Solicitation W912WJ20Q0069.pdf

CIVIL ENGINEERING SEC

PHILLIPS, HENRY S

696 VIRGINIA ROAD

CONCORD MA 01742-2751

TEL: (978) 318-8503 FAX:

W13G8601636589

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912WJ20Q0069 09-Jul-2020 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

24-Jul-2020(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

978-318-8324JENNIFER M SAMELA

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912WJ20Q0069

Section B - Supplies or Services and Prices

INSTRUCTIONS TO OFFERORS

52.237-1 SITE VISIT (APR 1984)

Offerors or quoters are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

Due to health and safety concerns related to the COVID-19 pandemic, the site visit for this project will be conducted virtually. The virtual site visit will involve a virtual walk through of the site that may contain photos and video recording of site features. This video will be recorded during the solicitation period and an amendment will be issued stating how to obtain the video once it is available.

*PLEASE DIRECT QUESTIONS TO JENNIFER M. SAMELA AT (978) 318-8324 or

JENNIFER.M.SAMELA@USACE.ARMY.MIL. ANY INFORMATION RECEIVED AT THE SITE VISIT

WHICH CONFLICTS WITH THIS SOLICITAION SHOULD BE BROUGHT TO THE ATTENTION OF

JENNIFER M. SAMELA. THE SOLICITATION AND RESULTING CONTRACT SHALL BE THE

GOVERNING DOCUMENT IN ALL CASES.

** QUOTES CAN BE E-MAILED TO JENNIFER M. SAMELA AT

JENNIFER.M.SAMELA@USACE.ARMY.MIL.

NOTE 1: In accordance with FAR Part 28.101-1(c), the Contractor will NOT be required to provide a Bid Guarantee.

NOTE 2: In accordance with FAR Part 28.102-1(b), the Contractor will be required to provide the following payment protections for all construction contracts greater than $150,000.00.

(i) Payment Bond or

(ii) Irrevocable Letter of Credit and

(iii) Performance Bond

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

A Performance Bond shall be required if the total price of the quote is greater than $150,000.00. The penal amount of the Performance Bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall also be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 3: In accordance with FAR Part 28.102-1(c), the Contractor will be required to provide one of the following payment protections for all construction contracts greater than $35,000.00 but not greater than $150,000.00.

(i) Payment bond or

(ii) Irrevocable letter of credit

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 4:

QUOTATION INSTRUCTIONS:

1. If subcontractor will be used for this work, please provide company name:

2. In accordance with FAR Part 52.204-7(b)(1) Contractors must be registered in the System for Award Management (SAM) database (www.SAM.gov) to submit an offer. (Formerly the Central Contractor Registration (CCR) database and the On-Line Representations and Certifications (ORCA).) Any reference to CCR or ORCA in any clause or provision is referring to the www.sam.gov website. Please note that Google and Google Chrome are not supported browsers for SAM registration. Mozilla FireFox, Safari, and Internet Explorer are supported browsers.

NOTE: SAM.gov registration takes approximately 3 weeks (DUNS registration 1-2 business days; CAGE code validation up to 10 business days; IRS validation and overall submission 7-10 business days). It is the contractor’s responsibility to track SAM.gov registration and follow-up with required tasks.

In addition, if you are registering a new entity in SAM.gov, you must provide an original, signed notarized letter stating that you are the authorized Entity Administrator. The Entity Administrator must establish a LOGIN.GOV account using the e-mail address that will be associated with the SAM registration. See https://www.gsa.gov/about-us/organization/federal-acquisition-service/office-of-systems-management/integrated-award-environment-iae/sam-update for additional information.

3. Provide business DUNS number: _______________________________ (phone 800-333-0505 for DUNS).

4. Provide business CAGE code: __________________________________

5. Tax Identification Number: ___________________________________

6. Contractors shall provide completed FAR clause 52.204-8 (Annual Representations and Certifications) found in Section K of this solicitation with their quote, if the Contractors have not completed their annual representations and certifications electronically via the SAM website at www.sam.gov. (See Paragraph 2 above).

7. Contractors are not required to submit an Accident Prevention Plan (APP) with their quote. The successful offeror will be required to submit this document at the direction of the Technical Point of Contact. The APP must be accepted by the Government Designated Authority prior to the commencement of work.

POTENTIAL OFFERORS ARE NOTIFIED THAT THE BASIS ON WHICH AWARD WILL BE MADE IS

PRICE ALONE.

ALL RESPONSIBLE SOURCES MAY SUBMIT A RESPONSE WHICH, IF TIMELY RECEIVED, MUST BE

CONSIDERED BY THE AGENCY.

INVOICES SHALL BE SENT TO TECHNICAL POINT OF CONTACT.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Green Tree Pond Dam Repairs

FFP

Contractor shall furnish all labor, materials, and equipment necessary to perform dam repairs in accordance with the Specifications and Plans.

FOB: Destination

MILSTRIP: W13G8601636589

PURCHASE REQUEST NUMBER: W13G8601636589

PSC CD: Y1QA

NET AMT

0002 1 Job Seavey Pond Dam Repairs

FFP

Contractor shall furnish all labor, materials, and equipment necessary to perform dam repairs in accordance with the Specifications and Plans.

FOB: Destination

MILSTRIP: W13G8601636589

0003 1 Job

CMRA

FFP

Time for fulfilling the CMR requirement if included or if not included in your overhead for initial CMR database set up and for annual CMR reporting. The Contractor will report ALL contractor manpower (including all subcontractor manpower) required for performance of this contract to include all task orders and modifications IAW the Office of the Assistant Secretary of the Army (Manpower and Reserve Affairs). Refer to clause 52.204-9002 for additional information.

FOB: Destination

MILSTRIP: W13G8601636589

Section C - Descriptions and Specifications

STATEMENT OF WORK

SEE SPECIFICATIONS AND PLANS INCLUDED AS SEPARATE FILES

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 150 dys. ANP 1 CIVIL ENGINEERING SEC

PHILLIPS, HENRY S

696 VIRGINIA ROAD

CONCORD MA 01742-2751

(978) 318-8503 FOB: Destination

W912WJ

0002 150 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 150 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section H - Special Contract Requirements

SECURITY REQUIREMENTS

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Technical Point of Contact NLT 5 calendar days after the completion of the training.

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the Technical Point of Contact no later than 3 business days after the initial contract award.

WAGE DETERMINATION

General Decision Number: NH20200024 02/14/2020

Superseded General Decision Number: NH20190024

State: New Hampshire

Construction Type: Heavy

County: Hillsborough County in New Hampshire.

HEAVY CONSTRUCTION PROJECTS

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2020. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2020 1 02/14/2020

* ELEC0490-008 01/01/2020

Rates Fringes

ELECTRICIAN......................$ 30.28 20.58

IRON0007-039 03/16/2019

Rates Fringes

IRONWORKER (Reinforcing and Structural)......................$ 26.01 22.57

PLUM0131-005 06/01/2019

Rates Fringes

PIPEFITTER.......................$ 34.07 23.48

SUNH2015-010 06/16/2017

Rates Fringes

CARPENTER, Includes Form Work....$ 26.83 6.94

CEMENT MASON/CONCRETE FINISHER...$ 27.46 13.30

LABORER: Asphalt, Includes Raker, Shoveler, Spreader and Distributor......................$ 23.70 1.54

LABORER: Common or General......$ 16.93 1.70

LABORER: Pipelayer..............$ 22.80 1.45

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 25.00 1.84

OPERATOR: Bulldozer.............$ 21.70 4.09

OPERATOR: Crane.................$ 28.37 9.74

OPERATOR: Drill.................$ 27.15 13.39

OPERATOR: Loader................$ 20.80 2.65

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 27.10 5.69

OPERATOR: Roller................$ 24.09 4.43

PAINTER (Brush and Roller).......$ 30.00 25.50

TRAFFIC CONTROL: Flagger.......$ 17.24 1.54

TRUCK DRIVER: Dump Truck........$ 19.02 5.73

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

CMRA

The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including subcontractor manpower) required for performance of this contract to include all task orders and modifications (this only applies to work performed on a Army

Installation) . The contractor is required to completely fill in all the information in the format described at the following web address: https://cmra.army.mil. This website address includes links to a helpdesk and a user's manual. As part of its submission, the contractor will also provide the estimated total cost (if any) incurred to comply with this reporting requirement. The reporting period will be from the beginning of the period of performance until 30 September of each government fiscal year, not to exceed 12 months and must be reported by 31 October of each calendar year. The awarded contract shall include a contract line item number (CLIN) for the Base period that shall cover cost if any for the initial CMR database setup and the annual requirement for CMR reporting. There will also be CMR option CLINs included to be exercised annually for each option period awarded. Further information and frequently asked questions are located at the following website: http://www.ecmra.mil/help/help.html. The contractor may choose to price or not separately price for this requirement. See line items for specific CLIN information.

Section I - Contract Clauses

52.236-4002

52.236-4002 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled “DEFAULT (FIXED PRICE CONSTRUCTION).” In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

BASED ON 5 DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(11) (9) (5) (2) (1) (1) (1) (1) (1) (1) (3) (10)

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delaydays exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “DEFAULT (FIXED PRICE CONSTRUCTION).”

52.204-9002

52.204-9002 REPORTING OF CONTRACTOR MANPOWER DATA ELEMENTS

(a) Scope. The following sets forth contractual requirements for reporting of contractor labor work year equivalents (also called Contractor Man-year Equivalents (CMEs)) in support of the Army, pursuant to 10 U.S.C. 129a, 10 U.S.C. 2461(g), Section 343 of P.L. 106-65, and 32 CFR 668. Reporting shall be accomplished electronically by direct contractor submission to the secure Army Web Site:

https://ecmra.mil. Information on the background, purposes, and significance of this reporting requirement, and the 32 CFR 668 Final Rule as published in the Federal Register, can be found at this Web Site. In addition, a Help Desk function, detailed instructions on what and how to report, FAQs, and a site demonstration are available. The Army’s objective is to collect as much significant CME data as possible to allow accurate reporting to Congress and for effective Army planning. The reporting data elements should not be viewed as an “all or nothing” requirement. Even partial reporting, e.g., direct labor hours, appropriation data, place of performance, Army customer, etc., will be helpful.

(b) Applicability. This reporting requirement applies to services covered by Federal Supply Class or Service codes for “Research and Development,” and “Other Services and Construction.” Report submissions shall not contain classified information. (Also see “Exemptions” at (d) below.)

(c) Requirements. The contractor is required to report the following contractor manpower information, associated with performance of this contract action in support of Army requirements, for all covered contracts, to the Office, Assistant Secretary of the Army (Manpower and Reserve Affairs) (ASA(M&RA)), using the secure Army data collection web-site at https://ecmra.mil. (Other information requirements associated with the manpower data collection (contract and task or delivery order numbers; appropriation data and amounts; total estimated value of contract; federal supply class or service code; major Army organizational element receiving or reviewing work; beginning and ending data for reporting period; place of performance; name, address, and point of contact for contractor; etc.) are specified and explained at the web site.)

(1) Labor Hours. Composite direct labor hours, and the value of those indirect labor hours plus compensation related costs for direct labor hours ordinarily included in the indirect pools1.

(2) Rates. Alternatively, contractors may report two distinct, relevant (annualized) composite or average indirect labor rates in lieu of raw indirect labor hours and the value of those indirect hours. Such rates shall be annualized average estimates for the reporting contractor and need not be developed for each reporting period. Either method chosen should be consistently reported.

(d) Exemption(s). If the contractor is unable to comply with these reporting requirements without creating a whole new cost allocation system or system of records (such as a payroll accounting system), or due to similar insurmountable practical or economic reasons, the contractor may claim an exemption to at least a portion of the reporting requirement by certifying in writing to the contracting officer the clear underlying reason(s) for exemption from the specified report data element(s), and further certifying that they do not otherwise have to provide the exempted information, in any form, to the United States Government. The “self-exemption” will apply to all contract actions involving the contractor and will be reviewed and approved by the Deputy Assistant Secretary of the Army (Procurement), in coordination with the Deputy Assistant Secretary of the Army (Force Management and Resources), whose decision is final in this matter.

(e) Uses and Safeguarding of Information. The information submitted will be treated as contractor proprietary when associated with a contractor name of contract number.

(f) Subcontract Data. The contractor shall ensure that all reportable subcontract data is timely reported to the data collection web site (citing this contract/order number). At the discretion of the prime contractor, this reporting may be done directly by subcontractors to the data collection site; or by the prime contractor after consolidating and rationalizing all significant data from their subcontractors.

(g) Report schedule. The contractor is required to report the required information to the ASA(M&RA) data collection web site annually. The reporting period will be from the beginning of the period of performance until 30 September of each government fiscal year, not to exceed 12 months and must be reported by 31 October of each calendar year.

(h) Reporting Flexibility. Contractors are encouraged to communicate with the Help Desk identified at the data collection web site to resolve reporting difficulties. The web site reporting pages include a “Remarks” field to accommodate non-standard data entries if needed to facilitate simplified reporting and to minimize reporting burdens arising out of unique circumstances. Changes to facilitate reporting may be authorized by the contracting officer or the Help Desk (under HQDA policy direction and oversight).

CLAUSES INCORPORATED BY REFERENCE

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

DEC 2019

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984

252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 days from notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (AUG 2019).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Jan 2020) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (JAN 2019) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov

(d) DELETED

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) DELETED

(g) DELETED

(h) DELETED

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEVIATION 2020-O0008) (MAR 2020)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. “Similarly situated entity,” as used in this clause, means a first-tier subcontractor, including an independent contractor, that—

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to—

(1) Contracts that have been set aside for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants;

(3) Contracts that have been awarded on a sole-source basis in accordance with subpart 19.8;

(4) Orders set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F), if the order amount is expected to exceed the simplified acquisition threshold;

(5) Orders competed among 8(a) participants in accordance with subpart 19.8 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F), regardless of dollar value;

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference; and

(7) Orders issued directly to small business concerns or 8(a) participants under multiple-award contracts as described in 19.504(c)(1)(ii).

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a NAICS code for—

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract. Other direct costs are excluded to the extent they are not the principal purpose of the contract and cannot be obtained from small business concerns;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph

(e) of this clause will be performed by the aggregate of the joint venture participants.

(g) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1) and (2) of this clause— [Contracting Officer check as appropriate.] ___ By the end of the base term of the contract and then by the end of each subsequent option period; or ___ By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(3) and (4) of this clause, by the end of the performance period for the order.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAR 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within…