SPRDL126Q0049-0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No. 3. Effective Date 4. Requisition/Purchase Req No. 5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code) 9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print) 16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0001 2026APR08

SPRDL1

DLA WEAPONS SUPPORT (WARREN)

WARREN, MI 48397-5000

ALEXANDRA STONE

EMAIL: ALEXANDRA.STONE@DLA.MIL

SPRDL1-26-Q-0049

2026APR06

X

X

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 4

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SUPPLEMENTAL INFORMATION

Buyer Name: ALEXANDRA STONE

Buyer Office Symbol/Telephone Number: ZGAB/(385)591-0886

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

The purpose to amendment P0001 to solicitation SPRDL1-26-Q-0049 is for the following

A change to narrative ES6304 Notice Regarding First Article Test Sample

The changes are below

The approved first article items, as described elsewhere in this contract, consist of a quantity of 3 that will be consumed or destroyed in testing.

A quantity of 0 that successfully passes all specified tests, less the destructive tests, if any, shall serve as a manufacturing standard for the remainder of the contract.

All other terms and conditions remain the same

*** END OF NARRATIVE A0003 ***

2 4

SPRDL1-26-Q-0049

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

INSPECTION AND ACCEPTANCE

ES6019

Use of MIL-STD 1916

a. The Government will not accept lots whose samples submitted for acceptance contain non-conformances unless appropriately documented and approved by the Procuring Contracting Officer (PCO). The Contractor shall use MIL-STD 1916, DOD Preferred Methods of Acceptance of

Product. The Verification Level (VL) shall be VL IV for major characteristics and VL II for minor characteristics.

b. MIL-STD HDBK-1916 provides guidance on the use of MIL-STD 1916. This handbook is not contractually binding.

************ End of Narrative ************

ES6304

Notice Regarding First Article Test Sample

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 3 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 0 that successfully passes all specified tests, less the destructive tests, if any, shall serve as a manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design, 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the Contractor will notify the Procuring Contracting Officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

************ End of Narrative ************

ES7001

Inspection and Acceptance Points - Origin

The Government's inspection and acceptance of the supplies offered under this contract/purchase order shall take place at ORIGIN.

Offeror must specify below the exact name, address, and CAGE of the facility where supplies to be furnished under this contract/purchase order will be available for inspection/acceptance.

INSPECTION POINT:

(Name) (CAGE)

(Address) (City) (State) (Zip)

ACCEPTANCE POINT:

(Name) (CAGE)

Address) (City) (State) (Zip)

************ End of Narrative ************

3 4

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

ES7032

Notice Regarding First Article

(a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Procuring Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(b) When any of the conditions above occurs, the Contractor shall notify the Procuring Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

************ End of Narrative ************

ES7043

Interchangeability of Components

(a) DESIGN CHANGES TO ITEMS NOT UNDER GOVERNMENT DESIGN CONTROL. Once the Government accepts the first production test item, or accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under

Government design control.

(b) WHEN THE POLICY CAN BE WAIVED. The Procuring Contracting Officer (PCO) will consider waiving this policy at your request. If your request reaches the PCO after the first production item test has been performed, then we may conduct another first production test at your expense.

(c) PRODUCTION OR DELIVERY DELAYS. Any production or delivery delays caused by this retesting will not be the basis for:

(1) an "excusable delay" as defined in the DEFAULT clause of this contract.

(2) be the basis for an increase in contract price or delivery schedule extension.

************ End of Narrative ************

ES7345

Delegation of Authority for First Article Approval

The Defense Contract Management Agency (DCMA) Administrative Contracting Officer (ACO) is hereby delegated the authority to approve or disapprove the First Article Test Report submitted in accordance with this contract (FAR 52.209-3 First Article Testing- Contractor

First Article). Any reference to Procuring Contracting Officer (PCO) as it relates to the submission of, and approval/disapproval of the

FAT Report shall be deemed to mean the DCMA ACO. ACO approval will be predicated upon Quality Assurance Representative (QAR) acceptance of the FAT Report. ACO approval authorizes the Contractor to proceed with production.

************ End of Narrative ************

*** END OF NARRATIVE E0001 ***

4 4