W911PT-15-R-0015.docx

W911PT-15-R-0015

Section SF 30 - BLOCK 14 CONTINUATION PAGE

CLAUSES INCORPORATED BY REFERENCE

Section A - Solicitation/Contract Form

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4950 Disclosure of Unit Price Information (Jun 2004) (ACC-WRN (WVA))

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices of the awardee in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such release prior to submission of initial proposals.

END OF CLAUSE

52.0000-4960 Contractor’s Representative (Jul 2007) (ACC-WRN (WVA))

Contractor’s Representative: A competent foreman or superintendent, with authority to act on behalf of the Contractor, must be present at the job site at all times that work is going on. The name of the foreman or superintendent will be furnished in writing to the Contracting Officer. If the foreman or superintendent is changed during the life of the contract, the Contracting Officer shall be notified accordingly.

(End of Provision)

Section B - Supplies or Services and Prices

PAVING AND CRACK FILLING

FFP

To provide all labor, material, parts and equipment to RESURFACE ~175,000 SQUARE FEET OF ROADWAYS AND PARKING LOTS. All work will be performed in accordance with Statement of Work under project #4PW119 which is attached and incorporated.

Wage Determination General Decision Number: NY2 07/03/2015 applies and is incorporated.

Magnitude of this Project with Options is Between $500,000 and $1,000,000.

Period of Performance is 45 calendar days from receipt of Notice to Proceed.

Contracting Officer Representative is Mr. Dan Clough.

100% Payment and Performance Bonds are required.

MID:43690M7PAVE

AAS# 151810056

FOB: Destination

NSN: AASSVC518903TG

MILSTRIP: W16H1F518903TG

PURCHASE REQUEST NUMBER: W16H1F518903TG

NET AMT

FFP

The contractor shall include in the price a quote to resurface approximately 15,220 SF of drive way around Quarters 3 and 4. Paving shall be per the original scope of work.

NY 102 Wage Determination applies to this line item only and is incorporated.

This option will be awarded this calendar year if funds are available.

FOB: Destination

NET AMT

FFP

The contractor shall include in the price a quote to resurface approximately 9,209 SF of drive way to the east of Quarters 6. Paving shall be per the original scope of work.

NY 102 Wage Determination applies to this line item only and is incorporated.

This option will be awarded this calendar year if funds are available.

NET AMT

FFP

The Government requests a 1 Square Foot price for additional paving. This option shall be for a total quantity of not to exceed 50,000 square feet in industrial areas.

The Government reserves the right to scale up or down the square footage based on the square foot unit price received and funds available for this option.

Pricing shall be for this calendar year only (CY 2015)

NET AMT

52.0000-4200 NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS (Dec 2014) (ACC-WRN(WVA)):

IMPORTANT DELIVERY/QUALITY REQUIREMENTS:

ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE REQUEST FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE ENSURE THAT YOU CAN MEET THE DELIVERY SCHEDULE.

ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE DELIVERY REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO COMPLY WITH THE CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION OF THE ORDER OR REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND DELIVERY. (NOTE: Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR CONSIDERATION IN MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms “we” and “you”, the term “we” means the government of the United States of America, and the term “you” means the contractor.

WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

“Watervliet Arsenal Information for Contractors” document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address: http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available.”

POC - CONTRACT SPECIALIST/BUYER: Matt Pember

TELEPHONE NUMBER: 518-266-5631

E-MAIL ADDRESS: matthew.b.pember.civ@mail.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: _________________________

VENDOR POC: __________________________

POC PHONE: ____________________________

E-MAIL ADDRESS (see note below): __________________________

DUNS NUMBER _______________________

CAGE CODE (if known) __________________

TAX ID NUMBER ________________________

VENDOR FAX NUMBER ________________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you. If we experience difficulties with e-mail, it will be datafaxed.

AWCF BULK FUND ____ DOES _x_ DOES NOT APPLY

POSTERS:

Walsh-Healey Act/Service Contract Act. Orders subject to these Acts require contractors to post WH Publication 1313, “Employee Rights on Government Contracts”.

Construction Orders. Orders for construction require contractors to post WH Publication 1321, “Employee Rights under the Davis Bacon Act” and the Office of Federal Contract Compliance poster on “Equal Employment Opportunity is the Law.”

These posters can be accessed electronically at http://www.dol.gov .

Hard copies of the posters will be made available upon request to the contracting officer.

PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the “my invoice” system. You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor’s responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.apd.army.mil/pdffiles/r360_1.pdf

(END OF CLAUSE)

52.0000-4201 SERVICES/CONSTRUCTION REQUIREMENTS (Dec 2014) (ACC-WRN(WVA)):

SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to "JOB".

WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the “Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won’t be considered an excusable delay to contract performance as defined in the contract clause “Default”. Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE

OF WATERVLIET ARSENAL TECHNOLOGY

1. The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

2. Any knowledge gained, as a result of my being permitted on Watervliet Arsenal’s premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company’s domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

3. Definitions:

a. CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components. It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

b. CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used an/or useful in the manufacturing of cannon.

(a) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(b) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(c) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(d) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2015 to be closed is January 9, 2015.

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won’t be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S. citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause “Default” contained in the contract. Therefore, offerors should consider the above contingencies during offer preparation.

CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

(END OF NOTICE)

Section C - Descriptions and Specifications

52.0000-4970 Scope of Work/Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-WRN (WVA)) Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cummulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as “applicable contractors”).

It is the contractor’s responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S/Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.watervliet.tacom.list.wate-safety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

· Total Case Incidence Rate (TCIR) - the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

· Days Away, Restricted, and/or Transfer Case Incident Rate (DART) - Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

· OSHA Form 300A Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

(End of Scope of Work)

Section E - Inspection and Acceptance

Section G - Contract Administration Data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Payment Invoice

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

N/A

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

N/A

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

52.0000-4210 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS FAR 52.232-27 NOTICE (SEP 2005) (ACC-WRN(WVA))

As authorized by FAR 32.908(b) para. (a)(1)(i)(A) and (a)(4)(i) the timeframes in clause 52.232-27 are changed as follows:

(a)(1)(i)(A), ....the due date for making payments shall be 21 days after the designated billing office receives a proper payment request. If the designated billing office fails to annotate the payment request with the actual date of receipt at the time of receipt, the payment due date shall be the 21st day after the date of the contractor's payment request, provided the designated billing office receives a proper payment request is received and there is no disagreement over quantity, quality, or contractor compliance with contract requirements.

(a)(4)(i), ....government acceptance or approval is deemed to occur constructively on the 30th day after the contractor has completed the work or services in accordance with the terms and conditions of the contract.

END OF NOTICE

52.0000-4953 ORDER OF PRECEDENCE (Jan 2006) (ACC-WRN)

(a) In accordance with Army Policy issued 12 Jul 05, subject: Proper Use of Non-Department of Defense (Non-DoD) contracts, DoD unique terms have been added to this order.

(b) In the event a conflict or inconsistency exists between the terms of this order and the terms and conditions of the underlying contract, the terms and conditions of this order shall govern.

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 45 calendar days* The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 15 calendar days of exercising option. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237130- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (AUG 2013)

(a) Definitions. As used in this clause--Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply that is--

(i) A commercial item (as defined in paragraph (1) of the definition at 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products. Per 46 CFR 525.1(c)(2), ``bulk cargo'' means cargo that is loaded and carried in bulk onboard ship without mark or count, in a loose unpackaged form, having homogenous characteristics. Bulk cargo loaded into intermodal equipment, except LASH or Seabee barges, is subject to mark and count and, therefore, ceases to be bulk cargo.

Employee assigned to the contract means an employee who was hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), who is directly performing work, in the United States, under a contract that is required to include the clause prescribed at 22.1803. An employee is not considered to be directly performing work under a contract if the employee--

(1) Normally performs support work, such as indirect or overhead functions; and

(2) Does not perform any substantial duties applicable to the contract.

Subcontract means any contract, as defined in 2.101, entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime Contractor or another subcontractor.

United States, as defined in 8 U.S.C. 1101(a)(38), means the 50 States, the District of Columbia, Puerto Rico, Guam, the Commonwealth of the Northern Mariana Islands, and the U.S. Virgin Islands.

(b) Enrollment and verification requirements.

(1) If the Contractor is not enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall--

(i) Enroll. Enroll as a Federal Contractor in the E-Verify program within 30 calendar days of contract award;

(ii) Verify all new employees. Within 90 calendar days of enrollment in the E-Verify program, begin to use E-Verify to initiate verification of employment eligibility of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); and

(iii) Verify employees assigned to the contract. For each employee assigned to the contract, initiate verification within 90 calendar days after date of enrollment or within 30 calendar days of the employee's assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(2) If the Contractor is enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall use E-Verify to initiate verification of employment eligibility of--

(i) All new employees. (A) Enrolled 90 calendar days or more. The Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(B) Enrolled less than 90 calendar days. Within 90 calendar days after enrollment as a Federal Contractor in E-Verify, the Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(ii) Employees assigned to the contract. For each employee assigned to the contract, the Contractor shall initiate verification within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(3) If the Contractor is an institution of higher education (as defined at 20 U.S.C. 1001(a)); a State or local government or the government of a Federally recognized Indian tribe; or a surety performing under a takeover agreement entered into with a Federal agency pursuant to a performance bond, the Contractor may choose to verify only employees assigned to the contract, whether existing employees or new hires. The Contractor shall follow the applicable verification requirements at (b)(1) or (b)(2), respectively, except that any requirement for verification of new employees applies only to new employees assigned to the contract.

(4) Option to verify employment eligibility of all employees. The Contractor may elect to verify all existing employees hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), rather than just those employees assigned to the contract. The Contractor shall initiate verification for each existing employee working in the United States who was hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), within 180 calendar days of--

(i) Enrollment in the E-Verify program; or

(ii) Notification to E-Verify Operations of the Contractor's decision to exercise this option, using the contact information provided in the E-Verify program Memorandum of Understanding (MOU).

(5) The Contractor shall comply, for the period of performance of this contract, with the requirements of the E-Verify program MOU.

(i) The Department of Homeland Security (DHS) or the Social Security Administration (SSA) may terminate the Contractor's MOU and deny access to the E-Verify system in accordance with the terms of the MOU. In such case, the Contractor will be referred to a suspension or debarment official.

(ii) During the period between termination of the MOU and a decision by the suspension or debarment official whether to suspend or debar, the Contractor is excused from its obligations under paragraph (b) of this clause. If the suspension or debarment official determines not to suspend or debar the Contractor, then the Contractor must reenroll in E-Verify.

(c) Web site. Information on registration for and use of the E-Verify program can be obtained via the Internet at the Department of Homeland Security Web site: http://www.dhs.gov/E-Verify.

(d) Individuals previously verified. The Contractor is not required by this clause to perform additional employment verification using E-Verify for any employee--

(1) Whose employment eligibility was previously verified by the Contractor through the E-Verify program;

(2) Who has been granted and holds an active U.S. Government security clearance for access to confidential, secret, or top secret information in accordance with the National Industrial Security Program Operating Manual; or

(3) Who has undergone a completed background investigation and been issued credentials pursuant to Homeland Security Presidential Directive (HSPD)-12, Policy for a Common Identification Standard for Federal Employees and Contractors.

(e) Subcontracts. The Contractor shall include the requirements of this clause, including this paragraph (e) (appropriately modified for identification of the parties), in each subcontract that--

(1) Is for--(i) Commercial or noncommercial services (except for commercial services that are part of the purchase of a COTS item (or an item that would be a COTS item, but for minor modifications), performed by the COTS provider, and are normally provided for that COTS item); or

(ii) Construction;

(2) Has a value of more than $3,000; and

(3) Includes work performed in the United States.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $100,000, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

(a) Except as stated in paragraph (b) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(1) Any such clause is unenforceable against the Government.

(2) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an ``I agree'' click box or other comparable mechanism (e.g., ``click-wrap'' or ``browse-wrap'' agreements), execution does not bind the Government or any Government authorized end user to such clause.

(3) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(b) Paragraph (a) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

(a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor.

(b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.

(c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items.

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

United States law will apply to resolve any claim of breach of this contract.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

252.225-7044 BALANCE OF PAYMENTS PROGRAM--CONSTRUCTION MATERIAL--BASIC (NOV 2014)

Commercially available off-the-shelf (COTS) item--

(i) Means any item of supply (including construction material) that is--

(A) A commercial item (as defined in paragraph (1) of the definition of ``commercial item'' in section 2.101 of the Federal Acquisition Regulation);

(B) Sold in substantial quantities in the commercial marketplace; and

(C) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(ii) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means any article, material, or supply incorporated directly into construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(i) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

ii) For components manufactured by the…