11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of theoffer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

J 1 6

0001 03 NOV 2026 W52H1B0098798860

W519TC

W6QK ACC-RI

ACC ROCK ISLAND BLDG 60, 3055 RODMAN AVE

ROCK ISLAND, IL 61299-0000

UNITED STATES

ANDREW OWENS, EMAIL: ANDREW.M.OWENS16.CIV@ARMY.MIL TELEPHONE: 520-

692-9835

SCD: PAS:

W519TC27QA014

05 OCT 2026

SEE SECTION G - CONTRACT ADMINISTRATION DATA

Re-open solicitation for full and open competition

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form

The following changes have been made:

Miscellaneous text in this section has been modified from:

SOLICITATION NARRATIVE

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation W519TC26QA230 for the procurement of Burner Rack Cradle Assembly in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC) and is issued in accordance with Federal Acquisition Regulation (FAR) Part 12 (Acquisition of Commercial Products and Commercial Services).

The Government intends to award one Firm Fixed Price (FFP) purchase order to the lowest price, responsive, and responsible contractor whose quote conforms to the terms and conditions of the solicitation and represents the lowest total evaluated price. Contractors are responsible for providing their best price at the time of the quote submission. Contractor's responsibility will be determined as outlined in FAR 9.104-1. The Government intends to evaluate proposals and issue an award without discussions with Offerors (except for clarifications as described in FAR 15.306 (a)).

Certificate of Conformance (COC) will be required for all items.

Please review attachment 0001 - RIA153238 DRAWING

2. All offerors must complete the following provision contained within this solicitation if they have not completed it within the System for Award Management (SAM). Failure to comply may result in your firm being considered noncompliant.

3. Quotes shall include delivery to Rock Island Arsenal, IL 61299.

4. On time delivery is critical. Therefore, the contractor must adhere to the delivery requirements indicated in this purchase order. Failure to comply with the contractual delivery schedule after award may result in termination of the order or require consideration if the Government elects to extend your delivery. The Government is not required to extend your delivery schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflict, etc., are not acceptable excuse for failing to meet your delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist and/or Contracting Officer designated in this purchase order prior to being late. Contractors must provide written notice of what the delay is, the new proposed delivery schedule, and offered consideration for the delay for Government consideration. If the Government elects to extend your delivery, a formal modification will be implemented. It is the responsibility of the contractor to ensure they are providing quality products that conform to the purchase order terms and conditions (to include delivery schedule). Early Delivery is acceptable at no cost to the Government.

5. Army Contracting Command Government Point of Contact (POC):

Title Name Email

Contract Specialist Andrew Owens Andrew.m.owens16.

civ@army.mil

Contracting Officer Kelly Hendricks kelly.d.hendricks5.civ@army.

mil

FAR 52.204-24 - Representation Regarding certain Telecommunications and Video Surveillance Services or Equipment.

END OF NARRATIVE

To:

AMENDMENT 0001 NARRATIVE

The purpose of Amendment 0001 is to...

1. Reopen the solicitation from small business set aside to full and open competition.

2. Closing date is now set for November 13th, 2026 at 6 PM Central Standard Time.

3. FAR references updated to RFO FAR references (Changed from FAR to RFO FAR Part 12.)

Changed from FAR 15.306 to RFO FAR 15.306.

4. Added compliance language for to complete Section B Supplies or Services & Prices or Costs section.

5. Added Attachment 0001 - RIA 153238 Drawing review compliance.

6. Added FAR Clause 52.204-24.

7. All other terms and conditions remain unchanged and in full effect.

END OF AMENDMENT NARRATIVE

SOLICITATION NARRATIVE

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation W519TC27QA014 for the procurement of Burner Rack Cradle Assembly in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC) and is issued in accordance with Revolutionary FAR Overhaul Federal Acquisition Regulation (RFO FAR) Part 12 (Acquisition of Commercial Products and Commercial Services).

The Government intends to award one Firm Fixed Price (FFP) purchase order to the lowest price, responsive, and responsible contractor whose quote conforms to the terms and conditions of the solicitation and represents the lowest total evaluated price. Contractors are responsible for providing their best price at the time of the quote submission. Contractor's responsibility will be determined as outlined in FAR 9.104-1. The Government intends to evaluate proposals and issue an award without discussions with Offerors (except for clarifications as described in RFO FAR 15.306(a)).

Certificate of Conformance (COC) will be required for all items.

Quoters shall review attachment 0001 - RIA153238 DRAWING to be compliant with this RFQ

2. All quoters must complete Section B Supplies or Services & Prices or Costs section within this solicitation if they have not completed it within the System for Award Management (SAM). Failure to comply may result in your firm being considered noncompliant.

3. Quotes shall include delivery to Rock Island Arsenal, IL 61299.

4. On time delivery is critical. Therefore, the contractor must adhere to the delivery requirements indicated in this purchase order. Failure to comply with the contractual delivery schedule after award may result in termination of the order or require consideration if the Government elects to extend your delivery. The Government is not required to extend your delivery schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflict, etc., are not acceptable excuse for failing to meet your delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist and/or Contracting Officer designated in this purchase order prior to being late. Contractors must provide written notice of what the delay is, the new proposed delivery schedule, and offered consideration for the delay for Government consideration. If the Government elects to extend your delivery, a formal modification will be implemented. It is the responsibility of the contractor to ensure they are providing quality products that conform to the purchase order terms and conditions (to include delivery schedule). Early Delivery is acceptable at no cost to the Government.

5. Army Contracting Command Government Point of Contact (POC):

Title Name Email

Contract Specialist Andrew Owens Andrew.m.owens16.

civ@army.mil

Contracting Officer Kelly Hendricks kelly.d.hendricks5.civ@army.

mil

END OF NARRATIVE

Supplies or Services & Prices or Costs

The following CLIN(s) / SLIN(s) / ELIN(s) were modified:

Deliveries or Performance

The delivery information for the following CLIN(s) / SLIN(s) / ELIN(s) were modified: