W9098S19T0074_AMENDMENT_0002_FINAL.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of Amendment 0002 is to change the Point of Contact information on the solicitation.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 22-Jul-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9098S19T0074

X 9B. DATED (SEE ITEM 11)

26-Jun-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

22-Jul-2019

CODE

ROCK ISLAND ARSENAL (ACC-RI)

JOINT MANUFACTURING & TECHNOLOGY CENTER

BLDG 211 RODMAN AVENUE

1 ROCK ISLAND ARSENAL

ROCK ISLAND IL 61299-5000

W9098S 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9098S19T0074

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0002

The purpose of this Amendment 0002 is to:

1. Chance the Point of Contact information from Aaron Oder to Lynn Baker.

2. All other terms and conditions remain unchanged.

The following have been modified:

SOLICITATION NARRATIVE

ADDENDUM TO 52.212-1. INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS

1. The Army Contracting Command – Rock Island (ACC-RI) hereby issues solicitation W9098S19T0074 for the procurement of Air Compressors in support of the Metal Working and Machine Shop Set (MWMSS) program at the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC). The solicitation is issued in accordance with FAR Part 12 (Acquisition of Commercial Items) and FAR Part 13.5 (Simplified Procedures for Certain Commercial Items). The result of this solicitation will be a Firm Fixed Price (FFP), 5-year Indefinite Delivery/Indefinite Quantity (IDIQ) contract. Award will be based on the lowest priced, responsive, responsible contractor quote whose offer conforms to the solicitation requirement to include delivery schedule and represents the lowest total evaluated price. Contractor responsibility will be determined as outlined by FAR 9.104-1.

The IDIQ will include a five year, 1-year evaluated ordering periods as followed:

Ordering Period One: Date of Contract to 365 calendar day Ordering Period Two: 366 calendar day to 731 calendar day Ordering Period Three: 732 calendar day to 1,096 calendar day Ordering Period Four: 1,097 calendar day to 1,462 calendar day Ordering Period Five: 1,463 calendar day to 1,827 calendar day

* Actual dates will be clarified at the time of award

* Any offeror submitting a quote agrees by submission that their quote and the prices contained therein will be valid for 90 days after receipt of proposals.

2. The Minimum Guaranteed Quantity (MGQ) is 1 Air Compressor, which will be awarded concurrently with the award of the IDIQ. The Government is under no further obligation to order additional quantities.

3. Deliveries:

Deliveries shall begin no later than 30 days of issuance of delivery order. Firm delivery dates will be expressed on the delivery order(s).

Delivery will be FOB Destination to:

TRANSPORTATION OFFICER, W52H1C

BLDG 299, BECK AND GILLESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND, IL 61299-5000

Failure to comply with the contractual delivery schedule after award may result in termination of the order or require consideration if the Government elects to extend your delivery. The Government is not required to extend your deliver schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflict, etc., are not acceptable excuse for failing to meet your delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist and/or Contracting Officer designated in this purchase order prior to being late.

Contractors must provide written notice of what the delay is, the new proposed delivery schedule, and offered consideration for the delay for Government consideration. If the Government elects to extend your delivery, a formal modification will be implemented.

It is the responsibility of the contractor to ensure they are providing quality products that conform to the purchase order terms and conditions (to include delivery schedule). Delivery of non-conforming products results in delivery/acceptance delays and increased cost to the Government.

Early Delivery is acceptable.

4. Warranty:

A commercial standard warranty (to include parts and labor) is required for all CLINS. All warranties will begin upon final acceptance by the United States Government (USG). Contractor shall provide the product warranty information IAW CDRL 0002 (Attachment 0003_CDRL 0002) upon award.

5. Payment:

Payment will be made 100% upon final acceptance by USG. Payments will be processed through Defense Finance and Accounting Systems (DFAS) via Wide Area Workflow (WAWF). Only Electronic invoices, submitted through WAWF, will be accepted. All other formats will be rejected.

6. Pricing:

Offerors shall complete the Price Matrix (Attachment 0001). Pricing provided at the CLIN level is not acceptable.

Each cell that requires the Offeror’s input on the Price Matrix has been highlighted in blue. The offeror shall enter firm fixed prices for each CLIN, Ordering Period, and Quantity Ranges on the applicable Price Matrix (Attachment 0001).

Proposed unit prices must be submitted on an FOB Destination basis. Ship to location is Rock Island, IL 61299- 5000. The quantity ranges on the Price Matrix are provided solely for the purpose of establishing reasonable ranges of quanitities against which to provide prices in the event all delivery orders are executed. In order to be acceptable, an offer must include firm fixed unit prices for all CLINs, all ordering periods and quantity ranges listed on the Price Matrix. Any order placed against the resulting contract will be at the unit price offered by the Contractor for the applicable quantity range and ordering period. Failure to complete the Price Matrix in its entirety may deem an offeror as non-responsive.

No other information is to be added to the Price Matrix, nor shall Offerors make any changes to the Price Matrix.

All proposed unit prices are limited to two decimal places and shall be stated in current U.S. dollars. All unit prices proposed will be binding. The Government reserves the right to require the submission of any data (i.e. certified cost or pricing data or data other than certified cost or pricing data) necessary to validate the reasonableness of an offer.

Award will be made to the Offeror whose quote represents the lowest total evaluated price. Therefore, the Contractor’s initial quote should contain the Contractor’s best terms.

Any order placed against the resulting contract will be at the unit price offered by the Contractor for the applicable quantity range and ordering period based on the date the delivery order is issued. Upon award, Delivery Order 0001 will be placed for at least the guaranteed minimum quantity.

7. Evaluation:

Award will be based on the lowest priced, responsive, responsible vendor quote whose offer conforms to the solicitation requirement to include delivery schedule and represents the lowest total evaluated price.

a. The Government will evaluate offers based on prices proposed for all Ordering Periods and any other price related factors required by the solicitation. Prices will be determined fair and reasonable IAW

FAR 13.106-2.

b. For each quote, the Government will calculate a weighted average price for each CLIN by multiplying the proposed unit prices for each Quantity Range and Ordering Period by their respective weight. Note that the weight associated with each range represents the likelihood that an order, if placed, would be placed within that range. The weighted average unit price is then multiplied by the estimated annual quantity for each ordering period to calculate an estimated annual total price. Note that the annual estimated quantity is just an estimate for evaluation purposes only and does not bind the Government to purchase those quantities in any ordering period.

c. The Total Evaluated Price is the sum of the evaluated price for each CLIN.

d. If an offeror fails to submit unit prices for all quantity ranges and Ordering Periods listed on the Price

Evaluation Sheet, its proposal may be considered unacceptable and the Government may reject the quote.

8. All offerors must complete the following. Failure to comply may result in your firm being considered non compliant.

FAR 52.223-22 – Public Disclosure of Greenhouse Gas Emissions and Reduction Goals – Representation is included in this solicitation.

Did your firm receive $7.5 million or more in Federal contract awards in the prior Federal fiscal year?

Please place an “X” next to the appropriate answer.

Yes______ Completion of 52.223-22, located in the Addendum to 52.212-1 below is required.

No_______ No further action for this provision is required.

9. The following is a list of documents incorporated as attachments to this solicitation:

Attachment 0001 Price Matrix Attachment 0002 CDRL_0001_CommercialManuals-Copyright Release Attachment 0003 CDRL_0002_ProductWarrantyInformation

10. Only ACC-RI (CCRC-AH) is authorized to issue delivery orders under this IDIQ contract.

11. Government Points of contact for this solicitation are as follows:

Title Name Phone # Email Contract Lynn Baker (309)782-5885 lynn.d.baker8.civ@mail.mil Specialist

Procuring Brittany Fleming (309)782-6814 brittany.m.fleming5.civ@mail.mil Contracting Officer

12. Accessing Rock Island Arsenal:

Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly suggested to pre-register at least three

(3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival.

It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order. DRIVERS WHO DO NOT MEET

THE INSTALLATION ACCESS REQUIREMENTS WILL NOT BE ALLOWED ON THE

INSTALLLATION AND WILL BE TURNED AWAY.

NOTE: As of 31 Dec 2015, Department of Defense and Department of the Army has directed that Driver Licenses and ID cards from Minnesota, Missouri and Washington are not compliant with the standards of the REAL ID Act and cannot be used on their own as a primary means of identification to apply for access to Rock Island Arsenal.

Driver’s Licenses that have written on the top of them “NOT FOR FEDERAL IDENTIFICATION PURPOSES” are also non-compliant.

These non-compliant driver’s license or state issued identification cards may still be presented at the Rock Island Visitor Control Center, but they must be accompanied by one of the following secondary forms of identification before a records check is conducted and installation access is granted:

*Current vehicle registration showing name and address *Social Security card *US passport or passport card *US Military or Draft Record (DD-214 or Selective Service Registration Card) *Veteran Health Identification Card issued by the US Department of Veterans Affairs *Transportation Worker Identification Credential *Personal Identification Verification card issued by the Federal Government *Personal Identification Verification 0 Interoperable card issued by the Federal Government *US Certificate of Naturalization or certificate of citizenship (Form N-550)

*US Department of Homeland Security “Trusted Traveler” card (Global Entry, NEXUS, SENTRI, or

FAST)

*Driver’s license issued by the US Department of State *US Military Identification Card for military members, dependents and retirees *US Permanent Resident/Alien Registration Receipt Card (Form 1-551) *US Coast Guard or Department of Homeland Security Merchant Mariner card *Native American Tribal Photo Identification card

Visitor Access Request Forms and a complete list of acceptable identification can be found at https://home.army.mil/ria/ (click on Menu, then Visitor Information, and then under How to Visit Rock Island Arsenal click on the second bullet “How to obtain a visitor pass”. Then on the right side of the screen click on “Access Request Process”) or call 309-782-0551.

Forms may be emailed for faxed

All visitors must process through the Moline Visitor Center Gate (I-74) off of River Drive in Moline, IL.

Visitors (to include transportation and freight providers) will require proper identification to access RIA

POC for this Policy are: RIA Visitor Center, Phone 309-782-0551, FAX 309-782-5029, email:

usarmy.ria.imcom.mbx.usag-access-request@mail.mil

RECEIVING HOURS OF OPERATION:

Monday – Friday, 6:30am to 2:00pm CST

Deliveries before or after the above stated hours will be turned away. Appointments are not necessary.

For Directions call: 309-782-8539 (Automated)

13. RECEIVING HOURS OF OPERATION:

Monday – Friday, 6:30am to 2:00pm CST Deliveries before or after the above stated hours will be turned away. Appointments are not necessary.

For Directions call: 309-782-8539

END OF ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL

(End of Summary of Changes)