SUBCONTRACTOR_DATA_FORM.pdf

This is a Subcontractor Data Form for Dorchester County in South Carolina related to a Request for Proposals for Job Order Contracting (JOC) Services for General Construction Projects. The form serves as a mandatory document that prime contractors must complete and submit with their original response to the solicitation. Respondents are required to list all subcontractors that will be utilized on the project, including each subcontractor's business name, address, phone number, and principal contact name, along with a brief description of the goods or services each subcontractor will provide. The form also requires respondents to indicate whether any licenses or certifications required by South Carolina law apply to each subcontractor or its employees.

Failure to complete the Subcontractor Data Form in its entirety or to submit it with the original proposal response may result in rejection of the bid. Prime contractors must use the prescribed form exactly as provided; substitutions are not acceptable. Additional copies of the form may be attached if additional space is needed to list all subcontractors being proposed for the project. This requirement ensures transparency in the subcontracting process and allows Dorchester County to verify the qualifications and compliance of all entities involved in project delivery.