Solicitation Amendment W519TC26QA1650003 SF 30 updated.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of theoffer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

J 1 10

0003 09 SEP 2026 W52H1B0097635158

W519TC

W6QK ACC-RI

ACC ROCK ISLAND BLDG 60, 3055 RODMAN AVE

ROCK ISLAND, IL 61299-0000

UNITED STATES

LEIGH WEEKS, EMAIL: LEIGH.A.WEEKS2.CIV@ARMY.MIL TELEPHONE: 520-693-0167

SCD: PAS:

W519TC26QA165

14 JUL 2026

SEE CONTINUATION

extending the proposal/response due date

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form Continuation

The following changes have been made:

Continuation of Description

Miscellaneous text in this section has been modified from:

SOLICITATION NARRATIVE

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation amendment W519TC26RA0520002 for the procurement of Bent Tube & Fittings, in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC) and is issued in accordance with Federal Acquisition Regulation (FAR) Part 12 (Acquisition of Commercial Items).

2. The following drawings apply:

11619659

11619660

11619662

11619664

Please note, access to the drawings is Authorized the Department of Defense and U.S. DOD Contractors only. Questions about Contract Opportunities within SAM.gov system should be addressed with the GSA helpdesk on the bottom right-hand side of the SAM.gov page where it states, "Customer Service" and then "Federal Service Desk" or try (866) 606-8220.

This Requirement is Full & Open Competition. QUOTES MUST BE SUBMITTED BY 02 SEPT .2026

3. Quotes must be submitted via email to the Contract Specialist listed below in the Points of Contact paragraph and received prior to the closing date and time to be considered for award. The offeror is responsible for assuring the quote is received by the Government on time, prior to the closing date and time, to be considered. It is the government's intent to award without discussions (except for clarifications as described by FAR 15.306(a)). Therefore, the Contractor's quote should be complete and contain the contractor's best price and delivery terms. A complete quote submission includes (but not limited to) the contractor's best term (price and delivery and all required fill-ins under this RFQ). IAW FAR clause 52.212-2, included in this RFQ, the Government reserves the right to conduct discussions if determined necessary by the Contracting Officer.

Quotes shall be prepared and authorized by a person(s) regularly employed by the contractor. The quote shall state the name of each person(s) contributing to the authorship of the quote, the person

(s) position/title, phone number, and an email address for the person who should be contacted if an award is to be made. The quote should be prepared in a clear, legible, practical manner. In addition, the quote shall be written in English and should be specific and complete.

Pricing should be IAW the information on the CLIN and any attachments to this solicitation and should be documented directly on the SF1449 form, including a unit price on each CLIN, a total CLIN amount, and a grand total for the entire solicitation (including shipping FOB destination to Rock Island, IL to be paid by the contractor), all clauses that require fill ins should be completed, and the authorized preparer shall sign and date prior to submission. The solicitation should be emailed to the POCs listed below.

Certified Test Report (CTR) and Certificate of Conformance (COC) are required IAW FAR 52.246-15 with every delivery.

4. The Government intends to award one firm fixed price purchase order (without discussions, except clarifications as described in FAR 15.306(a)) to the Offeror determined to be responsible (in accordance with (IAW) the Federal Acquisition Regulation (FAR) subpart 9.1) whose quote conforms with the RFQ requirements and is determined to be the lowest total evaluated (fair and reasonable) priced quote.

5. Delivery for this item is specified on the CLIN(s), however early and incremental delivery is authorized and encouraged with no additional cost to the Government. All quotes shall be quoted as FOB Destination Rock Island, IL, see FAR 52.247-34, therefore, all shipping charges should be included in the quote.

On time delivery is critical. Therefore, contractor must adhere to the delivery requirements indicated in the resulting award. Failure to comply with the contractual delivery schedule after award may result in termination of the award or require consideration if the Government elects to extend your delivery schedule. The Government is not obligated to extend your delivery if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflicts, etc., are not considered acceptable delays/excuses for the failing to meet the contractual delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contracting Officer designated in the award at least 10 days prior to being late. Such notification shall include the contractor's reasons for delay, proposed revised schedule, and the contractor's offered consideration for the delay should the Government elect to extend.

It is the responsibility of the contractor to ensure that they provide quality products that conform to the award terms and conditions as well as meet the required delivery schedule. Delivery of non conforming products results in delivery/acceptance delays and ultimately increased costs to the Government.

**Contractor shall package all shipments to RIA-JMTC IAW standard commercial guidelines.

NOTE RECEIVING HOURS OF OPERATION Monday-Friday, 6:30am to 2:00pm Central Time.

Deliveries before or after the above stated hours will be turned away. Appointments are not necessary. For directions call: (309)782-8539 (Automated).

6. WARRANTY: A one year parts and labor warranty is required for all CLINs. Warranties shall be provided for the item and all required tooling. All warranties will begin upon final acceptance by the Government. Contractor shall provide the product warranty information to the Contracting Officer upon award.

7. PAYMENT: Payment will be via Defense Finance and Accounting System (DFAS) via the Wide Area Workflow (WAWF) System. Only electronic invoices submitted through WAWF will be accepted. All other formats will be rejected. See DFARS 252.232-7003 and 252.232-7006 for additional invoicing guidance.

8. Offeror is cautioned to ensure their proposal is fully complete, including all fill-ins and blanks in the solicitation. Contractor agrees by submission that their proposal and the prices contained therein will be valid for 90 days after date of the quote submission

9. Army Contracting Command Government Point of Contact (POC):

Contract Specialist Leigh Weeks (520) 693-0167 leigh.a.weeks2.civ@army.mil

Procuring Officer: Daniel Sinnott (520) 693-0305 daniel.s.sinnot.civ@army.mil

**NOTE: Communication with the Government should start at the lowest possible level.

10. Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly advised to pre-register at least three (3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival.

All visitors must complete a Visitor Access Request Form. Access Request Forms should be emailed or faxed prior to the delivery. The Visitor Access Request Form can be found at http://www.usagria.army.mil/AccessRequests Follow the instructions on How to Obtain a Visitor Pass. All first time visitors must process through the Moline Gate Visitor Center.

TRUCKS MUST ENTER THROUGH MOLINE, IL GATE, OFF OF RIVER DRIVE IN MOLINE I-74.

Transportation Service Providers are required to send drivers with proper identification who meet all the installation access requirements. Transportation Service Providers are required to send United States Citizens and drivers that will pass applicable background checks. Failure to do so can result in warnings or Non-use. Real-ID access implementation is active at Rock Island Arsenal, IL. Individuals using a driver's license from the states of Illinois, Minnesota, Missouri, New

Mexico or Washington will have to use a secondary form of Identification to enter U.S. military installations. Additional forms of identification that may be used in conjunction with a state driver's license are Vehicle Registration with name and address, Veterans Health Identification Card, PIV Card, PIV-1 Card, DHS "Trusted Traveler" Card, U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550), and State of Illinois Firearm Owners Identification (FOID) card.

It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order.

DRIVERS WHO DO NOT MEET THE INSTALLATION ACCESS REQUIREMENTS WILL NOT BE

ALLOWED ON THE INSTALLLATION AND WILL BE TURNED AWAY.

POC for this Policy are:

Rock Island Arsenal Visitor Center

(309) 782-0485 -phone

(309) 782-5029-fax usarmy.ria.imcom.mbx.usag-access-request@mail.mil

To:

SOLICITATION NARRATIVE

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation amendment W519TC26RA0520002 for the procurement of Bent Tube & Fittings, in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC) and is issued in accordance with Federal Acquisition Regulation (FAR) Part 12 (Acquisition of Commercial Items).

2. The following drawings apply:

11619659

11619660

11619662

11619664

Please note, access to the drawings is Authorized the Department of Defense and U.S. DOD Contractors only. Questions about Contract Opportunities within SAM.gov system should be addressed with the GSA helpdesk on the bottom right-hand side of the SAM.gov page where it states, "Customer Service" and then "Federal Service Desk" or try (866) 606-8220.

This Requirement is Full & Open Competition. This amendment is to extend the proposal/response due date for quotes. .QUOTES MUST BE SUBMITTED BY 15 SEPT 2026

3. Quotes must be submitted via email to the Contract Specialist listed below in the Points of Contact paragraph and received prior to the closing date and time to be considered for award. The offeror is responsible for assuring the quote is received by the Government on time, prior to the closing date and time, to be considered. It is the government's intent to award without discussions (except for clarifications as described by FAR 15.306(a)). Therefore, the Contractor's quote should be complete and contain the contractor's best price and delivery terms. A complete quote submission includes (but not limited to) the contractor's best term (price and delivery and all required fill-ins under this RFQ). IAW FAR clause 52.212-2, included in this RFQ, the Government reserves the right to conduct discussions if determined necessary by the Contracting Officer.

Quotes shall be prepared and authorized by a person(s) regularly employed by the contractor. The quote shall state the name of each person(s) contributing to the authorship of the quote, the person

(s) position/title, phone number, and an email address for the person who should be contacted if an award is to be made. The quote should be prepared in a clear, legible, practical manner. In addition, the quote shall be written in English and should be specific and complete.

Pricing should be IAW the information on the CLIN and any attachments to this solicitation and should be documented directly on the SF1449 form, including a unit price on each CLIN, a total CLIN amount, and a grand total for the entire solicitation (including shipping FOB destination to Rock Island, IL to be paid by the contractor), all clauses that require fill ins should be completed, and the authorized preparer shall sign and date prior to submission. The solicitation should be emailed to the POCs listed below.

Certified Test Report (CTR) and Certificate of Conformance (COC) are required IAW FAR 52.246-15 with every delivery.

4. The Government intends to award one firm fixed price purchase order (without discussions, except clarifications as described in FAR 15.306(a)) to the Offeror determined to be responsible (in accordance with (IAW) the Federal Acquisition Regulation (FAR) subpart 9.1) whose quote conforms with the RFQ requirements and is determined to be the lowest total evaluated (fair and reasonable) priced quote.

5. Delivery for this item is specified on the CLIN(s), however early and incremental delivery is authorized and encouraged with no additional cost to the Government. All quotes shall be quoted as FOB Destination Rock Island, IL, see FAR 52.247-34, therefore, all shipping charges should be included in the quote.

On time delivery is critical. Therefore, contractor must adhere to the delivery requirements indicated in the resulting award. Failure to comply with the contractual delivery schedule after award may result in termination of the award or require consideration if the Government elects to extend your delivery schedule. The Government is not obligated to extend your delivery if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflicts, etc., are not considered acceptable delays/excuses for the failing to meet the contractual delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contracting Officer designated in the award at least 10 days prior to being late. Such notification shall include the contractor's reasons for delay, proposed revised schedule, and the contractor's offered consideration for the delay should the Government elect to extend.

It is the responsibility of the contractor to ensure that they provide quality products that conform to the award terms and conditions as well as meet the required delivery schedule. Delivery of non conforming products results in delivery/acceptance delays and ultimately increased costs to the Government.

**Contractor shall package all shipments to RIA-JMTC IAW standard commercial guidelines.

NOTE RECEIVING HOURS OF OPERATION Monday-Friday, 6:30am to 2:00pm Central Time.

Deliveries before or after the above stated hours will be turned away. Appointments are not necessary. For directions call: (309)782-8539 (Automated).

6. WARRANTY: A one year parts and labor warranty is required for all CLINs. Warranties shall be provided for the item and all required tooling. All warranties will begin upon final acceptance by the Government. Contractor shall provide the product warranty information to the Contracting Officer upon award.

7. PAYMENT: Payment will be via Defense Finance and Accounting System (DFAS) via the Wide Area Workflow (WAWF) System. Only electronic invoices submitted through WAWF will be accepted. All other formats will be rejected. See DFARS 252.232-7003 and 252.232-7006 for additional invoicing guidance.

8. Offeror is cautioned to ensure their proposal is fully complete, including all fill-ins and blanks in the solicitation. Contractor agrees by submission that their proposal and the prices contained therein will be valid for 90 days after date of the quote submission

9. Army Contracting Command Government Point of Contact (POC):

Contract Specialist Leigh Weeks (520) 693-0167 leigh.a.weeks2.civ@army.mil

Procuring Officer: Daniel Sinnott (520) 693-0305 daniel.s.sinnot.civ@army.mil

**NOTE: Communication with the Government should start at the lowest possible level.

10. Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly advised to pre-register at least three (3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival.

All visitors must complete a Visitor Access Request Form. Access Request Forms should be emailed or faxed prior to the delivery. The Visitor Access Request Form can be found at http://www.usagria.army.mil/AccessRequests Follow the instructions on How to Obtain a Visitor Pass. All first time visitors must process through the Moline Gate Visitor Center.

TRUCKS MUST ENTER THROUGH MOLINE, IL GATE, OFF OF RIVER DRIVE IN MOLINE I-74.

Transportation Service Providers are required to send drivers with proper identification who meet all the installation access requirements. Transportation Service Providers are required to send United States Citizens and drivers that will pass applicable background checks. Failure to do so can result in warnings or Non-use. Real-ID access implementation is active at Rock Island Arsenal, IL. Individuals using a driver's license from the states of Illinois, Minnesota, Missouri, New Mexico or Washington will have to use a secondary form of Identification to enter U.S. military installations. Additional forms of identification that may be used in conjunction with a state driver's license are Vehicle Registration with name and address, Veterans Health Identification Card, PIV Card, PIV-1 Card, DHS "Trusted Traveler" Card, U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550), and State of Illinois Firearm Owners Identification (FOID) card.

It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order.

DRIVERS WHO DO NOT MEET THE INSTALLATION ACCESS REQUIREMENTS WILL NOT BE

ALLOWED ON THE INSTALLLATION AND WILL BE TURNED AWAY.

POC for this Policy are:

Rock Island Arsenal Visitor Center

(309) 782-0485 -phone

(309) 782-5029-fax usarmy.ria.imcom.mbx.usag-access-request@mail.mil