SOW.docx

ARCHITECT-ENGINEER DESIGN SCOPE OF WORK

EHRM TRAINING AND ADMIN SUPPORT SPACE –

LEASED MODULAR BUILDING SITE PREPARATION

H.H. McGuire VA Medical center

PROJECT NO: 652-22-703

PROJECT NAME: EHRM – Training and Admin Support Space – Modular Bldg. Site Prep.

ESTIMATED COST OF CONSTRUCTION: $2,600,000

1. GENERAL INTENT:

The Contractor (herein referred to as “A/E”) shall provide Architect/Engineer (A/E) services to design a construction project at the Central Virginia VA Health Care System Campus in accordance with this design scope of work.

2. STATEMENT OF WORK:

A/E Part One Services (also known as Design Phase) for this design project includes site visits, field investigation, studies and user interviews to prepare drawings, specifications and cost estimates for all facets of work and disciplines/trades to facilitate a construction project to prepare the site for leased modular offices to be used for the Electronic Health Record Modernization (EHRM) training and administrative support spaces as defined later in the SOW.

A/E Part Two Services of this design project (also known as Construction Period Services) includes responding to construction contractor Requests For Information (RFIs) during the solicitation (solicitation support) and construction phases of the construction project, attendance at pre-bid, post-award construction project conferences, review of construction material submittals and shop drawings, approximately one site visit per month during construction (total of 5 site visits both scheduled and emergent) to ensure compliance with the design drawings and specifications, preparation of site visit reports, coordination with project commissioning requirements, review of any construction project modifications for cost and technical acceptability, attendance in the final acceptance inspection, preparation of the punch list and preparation of record drawings of the completed construction project based on the construction contractor’s as-built drawings. The A/E shall prepare a submittal log to be utilized by the VA during construction period services, maintain RFI log and provide meeting minutes for weekly construction meetings throughout the duration of construction. All Part Two Services are optional line items and will not be exercised at the time of award.

The above paragraphs constitute a basic outline of the work to be accomplished and in no way comprises all the details for design of this project. The A/E shall initiate detailed inspection of the project site to determine the needs and conditions for the design of this project. Copies of CVHCS record drawings and the EHRM infrastructure readiness assessment documents will be made available to the highest rated A/E firm; the A/E will verify the validity of the record drawings prior to the start of design work and conduct site investigations as necessary throughout the design. SOW Attachment 08 – Hunter Holmes McGuire Campus Map will give AE firm a basic understanding of the Central Virginia VA Health Care System (CVHCS) campus.

The specific site area that will be prepared as part of this project is defined in SOW Attachment 10 – Area for EHRM Training/Admin Support Space. The intent of this design is to prepare a hardscape area to place no more than 26,500 SF of rented modular office space. This area will have electrical, data, water and sanitary sewer utilities made available for hookup to the modular offices. Stormwater management sewer will be provided in accordance with local Virginial Department of Environmental Quality stormwater management regulations: https://www.deq.virginia.gov/water/stormwater/stormwater-construction/handbooks

The area will also provide parking for CERNER training/admin personnel.

The A/E shall be solely responsible for the management, including all associated labor, equipment, materials, mailing costs, and inspection, to meet the requirements of the design project. The A/E shall further provide meeting minutes for all meetings held under this design project.

The A/E firms’ representatives performing site investigations on Central Virginia VA Health Care System (CVHCS) campus must meet the following requirements in order to enter CVHCS facilities.

1. Attestation documentation of a negative TB Test, within the past calendar year for A/E personnel.

2. Wearing of a mask when inside any building on campus.

3. Annual influenza shot is highly recommended for all A/E staff performing work the CVHCS campus

Any further questions please refence the below document:

· Seasonal influenza with Vaccines (SOW Attachment 07)

3. DESIGN WITHIN FUNDING LIMITATIONS:

The design shall be prepared by the A/E to permit the award of a construction contract, using Federal Acquisition Regulation procedures for the construction of the facilities, at a cost that does not exceed the project’s estimated construction contract price of $2,600,000.

4. DESIGN INDEPENDENCE, FURNITURE AND EQUIPMENT: Designs for construction must produce a “complete and usable” facility or improvement when constructed. VA policy (VHA Office of Capital Assets Management, Engineering and Support memo Updated Construction Guidance and Expectations dated Sep 12, 2016) requires the A/E to certify that their design is independent of any future construction project. In addition, the A/E must certify that it has produced a design that does not include furniture and equipment that will be procured separately. Equipment that can be part of the design in the includes those items to meet code requirements for building occupancy, items covered in the VA’s Master Construction Specifications (PG-18-1) Divisions 1 through 10, 13 through 26 or 28 through 48, non-IT equipment items covered by Division 27 and items covered by Division Numbers 12 31 00, 12 32 00, 12 34 00 and 12 36 00.

The A/E shall submit as part of the Final Bid Documents submittal a signed letter on company letterhead stating the design’s independence.

5. DESIGN CRITERIA: The VA Technical Information Library (TIL) available at http://www.cfm.va.gov/til/index.asp is managed by the VA Office of Construction and Facility Management and is the master repository for all VA Numbered Standards for Construction to include design and construction specifications, procedures, standard details, BIM/CAD standards, equipment guides, space planning and design guides. The documents of the TIL shall be the minimum design criteria for all VA projects performed in the construction of new facilities and the modernization, alteration, addition, or improvement of its real property. All design documents shall be developed in accordance with the VA TIL, including (but not limited to) the following listed Department of Veterans Affairs References:

OIT Infrastructure Standard for Telecommunications Spaces v3.1 (1 July 2021)

The following references should also be used to complete the design documents:

· VA Standards Alert 017 – Infrastructure Standards for Telecommunications Spaces and all standards, guides, and manuals incorporated by reference (https://www.cfm.va.gov/til/sAlert/sAlert017.pdf)

· 00 VA OEHRM Site Infrastructure Requirements v3.1

· HEFP SEP Design Alert 1-9

Virginia Dept. of Environment Quality Erosion and Sediment Control Handbook https://www.deq.virginia.gov/water/stormwater/stormwater-construction/handbooks

Where conflicts exist between VA adopted codes and standards and the documents on the TIL, the A/E shall bring this to the attention of the VA. The resolution of the conflict shall be made by the authority having jurisdiction for VA to ensure consistency department wide.

The contractor shall execute work in accordance with the following contract security clauses, incorporated by reference:

VA Handbook 6500.6 Contract Security, Appendix C, Clauses 1. 2. 3. 5. 6. 7 and 9

6. DESIGN COLLABORATION: The A/E during this design project shall collaborate with the VHA Office of Healthcare Environment and Facilities Programs Special Engineering Program (HEFP/SEP) staff, VISN 6, CVHCS Engineering staff and the Independent Life Safety Review Agent (LS Agent) for the project. Design submittal comments from these contractors, if concurred with by VA, shall be incorporated into the design. HEPF/SEP and/or VISN deliverables shall be coordinated with the A/E’s design submittals to ensure compliance with all requirements are met. The A/E is required to ensure all elements of the design adhere to the Life Safety Code, including recommendations for temporary construction barriers, prior to the Independent Life Safety review.

7. INDEPENDENT LIFE SAFETY REVIEW: The A/E shall incorporate any comments from the VA 3rd party life safety review.

8. ENVIRONMENTAL PROTECTION: The A/E shall assist the VA with completion of a National Environmental Policy Act (NEPA) assessment as required by the Central Virginia VA Health Care System, Richmond VA. If the NEPA assessment results in potential environmental impacts, the A/E shall be responsible for completing any auxiliary documentation required per PG-18-17 NEPA Interim Guidance for Projects located on the TIL (http://www.cfm.va.gov/til/etc/NEPAGuidance.pdf). Additional requirements may include, but are not limited to, Environmental Assessment, Environmental Impact Statement, and Record of Decision. The NEPA analysis and concluding documentation must be completed by the Final Bid Documents submittal.

The A/E shall coordinate reviews of the stormwater management design with the Virginia Department of Environmental Quality. The A/E shall make any required changes to the SWM design as recommended by the Virginia DEQ and resubmit until an approved plan if obtained.

9. PHYSICAL SECURITY: The A/E must include a certified physical security specialist. The specialists must be involved with the design beginning with the concept phase and the qualifications must be submitted to the COR for review and approval prior to the concept/basis of design phase. The specialists shall meet the specific requirements listed in the Physical Security Design Manual for Mission Critical Facilities located on the TIL (http://www.cfm.va.gov/til/PhysicalSecurity/dmPhySecMC.pdf). The A/E shall ensure that all aspects of the applicable VA Physical Security Design Manual (either Life-Safety Protected or Mission Critical Facilities; both will be applicable depending on the area the work is taking place) are incorporated into the design and shall prepare a written report acknowledging compliance as required by the VAMC. The A/E must inform the COR of any physical security items that will be difficult to achieve during the concept/basis of design phase of the design and assist the VA with waiver requests as necessary.

10. TELECOMMUNICATIONS DESIGN: In accordance with “Telecommunications and Special Telecommunications Systems Design Manual,” (https://www.cfm.va.gov/til/dManual/dmTelecomm.pdf), paragraph 1.2 (d), Telecommunications design must be performed and stamped by a BICSI Registered Communications Distribution Designer (RCDD) for all projects.

11. SUBMITTAL REQUIREMENTS: Design submittals shall follow the requirements of Program Guide, PG-18-15, Volume C - A/E Submission Instructions for Minor and NRM Construction Program dated November 2008. This document is included as SOW Attachment 6. Submittal documents shall be prominently marked “For Official Use Only (FOUO)” if they contain qualifying data as defined in VHA Memorandum 2019-11-13 Sensitive Infrastructure Data Classification – For Official Use Only (FOUO). This memo is included as SOW Attachment 4, as it is hosted on a non-public VHA site (https://vaww.va.gov/vhapublications/ViewPublication.asp?pub_ID=8949).

The A/E shall deliver design submittal documents that follow the iterative phase breakdown for design work in PG-18-15 and as additionally specified below. Specific requirements for each discipline/work product listed under each phase can be found in PG-18-15; it is expected for the phase of design that each of the checked items in the SD/DD/CD columns will be completed for the submittal. The A/E shall attend a review meeting following each design submittal as indicated under the Project Schedule section of this Scope of Work. Each new submittal will incorporate all VA comments from the previous submittal.

The following submittals will be required for this project:

· Quality Assurance/Quality Control (QA/QC) Plan

· Basis of Design (BD) - 10% - In addition to the requirements in PG-18-15, a Basis of Design is required. Basis of Design is a narrative presentation of facts, sufficiently complete, to demonstrate that the project concept is fully understood, and that subsequent design details, and their ultimate presentation in the final drawings and specifications, will be based on sound architectural and engineering decisions. Conceptual drawings of the planned design and the initial cost estimate will additionally be included.

· Schematic Design (SD)- 35%

· Design Development One (DD) – 65%

· Construction Documents (CD)- 95%

· Final Bid Documents (Bid) – 100%

12. DRAWING FORMAT: All drawings shall adhere to VA project software requirements for Building Information Modeling (BIM) and Computer Aided Design (CAD) available at http://www.cfm.va.gov/til/projReq.asp. BIM software shall be Revit 2020 or the latest version available to H.H. McGuire VAMC.

The project BIM model minimum requirements shall be developed to include the systems described below as they would be built, the processes of installing them and to reflect record drawing conditions. The deliverable model at the SD, DD and CD design phases shall be developed to include as many of the systems described below (but not limited to) as are necessary and appropriate at that design phase.

Central Virginia VA Health Care System 1201 Broad Rock Blvd 11/15/2022 Richmond, VA 23249

· Site Electrical/Telecommunications

· Site Utilities (water, sanitary, storm)

· Site Lighting

· Exterior Improvements

13. SUBMITTAL FORMATS: Submittals shall be submitted in electronic format and hard copy formats as listed below. Portable Document Format (.pdf), Microsoft Office Suite formats (.doc, .xls, and .ppt), Microsoft Project (.mpp) and Autodesk Revit Project (.rvt) or Autodesk Drawing (.dwg) files are acceptable. Submittals shall additionally be compliant with Section 508 of the Rehabilitation Act (29 U.S.C. 794 d); information on the requirements for accessible media can be found at http://www.section508.gov/. The A/E shall be responsible for providing:

Meeting/Conference Minutes Meeting minutes for all formal meetings and conferences held with the VA; including weekly construction meetings. Meeting minutes shall be submitted within seven (7) calendar days of the meeting or conference. All documents in any of the electronic formats listed above.

Minimum meeting minutes requirements

· Project name, number, meeting host, Meeting Name

· Date, Time, meeting ID, call in number, Duration, and consecutive number of total related meetings

· Participant list (Name, Title, Phone number (office and Mobile), Email, Attended Meeting (yes/no Check box)

· Meeting purpose, Roll call, COVID-19, and Additional Items

· Agenda items (Decisions, action items, and fixes or next steps)

· Next meeting date and time

· Detailed attachment list

Construction Cost Estimates Construction cost estimates shall comply with Manual for Preparation of Cost Estimates & Related Documents for VA Facilities (latest version). This document is available on the TIL at http://www.cfm.va.gov/cost/index.asp. All estimates in any of the electronic formats listed above.

Quality Assurance/Quality Control (QA/QC) Plan

· All documents in any of the electronic formats listed above.

Basis of Design (BD)

· All documents in any of the electronic formats listed above.

· Two (2) half-size paper bond sets of drawings – 2 to VA

Schematic Design (SD)

· All documents in any of the electronic formats listed above.

· Two (2) half-size paper bond sets of drawings – 2 to VA

· Two (2) paper bond sets of specifications – 2 to VA

· Two (2) paper bond sets of investigation reports, design calculations, space planning data and cost estimate - 2 to VA

Design Development (DD), and Construction Documents (CD)

· All documents in any of the electronic formats listed above.

· Memo annotating what was not upgraded and corresponding justifications.

· One (1) full size paper bond sets of drawings - 1 to VA

· Two (2) half-size paper bond sets of drawings – 2 to VA

· Two (2) paper bond sets of specifications – 2 to VA

· Two (2) paper bond sets of investigation reports, design calculations, space planning data, construction schedule, construction statement of work (SOW) and cost estimate - 2 to VA

Final Bid Documents (Bid)

· PDF files of drawings, specifications, and any miscellaneous design analysis documents such as submittal log and physical security compliance report.

· Certified memo annotating what areas/times were not upgraded and the corresponding justifications.

· Certified memo that the A/E design is independent of future projects and includes all equipment required for the project to be activated/full functional.

· Word files of specifications.

· Revit and AutoCAD files of drawings.

· One (1) full size paper bond sets of drawings - 1 to VA

· Two (2) half-size paper bond sets of drawings – 2 to VA

· Two (2) paper bond sets of specifications – 2 to VA

· One (1) paper bond sets of investigation reports, design calculations, space planning data, construction schedule, construction SOW and cost estimate - 1 to VA

Construction Period Services (CPS)

Requests for Information (RFI) Requests for Information shall be submitted within three (3) calendar days of submittal to the A/E.

Submittal Reviews Submittal reviews shall be submitted within seven (7) calendar days of submittal to the A/E.

Site Visit Reports Site visit reports shall be submitted within seven (7) calendar days of the visit. All documents in any of the electronic formats listed above.

Modification/Change Order Requests Modification requests shall be submitted within seven (7) calendar days of submittal to the A/E. This includes the review of the contractor’s change order/modification proposal for construction change orders, as well as the formulation of an IGCE for the modification, as requested. The A/E's reply regarding his/her review of cost proposals and his/her recommendations shall include an independent breakdown of costs in detail, quantities, and unit prices and shall cover both additions and deductions of labor, materials, and equipment. The A/E shall also supply cost estimates as requested by the COR for Request for Proposals for anticipated changes.” All documents in any of the electronic formats listed above. Note - If major modification, VA will provide additional time and document format guidance.

Punch List Punch list shall be submitted within seven (7) calendar days of the final acceptance inspection. All documents in any of the electronic formats listed above.

Record Drawings Record drawings shall be delivered to the VA within thirty (30) calendar days after VA acceptance of the construction project. Autodesk Revit Project (.rvt) format and AutoCAD (.dwg) format.

14. PROJECT SCHEDULE/PERIOD OF PERFORMANCE: The A/E shall perform Part One Services/Design Phase work according to the schedule shown below. The A/E is also responsible for following specification Section 01 32 16.10 Architectural and Engineering CPM Schedules, which is located in SOW Attachment 05 - 01 32 16.01 EHRM Architectural and Engineering CPM Schedule. If a due date on the timeline below falls on a Holiday or Weekend, the submittal shall be due the following business day. The remaining timeline will not be shifted to accommodate Holidays or Weekends.

*This submittal period is longer to account for administrative duties when award is made.

Part Two Services/Construction Period Services (optional Line Items) shall be performed for the length of time between the time the option(s) are exercised and acceptance of Construction Completion. The VA has 365 calendar days from final acceptance of the design to exercise the option(s) for Construction Period Services.

15. SOLICITATION SUPPORT SERVICES (OPTION ITEM)

AE shall provide solicitation support services during the construction period’s solicitation phase.

Pre-bid site visit to include meeting and project walk around. This is the meeting where contractors are invited to the job site to visually inspect the construction site in order to accurately develop a construction bid package. The AE shall be available during this entire site visit to assist the VA in answering any contractor questions. All questions shall be logged by the AE and will be submitted in writing by the contractor to the Contracting Officer. Responses may not be provided verbally onsite.

Answer any technical questions/requests for information (RFI) received from contractors over the duration of the solicitation, including questions asked during the site visit. Questions from contractors may come at multiple times and cover several or a few questions over the course of the solicitation period. Technical question responses will be provided to the Contracting Officer who will distribute the information via amendment to the solicitation. Answers to RFIs will be required from the AE within five (5) calendar days of the date the questions are sent to the AE from either the project COR or CO. An alternate response period may be submitted for review, however, unless approved by the CO and COR, the AE is required to comply with the seven (7) calendar day requirement. Throughout the solicitation period, the AE shall provide addenda as necessary if required to revise specs and drawings. In response to any technical questions and/or addenda issued during the solicitation period, the AE shall provide any final revisions to the 100% FC CD as part of the construction contract. These documents shall be labeled Final Construction

16. CONSTRUCTION PERIOD SERVICES (OPTION ITEM)

Construction Period Services (CPS) – CPS shall be provided for entire duration of construction Contract. Although the AE is directed to design the construction project for a duration of five

(5) months from the effective date of the exercised option, which accounts for potential differing site conditions, design errors, and requirement changes; this duration may change with the exercising of an option line item. The AE shall provide following Construction Period Services:

Requests for Information (RFI) When necessary for contract in-scope changes to construction project requirements, prepare construction cost, completion schedule estimates and Construction Bulletins (CBs). AE RFI review time shall not exceed 7 calendar days. When CB is not for a design deficiency, VA will issue an RFP to the AE for re-design during CPS. Otherwise, CB shall be at no added cost to government. CBs include narrative cover page, stamped drawings or sketches, and edited/added specifications as well as a construction cost estimate. A full CB, if required, is due to VA within same 7 calendar day RFI response timeline. A CB is not required for simple clarifications, selections among options in contract specifications, nor for as-built markups within tolerance qualifying as “field adjustment” by Construction Contractor. CBs are required when any change occurs to scope, schedule, cost, or quality standards. CB drawings shall consist only of full-size drawing sheet edits, with numbered clouds and title bar notation in format to be given by VA. If additional details are needed, they shall be inserted into existing detail sheets. If they do not fit, a new detail sheet will be created, and cover sheet with TOC shall be updated accordingly. AE shall maintain an electronic version of Contract Set of drawings and specifications that reflects CBs through current version. From that date forward, Construction Contractor will use updated set as their as-built set for “field adjustment” markups.

Submittal Reviews Submittal reviews shall be submitted within seven (7) calendar days of submittal to the A/E. This service includes reviewing and providing comments and recommendations to government on items such as construction contractor’s quality control plan, initial and final network schedules, bar chart schedules, schedules of prices, safety plan, shop drawings (including MEP coordination drawing, shop drawings, diagrams, layouts, catalog cuts, performance and test data, samples finish chips, etc.), operation and maintenance manuals, and as-built drawings. For items that are shown as "CONDITIONAL, RE-SUBMITTAL REQUIRED", or "REJECTED" AE shall include an explanation that clearly describes reason(s) for recommended action.

Attendance at Meetings Attendance at various meetings such as pre-construction (kick-off) conference, routine quality control meetings, safety meetings, change order negotiations, claims meetings, scheduling meetings, and other conferences between government and construction contractor may be required by government. These meetings primarily pertain to weekly construction meetings but may include other various meetings, change order negotiations, claims meetings, scheduling meetings, and other conferences between government and construction contractor as may be called by government. AE should plan on a senior architect/engineer familiar with entire design, to attend each construction meeting phone call and furnish meeting minutes during the construction period.

Site Visit Reports Site visit reports shall be submitted within seven (7) calendar days of the visit. All documents in any of the electronic formats listed above.

Modification/Change Order Requests Modification requests shall be submitted within seven (7) calendar days of submittal to the A/E. This includes the review of the contractor’s change order/modification proposal for construction change orders, as well as the formulation of an IGCE for the modification, as requested. The A/E's reply regarding his/her review of cost proposals and his/her recommendations shall include an independent breakdown of costs in detail, quantities, and unit prices and shall cover both additions and deductions of labor, materials, and equipment. The A/E shall also supply cost estimates as requested by the COR for Request for Proposals for anticipated changes.” All documents in any of the electronic formats listed above. Note - If major modification, VA will provide additional time and document format guidance.

Punch List Punch list shall be submitted within seven (7) calendar days of the final acceptance inspection. The punch list shall include pictures and estimated costs. All documents in any of the electronic formats listed above.

Record Drawings Record drawings shall be delivered to the VA within thirty (30) calendar days after VA acceptance of the construction project. AE shall prepare Record Drawing set at construction completion. Add any new drawings and review Construction Contractor’s annotated drawings. Verify accuracy of contractor interim record drawings and as-built conditions as construction contractor document changes occur. Receive and review contractor “red-line” in preparation for production of final as-builts. Deliver electronic (AutoCAD) and hard copy record drawings to VAMC COR within 30 days of receipt of full as-built package from General Contractor. AutoCAD files shall not include external references.

Cost Proposals The A/E shall review the Contractor's requests for information and cost proposals for construction change orders when requested by the COR. The A/E's reply regarding his/her review of cost proposals and his/her recommendations shall include an independent breakdown of costs in detail, quantities, and unit prices and shall cover both additions and deductions of labor, materials, and equipment. The A/E shall also supply cost estimates as requested by the COR for Request for Proposals for anticipated changes.

17. CONTRACT OVERSIGHT: All contracts for this project shall be awarded by the Program Contracting Activity Central (PCAC); only a warranted VA Contracting Officer shall have authority to change the terms and conditions of a contract. These changes may involve the contract award amount, contract period of performance, issuance of stop work orders and changes to the statement of work.

PCAC shall designate a Contracting Officer’s Representative (COR) to monitor and manage the A/E’s performance under the design project contract. The COR shall be a representative of the Central Virginia VA Health Care System (CVHCS) Engineering Service Project Section and have the technical knowledge required to monitor and oversee the project.

A COR from the Central Virginia VA Health Care System (CVHCS) Engineering Service Project Section shall also be designated for the construction project contract to monitor and manage the construction contractor’s performance under the construction project contract. This designation under the construction contract shall be considered equivalent to the industry standard of “Owner’s Representative” and does not supersede or eliminate the A/E’s responsibility for Part Two Services/Construction Period Services. The A/E ultimately shall be responsible for any errors and omissions with the design discovered during and after the construction phase.

18. OI&T INFRASTRUCTURE STANDARD FOR TELECOMMUNICATION SPACE:

The latest version of Infrastructure Standard for Telecommunications Spaces is located on VA’s Technical Information Library (TIL) (https://www.cfm.va.gov/til/dguide/OIT-InfrastrucStdTelecomSpaces.pdf). The design for this project at the Central Virginia VA Health Care System (CVHCS) must meet the requirements of the Infrastructure Standard for Telecommunications Spaces.

The current version for this standard is version 3.1, dated July 1, 2021 (https://www.cfm.va.gov/til/dguide/OIT-InfrastrucStdTelecomSpaces.pdf). The design for this project at the H.H. McGuire VA Medical center in Richmond, VA must meet the Campus Support Center (CSC) requirements of the Infrastructure Standard for Telecommunications Spaces. The Infrastructure Standard for Telecommunications Spaces (The Standards) serves as the master reference document of criteria for Department of Veterans Affairs (VA) facility Information Technology (IT) support infrastructure. It defines the technical requirements necessary to maintain optimum reliability and efficiency within VA facilities and computing centers. IT Support Infrastructure is defined as all passive telecommunications, information technology equipment and supporting physical space and equipment. This standard is owned and maintained by Solution Delivery (SD) Data Center and Infrastructure Engineering and questions or concerns should be directed to the following email group: OIT ITOPS SD Data Center and Infrastructure Engineering. Users must ensure their use of this technology/standard is consistent with VA policies and standards, including, but not limited to, VA Handbooks 6102 and 6500; VA Directives 6004, 6513, and 6517; and National Institute of Standards and Technology (NIST) standards, including Federal Information Processing Standards (FIPS). Users must ensure sensitive data is properly protected in compliance with all VA regulations. Prior to use of this technology, users should check with their supervisor, Information Security Officer (ISO), Facility Chief Information Officer (CIO), or local Office of Information and Technology (OI&T) representative to ensure that all actions are consistent with current VA policies and procedures prior to implementation.

19. EXEMPTIONS TO VA OEHRM SITE INFRASTRUCTURE REQUIREMENTS:

Any variances or exemptions to SOW Attachment 02, most recent version, must be referenced, documented, and discussed with CO, COR and HEFP SEP. Following approval of variance or exemption, AE shall submit documentation describing variance or exemption, indicating reference in VA documentation, describe any mitigating measures, and include an attachment with documentation of discussion with CO, COR and HEFP SEP.

20. INFORMATION SECURITY:

The C&A requirements do not apply, and that a Security Accreditation Package is not required

21. REPORTING REQUIREMENTS:

The Contractor shall report Engineering Project Section, Facility Management Service, BLDG. 500 RM 2K--135 to check in with the COR during normal working hours. This check-in is mandatory. When the service is completed, the Contractor shall document services rendered on a legible field service report. The Contractor shall return to the same service and building to submit the field service report to the COR for signature during normal working hours.

23. SOW and ATTACHMENTS:

The following list of documents are attached to this SOW for A/E use and incorporation into the project documents:

· VHA Required Div 01 Specification Sections (See SOW Attachment 01)

· 00 VA OEHRM Site Infrastructure Requirements 3.1 (See SOW Attachment 02, for site data network requirements)

· VHA Directive 1061 Prevention of Healthcare Associated Legionella Disease (See SOW Attachment 03)

· Sensitive Infrastructure Data Classification FOUO (See SOW Attachment 04)

· 01 32 16.01 EHRM Architecture and Engineering CPM Schedule (See SOW Attachment 05)

· Program guide, PG-18-15 Volume C – A/E Submission Instructions for Minor and NRM Construction program dates November 2008 (See SOW Attachment 06)

· Seasonal influenza with vaccines (See SOW Attachment 07)

· Campus Map (See SOW Attachment 08)

· Training and Admin Support Space Planning Guide (See SOW Attachment 09, option 2)

· Area on campus for EHRM Training/Admin Support Space (See SOW Attachment 10)

· HEFP SEP Design Alerts 1-9 (SOW attachment 11)

End of SOW