract Terms and Conditions - Commercial Items, specifically 5 CFR 1315-4(b)(1)(B), Government acceptance shall be deemed to have occurred constructively on the 30th day after the contractor delivered the supplies or performed the services.

EVALUATION--COMMERCIAL ITEMS

(a) We will award a contract to the offeror that:

1. submits the lowest evaluated bid or offer, and

2. submits a bid or proposal that meets all the material requirements of this solicitation, and

3. meets all the responsibility criteria at FAR 9.104

(b) To make sure that you meet the responsibility criteria at FAR 9.104 we may:

1. arrange a visit to your plant and perform a preaward survey;

2. ask you to provide financial, technical, production, or managerial background information.

(c) Options (If requested in solicitation/schedule). We will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. We may determine that an offer is unacceptable if the option prices are significantly unbalanced.

Evaluation of options shall not obligate us to exercise the option(s).

(d) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, we may accept an offer (or part of an offer), regardless of whether there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

CRITICAL MILITARY TECHNOLOGY (APR 1988) ((ACC-WRN(WVA))

The documents, drawings (microfilms) listed herein contain critical military technology that is owned by the United States Government, Watervliet Arsenal. These documents, drawings (microfilm) are not to be used for any purpose other than the purpose for which they are furnished, nor shall they be distributed or reproduced for any purpose, nor any part of their contents revealed in any manner, to persons other than the individuals or organizations specified to receive it, or their employees, without written consent of the Watervliet Arsenal.

LIST OF DOCUMENTS/DRAWING NO.

# BL-11582988, Revision B

DISCLOSURE OF WATERVLIET ARSENAL TECHNOLOGY (APR 2005) (ACC-WRN(WVA))

In accordance with, Title 10 of the U.S. Code Section 4542, no Cannon Production Technology as defined herein, may be furnished to any foreign source or representative thereof. Therefore, solicitations and subsequent contracts for this requirement will be confined only to United States, Puerto Rico, and Canada which are considered part of the United States Industrial Base. Cannon Production Technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside the offeror's/contractor's firm and/or the United States of America (the latter prohibition includes, but is not limited to, disclosure to the offeror's/contractor's foreign subsidiaries, affiliates, etc.)

nor will such technology be used to manufacture cannon (as defined below) or other defense items being manufactured or developed at Watervliet Arsenal, in response to requests from anyone other than Watervliet Arsenal, without prior written approval of Watervliet Arsenal (WVA). The offeror/contractor is hereby notified that any breach by him/her of the above provision may legally be pursued by the Government as a breach of implied contract (with respect to an offeror) or breach in contract (with respect to the firm awarded the contract). The offeror/contractor is hereby also placed on written notice that any damages the Government chooses to pursue for such breach may include any consequential damages for which the offeror/contractor would be liable. In addition, injunctive relief may be pursued in the event of violation of the above provision. If prior approval of Watervliet Arsenal has been obtained, as required by the above provision, any subcontract is involved, the contractor shall insert the substance of this provision (that is, the first three full paragraphs above) in such subcontract.

Failure of the contractor to include this provision in any subcontract may be pursued by the Government as a breach of contract by the contractor whereby he/she may be liable for any damage, to include consequential damages, caused Watervliet Arsenal due to unauthorized release or use of the data by the subcontractor. Additionally, any drawings, specifications, or other technical data furnished with this solicitation need not be returned to the Watervliet Arsenal, but should be disposed of by the offeror, however care must be taken to assure disposal of the data is made in a manner which will comply with the terms of this provision.

Notice for AbilityOne Subcontracting Goal Credit

"Note: In accordance with Public Law 102-396, AbilityOne organizations will be afforded the maximum practical opportunity to participate as subcontractors and suppliers in the performance of this contract. As prescribed by 10 U.S.C. 2410d and Section 9077 of Public Law 102-396, and in accordance with DFARS 219.703, Eligibility requirements for participating in the program, offerors may receive credit towards the small business subcontracting goal for subcontracts placed with qualified nonprofit agencies participating in the AbilityOne program.

AbilityOne organizations are qualified nonprofit agencies for the blind and other severely disabled that are approved by the Committee for Purchase from People Who Are Blind or Severely Disabled under the Javits-Wagner-O'Day Act (41 U.S.C. 46-48).

For additional information on AbilityOne's program and products see http://www.abilityone.gov /index.html. For additional information on DoD activities in support of AbilityOne see http://www.

acq.osd.mil/dpap/cpic/cp/abilityone_program.html.

TECHNICAL DATA PACKAGE INFORMATION

The following "X"d item applies to this solicitation:

[ ] 1. There is no Technical Data Package (TDP) included with this solicitation.

[X] 2. The TDP for this solicitation resides within the System for Award Management (SAM) (https://SAM.gov) associated with this solicitation number:

-1-

To access the data through SAM:

a. Log on to the SAM web site: https://SAM.gov.

b. Search for the solicitation number.

c. Click on the attachment you would like to view.

d. If the attachment is restricted, request access to the document.

(1) TDPs that have an Export Control Warning Notice are subject to the Arms Export Control Act (Title 22, U.S.C., Sec 2751, et.seq.) or the Export Administration Act of 1979, as amended, Title 50, U.S.C, App. 2401 et. seq..

(2) Further dissemination must be in accordance with provisions of DoD Directive 5230.25. This also applies to distribution of the TDP to all SUBCONTRACTORS at every level.

(3) To obtain these TDPs, contractors must have a current DD 2345, Militarily Critical Technical Data Agreement on file with Defense Logistics Information Service (DLIS). To obtain certification, go to https://public.logisticsinformationservice.dla.mil/jcp/search.aspx

(4) Upon completion of the purposes for which Government Technical Data has been provided, the Contractor is required to destroy all documents, including all reproductions, duplications, or copies thereof as may have been further distributed by the Contractor. Destruction of this technical data shall be accomplished by: shredding, pulping, burning, or melting any physical copies of the TDP and/or deletion or removal of downloaded TDP files from computer drives and electronic devices, and any copies of those files.

e. If technical data is otherwise restricted, select "Request Explicit Access." This will generate an email to the Contract Specialist and Contracting Officer at Army Contract Command - Warren (DTA) with all the information needed to grant contractor access to restricted documents. SAM will automatically generate an email stating when the requesting contractor has permission to view or download TDP items.

f. If multiple individuals in the contractor's organization need access to the Technical Data Package (TDP) for a solicitation and an explicit access request is required, each individual MUST submit an explicit access request to be granted approval to view the

TDP. Those same individuals MUST be registered in SAM. Any individuals no longer with the company should be deleted. Questions related to registration in SAM should be directed to https://www.sam.gov/ The SAM helpdesk phone number is (866)

606-8220. Vendors are responsible for placing correct information in SAM.

g. It is strongly suggested that contractors submit the explicit access request and provide the buyer with the completed "Use and Non-Disclosure Agreement" at the same time if the solicitation requires both to gain access to view the TDP.

*** END OF NARRATIVE 1 ***

Continuation of Supplies or Services and Prices/Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

6,600 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F53080027

WBS: EH26UWV441EHM71

0002 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

1,584 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256

CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F5308002I

WBS: EH26UWV353EHM71

0003 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

740 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F5308002K

WBS: EH25UWV370EHM71

0004 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

951 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F5308002L

WBS: EH25UWV371EHM71

0005 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

528 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F53080020

WBS: EH25UWV389EHM71

0006 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72

442 Pound

Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F53080022

WBS: EH25UWV391EHM71

0007 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

4,158 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F534300RV

WBS: EH26UWV441EHM71

0008 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

792 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F534300RY

WBS: EH26UWV353EHM71

0009 FIBERGLASS, ROVING

Manufacturer's CAGE: 6XX72 Manufacturer's Part Number: 11582988 Pricing Arrangement: Firm Fixed Price

528 Pound

Additional Descriptive Data:

FIBERGLASS ROVING, PER DRAWING NUMBER 11582988, REVISION B,

SINGLE-END, E-TYPE FIBERGLASS ROVING +/-7%; FIRE RETARDANT EPOXY

RESIN; RESIN CONTENT 36% +/-3%;. Requires a CDRL #5. FOR 120MM M256 CANNON, To include contract data prepared and delivered in accordance with

CONTRACT DATA REQUIREMENTS LIST (DD FORM 1423)- EXHIBIT A.

INSPECTION REQUIRED.

W16H1F534300S1

WBS: EH26UWV390EHM71

Continuation of Description

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F53080027

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F5308002I

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F5308002K

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F5308002L

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F53080020

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F53080022

Product Service Code : 3455

North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F534300RV

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F534300RY

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP) : W16H1F534300S1

Product Service Code : 3455 North American Industry Classification System (NAICS) : 325991 Bill to Party: W16H1F

Continuation of Packaging and Marking

Continuation of Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

0001 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0002 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0003 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0004 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0005 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0006 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0007 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0008 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

0009 Inspection and Acceptance Location

Both Destination Instructions: INSPECT/ACCEPT

DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050

WATERVLIET, NY 12189-4050

UNITED STATES

JJ ESMELLARIN

Email: jan.j.esmellarin.civ@army.mil Telephone: 518-266-4656

Continuation of Deliveries or Performance

0001 Partial Delivery Schedule Delivery On Or Before Delivery Date 30 Apr 2026 3,300 Pound Partial Delivery Schedule Delivery On Or Before Delivery Date 15 Aug 2026 3,300 Pound

6,600 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0002 Delivery Schedule Delivery On Or Before Delivery Date 15 Apr 2026

1,584 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0003 Delivery Schedule Delivery On Or Before Delivery Date 15 Aug 2026

740 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0004 Delivery Schedule Delivery On Or Before Delivery Date 15 Aug 2026

951 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F

CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0005 Delivery Schedule Delivery On Or Before Delivery Date 15 Apr 2026

528 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0006 Delivery Schedule Delivery On Or Before Delivery Date 15 Apr 2026

442 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0007 Delivery Schedule Delivery On Or Before Delivery Date 31 Dec 2026

4,158 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0008 Delivery Schedule Delivery On Or Before Delivery Date 31 Dec 2026

792 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0009 Delivery Schedule Delivery On Or Before Delivery Date 31 Dec 2026

528 PoundQuantity

Address and POC Ship To DoDAAC: W16H1F CountryCode: USA

W0K9 OSC WVA-STOCK RECORD ACCT

1 BUFFINGTON ST BLDG 35, WATERVLIET NY 12189-4050 WATERVLIET, NY

12189-4050 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

Continuation of Accounting and Appropriation Data

Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-3 Gratuities. 1984-04

52.203-6 Restrictions on Subcontractor Sales to the Government. (Alternate I)

2020-06 Alternate I

2021-11

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards.

2020-06

52.204-13 System for Award Management Maintenance.

2018-10

52.204-18 Commercial and Government Entity Code Maintenance.

2020-08

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

2021-11

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

2025-01

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters.

2018-10

52.212-4 Contract Terms and Conditions- Commercial Products and Commercial Services.

2023-11

52.219-6 Notice of Total Small Business Set-Aside. 2020-11

52.222-19 Child Labor-Cooperation with Authorities and Remedies.

2025-01

52.222-37 Employment Reports on Veterans. 2020-06

52.222-40 Notification of Employee Rights Under the National Labor Relations Act.

2010-12

52.222-50 Combating Trafficking in Persons. 2021-11

52.225-13 Restrictions on Certain Foreign Purchases. 2021-02

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.232-33 Payment by Electronic Funds Transfer- System for Award Management.

2018-10

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-3 Protest after Award. 1996-08

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.204-7022 Expediting Contract Closeout. 2021-05

252.223-7008 Prohibition of Hexavalent Chromium. 2023-01

252.225-7001 Buy American and Balance of Payments Program.

2024-02

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

2023-01

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

2018-12

252.232-7010 Levies on Contract Payments. 2006-12

252.243-7002 Requests for Equitable Adjustment. 2022-12

252.244-7000 Subcontracts for Commercial Products or Commercial Services.

2023-11

252.247-7023 Transportation of Supplies by Sea. 2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017)

(a) Definitions. As used in this clause-

Internal confidentiality agreement or statement means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.

Subcontract means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.

(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.

g., agency Office of the Inspector General).

(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.

(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause.

(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

(End of clause)

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

2023-12

Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities. (Dec 2023)

(a) Definitions. As used in this clause-

Kaspersky Lab covered article means any hardware, software, or service that-

(1) Is developed or provided by a Kaspersky Lab covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a Kaspersky Lab covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a Kaspersky Lab covered entity.

Kaspersky Lab covered entity means-

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab, including any change in name, e.g., "Kaspersky";

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab;

or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any Kaspersky Lab covered article. The Contractor is prohibited from-

(1) Providing any Kaspersky Lab covered article that the Government will use on or after October 1, 2018; and

(2) Using any Kaspersky Lab covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractoridentifies a Kaspersky Lab covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 3 business days from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number);

item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a Kaspersky Lab covered article, any reasons that led to the use or submission of the Kaspersky Lab covered article, and any additional efforts that will be incorporated to prevent future use or submission of Kaspersky Lab covered articles.

(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

52.204-27 Prohibition on a ByteDance Covered Application.

2023-06

Prohibition on a ByteDance Covered Application (Jun 2023)

(a) Definitions. As used in this clause-

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)-

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub.

L. 117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23- 13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

52.219-8 Utilization of Small Business Concerns. 2025-01

Utilization of Small Business Concerns (Jan 2025)

(a) Definitions. As used in this contract-

HUBZone small business concern means a small business concern that meets the requirements described in 13 CFR 126.200, certified by the Small Business Administration (SBA) and designated by SBA as a HUBZone small business concern in the Dynamic Small Business Search (DSBS) and SAM.

Service-disabled veteran-owned small business (SDVOSB) concern means a small business concern-

(1)

(i) Not less than 51 percent of which is owned and controlled by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran; or

(2) A small business concern eligible under the SDVOSB Program in accordance with 13 CFR part 128 (see subpart 19.14).

(3) Service-disabled veteran, as used in this definition, means a veteran, as defined in 38 U.

S.C.101(2), with a disability that is service-connected, as defined in 38 U.S.C.101(16), and who is registered in the Beneficiary Identification and Records Locator Subsystem, or successor system that is maintained by the Department of Veterans Affairs' Veterans Benefits Administration, as a service-disabled veteran.

Service-disabled veteran-owned small business (SDVOSB) concern eligible under the SDVOSB Program means an SDVOSB concern that-

(1) Effective January 1, 2024, is designated in the System for Award Management (SAM) as certified by the Small Business Administration (SBA) in accordance with 13 CFR 128.300; or

(2) Has represented that it is an SDVOSB concern in SAM and submitted a complete application for certification to SBA on or before December 31, 2023.

Service-disabled veteran-owned small business (SDVOSB) Program means a program that authorizes contracting officers to limit competition, including award on a sole-source basis, to SDVOSB concerns eligible under the SDVOSB Program.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation and qualified as a small business under the criteria and size standards in 13 CFR part 121, including the size standard that corresponds to the NAICS code assigned to the contrac t or subcontract.

Small disadvantaged business concern, consistent with 13 CFR 124.1001, means a small business concern under the size standard applicable to the acquisition, that-

(1) Is at least 51 percent of which is owned and controlled (as defined at 13 CFR 124.105) by-

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual…