SPMYM418Q0415.docx

SPMYM418Q0415

Section SF 30 - BLOCK 14 CONTINUATION PAGE

SAM

THE FOLLOWING INFORMATION MUST BE PROVIDED OR YOUR QUOTE

WILL NOT BE ACCEPTED

Estimated delivery time ______________ days/month ________ FOB Destination (Vendor pay to Destination)

Business Size (in accordance with Federal Government Standards) Small ______ Large _______ Women-owned _____Disadvantaged _________

Prompt Payment Terms _________% _______ Days Net __________

Basis for price: [ ] Current Catalog: Title (or No.) ________________________

If on GSA Contract: [ ] GSA Contract # _________________________________ [ ] Expiration Date: _________________________________

Cage Code (Commercial & Government Entity No. ________________ DUNS (Dunn & Bradstreet No. ________________________________ SAM (System for Award Management ) Yes No (circle one)

TO OBTAIN A CAGE CODE @ 1-888-352-9333, fax (616) 691-5305, or email disc-cso@disc.dla.mil

TO OBTAIN A DUNS AND BRADSTREET NO. - CALL 1-800-333-0505

Or use web site (http: //www.dnb.com/dunsno/whereduns.htm)(A DUNS NO.

IS MANDATORY DATA FOR REGISTERING IN THE CCR)

The Contractor shall be registered in the SAM database prior to receiving of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

The SAM registration shall be for the same name and address identified on the contract, with its associated CAGE code and DUNS or DUNS+4 Contractors may obtain information on registration and annual confirmation requirements via the SAM accessed through https://www.acquisition.gov or by calling 866-606-8220, or 334-206-7828 for international calls.

Section B - Supplies or Services and Prices

FLEXIBLE CONDUIT

FFP

FLEXIBLE CONDUITFLEXIBLE CONDUIT, 3/4" OUTSIDE DIAMETER, DASH 24 BRASS CORE BRONZE INNER SHIELD, GRAY EPDM OUTER JACKET, ENTRACO P/N: CC261-24. DWG#: CC261-TAB REVISION-, SHEET 1, FIGURE 1 & TABLE 1 & NAVSEA DRAWING 474-8215935 REVISION-A.

ORDERING DATA: A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW WITH ATTACHED SHEET; C) AND D) AS SPECIFIED; E) COMMERCIAL

ONE CONTINUOUS LENGTH

FOB: Destination

NSN: 5975

MILSTRIP: N3225380162705

MFR PART NR: CC261-24

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380162705

PROJECT: NM1

NET AMT

ADAPTER ASSEMBLY

CONDUIT FITTING CRES 316, MALE PIPE THREAD SWIVEL 1"-11-1/2 NPT X DASH 24 CONDUIT END, ENTRACO PART NUMBER: AX0735-3224SP. DWG#: AX#735-TAB REVISION-, SHEET 1 & SHEET 2, FIGURE 1 & TABLES 1 THRU 3.

ORDERING DATA: A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW WITH ATTACHED SHEET; C) AND D) AS SPECIFIED; E) COMMERCIAL

FOB: Destination

NSN: 5975

MILSTRIP: N3225380162706

MFR PART NR: AX0735-3224-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380162706

NET AMT

ADAPTER ASSEMBLY

CONDUIT FITTING STUFFING TUBE "D" ADAPTER, 316 CRES MALE SWIVEL 1-1/4" 12UNEF X DASH 24 CONDUIT END, ENTRACO PART NUMBER: AX0685-4024-SP. DWG#: AX#685-TAB REVISIO-N, SHEET 1 & 2, FIGURE 1 & TABLES 1 THRU 3.

ORDERING DATA: A)CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH); DTD 24 SEP 04 B) FIRST ARTICLE TESTING REQUIRED IAW WITH ATTACHED SHEET; C) & D) AS SPECIFIED E) COMMERCIAL

MILSTRIP: N3225380162707

MFR PART NR: AX0685-4024-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380162707

NET AMT

FLEX CONDUIT

MIL-PRF-24758A, 1" OD, BRASS CORE, GRAY EPDM OUTER JACKET, ENTRACO P/N: CC261-32.

ORDERING DATA: 6.2 A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW ATTACHED SHEET; C & D) AS SPECIFIED; E) COMMERCIAL;

ONE CONTINUOUS LENGTH

FOB: Destination

NSN: 5975

MILSTRIP: N3225380262700

MFR PART NR: CC261-32

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380262700

NET AMT

FLEX CONDUIT

; MIL-PRF-24758A, 1.250" OD, BRASS CORE, GRAY EPDM OUTER JACKET, ENTRACO P/N: CC261-40.

ORDERING DATA: 6.2 A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW ATTACHED SHEET; C & D) AS SPECIFIED; E) COMMERCIAL;

ONE CONTINUOUS LENGTH

FOB: Destination

NSN: 5975

MILSTRIP: N3225380262701

MFR PART NR: CC261-40

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380262701

NET AMT

CONDUIT FITTING STL

STUFFING TUBE CONDUIT FITTING "G" ADAPTER; 316L CRES MALE SWIVEL 1-1/2" 12UNEF X DASH 40 CONDUIT END, ENTRACO SEA-FROST P/N: AX0685-4840-SP.

MILSTRIP: N3225380262702

MFR PART NR: AX0685-4840-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380262702

NET AMT

CONDUIT FITTING

ADAPTER; CIRCULAR FEMALE SWIVEL 316L CRES, 1.4375"-18UNEF X DASH 40 CONDUIT, ENTRACO SEA-FROST P/N: AX0765-21-2440-SP.

MILSTRIP: N3225380262703

MFR PART NR: AX0765-21-2440-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380262703

NET AMT

BOX HUB FITTING

STANDARD BOX HUB FITTING ADAPTER, STRAIGHT, FEMALE SWIVEL CRES 316L PASSIVATED, 1.250-18UNEF X DASH 32 CONDUIT WITH MISTY YOKE, ENTRACO PART NUMBER: AX0737M-4032-SP.

ORDERING DATA: A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW WITH ATTACHED SHEET; C) AND D) AS SPECIFIED; E) COMMERCIAL

MILSTRIP: N3225380542711

MFR PART NR: AX0737M-4032-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380542711

NET AMT

REDUCING BOX HUB FTG

FTGREDUCING BOX HUB FITTING, ADAPTER, PASSIVATED CRES 316L 2"-18UNS X 1.250-18UNEF WITH BOX SEAL, O-RING, WASHER GASKET AND JAM NUT, ENTRACO SEA-FROST PART NUMBER: AX0851-6440-SP.

ORDERING DATA: A) CONDUIT SYSTEMS, FLEXIBLE, WEATHERPROOF; MIL-PRF-24758A(SH) DTD 24SEP04; B) FIRST ARTICLE TESTING REQUIRED IAW WITH ATTACHED SHEET; C) AND D) AS SPECIFIED; E) COMMERCIAL

MILSTRIP: N3225380542712

MFR PART NR: AX0851-6440-SP

PC NR: NONE

PURCHASE REQUEST NUMBER: N3225380542712

NET AMT

CLAUSES INCORPORATED BY FULL TEXT

252.225-7000 BUY AMERICAN--BALANCE OF PAYMENTS PROGRAM CERTIFICATE--BASIC (NOV 2014)

(a) Definitions. Commercially available off-the-shelf (COTS) item, component, domestic end product, foreign end product, qualifying country, qualifying country end product, South Caucasus/Central and South Asian (SC/CASA) state, South Caucasus/Central and South Asian (SC/CASA) state end product, and United States, as used in this provision, have the meanings given in the Buy American and Balance of Payments Program--Basic clause of this solicitation.

(b) Evaluation. The Government--

(1) Will evaluate offers in accordance with the policies and procedures of Part 225 of the Defense Federal Acquisition Regulation Supplement; and

(2) Will evaluate offers of qualifying country end products without regard to the restrictions of the Buy American statute or the Balance of Payments Program.

(c) Certifications and identification of country of origin.

(1) For all line items subject to the Buy American and Balance of Payments Program-- Basic clause of this solicitation, the offeror certifies that--

(i) Each end product, except those listed in paragraph (c)(2) or (3) of this provision, is a domestic end product; and

(ii) For end products other than COTS items, components of unknown origin are considered to have been mined, produced, or manufactured outside the United States or a qualifying country.

(2) The offeror certifies that the following end products are qualifying country end products:

___ (Line Item Number Country of Origin)

___ (Country of Origin)

(3) The following end products are other foreign end products, including end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (ii) of the definition of ``domestic end product'':

(Line Item Number) ___

(Country of Origin (If known)) ___

(End of provision)

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

Section F - Deliveries or Performance

DELIVERY INFORMATION

MIKE WATTERS

RECEIVING DEPT, CODE Z0S

667 SAFEGUARD ST, BLDG 167

JBPHH HI 96860-5033

808-306-1932

N32253

N32253

N32253

N32253

N32253

N32253

N32253

N32253

N32253

Section G - Contract Administration Data

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

52.209-3 FIRST ARTICLE APPROVAL--CONTRACTOR TESTING (SEP 1989)

(a) The Contractor shall test 3 unit(s) of Lot/Item 0001 thru 0009 as specified in this contract. At least 15 calendar days before the beginning of first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests.

(b) The Contractor shall submit the first article test report within __30___ calendar days from the date of this Contract to:

DLA Maritime Pearl harbor Competitive Sourceing Div 667 Safeguard St.

JBPHH, Hawaii 96860-5033 marked "FIRST ARTICLE TEST REPORT: Contract No. , Lot/Item No. " Within 30 calendar days after the Government receives the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article. The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval.

(c) If the first article is disapproved, the Contractor, upon Government request, shall repeat any or all first article tests. After each request for additional tests, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing. All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall then conduct the tests and deliver another report to the Government under the terms and conditions and within the time specified by the Government. The Government shall take action on this report within the time specified in paragraph (b) above. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule, or for any additional costs to the Government related to these tests.

(d) If the Contractor fails to deliver any first article report on time, or the Contracting Officer disapproves any first article, the Contractor shall be deemed to have failed to make delivery within the meaning of the Default clause of this contract.

(e) Unless otherwise provided in the contract, and if the approved first article is not consumed or destroyed in testing, the Contractor may deliver the approved first article as part of the contract quantity if it meets all contract requirements for acceptance.

(f) If the Government does not act within the time specified in paragraph (b) or (c) above, the Contracting Officer shall, upon timely written request from the Contractor, equitably adjust under the changes clause of this contract the delivery or performance dates and/or the contract price, and any other contractual term affected by the delay.

(g) Before first article approval, the acquisition of materials or components for, or the commencement of production of, the balance of the contract quantity is at the sole risk of the Contractor. Before first article approval, the costs thereof shall not be allocable to this contract for (1) progress payments, or (2) termination settlements if the contract is terminated for the convenience of the Government.

(h) The Government may waive the requirement for first article approval test where supplies identical or similar to those called for in the schedule have been previously furnished by the offeror/contractor and have been accepted by the Government. The offeror/contractor may request a waiver.

(End of clause)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (Feb 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that—

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

CONTRACTOR RETENTION OF TRACEABILITY DOCUMENTATION

(a) This clause applies whenever the Contractor is not the manufacturer of the item(s) to be furnished.

(b)(1) The Contractor shall retain evidence to document that items furnished under this contract conform to contract requirements. Evidence will generally include information tracing the items back to the manufacturing source or its authorized distributor. At a minimum, evidence shall be sufficient to establish the identity of the item, its manufacturing source, and conformance to the item description.

(2) Examples of traceability documentation include, but are not limited to, the following:

(i) Purchase order(s)/invoice(s) between manufacturer(s)/distributor(s), identifying part number (and/or technical data package (TDP) with revision level) and quantities;

(ii) Original equipment manufacturer (OEM) or approved/qualified source’s packing slips, identifying part number (and/or TDP with revision level) and quantities;

(iii) OEM or approved/qualified source’s certification, identifying part number (and/or TDP with revision level) and quantities; and/or

(iv) OEM or approved/qualified source’s identifiable standard packaging, with part number (and/or TDP with revision level) cited on the package.

(3) The Contractor shall be responsible for the assurance of type, kind, count, and condition. Preservation, packing, packaging, and marking shall be in accordance with contractual requirements.

(4) The Contractor shall provide documentation of traceability for review—

(i) Upon request by the Contracting Officer at any time prior to or after award;

(ii) At time of Government source inspection, if applicable; and/or

(iii) During random or directed post-award audits.

(5) The Contractor shall retain documentation in accordance with this clause for 5 years after final payment under this contract.

c) The Offeror/Contractor shall provide documentation of traceability for review—

(1) Upon request by the Contracting Officer at any time prior to or after award;

(2) At time of Government source inspection, if applicable; and/or

(3) During random or directed post-award audits.

(d) Traceability documentation shall, at a minimum, include the following:

(1) If the Offeror/Contractor is an authorized dealer/distributor for an approved source for the specific item being procured by the Government, the following requirements apply:

(i) The Offeror/Contractor shall maintain at least one of the following:

(A) A copy of its current dealer/distributorship agreement;

(B) A letter of authorization from the approved source; or

(C) A link to an official website maintained by the approved source, which shall clearly identify the Offeror as an authorized dealer/distributor.

(ii) By submission of documentation described in subparagraph (d)(1)(i) of this clause, the Offeror/Contractor represents that:

(A) The dealer/distributor relationship with the approved source applies to the specific item being procured by the Government; and

(B) If the Contractor’s dealer/distributor status with the approved source changes after award, the Contractor shall promptly notify the Contracting Officer. Failure to provide such notification is grounds for cancellation of award or termination for default/cause, as applicable.

(2) If the Offeror/Contractor is not an authorized dealer/distributor for an approved source for the specific item being procured by the Government, the following requirements apply:

(i) If the Offeror/Contractor identified the offered item as “not in stock/not currently owned by the Offeror" or "not yet manufactured," the Offeror/Contractor shall—

(A) Maintain a verifiable quotation from the approved source, or from an authorized dealer/distributor for the approved source.

(B) Include the following information in its quotation:

(1) The item part number or designation, which shall be provided in sufficient detail to document that the item being quoted is the same as the item being procured by the Government;

(2) The quantity, which shall be sufficient to satisfy the solicitation requirement;

(3) The unit price quoted by the approved source, or by the authorized dealer/distributor for the approved source;

(4) The date of the quotation; and

(5) The name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source.

(C) The quotation shall be on the letterhead of the approved source, or of an authorized dealer/distributor for the approved source; or an electronic quotation, which shall be clearly identifiable as coming to the Offeror/Contractor from the approved source, or from an authorized dealer/distributor for the approved source.

(D) If the offered items are obtained from an authorized dealer/distributor for the approved source, the Offeror/Contractor shall maintain the information described in subparagraph (d)(1)(i) of this clause to document the authorized dealer/distributor arrangement; and the terms in subparagraph (d)(1)(ii) of this clause shall apply.

(ii) If the Offeror/Contractor identified the offered item as “shipped” or “in stock/currently owned by the Offeror,” the following requirements apply:

(A) The Offeror/Contractor shall maintain one of the following documents:

(1) The invoice received by the Offeror/Contractor from the approved source, or from an authorized dealer/distributor for the approved source; or

(2) The packing slip that accompanied the shipment to the Offeror/ Contractor from the approved source, or from an authorized dealer/distributor for the approved source. The packing slip shall include a packing slip number. (If no packing slip number was provided, the Offeror/Contractor shall obtain and maintain written documentation from the approved source, or from the authorized dealer/distributor for the approved source, verifying the packing slip number. Such documentation shall include the name and address of the approved source, or of the authorized dealer/distributor for the approved source; the date of the correspondence; and the name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source, who provided the information.)

(B) The documentation furnished in accordance with subparagraph (c)(2)(ii)(A) of this clause shall include the following:

(1) Date;

(2) the name and address of the approved source, or of the authorized dealer/distributor for the approved source;

(3) the name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source;

(4) the item part number or designation, which shall be provided in sufficient detail to document that the item provided to the Contractor is the same as the item being procured by the Government;

(5) the quantity, which shall be sufficient to satisfy the solicitation requirement;

(6) the unit price charged by the approved source, or by the authorized dealer/distributor for the approved source; and

(7) the Offeror’s/Contractor’s name and address.

(C) If the offered items are obtained directly from an authorized dealer or distributor, the Offeror/Contractor shall maintain the information described in subparagraph (d)(1)(i) of this clause to document the authorized dealer/distributor arrangement; and the terms in subparagraph (d)(1)(ii) of this clause shall apply.

(3) If the offered items are not obtained directly from an approved source, or from an authorized dealer/distributor of an approved source, the Offeror/Contractor shall maintain documentation, as described in subparagraph (d)(2) of this clause, sufficient to establish the complete line of ownership or distribution from the approved source, or from an authorized dealer/distributor for the approved source, to the Offeror/Contractor.

(e) The Contracting Officer determines the acceptability and sufficiency of documentation or other evidence, at his or her sole discretion. If the Contracting Officer finds the evidence to be unacceptable, or if the Contractor fails to retain or provide the requested evidence, the award may be cancelled or contract may be terminated for cause/default, as applicable.

(f) At the Contracting Officer’s discretion, documentation of traceability provided by the Contractor, in accordance with provisions in the solicitation and/or clauses included in this contract, may be used to determine the acceptability of documentation retained in accordance with this clause.

(g) Notwithstanding any documentation provided by the Offeror prior to purchase order issuance/contract award, the Government reserves the right to require additional documentation attesting to the authenticity of the material at any time before or after contract delivery.

(h) If the solicitation states inspection and acceptance shall take place at destination, the Government reserves the right to change the place of inspection and acceptance to origin and to invoke 52.246-9004, Product Verification Testing, at time of award, with no increase in the awarded unit price.

(i) The Contractor shall be responsible for the assurance of type, kind, count, and condition. Preservation, packing, packaging, and marking shall be in accordance with contractual requirements.

(j) The Contractor shall retain documentation in accordance with this clause for 5 years after final payment under this contract.

(End of Clause)

SUBSTITUTION OF ITEM AFTER AWARD

When the purchase order text (POT) identifies supplies by manufacturer's name, commercial and Government Entity (CAGE) code , and part number, the specified item(s) are the only item(s) acceptable under this contract. The Contractor may not substitute a different item after award.

PHYSICAL ITEM IDENTIFICATION/BARE ITEM MARKING – DLA LAND AND MARITIME

Unless authorized by exclusions listed below, all items shall be marked as specified in military standard (MIL-STD) 130N. The following DLA Land and Maritime supplemental marking requirements shall take precedence in case of conflict with MIL-STD-130N.

DLA Land and Maritime Exclusion:

(a) Unless the design control document specifically cites other marking requirements, the item will be considered too small to mark under the conditions listed below (however, 52.211-9035, Marking Requirements, applies):

(1) For federal supply classes (FSCs) 5905, 5910, 5935, 5961, 5962, and 5999, items smaller than .100 inch in diameter and .250 inch in length or .100 inch square X .250 inch in length, exclusive of wire leads, will not be marked.

(2) Other FSCs managed by DLA Land and Maritime will not be marked if the item is smaller than .250 inch in diameter X .500 inch long or .250 inch square X .500 inch long, exclusive of wire leads.

(3) Restrictions (1) and (2) above will not preclude marking of items of smaller dimensions if it is the manufacturers or vendor's standard practice to do so.

(b) No other physical item marking exclusions are authorized unless specified by MIL-STD-130N.

52.212-2 EVALUATION--COMMERCIAL ITEMS

(a)The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. This acquisition will utilize Lowest Price Technically Acceptable (LPTA) procedures. Past Performance will be waived by the Contracting Officer.

The following factors will be used to evaluate offers:

Factor 1 – Technical The sub-factor within the technical factor will receive one of the ratings described below based on the criteria listed below. Individual sub-factor ratings will be used to determine the overall technical acceptability of each offeror. To be determined technically acceptable at the factor level, the Offeror must be rated acceptable in each sub-factor. A final unacceptable sub-factor assessment will determine an overall technical unacceptable rating.

Sub-factor 1: Special Qualifications The Government will assess the Offeror’s proposed Special Qualifications. Offeror’s proposal SHALL thoroughly substantiate all the following essential components with little potential for disruption of schedule, increased cost or degradation of performance:

1. The Contractor shall provide signed documents which illustrate the offering of: CLIN 0001 THRU 0009

1. The Contractor shall provide documentation listing a delivery method of F.O.B. destination; along with a minimum delivery schedule of: 8 weeks

Factor 2 – Cost/Price The Government shall evaluate the Total Evaluated Price (TEP) of all technically acceptable Offerors.

(b) A written notice of award or acceptance of an offer mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017) ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ . [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a…