Solicitation - W912P526QA037 Lake Barkley Paving at Canal Campground and Cadiz Recreation Area.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Patrick.Ferguson Line

Patrick.Ferguson Line

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quanti ty

Unit Unit Price Amount

0001 Lake Barkley paving at Cadiz Recreation Area and Canal Campground. Offer shall provide itemized pricing for the requirements identified in Attachment 0004, W912P526QA037_RTA_Bid Schedule_Barkley Paving.pdf.

Product Service Code: Z1LB

North American Industry Classification System (NAICS):

237310

Pricing Arrangement: Firm Fixed Price

1 Job

Option Line Item

Option for additional paving and related requirements at Lake Barkley at Cadiz Recreation Area and Canal Campground. Offer shall provide itemized pricing for the requirements identified in Attachment 0004, W912P526QA037_RTA_Bid Schedule_Barkley Paving.pdf.

Product Service Code: Z1LB

North American Industry Classification System (NAICS):

237310

1 Job

W912P526QA037

Pricing Arrangement: Firm Fixed Price

Section C - Description/Specifications/Statement of Work

Requirements Lake Barkley Paving at Cadiz Recreation Area and Canal Campground The Technical Plans and Specifications are provided as separate documents but are intended to be a part of this solicitation and resulting contract award.

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.246-12 Inspection of Construction. 1996-08

Section F - Deliveries or Performance

0001 1 JobQuantity

Address and POC

Period of Performance From 07 Oct 2026 To 14 Jul 2027

Option Line Item

1 JobQuantity

Address and POC

Period of Performance From 07 Oct 2026 To 14 Jul 2027

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative.

1991-12

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

2018-12

252.236-7000 Modification Proposals--Price Breakdown.

1991-12

Section H - Special Contract Requirements

SPECIAL CONTRACT CONDITIONS

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK - CONSTRUCTION (APR

1984)

The Contractor shall be required to (a) commence work under this contract within ten calendar days after the date the Contractor receives the notice to proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire project not later than 280 calendar days after issuance of NTP. The time stated for completion shall include final cleanup of the premises.

If exercised, options will extend the contract completion date by 16 calendar days.

SITE VISIT (CONSTRUCTION) (FEB 1995) - Alternate I

(a) The conditions, Differing Site Conditions, and Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for:

26 August 2026 at 9:30AM Central Time

(c) Participants will meet at: The site visit will start at Canal Campground and conclude at Cadiz Recreation Area.

Canal Campground: 1010 Canal Campground Road, Grand Rivers, KY, 42045

Cadiz Recreation Area (West Cadiz Park): 31 Hamilton Street, Cadiz, KY 42211

SCHEDULE OF INSURANCE

a. The contractor shall, at its own expense, provide and maintain during the entire performance period of this contract at least the kinds and minimum amounts of insurance required below:

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance for Bodily Injury Liability

Minimum Per Occurrence for Bodily Liability $500,000

Minimum Per Each Accident for Property Damage $100,000

Minimum Aggregate for Bodily Injury $500,000

Automobile Liability Insurance

Minimum Per Person $200,000

Minimum Per Occurrence for Bodily Injury $500,000

Minimum Per Occurrence for Property Damage $20,000

b. Before commencing work under this contract, the contractor shall certify to the Contracting Officer in writing that the required insurance has been obtained.

The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the state in which this contract is to be performed or prescribed, and (2) until 30 days after the insurer of the contractor gives written notice to the Contracting Officer.

c. The contractor shall insert the substance of the clause entitled "Insurance Work on a Government Installation (FAR 52.228-5), "in subcontracts under this contract that require work on a Government Installation and shall require subcontractors to provide and maintain the insurance required above.

The Certificate of Liability Insurance, ACORD Form 25, contains a standard cancellation clause on the lower, right side of the form. The cancellation clause shall not be accepted by the Government as written. The cancellation clause on the Certificates of Liability Insurance, ACORD Form 25, shall only be accepted by the Government as follows:

SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED

BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL

MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO

THE LEFT.

PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by the Government.

(b) Anticipated adverse weather delay days (based on a 5-day work week):

Month 7 Calendar Days 6 Day Work WK 5 Day Work WK 4 Day Work WK

January 6 6 5 4

February 4 4 3 3

March 3 3 3 2

April 3 3 3 2

May 3 3 3 2

June 3 3 3 2

July 4 4 3 3

August 3 3 3 2

September 2 2 2 2

October 2 2 2 2

November 2 2 2 2

December 4 4 3 3

(c) Adequate laydown areas exist at the project site.

(End of clause)

TIME EXTENSION FOR UNUSUALLY SEVERE WEATHER:

a. This provision specifies the procedures for the determination of time extensions for unusually sever weather in accordance with RFO Clause 52.212-4(f) Excusable Delays. In order for the Contracting Officer to award a time extension the following conditions must be met:

1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor. See Special Contract Condition, "Physical Data", for the typical number of anticipated adverse weather days. The number of days shall be exceeded for a given month before a time extension is granted.

b. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily contractor's quality control (CQC) report, the occurrence of adverse weather and resultant impact to the normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in a previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in Special Contract Condition "Physical Data", the Contracting Officer will convert any qualifying days to calendar days, giving full consideration for equivalent fair-weather workdays, and issue a modification in accordance with RFO Clause 52.212-4(f) Excusable Delays.

*** END OF NARRATIVE ***

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-3 Gratuities. 1984-04

52.203-6 Restrictions on Subcontractor Sales to the Government.

(Alternate I)

2020-06 Alternate I 2021-11

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel.

2011-01

52.204-13 System for Award Management- Maintenance. (Deviation 2026- O0038)

2026-02

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation 2026- O0038)

2026-02

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation 2026-O0038)

2026-02

52.212-4 Terms and Conditions- Commercial Products and Commercial Services. (Deviation

2026-02

2026-O0038)

52.219-6 Notice of Total Small Business Set-Aside. (Deviation 2026- O0038)

2026-02

52.219-8 Utilization of Small Business Concerns. (Deviation 2026- O0038)

2026-02

52.222-3 Convict Labor. (Deviation 2026- O0038)

2026-02

52.222-4 Contract Work Hours and Safety Standards-Overtime Compensation. (Deviation 2026- O0038)

2026-02

52.222-6 Construction Wage Rate Requirements. (Deviation 2026- O0038)

2026-02

52.222-7 Withholding of Funds. (Deviation 2026-O0038)

2026-02

52.222-8 Payrolls and Basic Records.

(Deviation 2026-O0038)

2026-02

52.222-9 Apprentices and Trainees.

(DEVIATION 2025-O0003)

2026-02 Deviation 2025- O0003

2025-03

52.222-10 Compliance with Copeland Act Requirements. (Deviation 2026- O0038)

2026-02

52.222-11 Subcontracts (Labor Standards).

(Deviation 2026-O0038)

2026-02

52.222-12 Contract Termination-Debarment. 2014-05

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. (Deviation 2026- O0038)

2026-02

52.222-15 Certification of Eligibility. 2014-05

52.222-35 Equal Opportunity for Veterans.

(Deviation 2026-O0038)

2026-02

52.222-36 Equal Opportunity for Workers with Disabilities. (Deviation 2026- O0038)

2026-02

52.222-37 Employment Reports on Veterans. (Deviation 2026- O0038)

2026-02

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Deviation 2026- O0038)

2026-02

52.222-50 Combating Trafficking in Persons. (Deviation 2026-O0038)

2026-02

52.222-54 Employment Eligibility Verification. (Deviation 2026- O0038)

2026-02

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (Deviation 2026-O0038)

2026-02

52.222-62 Paid Sick Leave Under Executive Order 13706. (Deviation 2026-

2026-02

O0038)

52.222-90 Addressing DEI Discrimination by Federal Contractors.

(Deviation 2026-O0040, Revision 1)

2026-04

52.223-2 Reporting of Biobased Products Under Service and Construction Contracts. (Deviation 2026- O0038)

2026-02

52.223-23 Sustainable Products. (Deviation 2026-O0038)

2026-02

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.227-1 Authorization and Consent. 2020-06

52.227-4 Patent Indemnity-Construction Contracts.

2007-12

52.228-2 Additional Bond Security. 1997-10

52.228-5 Insurance-Work on a Government Installation.

1997-01

52.228-11 Individual Surety-Pledge of Assets.

2021-02

52.228-12 Prospective Subcontractor Requests for Bonds.

2022-12

52.228-15 Performance and Payment Bonds-Construction.

2020-06

52.232-17 Interest. 2014-05

52.232-23 Assignment of Claims. (Alternate I)

2014-05 Alternate I 1984-04

52.232-27 Prompt Payment for Construction Contracts.

2017-01

52.232-33 Payment by Electronic Funds Transfer-System for Award Management.

2018-10

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-3 Protest after Award. (Deviation 2026-O0038)

2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation 2026- O0038)

2026-02

52.236-2 Differing Site Conditions.

(Deviation 2026-O0038)

2026-02

52.236-3 Site Investigation and Conditions Affecting the Work. (Deviation 2026-O0038)

2026-02

52.236-5 Material and Workmanship.

(Deviation 2026-O0038)

2026-02

52.236-6 Superintendence by the Contractor. (Deviation 2026- O0038)

2026-02

52.236-7 Permits and Responsibilities.

(Deviation 2026-O0038)

2026-02

52.236-8 Other Contracts. (Deviation 2026-

2026-02

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (Deviation 2026-O0038)

2026-02

52.236-10 Operations and Storage Areas.

(Deviation 2026-O0038)

2026-02

52.236-11 Use and Possession Prior to Completion. (Deviation 2026- O0038)

2026-02

52.236-12 Cleaning Up. (Deviation 2026- O0038)

2026-02

52.236-13 Accident Prevention. (Deviation 2026-O0038)

2026-02

52.236-15 Schedules for Construction Contracts. (Deviation 2026- O0038)

2026-02

52.236-17 Layout of Work. (Deviation 2026- O0038)

2026-02

52.236-21 Specifications and Drawings for Construction. (Deviation 2026- O0038)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation 2026- O0038)

2026-02

52.240-93 Basic Safeguarding of Covered Contractor Information Systems.

(Deviation 2026-O0038)

2026-02

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-04

52.246-21 Warranty of Construction. 1994-03

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense- Contract-Related Felonies.

2023-01

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting (DEVIATION 2026- O0025)

2024-05 Deviation 2026- O0025

2026-06

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.223-7008 Prohibition of Hexavalent 2023-01

Chromium.

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.225-7052 Restriction on the Acquisition of Certain Magnets, Tantalum, and Tungsten.

2024-05

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime.

2023-01

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.232-7010 Levies on Contract Payments. 2006-12

252.240-7997 NIST SP 800-171 DoD Assessment Requirements.

(DEVIATION 2026-O0025)

2026-02 Deviation 2026- O0025

2026-02

252.243-7001 Pricing of Contract Modifications. 1991-12

252.243-7002 Requests for Equitable Adjustment.

2022-12

252.244-7000 Subcontracts for Commercial Products or Commercial Services.

2023-11

252.244-7999 Subcontracts for Commercial Products or Commercial Services. (DEVIATION 2026- O0015)

2026-02 Deviation 2026- O0015

2026-02

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.211-12 Liquidated Damages- Construction.

2000-09

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,254.69 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.217-7 Option for Increased Quantity- Separately Priced Line Item.

1989-03

Option for Increased Quantity-Separately Priced Line Item (Mar 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 280 calendar days of

. Delivery of added items shall continue at the same rate that like items are the notice to proceed called for under the contract, unless the parties otherwise agree.

(End of clause)

52.219-14 Limitations on Subcontracting

(DEVIATION 2021-O0008)

2026-02 Deviation 2021- O0008

2023-02

LIMITATIONS ON SUBCONTRACTING (FEB 2023) (DEVIATION 2021-O0008)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that--

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to--

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are--

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405- 5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are--

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for--

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding certain other direct costs and certain work performed outside the United States (see paragraph (e)(1)(i)), to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract. The following services may be excluded from the 50 percent limitation:

(i) Other direct costs, to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service. Examples include airline travel, work performed by a transportation or disposal entity under a contract assigned the environmental remediation NAICS code 562910), cloud computing services, or mass media purchases.

(ii) Work performed outside the United States on awards made pursuant to the Foreign Assistance Act of 1961, or work performed outside the United States required to be performed by a local contractor.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the

Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause--

[Contracting Officer check as appropriate.]

[ ] By the end of the base term of the contract and then by the end of each subsequent option period; or

[ ] By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protégé and its mentor approved by the Small Business Administration, the small business protégé shall perform at least 40 percent of the work performed by the joint venture. Work performed by the small business protégé in the joint venture must be more than administrative functions.

(2) In an 8(a) joint venture, the 8(a) participant(s) shall perform at least 40 percent of the work performed by the joint venture. Work performed by the 8(a) participants in the joint venture must be more than administrative functions.

(End of clause)

52.219-28 Postaward Small Business Program Rerepresentation.

(Deviation 2026-O0038)

2026-02

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document /support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under ____NAICS Code assigned to ____contract number.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (g)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1001.

(3) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(4) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __ .]

(5) Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program. The Contractor represents that it [ ] is, [ ] is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402.

[____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(6) HUBZone joint venture eligible under the HUBZone Program.[ Complete only if the offeror is a HUBZone small business concern. ] The offeror represents, as part of its offer, that It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture must be certified as a HUBZone concern. [____Contractor to sign and date and insert authorized signer's name and title.]

52.225-9 Buy American-Construction Materials. (Deviation 2026- O0038)

2026-02

Buy American-Construction Materials (Feb 2026) (Deviation 2026-O0038)

(a) . As used in this clause-Definitions

Commercially available off-the-shelf (COTS) item-

(1) Means any item of supply (including construction material) that is-

(i) A commercial product (as defined in paragraph (1) of the definition of "commercial product" at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.

However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means-

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if-

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States.

Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

None

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable.

(A) For domestic construction material that is not a critical item or does not contain critical .components

(1) The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(2) For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A) of this clause.(1)

(3) The procedures in paragraph (b)(3)(i)(A) of this clause will no longer apply as of January (2) 1, 2030.

(B) .For domestic construction material that is a critical item or contains critical components

(1) The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds 55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3) (i)(B) of this clause.(1)

(3) The procedures in paragraph (b)(3)(i)(B) of this clause will no longer apply as of January (2) 1, 2030.

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)

(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute or Balance of Payments Program.

(d) . To permit evaluation of requests under paragraph (c) of this clause based on Data unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of measure Quantity Price (dollars)*

Item 1:

Foreign construction material.

Domestic construction material.

Item 2:

Foreign construction material.

Domestic construction material.

[* Include all delivery costs to the construction site and any applicable duty (whether or not a ].duty-free entry certificate is issued)

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of ]response; if oral, attach summary.

[ ]Include other applicable supporting information.

(End of clause)

52.232-5 Payments under Fixed-Price Construction Contracts.

2014-05

Payments under Fixed-Price Construction Contracts (May 2014)

(a) Payment of price. The Government shall pay the Contractor the contract price as provided in this contract.

(b) Progress payments. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

(1) The Contractor's request for progress payments shall include the following substantiation:

(i) An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment requested.

(ii) A listing of the amount included for work performed by each subcontractor under the contract.

(iii) A listing of the total amount of each subcontract under the contract.

(iv) A listing of the amounts previously paid to each such subcontractor under the contract.

(v) Additional supporting data in a form and detail required by the Contracting Officer.

(2) In the preparation of estimates, the Contracting Officer may authorize material delivered on the site and preparatory work done to be taken into consideration. Material delivered to the Contractor at locations other than the site also may be taken into consideration if-

(i) Consideration is specifically authorized by this contract; and

(ii) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract.

(c) Contractor certification. Along with each request for progress payments, the Contractor shall furnish the following certification, or payment shall not be made: (However, if the Contractor elects to delete paragraph (c)(4) from the certification, the certification is still acceptable.)

I hereby certify, to the best of my knowledge and belief, that-

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of Chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract; and

(4) This certification is not to be construed as final acceptance of a subcontractor's performance.

____ (Name)

____ (Title)

____ (Date)

(d) Refund of unearned amounts. If the Contractor, after making a certified request for progress payments, discovers that a portion or all of such request constitutes a payment for performance by the Contractor that fails to conform to the specifications, terms, and conditions of this contract (hereinafter referred to as the "unearned amount"), the Contractor shall-

(1) Notify the Contracting Officer of such performance deficiency; and

(2) Be obligated to pay the Government an amount (computed by the Contracting Officer in the manner provided in paragraph (j) of this clause) equal to interest on the unearned amount from the 8th day after the date of receipt of the unearned amount until-

(i) The date the Contractor notifies the Contracting Officer that the performance deficiency has been corrected; or

(ii) The date the Contractor reduces the amount of any subsequent certified request for progress payments by an amount equal to the…