W50S7X-22-C-0002.pdf

F7V3MS2235A001

Construction Contract for Project No. PRQE 222015, Replace CRAC Unit #2 at Bldg. 54, McConnell AFB, KS 67221. Work w ill be in accordance w ith the contract, plans, and technical specifications.

This action is being solicited on a 100% Small Business Set Aside basis.

The North American Industry Classif ication (NAICS) Code is 238220 - Plumbing, Heating and Air-Conditioning Contractors and the size standard for small business is $16.5M average annual revenue for the past three years.

Project magnitude is betw een $100,000.00 and $250,000.00.

Persons intending on submitting a BID should attend the Site Visit. Failure to submit a bid on all items shall result in rejection of the bid.

Solicitation information, notices and amendments w ill be posted at https://sam.gov/.

Aw ard w ill be made to the responsible bidder w hose bid conforms to the invitation for bids and is most advantageous to the Government considering only price.

Funds are not presently available for this acquisition. The Government anticipates funds w ill become available prior to aw ard as this action has been identif ied on the National Guard priority list. No contract aw ard w ill be made until appropriated funds are made available.

X

DARIN L. BRUN 316.759.7591

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

24-Aug-2022

(RFP)

(IFB)

CALL:

Repalce CRAC Unit #2 at Building 54

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________420 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, X negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________05 Aug 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______30 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

W50S7X22C0002

7. ISSUED BY CODE

USPFO KS 184 MISSION SUPPORT CONTRACTING

52955 JAYHAWK DR SUITE 153

MCCONNELL AFB KS 67221-9000

W50S7X

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

PRQE 222015

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W50S7X22B00020001 54

See Item 7

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE

6VX72

FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

SEE SCHEDULE

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

$222,935.00 See Schedule

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE F8770027. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

DFAS DEAMS

ACCTG DISB STA NR 387700

DFAS DEAMS

27 ARKANSAS RD

LIMESTONE ME 04751-6216

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR

SOUTHTOWN GLASS INC

SGI

MIKE WILSON

105 N STEWART CT STE 240H

LIBERTY MO 64068-1397

15. TELEPHONE NO. (Include area code) 816-582-3291

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print) DARIN L. BRUN / CONTRACT OFFICER

TEL: 316.759.7591 EMAIL: darin.brun@us.af.mil

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY 25-Aug-2022

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

X

W50S7X22C0002

Section SF 30 - BLOCK 14 CONTINUATION PAGE

CONTINUATION SHEET

A. NECESSITY FOR CHANGE: An updated wage determination and questions that arose during the site visit requires this amendment to allow contractors to accurately bid the project.

B. DESCRIPTION OF CHANGE: This amendment is being issued to incorporate the following into the solicitation:

1. Add new wage rate determination – General Decision Number : KS20220057 Dated 07/08/2022

2. Revised drawings MD-1 & M-1. New sheets are clouded and marked REVISED SHEET

3. Revised Statement of Work (SOW) dated 14 July 2022.

C. TIME: The solicitation date and time is unchanged

D. WAGE RATES: The wage rates applicable to this solicitation has been updated.

E. POSTING: New wage determination and SOW will be attached to the SF 30. The addenda drawings will be posted at SAM (https://sam.gov/content/home) for the contractor to retrieve.

UPDATED WAGE DETERMINATION

"General Decision Number: KS20220057 07/08/2022

Superseded General Decision Number: KS20210057

State: Kansas

Construction Type: Building

County: Sedgwick County in Kansas.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 |into on or after January 30, | generally applies to the |2022, or the contract is | contract.

|renewed or extended (e.g., an |. The contractor must pay |option is exercised) on or | all covered workers at |after January 30, 2022: | least $15.00 per hour (or | | the applicable wage rate | | listed on this wage | | determination, if it is | | higher) for all hours | | spent performing on the | | contract in 2022.

|If the contract was awarded on|. Executive Order 13658 |or between January 1, 2015 and| generally applies to the |January 29, 2022, and the | contract.

|contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least |30, 2022: | $11.25 per hour (or the | | applicable wage rate listed|

| | on this wage determination,| | | if it is higher) for all | | hours spent performing on | | that contract in 2022.

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at https://www.dol.gov/agencies/whd/government-contracts.

Modification Number Publication Date 0 01/07/2022 1 02/04/2022 2 02/18/2022 3 02/25/2022 4 04/08/2022 5 06/03/2022 6 06/17/2022 7 07/08/2022

ASBE0027-005 10/01/2021

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR (MECHANICAL (Duct, Pipe & Mechanical System Insulation)).....................$ 37.80 28.57

BRKS0015-011 06/01/2020

Rates Fringes

TILE SETTER......................$ 36.79 15.78

BRKS0015-014 06/01/2020

Rates Fringes

TILE FINISHER....................$ 17.99 .91

ELEC0271-002 05/28/2022

Rates Fringes

ELECTRICIAN (including Alarm Installation)....................$ 35.99 16.41

ELEV0012-004 01/01/2021

Rates Fringes

ELEVATOR MECHANIC................$ 51.68 35.825+a+b

a. VACATION PAY: 6% for 6 months to 5 years service; 8% with 5 or more years of service.

b. PAID HOLIDAYS: Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Friday after, and Christmas Day.

ENGI0101-040 04/01/2016

Rates Fringes

POWER EQUIPMENT OPERATOR:

Bobcat/Skid Steer/Skid

Loader......................$ 37.63 15.97 Oiler.......................$ 32.08 15.97 Paver (Asphalt, Aggregate, and Concrete)...............$ 38.44 15.97

IRON0010-018 04/01/2021

Rates Fringes

IRONWORKER

(Ornamental/Reinforcing).........$ 34.50 31.99

* IRON0024-005 06/01/2022

Rates Fringes

IRONWORKER, STRUCTURAL...........$ 26.49 13.48

PAIN2012-008 04/01/2020

Rates Fringes

PAINTER (Brush, Roller, and Spray)...........................$ 32.91 17.86

PLUM0441-014 06/01/2022

Rates Fringes

PIPEFITTER (HVAC Pipe Installation Only)...............$ 36.02 18.58

PLUM0533-012 06/01/2016

Rates Fringes

PIPEFITTER (Excludes HVAC Pipe Installation)...............$ 45.33 19.32

SFKS0669-002 04/01/2022

Rates Fringes

SPRINKLER FITTER (Fire Sprinkler).......................$ 37.30 23.92

TEAM0541-010 04/01/2020

Rates Fringes

TRUCK DRIVER (Lowboy Truck)......$ 34.29 15.25

TEAM0541-011 04/01/2020

Rates Fringes

TRUCK DRIVER (Semi-Trailer Truck)...........................$ 34.29 15.25

* SUKS2015-026 07/08/2015

Rates Fringes

BRICKLAYER, Excludes Tile Finisher and Tile Setter.........$ 21.85 3.04

CARPENTER........................$ 17.62 1.93

CEMENT MASON/CONCRETE FINISHER...$ 17.17 2.23

LABORER: Common or General......$ 13.16 ** 1.44

LABORER: Mason Tender - Brick...$ 19.91 6.88

LABORER: Mason Tender - Cement/Concrete..................$ 11.55 ** 1.67

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 20.50 3.49

OPERATOR: Bulldozer.............$ 33.12 13.96

OPERATOR: Crane.................$ 33.19 14.16

OPERATOR: Forklift..............$ 34.83 14.16

OPERATOR: Grader/Blade..........$ 29.58 11.51

OPERATOR: Loader................$ 30.35 12.04

OPERATOR: Roller................$ 33.78 13.64

PLUMBER..........................$ 23.12 6.86

ROOFER...........................$ 13.33 ** 1.66

SHEET METAL WORKER (HVAC Duct Installation Only)...............$ 24.84 6.82

SHEET METAL WORKER, Excludes HVAC Duct Installation...........$ 22.25 4.42

TRUCK DRIVER: Dump (All Types)...$ 19.63 5.26

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

** Workers in this classification may be entitled to a higher minimum wage under Executive Order 14026 ($15.00) or 13658 ($11.25). Please see the Note at the top of the wage determination for more information.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example:

SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

UPDATED STATEMENT OF WORK

STATEMENT OF WORK

KANSAS AIR NATIONAL GUARD, McCONNELL AFB PRQE222015 Repair Bldg 54 #2 CRAC Unit Revised 14 July 2022

SW-1 LOCATION: McCONNELL Air Force Base, Wichita, KS. Arrangements for entrance onto the Base must be made by contacting Base Engineering at (316) 759-7477 between the hours of 7:00 a.m. and 4:00 p.m., Monday through Friday.

SW-2 SCOPE OF WORK: The work covered in this contract consists of furnishing all plant, labor, expertise, equipment, materials, facilities, transportation, and appliances necessary to perform operations in connection with the work described in paragraph SW-3. It is the intent of the government for the contractor to provide a complete and useable system. Any relevant details required for a complete system that are omitted in the contract plans and specifications will be provided by the Contractor at no cost to the government.

SW-3 SUMMARY OF WORK: Work shall consist of but is not limited to the following:

Task 1: Replace and reroute a portion of the existing copper refrigerant line sets on two existing 30 Ton Liebert Computer Room Air Conditioning (CRAC) Units. Each Liebert Unit has two R-22 refrigerant circuits each having approximately 120 pounds of refrigerant. Due to operational requirements of the server farm, only one circuit of one Liebert Unit can be down at a time. R-22 Freon can be recycled for #1 and #3 CRAC units if the acid content is acceptable, otherwise new Freon shall be used. If new refrigerant is needed, the KSANG will either provide the refrigerant or initiate a change order to purchase new refrigerant. CRAC-2 will be completely replaced with a new unit. Completely replace the refrigerant lines for the new CRAC-2 and charge the system. Each of the 6 existing line sets is comprised of one 1 inch line and one 1¼ inch line (see drawings for new and existing routing).

Replacement lines will use ACR copper piping and will be insulated with Rubatex insulation. Provide insulation blocks at pipe supports and aluminum jacket around exterior piping to protect insulation. There will be combination isolation/shraeder valves installed at the condenser end of the new portion of the line sets as well as isolation/shraeder valves installed on the linesets just outside the indoor unit (Evaporator) approximately 4 feet above the finished floor. The result will be two isolation/shraeder valves on each of the six lines. Include installation of replaceable filters and liquid line dryers and assemblies on all six circuits. Linesets will exit the building through the concrete precast wall at approximately 12 feet high. Lines will be supported by pipe stands or hangers keeping at least a 12 foot clearance above the ground until they reach the condensing units.

Note: The contractor will help ensure cooling to the server farm is maintainted during the performance of this work by only having one circuit of each CRAC unit down at a time. Air conditioning must be sufficient to keep the server farm continuously at 73 degrees +/- 2 degrees.

Task 2: Replace CRAC-2 in its intirety. The new unit will consist of an interior 30 Ton Precision Cooling System CRAC Unit with a new 30 Ton DX Air-Cooled Microchannel Condensing Unit. The new units will be installed in the same locations as the old interior/exterior systems. Due to the criticality of the server farm, it is critical the demolition of the existing CRAC only occur immediately prior to the installation of the new unit. Install combination isolation/shraeder valves at the condenser end of the line sets as well as just outside the indoor unit (Evaporator) approximately 4 feet above the finished floor.

It is understandable that there may be a long lead time on the new CRAC Unit. Tasks 1 can occur immediately after the Notice to Proceed is provided or wait until the new CRAC unit has been delivered.

Once work has started on replacing the refrigerant lines and removing the CRAC Unit, it shall be the contractors responsibility to assist the KSANG in ensuring the server farm temperature remains below 75 F by limiting the amount of time any one refrigerant circuit is down and also responding to issues related to the contract work in a timely manner. Upon request and in the event of an emergency, the KSANG will install and maintain a portable, trailer mounted 50 ton Roof Top Air Conditioning System. Also, Roughly 10 tons of building air can also be diverted to the server farm via the DDC controls as well. KSANG will service the existing CRAC Units to ensure function and respond to system failures 24/7/365. The contractor must be available in the event their work is causing the failure/issue leading to higher temperatures in the server farm.

Computer Room Air Conditioning Unit Specifications:

Computer Room Air Conditioning (CRAC) Unit Precision Cooling System – INDOOR UNIT Specifications ꞏ Capacity: Nominal 105kW (30 Ton) ꞏ Configuration: Air Cooled / Upflow ꞏ Voltage: 460 Volt, 60Hz, 3 Phase, 65,000 amps RMS Short Circuit Current Rating ꞏ Locking Disconnect Switch ꞏ Supply Air Configuration: Exits top of cabinet – shall be connected to existing ductwork via flexible/canvus duct ꞏ Return Air Configuration: Front return w/ grille ꞏ Humidifier: Infrared w/ automatic flush cycle; Capacity: 22 lbs/hr ꞏ Reheat: Three-stage, Finned tubular, 304/304 stainless steel electric; Capacity: 25kW ꞏ Refrigerant: R-407C or R-410A; field supplied and field charged on air-cooled units ꞏ Condensate Pump: factory installed dual float w/ unit alarm and high water shutdown. Rated for 100GPH at 20 ft head ꞏ Provide with leak detection, provide link for alarm on BMS and local display ꞏ Plenum: no, unit shall be connected to existing ductwork by others ꞏ Floorstand: yes, may reuse existing if it is compatible with new unit ꞏ Frame: 14 gauge, welded frame, with protective A-coating or E-coating.

ꞏ Frame can be field separated into three sections for transport through small areas (Unit shall be brought into the building through a standard 4’x7’ door opening) ꞏ Front Service Access ꞏ Exterior panels insulated & powder coated ꞏ 4" filters, MERV 8 rating ꞏ Centrifugal blower, minimum 200,000 hours L3 permanently lubricated pillow-block bearings. Static regain duct attached to bottom of blower ꞏ Dual fixed-pitch motor sheaves, dual fixed-pitch fan pulleys, dual belts and automatic belt-tensioning system ꞏ Open Drip Proof NEMA Premium Efficiency Motor ꞏ Dual refrigeration circuits with liquid line filter driers, refrigerant sight glasses, expansion valves, and liquid line solenoid valves ꞏ Two (2) independent Digital Scroll Compressors provide variable capacity, increased part-load energy efficiency, and reduced compressor cycling ꞏ A-frame Evaporator coil with stainless steel drain pan ꞏ Digital Controls with High Definition Display ꞏ Universal Building Management System communication w/ SNMP and BACnet IP (Ethernet Port); Ensure compatibility with existing BMS by Coordinating with Sandifer Engineering, Wichita, KS

Air-Cooled Microchannel Condensing Unit – OUTDOOR UNIT ꞏ Voltage: 460 Volt, 60Hz, 3 Phase, 65,000 amps RMS Short Circuit Current Rating ꞏ Legs: 18.0” aluminum, minimum ꞏ Microchannel aluminum coil ꞏ Variable Speed EC Fans

- Low Ambient temperature contols ꞏ Premium electronic control board providing communication with interior unit and BMS ꞏ Aluminum exterior panels ꞏ Dual refrigerant circuit condenser ꞏ R-407C or R-410A Refrigerant

Factory Services

ꞏ Parts Warranty: One Year Manufacturer’s warranty ꞏ Labor Warranty - Installation: One year to be provided by installer ꞏ Extended Compressor Warranty: Five year parts only, Labor not included ꞏ CAT5/6 networking cable(s) for BMS communication to be provided and installed by controls contractor

SW-4 CODES & STANDARDS: All work performed under this contract shall be in accordance with federal, state and local codes & standards, as well as widely accepted industry standards, including but not limited to:

International Building Codes, International Mechanical Code, International Plumbing Code, American Institute of Architects, American Concrete Institute, American Institute of Electrical Engineers, American Institute of Steel Construction, American National Standards Institute, American Society of Heating, Refrigerating and Air- Conditioning Engineers, American Society of Mechanical Engineers, American Society of Testing Materials, National Bureau of Standards, National Electric Code, American Welding Society, Brick Institute of America, Building Officials and Code Administrators, Federal Aviation Administration, National Fire Protection Association, Occupational Safety & Health Administration, Rubber Manufacturers Association, Underwriters Laboratories, and the Kansas DOT. standard specification. Additionally, all requirements of the Kansas Department of Health must be satisfied in their entirety for any work performed or materials bought under this contract. Failure to comply with any of the aforementioned codes and standards shall be considered as a failure to comply to contract specifications.

SW-5 UTILITIES: Contractors shall coordinate with all local utilities having jurisdiction: Kansas Gas and Electric, Wichita Water Dept., Southwestern Bell, AT&T, Wichita Sewer Dept. and the Base Engineers Office.

SW-6 CALL BEFORE YOU DIG: All contractors shall be responsible for “Call Before You Dig” for any excavations or penetrations into the ground greater than 4” deep. In addition, all contractors shall apply for a digging permit to the Base Engineers Office for any excavations or penetrations into the ground, greater than 4” deep. The contractor should expect a minimum of 7 days from the date of the request to the issuance of a permit.

The Contractor is encouraged to attend the Digging Permit Meeting. These meetings are scheduled for every Tuesday at 10:00 A.M.

SW-7 CONFINED SPACE: The Contractor shall provide a confined space entry permit to the Base Engineers Office prior to any entry into a permit-required confined space. The following steps shall be accomplished to acquire authorization to open or enter a confined space:

1. The Contractor shall provide written notice to the Contracting Office Technical Representative, (COTR) defining exact location of space requiring entry.

2. A KANG Confined Space Supervisor shall brief the Contractor on the following:

a. The contents of the space and known hazards that make the space permit-required.

b. The precautions and procedures that have been implemented by the organization to protect KANG personnel.

c. Emergency rescue responsibilities to determine whether the Contractor supplies the rescue team or if the installation fire department is expected to supply a rescue function.

d. It is the Contractor’s responsibility to contact the Fire Chief on the installation if the Contractor is planning to use the installation fire department as a rescue function.

e. Standard procedures if the project requires a combined effort involving both KANG and contracted personnel to access the space at the same time.

f. Contractor shall follow Air Force Occupational Safety and Health Standard 91-25 and

Occupational Safety and Health Administration 29 CFR 1910.146.

3. A written record of the briefing shall be signed by the Contractor and Confined Space Supervisor and kept on file in the project folder.

4. The Contractor accepts full responsibility at this point to initiate and maintain the permit and supply all material, equipment and labor to test, monitor, enter and exit the space in a safe manner.

5. The Contractor’s Confined Space Entry Permit shall be kept on site during entry to the space. A copy of the Contractor’s Permit shall be returned to the COTR at the completion of the project.

SW-8 MATERIALS: The materials shall conform to specifications, applicable industry codes and standards and the manufacturer's recommendations, which ever is more stringent. Certificates of compliance and Technical Data Sheets are required for all materials supplied.

SW-9 SITE INSPECTION: The Contractor is required to acknowledge, at time of Bid Opening that said contractor has inspected, and is fully cognizant of conditions at the site. No allowance or consideration will be given after award for any condition(s) which was(were) existing at the time of the site visit.

SW-10 BASE ACCESS: The contractor shall comply with all applicable installation/facility access and local security policies and procedures, which may be obtained from the Contracting Officer’s Representative (COR). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the local installation’s Security Forces, Director of Emergency Services or local Security Office. The contractor shall ensure compliance with all personal identity verification requirements as directed by DoD, HAF and/or local policy. Should the Force Protection Condition (FPCON) change, the Government may require changes in contractor security matters or processes. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (AFI 31-101 and AFI 10-245), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations. The contractor shall be provided an electronic Base Access Form to be filed out and submitted electronically to the Project Manager. The security check process can take up to 5 days to be processed by the 22nd Security Forces. The Project Manager will notify the General Contractor once the requests have been processed. Approved individuals must provide picture identification and if driving they will need a valid driver’s license, auto registration and proof of insurance at the time they pick up their Badges at the Visitor Center located at the East Gate off Rock Road. After Contractors have their Badge they should enter the Base at the West Gate.

Access is limited to locations noted on the Badge. All other areas are off limits. Vehicle Passes are not transferable to other vehicles. The Government reserves the right to deny access to any person, with no consequence to the contract.

SW-11 SAFETY: Compliance with OSHA and other applicable laws and regulations for the protection of employees is exclusively the obligation of the commercial contractor. Government employees must comply with

AFOSH.

SW-12 CLEAN-UP: Clean-up and remove debris generated by this contract to an approved off-base location. Two

(2) copies of the receiving (tipping or dumping) tickets, with a cover letter from the Prime Contractor stating the full name and address of the location to which debris was taken.

SW-13 GOVERNMENT RESOURCES: No Government resources shall be made available to the contractor, unless otherwise stated in this Statement of Work. The contractor shall provide for all necessary resources to provide a complete and usable facility or systems as described in the contract documents. The contractor shall not obligate Government resources in any manner. The Government shall seek remedy for any obligation or encumbrance imposed by the Contractors actions. Government resources include, but are not limited to, government owned materials, equipment, tools, vehicles, personnel and facilities.

SW-14 ATTACHMENTS

Building 54 Floor Plan with Construction Notes (2 Sheets)

-MD-1 DEMO #2 CRAC UNIT AND COOLANT LINES

-M-1 REPLACE #2 CRAC UNIT

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job $222,935.00 $222,935.00 Base Bid Project # 222015

FFP

Non personal services: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary to Replace CRAC Unit #2 at Building 54 in accordance with orginal solicitation and changes in amendment 01 to the soliciation acknowledged by SGI on their bid at time of bid opening.

Amendment 01 covered a revised SOW, revised drawings and updated Wage Determination.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination MFR PART NR: CRAC Unit Replacement

PURCHASE REQUEST NUMBER: F7V3MS2235A001

SIGNAL CODE: A

PSC CD: Z2BG

NET AMT $222,935.00

ACRN AA

CIN: 00000000000008109555

$222,935.00

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 184 KS AIR NATIONAL GUARD

57330 MUSTANG DRIVE

BLDG 3 184 CES

MCCONNELL AFB KS 67221-

Government 184 KS AIR NATIONAL GUARD

57330 MUSTANG DRIVE

BLDG 3 184 CES

MCCONNELL AFB KS 67221-

Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 24-AUG-2022 TO

29-DEC-2023

N/A 184 KS AIR NATIONAL GUARD

JOHN IVES

57330 MUSTANG DRIVE

BLDG 3 184 CES

MCCONNELL AFB KS 67221-9013

316.759.7476 FOB: Destination

F7V3CE

Section 00700 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-20 Contracts for Materials, Supplies, Articles, and Equipment JUN 2020 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-50 Combating Trafficking in Persons NOV 2021 52.222-54 Employment Eligibility Verification MAY 2022 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001

52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons.

JUN 2016

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners.

JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.223-20 Aerosols JUN 2016 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.228-2 Additional Bond Security OCT 1997 52.228-11 (Dev) Individual Surety--Pledge of Assets (DEVIATION 2020-

O0016)

FEB 2021

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 (Dev) Performance and Payment Bonds-Construction. (Deviation

2020-O0016)

JUN 2020

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

NOV 2021

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Products and Commercial

Services

JAN 2022

52.246-21 Warranty of Construction MAR 1994 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General AUG 2019 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7020 NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.211-7003 Item Unique Identification and Valuation MAR 2022 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities MAR 2022 252.225-7048 Export-Controlled Items JUN 2013 252.225-7972 (Dev) Prohibition on the Procurement of Foreign-Made Unmanned

Aircraft Systems (DEVIATION 2020-O0015)

MAY 2020

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

DEC 2018

252.232-7004 (Dev) DoD Progress Payment Rates (DEVIATION 2020-O0010) MAR 2020 252.232-7010 Levies on Contract Payments DEC 2006 252.232-7017 Accelerating Payments to Small Business Subcontractors--

Prohibition on Fees and Consideration

APR 2020

252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 420 days after NTP. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2021)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees if the acquisition--

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code assigned to contract number .

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture.

[The Contractor shall enter the name or names of the…