SPRDL116Q0278-0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No.

3. Effective Date

4. Requisition/Purchase Req No.

5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code)

9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In

The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set

Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print)

16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0001 2016NOV23

SPRDL1

DLA LAND WARREN

WARREN, MI 48397-5000

ROBERT HARRISON

EMAIL: ROBERT.W.HARRISON30.CIV@MAIL.MIL

SPRDL1-16-Q-0278

2016APR11

X

X 2016DEC30 04:00pm

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 16

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SUPPLEMENTAL INFORMATION

Buyer Name: ROBERT HARRISON

Buyer Office Symbol/Telephone Number: ZGA/(586)282-3200

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

Amendment 0001:

1. Amendment 0001 to SPRDL1-16-Q-0278 is to change procurement to Full and Open.

2. TDP link has been added

3. FAT Clauses added to solicitation

4. Part # has been changed in CLIN 0001AA and 0002AB to reflect TDP part # and date of current TDP

5. Closing date extended to 30 Dec 2016

6. All other terms of the original solicitation remain unchanged.

*** END OF NARRATIVE A0001 ***

2 16

SPRDL1-16-Q-0278 0001

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SUPPLIES OR SERVICES AND PRICES/COSTS

0001 WEAPON CONTROL UNIT

NSN: 1010-01-257-9961

Mfr CAGE: 53711

Mfr Part Number: 6289560

0001AA PRODUCTION QUANTITY 10 EA $ $ ____________________ ______________ __________________

COMMODITY NAME: WEAPON CONTROL UNIT

CLIN CONTRACT TYPE:

Firm Fixed Price

PRON: EH6V1217EH PRON AMD: 01

AMS CD: SM2B1100000

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 6289560

DATE: 28-APR-2016

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

SEE PACKAGING REQUIREMENTS CLAUSE

LEVEL PRESERVATION: Military

LEVEL PACKING: A

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

THERE IS A REQUIREMENT FOR FIRST

ARTICLE TESTING.

Your proposed price for this Production __________

SubCLIN 0001AA must include the cost___________________________ of the First Article Testing.

See Data Item SubCLIN 0001AB: First

Article Test Report.

The Date Item SubCLIN 0001AB is

"Not Separately Priced", which is _____________________ why the cost of testing must be included in this Production

SubCLIN 0001AA.

(End of narrative E001)

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 W56HZW6035T051 W562RP J 2

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

3 16

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

001 10 0510

FOB POINT: Destination

SHIP TO:

(W562RP) SR W0LX ARMY GENERAL SUPPLY

DLA DISTRIBUTION ANNISTON

7 FRANKFORD AVE

ANNISTON,AL,36201-4199

4 16

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0001AB DATA ITEM: FIRST ARTICLE TEST REPORT 1 EA $ ** NSP ** $ ** NSP ** ____________________________________ ______________ __________________

COMMODITY NAME: FIRST ARTICLE TEST REPORT

1 EA = 1 Each Test____

Report on Contractor

Performed First

Article Test (FAT)

NSP = Not Separately___

Priced.

(End of narrative B001)

FIRST ARTICLE TEST REPORT, PURSUANT TO THE

REQUIREMENTS OF THE CLAUSE ENTITLED "FIRST

ARTICLE APPROVAL - CONTRACTOR TESTING."

(SEE SECTION I OF THIS DOCUMENT.)

NOTE TO OFFEROR:

Please fill in the dollar amount you have

INCLUDED in Production CLIN 0001AA to cover the cost of performing FAT (First Article

Testing) and writing the FAT Report:

WE ARE REQUESTING OFFERORS TO FILL IN

THE DOLLAR AMOUNT IN THE PARAGRAPH ABOVE

SO WE WILL KNOW HOW MUCH TO SUBTRACT

FROM THE PRODUCTION CLIN IF WE WAIVE

FIRST ARTICLE TEST.

(End of narrative C001)

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Destination

Government Approval/Disapproval Days: 30

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 3

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 1 0120

FOB POINT: Destination

SHIP TO:

5 16

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

(Y00006) SEE FIRST ARTICLE TEST CLAUSE

FOR DISTRIBUTION

6 16

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0002 WEAPON CONTROL UNIT

NSN: 1010-01-257-9961

Mfr CAGE: 53711

Mfr Part Number: 6289560

0002AA UNEXERCISED OPTION QUANTITY 10 EA $ $ ___________________________ ______________ __________________

COMMODITY NAME: WEAPON CONTROL UNIT

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 6289560

DATE: 28-APR-2016

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

SEE PACKAGIING REQUIREMENTS CLAUSE

LEVEL PRESERVATION: Military

LEVEL PACKING: A

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 10 0360

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

7 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

Status Regulatory Cite Title Date Status Regulatory Cite Title Date _______ _______________ ______________________________________________________________________ ____________ _______ _______________ ______________________________________________________________________ ____________

1 CHANGED 52.211-4072 TECHNICAL DATA PACKAGE INFORMATION SEP/2015

(TACOM)

The following Xd item applies to this solicitation:

[ X ] 1. The TDP for this solicitation resides within FedBizOpps (https://http://www.fbo.gov), and is associated with this solicitation number and can be accessed via this URL:

https://www.fbo.gov/notices/aef84002c8c26d5d4fa8a2585cb05393

a. Log on to the FBO web site.

b. Enter your Marketing Partner Identification Number (MPIN).

c. Search for the solicitation number.

d. If solicitation is Export Controlled, select Verify MPIN.

(1) TDPs that have an Export Control Warning Notice are subject to the Arms Export Control Act (Title 22, U.S.C., Sec 2751, et.seq.)

or the Export Administration Act of 1979, as amended, Title 50, U.S.C, App. 2401 et. seq..

(2) Further dissemination must be in accordance with provisions of DoD Directive 5230.25. This also applies to distribution of the TDP to all SUBCONTRACTORS at every level.

(3) To obtain these TDPs, vendors and contractors must have a current DD 2345, Militarily Critical Technical Data Agreement on file with Defense Logistics Information Service (DLIS). If you are currently certified, your MPIN will be verified and you may proceed to the next step. To obtain certification, go to http://www.dlis.dla.mil/jcp/ click on documents and follow instructions provided.

Processing time is estimated at six (6) to ten (10) weeks after receipt. FBO will allow you to access export controlled TDPs once certification is confirmed.

(4) Upon completion of the purposes for which Government Technical Data has been provided, the Contractor is required to destroy all documents, including all reproductions, duplications, or copies thereof as may have been further distributed by the Contractor.

Destruction of this technical data shall be accomplished by: shredding, pulping, burning, or melting any physical copies of the TDP and/or deletion or removal of downloaded TDP files from computer drives and electronic devices, and any copies of those files.

e. If technical data is otherwise restricted, select Request Explicit Access. This will generate an email to the FBO system administrator at TACOM Warren with all the information needed for them to grant you access. FBO will subsequently automatically generate an email stating when you have permission to view or download TDP items. Allow 2 3 working days to complete this FBO-TDP access/approval process through the FBO system.

f. If multiple individuals in your company need access to the Technical Data Package (TDP) for a solicitation and an explicit access request is required, each individual MUST submit an explicit access request to be granted approval to view the TDP. Those same individuals MUST be registered in Federal Business Opportunities (FBO). Any individuals no longer with the company should be deleted.

Questions related to registration in FBO should be directed to https://www.fbo.gov/index The FBO helpdesk phone number is (866) 606-

8220. Vendors are responsible for placing correct information in FBO.

g. It is strongly suggested that you submit the explicit access request and provide the contract specialist with the completed Use and

Non-Disclosure Agreement at the same time if the solicitation requires both to gain access to view the TDP.

h. A user guide for FBO can be found at https://http://www.fbo.gov - on the right is User Guides - click on Vendor.

[ ] 2. The Government requires a Use and Non-Disclosure Agreement (NDA) to be signed by an authorized representative of your firm before you are granted access to the technical data. The appropriate Agreement is titled -4-, and is:

[ ] available by emailing the contract specialist listed on page 1 of this solicitation.

[ ] available as an attachment to this solicitation.

Follow the instructions on the Agreement, and email/fax it to the contract specialist at -5-. The contract specialist will notify the

FBO administrator upon receiving the NDA. The administrator will grant approval to view/download the TDP. An email stating approval has been granted will be sent to the vendor. It can take up to 24 hours after approval before you are able to view the TDP. If you have any questions/problems viewing the TDP contact the contract specialist.

8 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

[End of Clause]

2 CHANGED 52.246-4053 USE OF MIL-STD 1916 JAN/2001

(TACOM)

The Government will not accept lots whose samples submitted for acceptance contain nonconformances unless appropriately documented and approved by the contracting officer. The contractor shall use MIL-STD-1916, DOD Preferred Methods of Acceptance of Product. The

Verification Level (VL) shall be VL IV for major characteristics and VL II for minor characteristics. MIL-HDBK-1916 provides guidance on the use of MIL-STD 1916.

[End of Clause]

3 ADDED 52.211-4008 DRAWING LIMITATIONS NOV/2005

(TACOM)

(a) The drawings supplied with this contract are not shop or process drawings. They are engineering design drawings. They are ___ adequate to permit manufacture, and:

(1) depict the completed (item(s), and

(2) serve as the basis for inspection of the completed item(s).

(b) These drawings DON'T cover intermediate drawings/specifications or steps in the manufacturing process. As a result, even if you meet all the dimensions and tolerances specified in the engineering design drawing for each individual part, a cumulative unacceptable fit for the contract item could result.

(c) The Contractor is responsible for producing the shop or process drawings needed to cover intermediate steps in the _____________________________ manufacturing process.

(d) The Contractor is responsible for obtaining all specifications and drawings necessary to manufacture the items being solicited _____________________________ in accordance with the TDP including all incorporated specifications and drawings. Delivery delays are not excusable where the contractor asserts that it did not have a specification or drawing and has failed to request, in writing, the specification from either the Contracting Officer or Contract Specialist prior to the solicitation closing date.

(e) If you fail to produce an end item with a cumulative fit that conforms to Government drawings, specifications or other supplemental manufacturing documentation, you'll be responsible for correcting this condition at no additional cost to the Government and no delivery schedule extension.

[End of clause]

4 DELETED 52.211-4010 ACQUISITION OF SOURCE-CONTROLLED PART NUMBER FEB/1998

(TACOM)

5 ADDED 52.211-4015 CONFIGURATION CONTROL - ENGINEERING CHANGES JAN/2016

(TACOM)

(a) The contractor may submit Engineering Change Proposal(s) (ECPs) and Request for Variance(s) (RFVs) for the requirements in the

Government provided Technical Data Package (TDP). The contractor shall prepare and submit ECPs, Notice of Revision(s) (NORs), and RFVs as required by the accompanying DD Form 1423, Contract Data Requirements List (CDRL). If a Value Engineering Change Proposal(s) (VECPs) clause is included on this contract, VECPs shall be submitted in the same manner as ECPs.

(1) ECPs - The contractor may request a permanent change to the requirements specified in the TDP or any other baseline documentation by submitting an ECP. ECPs shall be submitted to include all NORs necessary to completely define the requested change. Each ECP shall be accompanied with at least one NOR per affected document. The contractor shall not present any production items for acceptance that incorporate any change to the TDP or other baseline documentation until notified by the Government the ECP has been approved and incorporated in the contract.

(i) Page 1 of DD Form 1692 (or equivalent) shall be submitted for all ECPs. Pages 2-7 of DD Form 1692 shall be submitted when required to properly explain all the potential logistics and technical impacts of the proposed change. DD Form 1695 NOR or DD

Form 1695-1 Tabulated NOR (or equivalents) shall be submitted to completely describe the desired change on each affected document.

(ii) All ECPs submitted by the contractor will be routine priority unless otherwise justified. If the contractor considers

9 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

the ECP to be emergency or urgent, they shall include justification within 48 hours of submittal of the ECP.

(2) RFVs - The contractor may request to temporarily depart from a requirement specified in the TDP or any other baseline documentation, by submitting an RFV. RFVs may be submitted either pre-production (formerly known as Request for Deviation (RFD)) or post-production and prior to acceptance by the Government (formerly known as Request for Waiver (RFW)). DD Form 1694 (or equivalent) shall be submitted for all RFVs. The contractor shall not present any production items for acceptance with any nonconformance to the requirements in the TDP or other baseline documentation until notified by the Government the RFV has been approved and incorporated in the contract.

(b) Submission of requested changes - The submission of an ECP or RFV by the Contractor does not affect the required delivery dates specified within the contract, shall not constitute excusable delay in the performance of this Contract by the Contractor or in any way relieve the contractor from compliance with the contract delivery schedule. If a delivery date change is needed, it must be negotiated with the Contracting Officer and documented via modification to the contract. The submission of an ECP and/or RFV by the Contractor shall not preclude the Government from exercising its rights under any clause of the Contract.

(c) Specifications - Permanent proposed changes to specifications which are part of the TDP or baseline documentation shall be requested with an ECP and NOR (i.e. Specification Change Notices (SCNs) are not required).

(d) Forms If any of the above listed forms are not included with the solicitation or contract, the contractor may contact the contract specialist listed on page 1 of the solicitation or contract for copies of the forms.

(End of clause)

6 DELETED 52.211-4018 ACQUISITION OF MANUFACTURER'S PART NUMBER MAY/1996

(TACOM)

INSPECTION AND ACCEPTANCE

7 DELETED 52.246-15 CERTIFICATE OF CONFORMANCE APR/1984

8 CHANGED 52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT DEC/2014

(a) The contractor shall comply with the higher-level quality standard(s) listed below.

ISO 9001:2008 (tailored: delete 7.3)

(b) The contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts in--

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require--

(i) Control of such things as design, work operations, in-process control, testing and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

9 CHANGED 52.209-4000 NOTICE REGARDING FIRST ARTICLE TEST SAMPLE MAR/2000

(TACOM)

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 2 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 0 that successfully passes all specified tests, less the destructive tests, if any, shall not serve as a manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design. 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it

10 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

meets all contractual requirements existing at time of delivery.

10 CHANGED 52.209-4333 INSPECTION AND ACCEPTANCE (FIRST ARTICLE APPROVAL) APR/2006

(TACOM)

In addition to inspection requirements specified in applicable drawings and/or specifications, the following provisions shall apply to this contract:

(1) FIRST ARTICLE APPROVAL-CONTRACTOR TESTING: First Article Approval-Contractor Testing shall be performed in accordance with FAT IAW Spec. #6288950.

(2) The First Article Test Report (FATR) shall be compiled by the contractor to the contractor's own format.The FATR shall document the results of all inspections and tests (including supplier's and vendor's inspection records and certifications, when applicable). The FATR shall include actual inspections and test results to include all measurements, recorded test data, and certifications (if applicable) keyed to each drawing, specification and Quality Assurance Provision (QAP) requirement and identified by each individual QAP characteristic, drawing/specification characteristic and unlisted characteristic. The FATR shall contain sufficient narrative content, technical data, illustrations or photographic evidence, and an objective determination by the contractor to allow the designated Government representative to determine that the First Article Test was successfully completed.

[End of Clause]

11 ADDED 52.209-4012 NOTICE REGARDING FIRST ARTICLE APR/2000

(TACOM)

(a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

[End of Clause]

12 DELETED 52.246-4803 DRAWINGS FOR INSPECTION JAN/2013

(DLA LAND

WARREN)

DELIVERIES OR PERFORMANCE

13 CHANGED 52.242-4022 DELIVERY SCHEDULE SEP/2008

(TACOM)

(a) Delivery under this contract must conform to the required schedule specified below, unless acceleration is acceptable.

(b) DEFINITIONS:

(1) DAYS means the number of days after the date of contract award when you must deliver the stated quantity (QTY) of supplies.

(2) DELIVERY is defined as follows:

11 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

FOB Origin - Contractor is required to deliver its shipment as provided in FAR 52.247-29(a)(1)-(4) by the time specified in the individual contract; or

FOB Destination - Contractor is required to deliver its shipment as provided in FAR 52.247-34(a)(1)-(2) by the time specified in the individual contract. The contractor must take into consideration the length of time necessary to deliver its shipment to the destination designated in the contract, to ensure that the item reaches its destination by the time reflected in the contract.

(c) The Government requires delivery to be made according to the following schedule:

(1) GOVERNMENT REQUIRED DELIVERY SCHEDULE WITH FIRST ARTICLE TEST (FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

0001AA 10 510 DARO

0001AB 1 120 DARO

0002AA 10 360 DARO - upon exercise of option

(2) GOVERNMENT REQUIRED DELIVERY SCHEDULE IF THERE IS NO FIRST ARTICLE TEST (FAT), OR IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

0001AA 10 360 DARO

0002AA 10 360 DARO - upon exercise of option

(d) Accelerated delivery schedule IS acceptable.

(e) If an accelerated delivery schedule is not acceptable, the required delivery schedule above will apply. If it is acceptable, you may propose an accelerated delivery schedule at no additional cost; fill in the appropriate information here:

(1) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITH FIRST ARTICLE TEST (FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

(2) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITHOUT FIRST ARTICLE TEST (FAT), or IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

[End of Clause]

12 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

CONTRACT CLAUSES

14 ADDED 252.227-7013 RIGHTS IN TECHNICAL DATA--NONCOMMERCIAL ITEMS FEB/2014

15 ADDED 252.227-7037 VALIDATION OF RESTRICTIVE MARKINGS ON TECHNICAL DATA SEP/2016

16 ADDED 252.246-7001 WARRANTY OF DATA--BASIC MAR/2014

17 CHANGED 52.209-3 FIRST ARTICLE APPROVAL -- CONTRACTOR TESTING (SEP 1989) -- ALTERNATE SEP/1989

I (JAN 1997) AND ALTERNATE II (SEP 1989)

(a) The Contractor shall test 2 unit(s) of Lot/Item 0001AA as specified in this contract. At least 20 calendar days before the beginning of first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests.

(b) The Contractor shall submit the first article test report within 120 calendar days from the date of this contract to Contracting

Officer - Robert Harrison robert.harrison@dla.mil marked First Article Test Report: Contract No. __________________, Lot/Item No. _______________________

______. Within 30 calendar days after the Government receives the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article. The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval.

(c) If the first article is disapproved, the Contractor, upon Government request, shall repeat any or all first article tests. After each request for additional tests, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing. All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall then conduct the tests and deliver another report to the

Government under the terms and conditions and within the time specified by the Government. The Government shall take action on this report within the time specified in paragraph (b) above. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule, or for any additional costs to the Government related to these tests.

(d) If the Contractor fails to deliver any first article report on time, or the Contracting Officer disapproves any first article, the

Contractor shall be deemed to have failed to make delivery within the meaning of the Default clause of this contract.

(e) Unless otherwise provided in the contract, and if the approved first article is not consumed or destroyed in testing, the Contractor may deliver the approved first article as part of the contract quantity if it meets all contract requirements for acceptance.

(f) If the Government does not act within the time specified in paragraph (b) or (c) above, the Contracting Officer shall, upon timely written request from the Contractor, equitably adjust under the changes clause of this contract the delivery or performance dates and/or the contract price, and any other contractual term affected by the delay.

(g) Before first article approval, the Contracting Officer may, by written authorization, authorize the Contractor to acquire specific materials or components or to commence production to the extent essential to meet the delivery schedules. Until first article approval is granted, only costs for the first article and costs incurred under this authorization are allocable to this contract for

(1) progress payments, or

(2) termination settlements if the contract is terminated for the convenience of the Government. If first article tests reveal deviations from contract requirements, the Contractor shall, at the location designated by the Government, make the required changes or replace all items produced under this contract at no change in the contract price.

(h) The Government may waive the requirement for first article approval test where supplies identical or similar to those called for in the schedule have been previously furnished by the offeror/contractor and have been accepted by the Government. The offeror/contractor may request a waiver.

(i) The Contractor shall produce both the first article and the production quantity at the same facility.

(End of Clause)

13 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF OFFERORS

18 ADDED 252.227-7017 IDENTIFICATION AND ASSERTION OF USE, RELEASE, OR DISCLOSURE JAN/2011

RESTRICTIONS

19 ADDED 252.227-7028 TECHNICAL DATA OR COMPUTER SOFTWARE PREVIOUSLY DELIVERED TO THE JUN/1995

GOVERNMENT

20 DELETED 252.217-7026 IDENTIFICATION OF SOURCES OF SUPPLY NOV/1995

21 DELETED 52.211-4038 REPRESENTATION OF INTENT TO SUPPLY A SOURCE-CONTROLLED ITEM APR/1997

(TACOM)

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

22 CHANGED 52.209-4005 CONTRACT PRICE REDUCTION FOR WAIVER OF FIRST ARTICLE TEST FEB/1998

(TACOM)

(a) All offerors are required to insert an amount for 0001AA which includes the full price for First Article testing. ___

(b) In addition, those offerors intending to request a waiver of the First Article Approval requirement, as described elsewhere in this Section L, shall insert the total price for First Article Testing under Item 0001AB (See Section B of this solicitation). If the successful offeror requests and is granted a waiver, the dollar amount entered for item 0001AB will be deducted from the total amount cited for 0001AA. The remaining dollar amount will constitute the price at which award will be made.

[End of Provision]

23 ADDED 52.209-4007 PROVISION FOR WAIVER OF REQUIRED FIRST ARTICLE APPROVAL MAY/2006

(TACOM)

(a) The requirement entitled FIRST ARTICLE APPROVAL in Section I of this solicitation may be waived by the Government, provided that the offeror meets the conditions identified below.

(1) Offerors who intend to request a waiver or partial waiver of the First Article Test must provide sufficient information in order for the Government to determine whether the request is to be approved. If the offeror intends to request a waiver, a First Article

Waiver Worksheet must be completed and submitted to the Government along with any supporting documentation. The worksheet can be found as an attachment/exhibit to the solicitation or by contating the contract specialist on page 1.

The offerors request will not be considered if the worksheet and any supporting documentation is not submitted to the Government. The ___ worksheet must be completed in its entirety. For those sections of the worksheet which do not apply, annotate with N/A (not applicable).

To substantiate or clarify information provided by the offeror, the Government may request additional information

(2) Offerors should not assume that the FAT waiver request will be granted even if the completed worksheet and any supporting information is submitted to the Government.

(3) The worksheet and any additional supporting documentation is part of your quote/offer and must be submitted as part of the response to this solicitation on Company letterhead and signed by an agent of the Company.

(4) The offeror may request a waiver for only a portion of the First Article Test, such as a vibration test or a salt water spray test, or the test on a component or subassembly of the procured item.

(5) The offeror shall list specifically on the worksheet, by technical data package reference, that portion of the test requested to be waived. The references shall include but may not be limited to the following as applicable:

(i) Identification of the specification or standard along with the specific specification or standard paragraph(s)

(ii) Identification of the drawing with specific references to the drawing notes.

(iii) Identification of the Quality Assurance Provision (QAP), or Quality Assurance Requirement (QAR) or Supplemental

Quality Assurance Provision (SQAP)with specific references to the specific paragraph.

(6) Supporting documentation.

14 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(i) The request for waiver must be accompanied by documentation in support of the request. The documentation may include information such as the following; (1) Copy of the Administrative Contracting Officers (ACOs) or Procuring Contracting Officers (PCO) letter approving a First Article Test report on a recent contract for the same or similar item. (2) Copy of a First Article Test report for the same or a similar item as that herein solicited. (3) Copy of an ACO or PCO letter approving a prior waiver request. (4) If the waiver request is based on similarity, a copy of the drawing/other appropriate technical requirements of the similar item.

(ii) If a copy of a First Article Test report is submitted in support of a request for waiver under this solicitation, the test report must have been approved and signed by an authorized representative of the Government.

(iii) The FAT report and all supporting documentation should be submitted by electronic media and should accompany the offerors proposal. If the FAT report and supporting documentation cannot be transmitted by electronic media, the offeror shall contact the PCO for further instruction.

(b) Note that if a waiver is granted to the successful offeror, an accelerated delivery schedule will apply. See Section F.

(c) Note: Cost considerations shall apply for approving a waiver or a portion thereof of a First Article Test.

[End of Provision]

24 DELETED 52.211-4048 NOTICE REGARDING REQUIRED MANUFACTURER'S PART NUMBER FEB/1998

(TACOM)

25 DELETED 52.211-4049 PART NUMBERS NOT CURRENTLY APPROVED NOV/1982

(TACOM)

26 ADDED 52.211-4052 SOURCE NOTES ON DRAWINGS: CONFORMANCE TO MILITARY TECHNICAL DATA NOV/1982

(TACOM) REQUIREMENTS

Notwithstanding the fact that ordnance drawings furnished with this solicitation may list particular manufacturer part numbers as approved sources, or as being the same as, or equivalent to, the ordnance part described on the drawing, the item to be supplied under this solicitation must conform to all specific technical requirements expressed on such drawing(s). To the extent that there may be any inconsistency between a manufacturer's part number and specific technical requirements expressed on an ordnance drawing which references the manufacturer's part number, the specific technical requirements shall control and take precedence. Offerors shall bear the responsibility of verifying that the approved part as supplied will conform with all such specific technical requirements.

[End of Provision]

EVALUATION FACTORS FOR AWARD

27 CHANGED 52.209-4006 EVALUATION FACTORS FOR FIRST ARTICLE TEST REQUIREMENT JUL/2000

(TACOM)

(a) If the offeror submits a request for waiver of First Article Testing but fails to comply with the requirements of the provision entitled PROVISION FOR WAIVER, the requested waiver may not be granted. If the waiver is not granted, more favorable alternative offers of price or delivery, conditioned upon the granting of a waiver, will not be considered in the evaluation process.

(b) DELIVERY EVALUATION FACTORS: ____________________________

(1) As specified in this solicitation, the Government reserves the right to waive the requirement entitled FIRST ARTICLE

APPROVAL, and will require an accelerated delivery schedule if the successful offeror is granted such a waiver. However, in no case will a delivery schedule predicated upon waiver of the First Article Test requirement be considered as an evaluation factor for award, even if such a schedule would be more advantageous to the Government.

(2) If an offeror requests waiver of First Article Testing but takes exception to the accelerated delivery schedule set forth in the Section F clause entitled DELIVERY SCHEDULE (52.242-4022, TACOM) herein, such offeror is not eligible for the requested waiver.

In consequence, any award to that offeror will reflect either (i) the Government-proposed delivery schedule shown in that same clause, or (ii) the contractor-proposed schedule in that clause, if the Goverment has accepted it.

(c) PRICE EVALUATION FACTORS: As specified in this solicitation, the Government reserves the right to waive the requirement in _________________________

15 16

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

Section I entitled FIRST ARTICLE APPROVAL, and requests the price of the proposed First Article Test (at Section B, Item 0001AB) from offerors who elect to seek such a waiver. In the event that the offeror requests and receives a waiver of First Article Test requirements, the price for such testing, as identified by the offeror in Section B, Item 0001AB, shall be deducted from the total price otherwise cited for the materiel herein solicited. The offer will then be evaluated for award at the resulting alternate price.

(1) If the offeror requests a waiver of First Article Test requirements, but fails to separately identify the cost of First

Article Testing in Section B, Item 0001AB of this solicitation, the Government reserves the right to evaluate the offer based upon the price for 0001AA & 0002AA, and to require that offeror perform on the contract at such price whether or not the First Article

Requirement is waived, at no additional cost to the Government.

(2) If the offeror requests but is not granted a waiver of First Article Testing, evaluation for award will be based upon the full amount entered for 0001AA & 0002AA: the amount entered for item 0001AB will not be deducted by the Government. ___

[End of Provision]

16 16