W911PT-19-Q-0011-01.pdf

W16H1F824700IM

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The reason for this amendment is to incorporate Local Clauses CS4002 - Request for Quote and MS4003 - Method of Evaluation of Options.

1. CONTRACT ID CODE PAGE OF PAGES

1 8

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W911PT19Q0011

X 9B. DATED (SEE ITEM 11)

28-Dec-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

U0001

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

28-Dec-2018

CODE

ARMY CONTRACTING COMMAND-WARREN (WVA)

ATTN: CCTA-HDW/BLDG 10

1 BUFFINGTON STREET

WATERVLIET NY 12189-4000

W911PT 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911PT19Q0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been modified:

LOCAL NARRATIVES

A.__ NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS

(a) IMPORTANT DELIVERY/QUALITY REQUIREMENTS:

(1) ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE

REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE

ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

(2) ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE

DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO

COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION

OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND

DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

(3) PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS

IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING

PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

(4) PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR

CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms “we” and “you”, the term “we” means the government of the United States of America, and the term “you” means the contractor.

(b) WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

“Watervliet Arsenal Information for Contractors” document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address:

http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available.”

POC - CONTRACT SPECIALIST/BUYER: Maria DeCrescenzo

TELEPHONE NUMBER: 518-266-4641

E-MAIL ADDRESS: maria.d.decrescenzo.civ@mail.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME:

VENDOR POC:

POC PHONE:

E-MAIL ADDRESS (see note below):

DUNS NUMBER

CAGE CODE (if known)

TAX ID NUMBER

VENDOR FAX NUMBER

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you.

If we experience difficulties with e-mail, it will be data faxed.

(c) AWCF BULK FUND _X__ DOES ____ DOES NOT APPLY

(d) POSTERS:

(1) Contracts for Material, Supplies, Articles and Equipment Exceeding $15,000/Service Contract Labor Standards. Orders subject to these Acts require contractors to post WH Publication 1313, “Employee Rights on Government Contracts”.

(2) Construction Orders. Orders for construction require contractors to post WH Publication 1321, “Employee Rights under the Davis Bacon” and the Office of Federal Contract Compliance poster on “Equal Employment Opportunity is the Law.”

(3) These posters can be accessed electronically at http://www.dol.gov .

(4) Hard copies of the posters will be made available upon request to the contracting officer.

(e) PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the “my invoice” system. You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

(f) RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor’s responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.usapa.army.mil/pdffiles/r360_1.pdf

C.__ REQUEST FOR QUOTE RESPONSES

ALL RESPONSES MUST BE ELECTRONIC. YOU MAY SUBMIT YOUR QUOTE RESPONSES USING ONE

OF THE FOLLOWING METHODS:

(a) Email to: (-1-)

(b) Federal Business Opportunities - FedBizOpps (FBO)

Requirements for the online FBO bid submission:

(1) Vendors must login to the FBO System to be able to submit electronic responses for opportunities.

(2) Vendors must also registered in the System for Award Management (SAM) at www.sam.gov (a Federal Government owned and operated free web site) and have a CAGE Code and CCR Marketing Partner Identification Number (MPIN).

(3) Once logged into the FBO System, vendors will be asked to enter basic information and then will be directed to upload one or more files containing the offer and any additional information as outlined in the solicitation.

(4) FBO will send an email to the email address on file for the user confirming the electronic submission.

(5) For additional information on submitting electronic bid responses via the Federal Business Opportunities System reference the FBO Vendor Guide – Section 4.3.1 Submitting an Electronic Response Topic (https://www.fbo.gov/downloads/FBO_Vendor_Guide.pdf).

(c) Request for Quotes must be filled out completely and sent in its entirety to be considered responsive.

C.__ Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-Warren (WVA)) Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cumulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as “applicable contractors”).

It is the contractor’s responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S/Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.watervliet.tacom.list.wate-safety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

- Total Case Incidence Rate (TCIR) - the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

- Days Away, Restricted, and/or Transfer Case Incident Rate (DART) - Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

- OSHA Form 300A

Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

C.__ CONTRACTOR MANPOWER REPORTING (CMR)

(a) The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract via secure data collection site. The contractor is required to completely fill in all required data fields in the format using the following web address: https://www.ecmra.mil/. The required information includes the following:

(1) Contracting Office, Contracting Officer, Contracting Officer's Technical Representative;

(2) Contract number, including task and delivery order number;

(3) Beginning and ending dates covered by reporting period;

(4) Contractor name, address, phone number, e-mail address, identity of contractor employee entering data;

(5) Direct labor hours (including sub-contractors);

(6) Direct labor dollars paid this reporting period (including sub-contractors);

(7) Total payments (including sub-contractors);

(8) Predominant Federal Service Code (FSC) reflecting services provided by contractor (and separate predominant FSC for each sub-contractor if different);

(9) Data collection cost;

(10) Organizational title associated with the Unit Identification Code (UIC) for the Army Requiring Activity (the Army Requiring Activity is responsible for providing the contractor with its UIC for the purposes of reporting this information);

(11) Locations where contractor and sub-contractors perform the work (specified by zip code in the United States and nearest city, country, when in an overseas location, using standardized nomenclature provided on website);

(12) Presence of deployment or contingency contract language; and

(13) Number of contractor and sub-contractor employees deployed in theater this reporting period (by country).

(b) Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year, beginning with 2013. Contractors may direct questions to the help desk at: https://armycmra.dmdc.osd.mil/ and clicking on the “Send an Email” link which is located under the Help Resources ribbon on the right hand side of the login page.

H.__ SERVICES/CONSTRUCTION REQUIREMENTS

(a) SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to

"JOB".

(b) WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the “Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won’t be considered an excusable delay to contract performance as defined in the contract clause “Default”. Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

(d) CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE

OF WATERVLIET ARSENAL TECHNOLOGY

(1) The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

(2) Any knowledge gained, as a result of my being permitted on Watervliet Arsenal’s premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company’s domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

(3) Definitions:

(a) CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components.

It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

(b) CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used and/or useful in the manufacturing of cannon.

(c) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(d) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(e) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(f) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

(e) JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2017 to be closed is January 6, 2017.

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won’t be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

(f) CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S. citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause “Default” contained in the contract. Therefore, offerors should consider the above contingencies during offer preparation.

(h) CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

M.__ EVALUATION OF OPTION TO EXTEND SERVICES UNDER FAR 52.217-8

As part of the price evaluation, the Government will evaluate the Option to Extend Services under FAR Clause 52.217-8 by adding one-half of the offeror’s final option period price to the offeror’s total price. Thus, the offeror’s total price for the purpose of the evaluation will include the base period, total of options, and one-half of the last year option to determine the price basis. Offerors are required only to price the base and each option. Offerors shall not submit a price for the potential one-half year extension of services period.

(End of Summary of Changes)