Solicitation W912WJ21Q0084.pdf

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912WJ21Q0084 26-Jul-2021 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

SEE SCHEDULE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ] FOB

DESTINATION

[ ] OTHER X

(See Schedule)

13-Aug-2021(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

978-318-8324JENNIFER M SAMELA

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

Section B - Supplies or Services and Prices

INSTRUCTIONS TO OFFERORS

*SITE VISITS ARE HIGHLY RECOMMENDED PRIOR TO PROVIDING A QUOTE. SEE CLAUSE 52.236-27

ALT I FOR ADDITIONAL INFORMATION.

*PLEASE DIRECT QUESTIONS TO JENNIFER M. SAMELA AT (978) 318-8324 or

JENNIFER.M.SAMELA@USACE.ARMY.MIL. ANY INFORMATION RECEIVED AT THE SITE VISIT

WHICH CONFLICTS WITH THIS SOLICITAION SHOULD BE BROUGHT TO THE ATTENTION OF

JENNIFER M. SAMELA. THE SOLICITATION AND RESULTING CONTRACT SHALL BE THE

GOVERNING DOCUMENT IN ALL CASES.

** QUOTES CAN BE E-MAILED TO JENNIFER M. SAMELA AT

JENNIFER.M.SAMELA@USACE.ARMY.MIL.

NOTE 1: In accordance with FAR Part 28.101-1(c), the Contractor will NOT be required to provide a Bid Guarantee.

NOTE 2: In accordance with FAR Part 28.102-1(b), the Contractor will be required to provide the following payment protections for all construction contracts greater than $150,000.00.

(i) Payment Bond or

(ii) Irrevocable Letter of Credit and

(iii) Performance Bond

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

A Performance Bond shall be required if the total price of the quote is greater than $150,000.00. The penal amount of the Performance Bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall also be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 3: In accordance with FAR Part 28.102-1(c), the Contractor will be required to provide one of the following payment protections for all construction contracts greater than $35,000.00 but not greater than $150,000.00.

(i) Payment bond or

(ii) Irrevocable letter of credit

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 4:

QUOTATION INSTRUCTIONS:

1. If subcontractor will be used for this work, please provide company name:

2. In accordance with FAR Part 52.204-7(b)(1) Contractors must be registered in the System for Award Management (SAM) database (www.SAM.gov) to submit an offer. (Formerly the Central Contractor Registration

(CCR) database and the On-Line Representations and Certifications (ORCA).) Any reference to CCR or ORCA in any clause or provision is referring to the www.sam.gov website. Please note that Google and Google Chrome are not supported browsers for SAM registration. Mozilla FireFox, Safari, and Internet Explorer are supported browsers.

NOTE: SAM.gov registration takes approximately 3 weeks (DUNS registration 1-2 business days; CAGE code validation up to 10 business days; IRS validation and overall submission 7-10 business days). It is the contractor’s responsibility to track SAM.gov registration and follow-up with required tasks.

In addition, if you are registering a new entity in SAM.gov, you must provide an original, signed notarized letter stating that you are the authorized Entity Administrator. The Entity Administrator must establish a LOGIN.GOV account using the e-mail address that will be associated with the SAM registration. See https://www.gsa.gov/about-us/organization/federal-acquisition-service/office-of-systems-management/integrated-award-environment-iae/sam-update for additional information.

3. Provide business DUNS number: _______________________________ (phone 800-333-0505 for DUNS).

4. Provide business CAGE code: __________________________________

5. Tax Identification Number: ___________________________________

6. Contractors shall provide completed FAR clause 52.204-8 (Annual Representations and Certifications) found in Section K of this solicitation with their quote, if the Contractors have not completed their annual representations and certifications electronically via the SAM website at www.sam.gov. (See Paragraph 2 above).

7. Contractors are not required to submit an Accident Prevention Plan (APP) with their quote. The successful offeror will be required to submit this document at the direction of the Technical Point of Contact. The APP must be accepted by the Government Designated Authority prior to the commencement of work.

POTENTIAL OFFERORS ARE NOTIFIED THAT THE BASIS ON WHICH AWARD WILL BE MADE IS

PRICE ALONE.

ALL RESPONSIBLE SOURCES MAY SUBMIT A RESPONSE WHICH, IF TIMELY RECEIVED, MUST BE

CONSIDERED BY THE AGENCY.

INVOICES SHALL BE SENT TO TECHNICAL POINT OF CONTACT.

BID SCHEDULE

BID SCHEDULE

Refer to STATEMENT OF WORK, Paragraph B, MEASUREMENT AND PAYMENT.

Item Estimated Unit Estimated No. Description Quantity Unit Price Amount

0001 Concrete Repairs, Interior

0001AA First 40 LF 40 LF $_______ $_______

0001AB Over 40 LF 40 LF $_______ $_______

0002 Concrete Repairs, Exterior

0002AA First 26 LF 26 LF $_______ $_______

0002AB Over 26 LF 39 LF $_______ $_______

0003 Permanent Fall Protection Features 1 Job Job $_________

0004 All Other Work 1 Job Job $_________

TOTAL ESTIMATED AMOUNT $_____________

Note 1: "LF" = Linear Foot.

Note 2: Vendors must provide a quote all items. The work will be awarded as a whole to one vendor. Quotes will be evaluated and the low quote determined by the Total Estimated Amount for Line Items 0001 through 0004.

Note 3: Item Numbers 0001 and 0002 are subdivided into two estimated quantities and shall be separately priced. The Government will evaluate this item on the basis of the total price of their sub-items. (AFARS 5152.211-9001 Variations in Estimated Quantities -- Subline Items).

Note 4: All work shall be completed within the time period specified in Section 00 80 00 SPECIAL CONTRACT REQUIREMENTS, Subpart COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK (APR 1984) FAR 52.211-10.

Note 5: In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended quote. If the vendor shows only the total price but fails to enter a unit price, the total divided by the estimated quantity will be held to be the intended unit price.

Note 6: The Contractor shall identify a point of contact e-mail for all correspondence related to this quote:

Section C - Descriptions and Specifications

STATEMENT OF WORK

THE STATEMENT OF WORK (SPECIFICATIONS) AND DRAWINGS FOR THIS ACTION WILL BE

INCLUDED AS SEPARATE FILES.

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

Section H - Special Contract Requirements

SECURITY REQUIREMENTS

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Technical Point of Contact NLT 5 calendar days after the completion of the training.

WAGE DETERMINATION

General Decision Number: NH20210021 02/12/2021

Superseded General Decision Number: NH20200021

State: New Hampshire

Construction Type: Building

County: Hillsborough County in New Hampshire.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.95 for calendar year 2021 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.95 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2021. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/01/2021 1 02/12/2021

ASBE0006-014 09/01/2019

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 38.75 29.75

BOIL0029-003 01/01/2017

Rates Fringes

BOILERMAKER......................$ 42.42 24.92

BRNH0003-001 06/01/2020

Rates Fringes

BRICKLAYER.......................$ 42.55 28.02

* ELEC0490-006 01/01/2021

Rates Fringes

ELECTRICIAN (Includes Low Voltage Wiring and Alarm Installation)....................$ 31.45 20.94

* ELEV0004-007 01/01/2021

Rates Fringes

ELEVATOR MECHANIC................$ 63.47 35.83

a. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, Christmas Day and the Friday after Thanksgiving.

b. VACATION: Employer contributes 8% of basic hourly rate for 5 years or more of service; 6% of basic hourly rate for 6 months to 5 years of service as vacation pay credit.

SUNH2015-007 06/16/2017

Rates Fringes

CARPENTER, Includes Acoustical Ceiling

Installation, Drywall Hanging, Form Work, and Metal Stud Installation................$ 24.43 6.49

CEMENT MASON/CONCRETE FINISHER...$ 27.70 2.61

DRYWALL FINISHER/TAPER...........$ 28.67 11.69

GLAZIER..........................$ 27.74 3.74

IRONWORKER, REINFORCING..........$ 22.60 19.89

IRONWORKER, STRUCTURAL...........$ 24.05 12.75

LABORER: Common or General......$ 17.46 9.86

LABORER: Mason Tender - Brick...$ 17.01 4.43

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 24.08 4.75

OPERATOR: Crane.................$ 27.42 3.83

OPERATOR: Loader................$ 22.54 2.29

OPERATOR: Roller................$ 23.56 3.28

PAINTER (Brush and Roller).......$ 20.00 3.28

PAINTER: Spray..................$ 22.99 3.28

PIPEFITTER, Includes HVAC Pipe Installation................$ 25.17 11.87

PLUMBER..........................$ 23.97 9.68

ROOFER...........................$ 17.55 3.25

SHEET METAL WORKER, Includes HVAC Duct Installation...........$ 33.83 10.09

SPRINKLER FITTER (Fire Sprinklers)......................$ 31.29 9.78

WATERPROOFER.....................$ 31.22 3.70

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

52.236-4002

52.236-4002 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled “DEFAULT (FIXED PRICE CONSTRUCTION).” In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS BASED ON 5 DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(12) (10) (5) (2) (2) (1) (1) (1) (1) (1) (2) (11)

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “DEFAULT (FIXED PRICE CONSTRUCTION).”

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-18 Variation in Estimated Quantity APR 1984 52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2020-O0008).

OCT 2020

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 (Dev) Individual Surety--Pledge of Assets (DEVIATION 2020-

O0016)

FEB 2021

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements NOV 2020 252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2020 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7004 (Dev) DoD Progress Payment Rates (DEVIATION 2020-O0010) MAR 2020 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JAN 2021

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 270 days after notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (FEB 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (NOV 2020).

(ix) 52.253-1, Computer Generated Forms (JAN 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (JAN 2020) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) (41 U.S.C. chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (OCT 2020) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (NOV 2020) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (JAN 2021) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract, and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (JUN 2020) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/

(d) DELETED

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) DELETED

(g) DELETED

(h) DELETED

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code 238190 assigned to contract number W912WJ21PXXXX.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture.

[The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: .] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a veteran-owned small business concern.

(7) [Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[Contractor to sign and date and insert authorized signer's name and title.]

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (SEP 2013)

(a) In the performance of this contract, the contractor shall make maximum use of biobased products that are United States Department of Agriculture (USDA)-designated items unless--

(1) The product cannot be acquired--

(i) Competitively within a time frame providing for compliance with the contract performance schedule;

(ii) Meeting contract performance requirements; or

(iii) At a reasonable price.

(2) The product is to be used in an application covered by a USDA categorical exemption (see 7 CFR 3201.3(e)).

For example, all USDA-designated items are exempt from the preferred procurement requirement for the following:

(i) Spacecraft system and launch support equipment.

(ii) Military equipment, i.e., a product or system designed or procured for combat or combat-related missions.

(b) Information about this requirement and these products is available at http://www.biopreferredgov.

(c) In the performance of this contract, the Contractor shall--

(1) Report to http://www.sam.gov, with a copy to the Contracting Officer, on the product types and dollar value of any USDA-designated biobased products purchased by the Contractor during the previous Government fiscal year, between October 1 and September 30; and

(2) Submit this report no later than--

(i) October 31 of each year during contract performance; and

(ii) At the end of contract performance.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (FEB 2021)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in…