Specifications 20210304.pdf

Missouri National Recreational River

PMIS 238608

Mulberry Bend Overlook Trail Reconstruction

FINAL CONSTRUCTION DOCUMENTS SUBMITTAL

MARCH 4, 2021

National Park Service

Task Order No. 140P6020F0075

SCHEMMER PROJECT NO. 07310.017

03/04/2021

MNRR- 238608 TOC-1

TABLE OF CONTENTS

DIVISION 00 – PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 05 Certifications Page

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work

01 26 01 Contract Modification Procedures

01 27 00 Definition of Contract Line Items

01 31 00 Project Management & Coordination

01 32 16 Construction Schedule

01 33 23 Submittal Procedures

01 35 23 Safety Requirements

01 40 00 Quality Requirements

01 42 00 Reference Standards

01 50 00 Temporary Facilities and Controls

01 57 23 Under-An-Acre Pollution Prevention

01 73 40 Execution

01 74 19 Construction Waste Management and Disposal

01 77 00 Closeout Procedures

DIVISION 03 – CONCRETE

03 10 00 Concrete Forming and Accessories

03 20 00 Concrete Reinforcing

03 30 00 Cast-In-Place Concrete

DIVISION 04 – MASONRY AND STONE

044313.13 Anchored Stone Masonry Veneer

DIVISION 31 - EARTHWORK

31 10 00 Site Clearing

31 20 00 Earth Moving

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 12 16 Asphalt Paving

32 13 13 Concrete Paving

32 17 23 Pavement Markings

32 92 00 Turf and Grasses

32 93 00 Native Seeding

DIVISION 33 - UTILITIES

33 41 00 Storm Utility Drainage Piping

MNRR - 238608 00 01 05 - 1

CERTIFICATIONS PAGE

SECTION 00 01 05 – CERTIFICATION PAGE

I hereby certify that the portion of this technical submission described below was prepared by me or under my direct supervision and responsible charge. I am a duly registered engineer under the laws of the State of Nebraska.

I hereby certify that the portion of this technical submission described below was prepared by me or under my direct supervision and responsible charge. I am a duly registered architect under the laws of the State of Nebraska.

Matthew J. Hubel E-12955 Patricia J. Birch A-2229

Name (Printed) Registration Number

Number

Signature Signature

Drawings covered by this Seal: Drawings covered by this Seal:

0, C00, C001, C101, C102, C103, C104, A101

C105, C201, C202

Sections covered by this Seal: Sections covered by this Seal:

Divisions 01, 31, 32, 33 Division 04

Date Issued:

03/04/2021 03/04/2021

MNRR - 238608 00 01 05 - 2

CERTIFICATIONS PAGE

I hereby certify that the portion of this technical submission described below was prepared by me or under my direct supervision and responsible charge. I am a duly registered engineer under the laws of the State of Nebraska.

Kevin Wenninghoff E-15700

Number

Signature

Drawings covered by this Seal:

Sections covered by this Seal:

Division 03

03/04/2021

MNRR - 238608 01 11 00 - 1

091015 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Contractor use of premises.

3. Public use of site.

4. Work Restrictions.

5. Special Construction Requirements.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Missouri National Recreational River, Mulberry Bend Overlook located on the south side of the Missouri River along Hwy 15 approximately 5 miles south of

Vermillion, SD. The project site is located in an area that is open to the public.

B. The Work consists of the following:

1. The Work includes replacement of existing concrete trail and parking with a new accessible concrete trail and overlook, and accessible parking in compliance with ABA requirements.

C. Project will be constructed under a single prime contract.

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to work in areas indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine constructions operations to area of and immediately adjacent to construction area.

B. Storage of Materials: Confine storage of materials to within designated staging area onsite as indicated on the plans..

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

MNRR - 238608 01 11 00 - 2

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways, roadways and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park

Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. The drive, parking area, trails and project site will be closed to the public during construction.

1.5 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 48 hours in advance of the work to the

Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.6 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 8:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: Only as approved by the Contracting Officer.

2. Early Morning Hours: Only as approved by the Contracting Officer.

MNRR - 238608 01 11 00 - 3

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by

Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

1.7 SPECIAL CONSTRUCTION REQUIREMENTS

A. Project Website: A project website administered by the NPS will be used for purposes of managing communication and documents during the construction stage.

1. See Section 01 31 00 “Project Management and Coordination” for requirements on using the Project Website.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

MNRR - 238608 01 26 01 - 1

031414 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

MNRR - 238608 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating

General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums, such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

MNRR - 238608 01 26 01 - 3

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank

MNRR - 238608 01 26 01 - 4

they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate

Form, or their own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. The proposal must indicate any changes to the period of performance for the work included in the modification.

4. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction

Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the

Contractor waiving the right for additional time and no time extension will be allowed.

5. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

6. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS.

All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

7. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

http://www.nps.gov/dscw/publicforms.htm#ct http://www.nps.gov/dscw/publicforms.htm#ct

MNRR - 238608 01 26 01 - 5

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule

(use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the

US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10%

Profit…………………10%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

MNRR - 238608 01 26 01 - 6

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par

1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS - (Not Used)

PART 3 - EXECUTION - (Not Used)

END OF SECTION 012601

MNRR - 238608 01 27 00 - 1

082714 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 0001.

1. This item consists of All work identified on the drawings except for that work shown as

Option A.

2. Payment will be made at the contract lump sum price.

B. Option A: Removal of Upper Trail.

1. Contract Line Item No. 0002

a. This item consists of removal of upper trail and steps and then stabilization of associated disturbed areas.

b. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

MNRR - 238608 01 31 00 - 1

091015 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Requests for Information (RFIs).

5. Project meetings.

6. Environmental Coordination.

7. Permits

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

MNRR - 238608 01 31 00 - 2

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Project closeout activities.

1.3 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to

Proceed will not be issued, and the Contracting Officer will consider other contractual remedies.

Work shall not commence until written Notice to Proceed has been issued.

MNRR - 238608 01 31 00 - 3

1.4 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the NPS form.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

C. RFI Form: Complete the RFI Form and submit to NPS.

D. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of COR's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

MNRR - 238608 01 31 00 - 4

1.5 PROJECT MEETINGS

A. Preconstruction Conference (may be a virtual meeting rather than on-site): Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. Acceptance/rejection of work.

17. Progress meetings.

18. Submittal procedures.

19. NPS Final Accessibility Inspection.

20. Environmental requirements.

21. Permit requirements.

22. As-constructed drawings/operation and maintenance (O&M) manuals.

23. Saturday, Sunday, holiday and night work.

24. Reference materials.

25. Value engineering.

B. Progress Meetings: The Contracting Officer will schedule bi-weekly meetings with the

Contractor. The Contractor shall be responsible for preparing meeting agenda and meeting minutes for each meeting.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

MNRR - 238608 01 31 00 - 5

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

1.6 ENVIRONMENTAL COORDINATION

A. Designate an on-site party responsible for overseeing the Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan(WMP).

c. Implementation of the Storm Water Pollution Prevention Plan(SWPPP).

d. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

e. Training for Contractor personnel in accordance with their position requirements.

f. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements.

2. Regulatory Requirements.

3. Temporary Storm Water Pollution Prevention Environmental Management.

4. Construction Waste Management.

C. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, and Storm Water Pollution Prevention Plan.

1.7 PERMITS

A. General:

1. Permits and Responsibilities: The Contractor shall, without additional expense to the

Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor’s fault or negligence. The

Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the work.

2. For the purpose of this contract the Contractor will not be considered an agent of the

Government. Therefore, the Contractor will comply with the appropriate Federal, State and local laws.

MNRR - 238608 01 31 00 - 6

B. Government Furnished Permits:

1. None.

C. Coordination with Agency(ies) with Jurisdiction Issuing Permits

1. Coordination: Contact the Agency(ies) with Jurisdiction as needed and sufficiently in advance to avoid delaying the work: Coordinate meetings, reporting requirements, inspections, or any other requirements.

D. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with Agency(ies) with Jurisdiction, Construction Manager, and Park to avoid conflicts and to ensure orderly execution of the Work.

2. Supply all needed information to Agency(ies) with Jurisdiction issuing permits, pay any fees required and provide all material needed to comply with the permit’s conditions and provisions.

3. Submit permits to NPS when the permits are obtained.

PART 2 - PRODUCTS (Not Used)

END OF SECTION 01 31 00

MNRR - 238608 01 32 16 - 1

031414 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The

Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the

Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

MNRR - 238608 01 32 16 - 2

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be provided in the native electronic file format. It is the intent of the Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit electronic copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including phasing and partial Government occupancy.

4. Review delivery dates for Government-furnished products.

5. Review schedule for work of separate Government contracts.

6. Review time required for review of submittals and re-submittals.

7. Review requirements for tests and inspections by independent testing and inspecting agencies.

8. Review time required for completion and startup procedures.

9. Review time required for obtaining and activating permits.

10. Review and finalize list of construction activities to be included in schedule.

11. Review baseline schedule comments, resolve issues and progress on incorporating them

12. Review procedures for updating schedule.

13. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

MNRR - 238608 01 32 16 - 3

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting

Officer before the first progress payment is processed.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule:

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later one week prior to pre-construction meeting..

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

MNRR - 238608 01 32 16 - 4

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

3. The Construction Baseline Schedule as developed shall show the sequence and interdependence of activities required for complete performance of the work. Ensure all work sequences are logical and the Construction Baseline Schedule shows a coordinated plan of the work.

4. Consider seasonal weather conditions in planning and scheduling all work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of all work within the contract time.

5. Time Frame: Proposed duration assigned to each activity shall be the Contractor's best estimate of time required to complete the activity considering the scope and resources planned for the activity.

6. Constraints: Include constraints and work restrictions indicated in the Contract

Documents and as follows in schedule, and show how the sequence of the Work is affected.

7. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed, Substantial Completion and the following interim milestones:

a. Completion of erosion control installation, removals, grading, paving, and seeding/stabilization.

C. Joint Review, Revision, and Acceptance:

1. Within seven calendar days of receipt of the Contractor's proposed Construction Baseline

Schedule, the Contracting Officer and Contractor shall meet for joint review, correction, or adjustment of the initial Construction Baseline Schedule. Any areas which, in the opinion of the Contracting Officer, conflict with timely completion of the project shall be subject to revision by the Contractor.

2. Within seven calendar days after the joint review between the Contractor and Contracting

Officer, the Contractor shall revise and resubmit the Construction Baseline Schedule in accordance with agreements reached during the joint review.

3. In the event the Contractor fails to define any element of work, activity, or logic, and the

Contracting Officer review does not detect this omission or error, such omission or error, when discovered by the Contractor or Contracting Officer, shall be corrected by the

Contractor within seven calendar days and shall not affect the contract period.

MNRR - 238608 01 32 16 - 5

4. Upon acceptance of the Construction Baseline Schedule by the Contracting Officer, save the schedule as a baseline and update on a monthly basis. The construction schedule update will be used to evaluate the Contractor's monthly applications for payment based upon information developed at the monthly Construction Schedule update meeting.

D. Recovery Schedule: When periodic schedule update indicates the Work is 14 or more calendar days behind the current accepted schedule, a separate recovery schedule indicating means by which Contractor intends to regain compliance with the schedule must also be submitted.

Indicate changes to working hours, working days, crew sizes, and equipment required to achieve compliance, and date by which recovery will be accomplished.

PART 3 - EXECUTION

3.1 CONSTRUCTION SCHEDULE UPDATES

A. Progress Meeting Updates: Provide a 2 week look-ahead schedule, derived from the currently accepted schedule, before each weekly progress meeting. Utilize the look-ahead schedule to facilitate and take notes on discussions held during the progress meeting.

B. Monthly Schedule Updates:

1. General: Update the Construction Schedule on a monthly basis to reflect actual construction progress and activities throughout the entire contract period and until project substantial completion. The status date of each schedule update shall be the 7th day preceding the progress payment request date.

C. Distribution: Distribute electronic copies of accepted schedule to Contracting Officer, Contracting Officers Representative, Construction Management Representative, Subcontractors, testing and inspecting agencies, and other parties identified by Contractor with a need-to-know schedule responsibility.

D. Construction Schedule Revisions:

1. Required Revisions: If as a result of the monthly schedule update, it appears the currently accepted Construction Schedule no longer represents the actual prosecution and progress of the work, the Contracting Officer will request, and the Contractor shall submit, a revision to the Construction Schedule. The Contractor may also request reasonable revisions to the currently accepted Construction Schedule in the event the

Contractor's planning for the work is revised. If the Contractor desires to make changes, the Contractor shall notify the Contracting Officer in writing, stating the reason for the proposed revision. Accepted revisions will be incorporated into the currently accepted

Construction Schedule for the next monthly schedule update.

2. Procedure: If revision to the currently accepted Construction Schedule is contemplated, the Contractor or Contracting Officer shall so advise the other in writing at least seven calendar days prior to the next monthly schedule update meeting, describing the revision and reasons for the revision. Government-requested revisions will be presented in writing to the Contractor, who shall respond in writing within seven calendar days.

MNRR - 238608 01 32 16 - 6

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

f. Changes in total float or slack time.

END OF SECTION 01 32 16

MNRR - 238608 01 33 23 - 1

031414 SUBMITTAL PROCEDURES

SECTION 01 33 23 - SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative and procedural requirements for submitting Shop

Drawings, Product Data, Samples, and other submittals.

1.2 DEFINITIONS

A. Action Submittals: Written, graphic information, and physical samples that require

Government’s responsive action.

B. Informational Submittals: Written information that does not require Government’s responsive action. Submittals may be rejected for not complying with the requirements.

C. File Transfer Protocol (FTP): Communications protocol that enables transfer of files to and from another computer over a network and that serves as the basis for standard Internet protocols. An FTP site is a portion of a network located outside of network firewalls within which internal and external users are able to access files.

D. Portable Document Format (PDF): An open standard file format licensed by Adobe Systems used for representing documents in a device-independent and display resolution-independent fixed-layout document format.

1.3 GENERAL SUBMITTAL PROCEDURES

A. General: Prepare and submit submittals required by individual Specification Sections. Types of submittals are indicated in individual specific sections.

1. Contracting Officer reserves the right to require submittals in addition to those called for in individual sections.

B. Coordination: Coordinate preparation and processing of submittals with performance of construction activities. Review them for legibility, accuracy, completeness, and compliance with Contract Documents.

1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals, and related activities that require sequential activity.

2. Coordinate transmittal of different types of submittals for related parts of the Work so processing will not be delayed because of need to review submittals concurrently for coordination.

a. Contracting Officer reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received.

MNRR - 238608 01 33 23 - 2

C. Submittal List: A submittal list has been attached to the end of this Specification Section. The intent is to provide an overall summary of submittal requirements and not a comprehensive list.

The requirements of the individual Specification Sections, terms and conditions of the Contract still apply regardless of what is shown on the submittal list.

D. Processing Time: Allow enough time for submittal review, including time for re-submittals, as follows. Time for review shall commence when an e-mail notification is received by the

Contracting Officer (or designee) indicating the submittal has been posted and is ready for review. When the Contracting Officer has completed their review, an e-mail notification will be sent to the Contractor indicating the submittal has…