Solicitation - W519TC26QA226.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Patrick.Ferguson Line

Patrick.Ferguson Line

Section A - Solicitation/Contract Form

GREEN CANVASInstrument Name:

Product Service Code : 8340

SOLICITATION NARRATIVE

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation W519TC26QA226 for the procurement of GREEN CANVAS in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC).

2. The following drawings apply:

IIE42I077

Please note, access to the drawings is Authorized the Department of Defense and U.S. DOD Contractors only. Questions about Contract Opportunities within SAM.gov system should be addressed with the GSA helpdesk on the bottom right-hand side of the SAM.gov page where it states, "Customer Service" and then "Federal Service Desk" or try (866) 606-8220.

3. Quotes must be submitted via email to the Contract Specialist listed below in the Points of Contact paragraph and received prior to the closing date and time to be considered for award. The offeror is responsible for assuring the quote is received by the Government on time, prior to the closing date and time, to be considered. It is the government's intent to award without discussions (except for clarifications as described by FAR 15.306(a)). Therefore, the Contractor's quote should be complete and contain the contractor's best price and delivery terms. A complete quote submission includes (but not limited to) the contractor's best term (price and delivery and all required fill-ins under this RFQ). IAW FAR clause 52.212-2, included in this RFQ, the Government reserves the right to conduct discussions if determined necessary by the Contracting Officer.

Quotes shall be prepared and authorized by a person(s) regularly employed by the contractor. The quote shall state the name of each person(s) contributing to the authorship of the quote, the person

(s) position/title, phone number, and an email address for the person who should be contacted if an award is to be made. The quote should be prepared in a clear, legible, practical manner. In addition, the quote shall be written in English and should be specific and complete.

W519TC26QA226

Pricing should be IAW the information on the CLIN and any attachments to this solicitation and should be documented directly on the SF1449 form, including a unit price on each CLIN, a total CLIN amount, and a grand total for the entire solicitation (including shipping FOB destination to Rock Island, IL to be paid by the contractor), all clauses that require fill ins should be completed, and the authorized preparer shall sign and date prior to submission. The solicitation should be emailed to the POCs listed below.

Certificate of Conformance (COC) is required IAW FAR 52.246-15 with every delivery.

4. The Government intends to award one firm fixed price purchase order (without discussions, except clarifications as described in FAR 15.306(a)) to the Offeror determined to be responsible (in accordance with (IAW) the Federal Acquisition Regulation (FAR) subpart 9.1) whose quote conforms with the RFQ requirements and is determined to be the lowest total evaluated (fair and reasonable) priced quote.

5. Delivery for this item is specified on the CLIN(s), however early and incremental delivery is authorized and encouraged with no additional cost to the Government. All quotes shall be quoted as FOB Destination Rock Island, IL, see FAR 52.247-34, therefore, all shipping charges should be included in the quote.

On time delivery is critical. Therefore, contractor must adhere to the delivery requirements indicated in the resulting award. Failure to comply with the contractual delivery schedule after award may result in termination of the award or require consideration if the Government elects to extend your delivery schedule. The Government is not obligated to extend your delivery if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflicts, etc., are not considered acceptable delays/excuses for the failing to meet the contractual delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contracting Officer designated in the award at least 10 days prior to being late. Such notification shall include the contractor's reasons for delay, proposed revised schedule, and the contractor's offered consideration for the delay should the Government elect to extend.

It is the responsibility of the contractor to ensure that they provide quality products that conform to the award terms and conditions as well as meet the required delivery schedule. Delivery of non conforming products results in delivery/acceptance delays and ultimately increased costs to the Government.

**Contractor shall package all shipments to RIA-JMTC IAW standard commercial guidelines.

NOTE RECEIVING HOURS OF OPERATION Monday-Friday, 6:30am to 2:00pm Central Time.

Deliveries before or after the above stated hours will be turned away. Appointments are not necessary. For directions call: (309)782-8539 (Automated).

6. WARRANTY: A one year parts and labor warranty is required for all CLINs. Warranties shall be provided for the item and all required tooling. All warranties will begin upon final acceptance by the Government. Contractor shall provide the product warranty information to the Contracting Officer upon award.

7. PAYMENT: Payment will be via Defense Finance and Accounting System (DFAS) via the Wide Area Workflow (WAWF) System. Only electronic invoices submitted through WAWF will be accepted. All other formats will be rejected. See DFARS 252.232-7003 and 252.232-7006 for additional invoicing guidance.

8. Offeror is cautioned to ensure their proposal is fully complete, including all fill-ins and blanks in the solicitation. Contractor agrees by submission that their proposal and the prices contained therein will be valid for 90 days after date of the quote submission.

9. Army Contracting Command Government Point of Contact (POC):

Contract Specialist Leigh Weeks (520) 693-0167 leigh.a.weeks2.civ@army.mil

Procuring Officer: Daniel Sinnott (520) 693-0305 daniel.s.sinnot.civ@army.mil

**NOTE: Communication with the Government should start at the lowest possible level.

10. Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly advised to pre-register at least three (3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival.

All visitors must complete a Visitor Access Request Form. Access Request Forms should be emailed or faxed prior to the delivery. The Visitor Access Request Form can be found at http://www.usagria.army.mil/AccessRequests Follow the instructions on How to Obtain a Visitor Pass. All first time visitors must process through the Moline Gate Visitor Center.

TRUCKS MUST ENTER THROUGH MOLINE, IL GATE, OFF OF RIVER DRIVE IN MOLINE I-74.

Transportation Service Providers are required to send drivers with proper identification who meet all the installation access requirements. Transportation Service Providers are required to send United States Citizens and drivers that will pass applicable background checks. Failure to do so can result in warnings or Non-use. Real-ID access implementation is active at Rock Island Arsenal, IL. Individuals using a driver's license from the states of Illinois, Minnesota, Missouri, New Mexico or Washington will have to use a secondary form of Identification to enter U.S. military installations. Additional forms of identification that may be used in conjunction with a state driver's license are Vehicle Registration with name and address, Veterans Health Identification Card, PIV Card, PIV-1 Card, DHS "Trusted Traveler" Card, U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550), and State of Illinois Firearm Owners Identification (FOID) card.

It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order.

DRIVERS WHO DO NOT MEET THE INSTALLATION ACCESS REQUIREMENTS WILL NOT BE

ALLOWED ON THE INSTALLLATION AND WILL BE TURNED AWAY.

POC for this Policy are:

Rock Island Arsenal Visitor Center (309) 782-0485 -phone

(309) 782-5029-fax usarmy.ria.imcom.mbx.usag-access-request@mail.mil

*** END OF NARRATIVE 1 ***

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quanti ty

Unit Unit Price Amount

0010 CANVAS, GREEN

Manufacturer's CAGE: 59678

Manufacturer's Part Number:

11E421077-2RIA

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP): W52H1B624401CV

Product Service Code: 8340

North American Industry Classification System (NAICS):

314910

Bill to Party: W52H1B

Pricing Arrangement: Firm Fixed Price

761 Squar e Yard

Additional Descriptive Data:

RIA-JMTC 01-23-2019

CANVAS, MIL-PRF-20696, TYPE I, II, OR IV, COLOR 383 GREEN, COLOR CHIP

34094 OF FED-STD-595

PURCHASE IAW PRINT# 11E421077 ***ONLY OPTION TWO (2) APPROVED FOR

USE***

RIA-JMTC 01-23-2019

CANVAS, MIL-PRF-20696, TYPE I, II, OR IV, COLOR 383 GREEN, COLOR CHIP

34094 OF FED-STD-595

PURCHASE IAW PRINT# 11E421077 ***ONLY OPTION TWO (2) APPROVED FOR

USE***

RIA-JMTC 01-23-2019

CANVAS, MIL-PRF-20696, TYPE I, II, OR IV, COLOR 383 GREEN, COLOR CHIP

34094 OF FED-STD-595

PURCHASE IAW PRINT# 11E421077 ***ONLY OPTION TWO (2) APPROVED FOR

USE***

0020 CANVAS, GREEN

Manufacturer's CAGE: 59678

Manufacturer's Part Number:

11E421077-2RIA

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP): W52H1B624401CW

Product Service Code: 8340

North American Industry Classification System (NAICS):

314910

Bill to Party: W52H1B

Pricing Arrangement: Firm Fixed Price

254 Squar e Yard

0030 CANVAS, GREEN

Manufacturer's CAGE: 59678

Manufacturer's Part Number:

11E421077-2RIA

CLIN only - Requisition Document Number (MILSTRIP, DLMS, FEDSTRIP): W52H1B624401CX

Product Service Code: 8340

1,521 Squar e Yard

North American Industry Classification System (NAICS):

314910

Bill to Party: W52H1B

Pricing Arrangement: Firm Fixed Price

Section C - Description/Specifications/Statement of Work

Requirements

CANVAS, GREEN

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.246-15 Certificate of Conformance. 1984-04

Overall Contract Inspection/Acceptance Locations

0010 Inspection and Acceptance Location

Both Destination Instructions: Inspection by the Government at JMTC Certificate of Conformance - FAR 52.246-15 is required

DoDAAC: W52H1B CountryCode: USA

W0K8 RIA INSTL STK REC ACCT

BLDG 299 GILLESPIE AV AND BECK LANE, ROCK ISLAND IL 61299-5000

ROCK ISLAND, IL 61299-5000

UNITED STATES

0020 Inspection and Acceptance Location

Both Destination Instructions: Inspection by the Government at JMTC Certificate of Conformance - FAR 52.246-15 is required

DoDAAC: W52H1B CountryCode: USA

W0K8 RIA INSTL STK REC ACCT

BLDG 299 GILLESPIE AV AND BECK LANE, ROCK ISLAND IL 61299-5000

ROCK ISLAND, IL 61299-5000

UNITED STATES

0030 Inspection and Acceptance Location

Both Destination Instructions: Inspection by the Government at JMTC Certificate of Conformance - FAR 52.246-15 is required

DoDAAC: W52H1B CountryCode: USA

W0K8 RIA INSTL STK REC ACCT

BLDG 299 GILLESPIE AV AND BECK LANE, ROCK ISLAND IL 61299-5000

ROCK ISLAND, IL 61299-5000

UNITED STATES

Section F - Deliveries or Performance

0010 Partial Delivery Schedule Delivery Required On Delivery Date 23 Nov 2026 761 Square Yard

761 Square YardQuantity

Address and POC Ship To DoDAAC: W52H1B CountryCode: USA

W0K8 RIA INSTL STK REC ACCT

BLDG 299 GILLESPIE AV AND BECK LANE, ROCK ISLAND IL 61299-5000 ROCK

ISLAND, IL 61299-5000 UNITED STATES

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0020 Delivery Schedule Delivery On Or Before Delivery Date 23 Nov 2026 Partial Delivery Schedule Delivery Required On Delivery Date 23 Nov 2026 254 Square Yard

254 Square YardQuantity

Address and POC Ship To DoDAAC: W52H1B

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

0030 Delivery Schedule Delivery On Or Before Delivery Date 23 Nov 2026 Partial Delivery Schedule Delivery Required On Delivery Date 23 Nov 2026 1,521 Square Yard

1,521 Square YardQuantity

Address and POC Ship To DoDAAC: W52H1B

Special Handling/Notes FoB Details

Party to Pay Transportation Cost: Contractor

Point Type: Destination

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.242-17 Government Delay of Work. 1984-04

52.247-34 F.o.b. Destination. 1991-01

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

2018-12

DFARS Clauses Incorporated by Full Text

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.232-7006 Wide Area WorkFlow Payment Instructions.

2023-01

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web- Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

combo

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0303 Issue By DoDAAC W519TC Admin DoDAAC W519TC Inspect By DoDAAC W52H1B Ship To Code W52H1B Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) W52H1B

Service Acceptor (DoDAAC) W52H1B Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A (*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

leigh.a.weeks2.civ@army.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-13 System for Award Management- Maintenance. (Deviation 2026- O0038)

2026-02

52.204-19 Incorporation by Reference of Representations and Certifications.

2014-12

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation 2026-O0038)

2026-02

52.211-5 Material Requirements.

(Deviation 2026-O0038)

2026-02

52.213-4 Terms and Conditions-Simplified Acquisitions (Noncommercial).

(Deviation 2026-O0038)

2026-02

52.219-6 Notice of Total Small Business Set-Aside. (Deviation 2026- O0038)

2026-02

52.222-3 Convict Labor. (Deviation 2026- O0038)

2026-02

52.222-19 Child Labor-Cooperation with Authorities and Remedies.

2026-03

(Deviation 2026-O0038)

52.222-36 Equal Opportunity for Workers with Disabilities. (Deviation 2026- O0038)

2026-02

52.222-50 Combating Trafficking in Persons. (Deviation 2026-O0038)

2026-02

52.222-90 Addressing DEI Discrimination by Federal Contractors.

(Deviation 2026-O0040, Revision 1)

2026-04

52.223-23 Sustainable Products. (Deviation 2026-O0038)

2026-02

52.224-3 Privacy Training. 2017-01

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.232-1 Payments. 1984-04

52.232-8 Discounts for Prompt Payment. 2002-02

52.232-11 Extras. 1984-04

52.232-25 Prompt Payment. 2017-01

52.232-27 Prompt Payment for Construction Contracts.

2017-01

52.232-33 Payment by Electronic Funds Transfer-System for Award Management.

2018-10

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-1 Disputes. (Deviation 2026- O0038)

2026-02

52.233-3 Protest after Award. (Deviation 2026-O0038)

2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation 2026- O0038)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation 2026- O0038)

2026-02

52.243-1 Changes-Fixed-Price. (Deviation 2026-O0038)

2026-02

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-04

52.247-15 Contractor Responsibility for Loading and Unloading.

1984-04

52.247-18 Multiple Shipments. 1984-04

52.247-68 Report of Shipment (REPSHIP). 2006-02

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form).

1984-04

DFARS Clauses Incorporated by Reference

Alternate Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting.

2024-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium.

2023-01

252.225-7048 Export-Controlled Items. 2013-06

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime.

2023-01

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.232-7010 Levies on Contract Payments. 2006-12

252.243-7001 Pricing of Contract Modifications. 1991-12

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development.

2000-09

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $____ per calendar day of delay [Contracting Officer insert amount].

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

52.217-9 Option to Extend the Term of the Contract.

2000-03

Option to Extend the Term of the Contract (Mar 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30[insert the period of time within which the Contracting Officer may exercise the option];

provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days[60days unless a different number of days is inserted] before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 12 month(months) (years).

52.219-17 Section 8(a) Award. 2019-10

Section 8(a) Award (Oct 2019)

(a) By execution of a contract, the Small Business Administration (SBA) agrees to the following:

(1) To furnish the supplies or services set forth in the contract according to the specifications and the terms and conditions by subcontracting with the Offeror who has been determined an eligible concern pursuant to the provisions of section 8(a) of the Small Business Act, as amended (15 U.S.C. 637(a)).

(2) Except for novation agreements, delegates to the ____[insert name of contracting activity] the responsibility for administering the contract with complete authority to take any action on behalf of the Government under the terms and conditions of the contract; provided, however that the contracting agency shall give advance notice to the SBA before it issues a final notice terminating the right of the subcontractor to proceed with further performance, either in whole or in part, under the contract.

(3) That payments to be made under the contract will be made directly to the subcontractor by the contracting activity.

(4) To notify the ____[insert name of contracting agency]Contracting Officer immediately upon notification by the subcontractor that the owner or owners upon whom 8(a) eligibility was based plan to relinquish ownership or control of the concern.

(5) That the subcontractor awarded a subcontract hereunder shall have the right of appeal from decisions of the cognizant Contracting Officer under the "Disputes" clause of the subcontract.

(b) The offeror/subcontractor agrees and acknowledges that it will, for and on behalf of the SBA, fulfill and perform all of the requirements of the contract.

52.219-18 Notification of Competition Limited to Eligible 8(a) Participants.

2022-10

Notification of Competition Limited to Eligible 8(a) Participants (Oct 2022)

(a) Offers are solicited only from-

(1) Small business concerns expressly certified by the Small Business Administration (SBA) for participation in SBA's 8(a) program and which meet the following criteria at the time of submission of offer-

(i) The Offeror is in conformance with the 8(a) support limitation set forth in its approved business plan; and

(ii)The Offeror is in conformance with the Business Activity Targets set forth in its approved business plan or any remedial action directed by SBA;

(2) A joint venture, in which at least one of the 8(a) program participants that is a party to the joint venture complies with the criteria set forth in paragraph (a)(1) of this clause, that complies with 13 CFR 124.513(c); or

(3) A joint venture-

(i) That is comprised of a mentor and an 8(a) protégé with an approved mentor-protégé agreement under the 8(a) program;

(ii) In which at least one of the 8(a) program participants that is a party to the joint venture complies with the criteria set forth in paragraph (a)(1) of this clause; and

(iii) That complies with 13 CFR 124.513(c).

(b) By submission of its offer, the Offeror represents that it meets the applicable criteria set forth in paragraph (a) of this clause.

(c) Any award resulting from this solicitation will be made to the Small Business Administration, which will subcontract performance to the successful 8(a) offeror selected through the evaluation criteria set forth in this solicitation. A contracting officer may consider a joint venture for contract award. SBA does not approve joint ventures for competitive awards, but see 13 CFR 124.501(g) for SBA's determination of participant eligibility.

(d) The ____[insert name of SBA's contractor]will notify the____[insert name of contracting agency]Contracting Officer in writing immediately upon entering an agreement (either oral or written) to transfer all or part of its stock.

52.219-28 Postaward Small Business Program Rerepresentation.

(Deviation 2026-O0038) (Alternate I)

2026-02 Alternate I 2026-02

Alternate I (Feb 2026) (Deviation 2026-O0038). As prescribed in 19.101(a)(2)(iii)(B), substitute the following paragraph (g)(1) for paragraph (g)(1) of the basic clause:

(g)(1) The Contractor represents its small business size status for each one of the NAICS codes assigned to this contract.

NAICS Code Small business concern (yes/no) [Contracting Officer to insert NAICS codes.]

52.219-28 Postaward Small Business Program Rerepresentation.

(Deviation 2026-O0038)

2026-02

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document /support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under ____NAICS Code assigned to ____contract number.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (g)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1001.

(3) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(4) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __ .]

(5) Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program. The Contractor represents that it [ ] is, [ ] is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402.

[____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(6) HUBZone joint venture eligible under the HUBZone Program.[ Complete only if the offeror is a HUBZone small business concern. ] The offeror represents, as part of its offer, that It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture must be certified as a HUBZone concern. [____Contractor to sign and date and insert authorized signer's name and title.]

52.222-49 Service Contract Labor Standards-Place of Performance Unknown. (Deviation 2026- O0038)

Service Contract Labor Standards-Place of Performance Unknown (Feb 2026) (Deviation 2026-

(a) This contract is subject to the Service Contract Labor Standards statute, and the place of performance was unknown when the solicitation was issued. In addition to places or areas identified in wage determinations, if any, attached to the solicitation, wage determinations have also been requested for the following: ____[insert places or areas]. The Contracting Officer will request wage determinations for additional places or areas of performance if asked to do so in writing by ____[insert time and date].

(b) Offerors who intend to perform in a place or area of performance for which a wage determination has not been attached or requested may nevertheless submit bids or proposals.

However, a wage determination must be requested and incorporated in the resultant contract retroactive to the date of contract award, and there shall be no adjustment in the contract price.

52.252-2 Clauses Incorporated by Reference.

1998-02

Clauses Incorporated By Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

____ ____ ____[Insert one or more Internet addresses]

52.252-4 Alterations in Contract. 1984-04

Alterations in Contract (Apr 1984)

Portions of this contract are altered as follows:

52.252-6 Authorized Deviations in Clauses. 2020-11

Authorized Deviations in Clauses (Nov 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any ____[insert regulation name] (48 CFR ____) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section K - Representations, Certification, & Other Statements

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation 2026-

DFARS Provisions Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials.

2022-09

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls.

2016-10

252.225-7055 Representation Regarding Business Operations with the Maduro Regime.

2022-05

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

2023-06

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.203-2 Certificate of Independent Price Determination.

1985-04

Certificate of Independent Price Determination (Apr 1985)

(a) The offeror certifies that-

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to-

(i) Those prices;

(ii) The intention to submit an offer; or

(iii) The methods or factors used to calculate the prices offered.

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory-

(1) Is the person in the offeror's organization responsible for determining the prices being offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to paragraphs (a)(1) through (a)(3) of this provision; or

(2)

(i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to paragraphs (a)(1) through (a)(3) of this provision ____[insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization];

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) of this provision have not participated, and will not participate, in any action contrary to paragraphs (a)

(1) through (a)(3) of this provision; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to paragraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) above, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

(End of provision)

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation.

2021-05

PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS

EQUIPMENT OR SERVICES-REPRESENTATION (MAY 2021)

The Offeror is not required to complete the representation in this provision if the Offeror has represented in the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument."

(a) Definitions. "Covered defense telecommunications equipment or services," "covered mission," "critical technology," and "substantial or essential component," as used in this provision, have the meanings given in the 252.204-7018 clause, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services, of this solicitation.

(b) Prohibition. Section 1656 of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits agencies from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities that are excluded when providing any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless a waiver is granted.

(d) Representation. If in its annual representations and certifications in SAM the Offeror has represented in paragraph (c) of the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does" provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument, then the Offeror shall complete the following additional representation:

The Offeror represents that it [ ] will [ ] will not provide covered defense telecommunications equipment or services as a part of its offered products or services to DoD in the performance of any award resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it "will provide covered defense telecommunications equipment or services," the Offeror shall provide the following information as part of the offer:

(1) A description of all covered defense telecommunications equipment and services offered (include brand or manufacturer; product, such as model number, original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable).

(2) An explanation of the proposed use of covered defense telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition referenced in paragraph (b) of this provision.

(3) For services, the entity providing the covered defense telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known).

(4) For equipment, the entity that produced or provided the covered defense telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

Section L - Instructions, Conditions, & Notices to Offerors or Quoters

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements- Representation.

2017-01

52.204-7 System for Award Management- Registration. (Deviation 2026-

DFARS Provisions Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.204-7024 Notice on the Use of the Supplier Performance Risk System.

2023-03

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors. (DEVIATION 2026- O0048)

2023-01 Deviation 2026- O0048

2026-07

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective

52.207-4 Economic Purchase Quantity- Supplies.

1987-08

Economic Purchase Quantity-Supplies (Aug 1987)

(a) Offerors are invited to state an opinion on whether the quantity(ies) of supplies on which bids, proposals or quotes are requested in this solicitation is (are) economically advantageous to the Government.

(b) Each offeror who believes that acquisitions in different quantities would be more advantageous is invited to recommend an economic purchase quantity. If different quantities are recommended, a total and a unit price must be quoted for applicable items. An economic purchase quantity is that quantity at which a significant price break occurs. If there are significant price breaks at different quantity points, this information is desired as well.

Offeror Recommendations Item Quantity Price Quotation Total

(c) The information requested in this provision…