SOLICITATION SPMYM2-24-Q-0241.pdf

SEE ADDENDUM

(No Collect Calls)

SPMYM224Q0241 08-Nov-2023

b. TELEPHONE NUMBER

360-476-5363

8. OFFER DUE DATE/LOCAL TIME

10:00 AM 19 Nov 2023

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

SPMYM29. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

KIM A. VO

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

N4523ALUMBERIDIQFY24

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

DLA MARITIME PUGET SOUND

ATTN: KIM VO

467 W STREET

BREMERTON WA 98314

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

360-476-4121FAX:

TEL: 360-476-5363 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

321211

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF167

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

SPMYM224Q0241

Section SF 1449 - CONTINUATION SHEET

VENDOR INFORMATION

1. The Contractor’s POC is:

Phone:

E-mail:

2. Buyer POC is: KIM VO

E-mail: KIM.VO@DLA.MIL

3. Invoice Information:

The contractor shall utilize the electronic invoicing upon delivery of supplies indicated herein. Invoice may be submitted not more than one every two weeks. Invoices must be submitted electronically using Wide Area Work Flow (WAWF) – Receipt and Acceptance. The contractor shall self-register at the web site: https://wawf.eb.mil.

Contractor training is available on the Internet at https://wawftraining.eb.mil.

Additional support can be accessed by calling the NAVY WAWF Assistance Line: 1-877-251-9293.

See clause 252.232-7006 for WAWF table.

4. Inspection Level:

QA 4 7 days inspection

5. Defense Biometric Identification System (DBIDS):

Effective 14 August 2017, NCACS credentials will no longer be accepted for base access. Any new contractor, vendor or supplier requesting base access will be required to obtain a Defense Biometric Identification System (DBIDS) credential. NCACS credentials will no longer be issued. Only DBIDS credentials will be issued to ALL contractors, vendors and suppliers seeking base access AFTER 30 June 2017. Defense Biometric Identification System (DBIDS) increases installation security and communications by receiving frequent database updates on changes to personnel/credential status, law enforcement warrants, lost/stolen cards, and force protection conditions.

The system provides continuous vetting anytime the DBIDS card is scanned at an installation entry point.

If you currently have a Navy Commercial Access Control System (NCACS) card, the following is required to get a DBIDS credential:

Present your NCACS Card and a completed copy of the SECNAV FORM 5512/1 to the base Visitor Control Center (VCC) representative.

The VCC will pull up your information in the computer, ensuring all information is current and correct.

Once your information is validated, a temporary DBIDS credential is provided.

Your temporary credential will have an expiration date, prior to which you will need to obtain your permanent DBIDS credential (~ 180 days).

For each additional U.S. Navy installation to which you need access, the first time you visit you only need to bring your DBIDS credential and statement of purpose for base access when arriving at the Visitor Control Center.

The representative will enter base access authorization and then you may proceed to work.

If you do NOT have an NCACS Card, the following is required to obtain a DBIDS credential:

Present a letter or official document from any government sponsoring organization that provides the purpose for your access.

Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

Present a completed copy of the SECNAV 5512/1 form to obtain your background check.

Upon completion of the background check, the Visitor Control Center representative will complete the

DBIDS enrollment process, which includes your photo, finger prints, base restrictions, and several other assessments; after all this is done, you will be provided with your new DBIDS credential.

All deliveries must pass through the base Truck Inspection Station. All delivery vehicles are subject to inspection.

Drivers should expect delays due to heightened security.

For access to the main, perimeter gates at any Navy Base Kitsap installation, contractors are required to be a US Citizen and have either:

(a) DBIDS badge or

(b) Request a One-day Visitor badge at Pass & ID. Be prepared to present:

-Photo ID -Original proof of citizenship (any one of the following is acceptable):

State Certified Birth Certificate (must have the raised seal) Unexpired U.S. passport/Passport Card Alien Registration Card

Enhanced state-issued driver's license only accepted from Michigan, Minnesota, New York, Vermont, and Washington. Real ID licenses are not accepted at this time.

Naturalization papers Certificate/Statement of Birth Born Abroad)

-Current vehicle registration and insurance -Bill of lading that has the delivery address on it

Please note: The DBIDS badge does not give access through the second, Operational Area (OA) gate to lower base Bangor or to the Controlled Industrial Area (CIA) at Puget Sound Naval Shipyard (PSNS). To gain access to either the OA Gate or CIA area, a Navy Region Bangor or NAVSEA Badge is required.

To request a NAVY REGION NW badge, https://www.bavr.cnic.navy.mil/. Sponsor email is trina.williamson@navy.mil

To request a NAVSEA badge, call PSNS Pass & ID 360-476-4882.

FOR MORE INFORMATION VISIT: https://www.cnic.navy.mil/om/dbids.html

PAYMENT REQUEST FORM: GOVERNMENT PURCHASE CARD

Please follow the steps below to receive payment via Government-Wide Purchase Card.

1. After product shipment or service is rendered, complete the form below and email or fax to Accounts Payable (A/P). PSNS & IMF Cardholder contact information is below:

c600.creditcard.fct@navy.mil

Fax: (360) 476-8553

2. An itemized and serialized invoice with the Government Purchase Order number and Delivery Order number (if applicable) clearly indicated on all pages. This is required to be included with this payment request form.

3. FOB Origin, Prepaid, Prepay & Add sales require evidence of freight paid. Submit copy of freight bill with payment request form. Packaging and handling charges will not be reimbursed.

4. Upon receipt of all required documentation, a Government purchase card holder will contact the contractor’s designated person of contact with purchase card information.

5. Code 600 Method of Payment policies does not allow the use of third party card processing companies such as Paypal, Paypro, etc.

6. If a Government card number is necessary for order processing purposes, the vendor can EMAIL or FAX this form and a proforma invoice to A/P to request a cardholder’s number. A/P will provide the card information via phone call.

Specify “Order Processing Purposes Request” on the top of the form.

AT NO TIME CAN AN ORDER PROCESSING CARD NUMBER BE CHARGED WITHOUT THE

CARDHOLDER’S FINAL AUTHORIZATION.

Failure to receive authorization will result in an immediate request for credit and/or dispute of the transaction.

Contract #/Delivery Order #: _________________________________________ Date: ____________________ Contractor Name:_______________________________________________ Address:______________________________________________________ Point of Contact and Title:_________________________________________ Phone and fax number:_________________________________ E-Mail:___________________________ Shipment or service date:__________________________________________ Total amount of sale:______________________________________________ ----------------------------------------GPC AUTHORIZATION----------------------------------- (for Government use only) Date:____________________________ Amount Authorized:____________________________ Name/Phone Number:______________________________________________ Invoice Number:_________________________________________ Initials:________ Comments: ___________________________________________________

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 9,000 Board Feet

SOFTWOOD LUMBER STANDARD

FP-EPA

BASE YEAR

A. NIST VOLUNTARY PRODUCT STANDARD; AMERICAN SOFTWOOD

LUMBER STANDARD

PS 20 04/26/07

1. SPECIES: DOUGLAS FIR / WESTERN HEMLOCK

2. MOISTURE NOT TO EXCEED 26%

3. SIZE 4" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH 8' TO 14' LONG OR LONGER

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE CONSTRUCTION AND/OR #1, per WCLIB

7. PATTERN N/A

8. PRESERVATION N/A

9. FIRE RETARDANT N/A

10. PACKAGING IAW BEST COMMERCIAL PRACTICES

FOB: Destination

NSN: 5510-00-220-6178

MILSTRIP: N4523AIDIQLUMBER

PURCHASE REQUEST NUMBER: N4523ALUMBERIDIQFY24

PSC CD: 5510

MAX NET AMT

UNIT UNIT PRICE MAX AMOUNT

0002 17,000 Board

PS 20 09/01/99

1. SPECIES: DOUGLAS FIR

2. MOISTURE: NOT TO EXCEED 19%

3. SIZE: 2" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH: 50% TO BE 16' LONG & 50% TO BE 20' LONG

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE: #2 OR STANDARD IAW PS 20 & WCLIB

7. PATTERN: N/A

8. PRESERVATION: N/A

9. FIRE RETARDANT: N/A

10. PACKAGING: IAW BEST COMMERCIAL PRACTICES

NSN: 5510-00-220-6194

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0003 15,408 Board

LUMBER: SOFTWOOD

IAW SPECIFICATIONS PS-20 04/26/07

SPECIES - DOUGLAS FIR IAW PARA 3.2

MOISTURE - NOT TO EXCEED 19% IAW PARA 3.3

SIZE - 2" THK X 6" WIDE IAW PARA 3.4 3.4.4 & TABLE #3

LENGTH - 16' TO 20' LONG, MIN/MAX IAW PARA 3.4.4 (SEE NOTE A)

SURFACING - DRESSED, S4S IAW PARA 3.5

GRADE #2 OR STANDARD IAW PARA 3.6 & WCLIB (SEE PS-20)

PATTERN - N/A

PRESERVATIVE TREATMENT - N/A

FIRE RETARDANT TREATMENT - N/A

TEST METHOD - N/A

BUNDLING, UNITIZING & MARKING IAW PARA 5.1 & MIL-DTL-

14362H(1)

A. LENGTH EXCEPT TO NSN

1. 50% TO BE 16' LONG

2. 50% TO BE 20' LONG

NSN: 5510-00-220-6196

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0004 360 Sheet

CONSTRUCTION PLYWOOD

A-A-55075A PANELS, WOOD/WOOD BASED: CONSTRUCTION &

DECORATIVE.

1. TYPE-A, DOUGLAS FIR/WESTERN/ HEMLOCK

B. GRADE A-B EXTERIOR

C. DIMENSIONS: 1/4 INCH THICK X 48 INCH WIDE X 96 INCH LONG

D. 3 PLY, SANDED 2 SIDES

E. LEVEL C PACKING

120 SHEETS ON A PALLET

MATHEUS LUMBER PART #: X305613

NSN: 5530-00-262-8180

MILSTRIP: N4523AIDIQLUMBER

PURCHASE REQUEST NUMBER: N4523ALUMBERIDIQFY24

PROJECT: 5E3

PSC CD: 5530

UNIT UNIT PRICE MAX AMOUNT

0005 180 Sheet

CONSTRUCTION PLYWOOD

PLYWOOD CONSTRUCTION (80 PER SLING)

7.2.1 PANELS, WOOD/WOOD BASED: CONSTRUCTION & DECORATIVE

A-A-55057B DATED 12/15/2010; TYPE A

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; 3 PLIES, SANDED 2 SIDES

(S2S), EXTERIOR, GRADE A-B EXTERIOR, 3/8" THICK X 48" WIDE X 96"

LONG

7.2.3 N/A

7.2.4 N/A

NSN: 5530-00-262-8181

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0006 1,100 Sheet

CONSTRUCTION PLYWOOD

CONSTRUCTION PLYWOOD (44 SHEETS PER SLING), S2S SOFT WOOD

A-A-55057 B; TYPE A 12/15/2010

7.2.2 TYPE-A PLYWOOD AS FOLLOWS:

A. SOFT WOOD, FIR/HEMLOCK

B. 5 PLY

C. REGULAR SANDED TWO SIDES

D. GRADE A-B EXTERIOR

E. 3/4" THK X 48" WIDE X 96" LONG

NSN: 5530-00-262-8182

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0007 396 Sheet

CONSTRUCTION PLYWOOD

SANDED 2 SIDES (66 SHEETS PER SLING)

1/2" THK X 48" W X 96" LG, 5 PLY, GRADE A-B, EXTERIOR WOOD,

SOFT, DOUGLAS FIR/WESTERN HEMLOCK

LEVEL-C PACKING

A-A-55057B; TYPE-A

NSN: 5530-00-262-8195

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0008 2,200 Board

HARDWOOD LUMBER

2" THK X 4"-7" WITH WIDER X 6'-14' LONG/LONGER, FULL SAWN,

ROUGH WOOD, HARD MAPLE, GRADE-SELECT, IAW NHLA, 12 % MAX

MOISTURE

A. FEDERAL SPECIFICATION, LUMBER, HARDWOOD

MM-L-736 D 05/06/2008

B. TYPE 1 CUTTING GRADE IAW PARA 1.2

C. MAPLE, HARD, GRADE - SELECT IAW PARA 3.1.1 AND NHLA

D. 2" THK X 4" - 7" WIDE & WIDER X 6' - 14' LONG & LONGER

IAW PARA 3.2 & 6.3

E. SEASONED IAW PARA 3.3

F. 12% MOISTURE CONTENT IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

O. UNITIZING, MARKING & LOADING IAW PARA 5.1

********************* NOTE **********************

1. LENGTH: 6' AND LONGER, MAX OF 30% 6'- 11' LONG. 1/6 MAY BE 6' &

7' LONG

A MIN OF 25% TO BE 14' LONG OR LONGER.

2. WIDTH: 4" & WIDER, A MIN OF 35% TO BE 7" & WIDER.

NSN: 5510-00-267-2283

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0009 150,000 Board

SOFTWOOD LUMBER

LUMBER, SOFTWOOD, TIMBER, STD ROUGH 14" W X 14" THK X 16' &

20' LONG; DOUGLAS FIR, NO.1 STRUCTURAL, IAW WCLIB; DOUGLAS

FIR 14X14

NBS VOLUNTARY PRODUCT STANDARD FOR AMERICAN SOFTWOOD

PS-20 04/26/07

LUMBER, SPECIES: DOUGLAS FIR

MOISTURE: ANY STAGE OF SEASONING IS ACCEPTABLE

SIZE: 14" THICK X 14" WIDE IAW TABLE 3 OF PS20-70

LENGTH: 16' & 20' LONG

GRADE: NO. 1 STRUCTURAL IAW PS20-70 & WCLIB

DRESSED: STD ROUGH SAWN

PRESERVATION: N/A

FIRE RETARDANT: N/A

PACKAGING: IAW BEST COMMERCIAL PRACTICES

PATTERN: N/A

NOTE: MATERIAL MUST BE SHIPPED AND DELIVERED TO:

NBK Bangor BLDG. 88000

DLA Laydown Area Thresher Ave

Silverdale, WA 98315

"TO COORDINATE DELIVERY CONTACT 360-476-7441

NSN: 5510-00-550-6821

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0010 15 Sheet

CONSTRUCTION PLYWOOD

ANY ACCEPTABLE C-D EXTERIOR (CDX) ROUGH SANDED (80 SHEETS

PER SLING); A-A-55057B; TYPE A

A-A-55057 B 12/15/10

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; SOFT; 3 OR 4 PLY; ROUGH

SANDED; CDX, GRADE C-D INTERIOR W/ EXTERIOR GLUE. 3/8" THICK

X 48" WIDE X 96" LONG

7.2.3 TYPE-A PANELS REQUIRED, DO NOT SUBSTITUTE

NSN: 5530-00-618-6956

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0011 738 Sheet

CONSTRUCTION PLYWOOD

1/2" THK X 48" W X 96" LONG; LEVEL-C PACKING; A-A-55057B TYPE-A

(66 SHEETS PER SLING)

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; SOFT; 4/5 PLY; ROUGH

SANDED, CDX ; GRADE C-D INTERIOR WITH EXTERIOR GLUE. 1/2"

THICK X 48" WIDTH X 96" LENGTH

NSN: 5530-00-618-6958

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0012 80 Sheet

CONSTRUCTION PLYWOOD

GRADE C-D (40/44 SHEETS PER SLING), ANY ACCEPTABLE C-D

EXTERIOR.

A-A-55057 B 12/15/2010

B. 5/7 PLY

C. ROUGH SANDED

D. INTERIOR

E. GRADE C-D INTERIOR WITH EXTERIOR GLUE (CDX)

F. 3/4" THICK X 48" WIDE X 96" LONG

NSN: 5530-00-618-8073

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0013 25,344 Board

192 BOAR FEET PER SLING

LUMBER AND PLYWOOD, FIRE-RETARDANT TREATED

MIL-L-19140 E Amendment 02 01/29/97

A. LUMBER, SOFTWOOD, DOUGLAS FIR/SOUTHERN PINE IAW VPS PS-

20 AND WCLIB FEDERAL SPECS

B. TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 19% IAW PARA 3.12, GRADE - SELECT STRUCTURAL WOOD

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. N/A

J. REQUIRED IAW PARA 6.3.1; TO BE FORWARDED WITH MATERIAL

K. 2" THICK X 4" WIDTH X 16' OR 20' LENGTH

NOTE: ***DEVIATION FROM THE NSN TECHNICAL DESCRIPTION***

1. LENGTH- 16' OR 20'LONG

2. SURFACE - S4S

NSN: 5510-00-663-4687

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0014 33,664 Board

128 PER SLING

A. LUMBER, SOFTWOOD, DOUGLAS FIR/SOUTHERN PINE IAW PS-20 &

WCLIB SPECS. FIRE RETARDANT, GRADE - SELECT STRUCTURAL

B. TREATMENT- TY-2, WEATHER RESISTANT

C. CATEGORY- 2, NAVAL SHIPBUILDING AND REPAIR

D. INCISING- REQUIRED IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. MOISTURE- 19% IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING- IAW PARA 3.12.2 AND 6.4.5 FOR CATEGORY-2

I. N/A

J. REQUIRED IAW PARA 6.3.1 AND MUST ACCOMPANY MATERIAL

NOTE: ***DEVIATION FROM NSN TECHNICAL DESCRIPTION***

1. LENGTH- 16' OR 20' LONG

2. SURFACE- S4S

K. 2" THICK X 6" WIDTH X 16' OR 20' LENGTHS.

NSN: 5510-01-016-7437

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0015 4,000 Each

SOFTWOOD LUMBER

LUMBER, SCAFFOLD PLANK, SOFTWOOD, LAMINATED

1-3/4" THK X 11-3/4" X 16', ROUGH, TREATED SOFTWOOD, PRUCE

LUMBER, LAMINATED, MASTER PLANK

FIRE RETARDENT TREATMENT IAW MIL-L-19140

19% MAXIMUM MOISTURE CONTENT AFTER TREATMENT AND AT

THE TIME OF SHIPMENT

2” THK X 12”W X 16’ LONG, ROUGH, SPRUCE

TY-II (EXTERIOR)

CATEGORY 2

CONFORMANCE TO PARA 3.4 MIL-L-19140 REQUIRED

MATERIAL SHALL BE O.S.H.A CERTIFIED & MARKED

NSN: 5510-01-326-1535

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0016 4,836 Each

SHOLE BLOCK

3" THICK X 12" WIDE X 14" LONG

FIR, ROUGH CUT, STRUCTURAL GRADE, MAX 19% MOISTURE. "MUST

BE SHRINK WRAPPED".

156 PER PALLET

FOB: Destination

NSN: 5510-LL-S03-6939

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0017 420 Board

A. LUMBER; HARDWOOD MM-L-736 D DTD 05/06/08

B. TYPE-II

C. DOMESTIC BLACK CHERRY, GRADES 1 & 2 (FAS)

D. 1" THK, (4/4")WIDTH 8" UP TO AVG 10" WIDE, 8' TO 12' LG

E. N/A

F. 10% OR LESS MOISTURE

G. N/A

H. N/A

I. ROUGH

J. N/A

K. N/A

L. N/A

M. MILL CERTIFICATION OF GRADE TO ACCOMPANY MATERIAL

N. MARKING NOT REQUIRED

0. BEST COMMERCIAL PRACTICE

NSN: 5510-LL-S04-1608

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0018 560 Board

A. LUMBER; HARDWOOD MM-L-736 D 05/06/08

B. TYPE 1, STANDARD HARDWOOD CUTTING GRADES IAW PARA 1.2

C. CHERRY, DOMESTIC BLACK, GRADES 1 & 2 IAW PARA 3.1.1 &

N.H.L.A.

D. 2" THK X 6/8" WIDE W/AVE OF 8" W X 8/10' LG IAW PARA 3.2 & 6.3

SEASONED IAW PARA 3.3

E. N/A

F. 12% MOISTURE CONTENT OR LESS IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5 & 6.4

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

O. BEST COMMERCIAL PRACTICE UNITIZING IAW PARA 5.1 & MIL-L-

14362H

NSN: 5510-LL-S04-1609

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0019 12,877 Each

WOOD WEDGE

3" W X 3" THK X 16" LONG, CUT ON A TAPER TO A FEATHERED EDGE

WOOD, DOUGLAS FIR, (ONLY), SHALL BE FREE FROM

CRACKS/CHECKS

MINIMUM ISSUE QUANTITY = 18 (900 PER PALLET)

FOB: Destination

NSN: 5510-S04-7728

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0020 56,000 Board

LUMBER, HARDWOOD, TIMBER, ROUGH WOOD, OAK, WHITE OR RED

A. LUMBER; HARDWOOD MM-L-736D DTD 05/06/08

B. TYPE-2, CONSTRUCTION IAW PARA 1.2

C. OAK, RED OR WHITE, GRADE COMMON DIMENSION IAW PARA

3.1.1 AND NHLA

D. 6" THICK X 14" WIDE X 8' TO 16' LONG, WITH AVERAGE OF

12' TO 14' LONG (SEE NOTE)

E. ANY STAGE OF SEASONING IAW PARA 3.3

F. N/A

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION TO BE ISSUED BY CERTIFIED MILL

GRADER

N. REQUIREMENTS OF PARA 3.8 WAIVED FOR THIS ORDER

O. PREPARE LOAD FOR DELIVERY IAW BEST COMMERCIAL

PRACTICE

NOTES:

1. RE: (D) LENGTH MUST BE IN 2' INCREMENTS, I.E. 8,10,12,14 & 16

2. MARK LENGTH ON AT LEAST ONE PIECE OF EACH LENGTH

DELIVERED

NSN: 5510-LL-S05-0814

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0021 4,000 Sheet

CONSTRUCTION PLYWOOD

3/4" THICK X 48" WD X 96" LONG; TYPE-A, EXTERIOR (CCX) (40/44 SH

TO A SLING) PN MIL-L-19140E TY-2 CAT-2

A. LUMBER AND PLYWOOD, FIRE-RETARDANT TREATED

B. WOOD SOFT, 5 PLY IAW A-A55057B, TY-2, GRADE C-C WEATHER

RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. STANDARD COMMERCIAL UNITIZING & LOADING

J. VERIFICATION INFORMATION IS REQUIRED IAW PARA 6.3.1 AND IS

TO BE FORWARDED WITH MATERIAL

K. 3/4" THICK X 48" WIDTH x 96" LENGTH, 5 PLY, FIRE RETARDANT/44

SHEETS TO A SLING.

NSN: 5530-LL-S05-0913

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0022 480 Sheet

CONSTRUCTION PLYWOOD

100/120 SHEETS TO A SLING; SOFT; IAW A-A-55057 TY-A, GRADE C-C,

EXTERIOR; FIRE RETARDANT TREATED; MIL-L-19140E

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARK IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. LEVEL-C IAW PARA 5.2.1 AND A-A-55057B

J. VERIFICATION INFORMATION REQUIRED IAW PARA 6.3.1

K. 5/16" THICK X 48" WIDTH X 96" LENGTH, 3 PLY

FORWARD VERIFICATION INFORMATION WITH MATERIAL.

NSN: 5530-LL-S05-0914

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0023 1,496 Sheet

CONSTRUCTION PLYWOOD

80/88 SHEETS TO A SLING

3/8" THK X 48" WD X 96" LG, 3-PLIES, FIRE RETARDANT WOOD, SOFT

IAW A-A-55057B, GRADE C-C EXTERIOR, CCX CONSTRUCTION

PLYWOOD, MIL-L-19140E TY-2 CAT-2

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING-PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. INDENTIFYING MARKING- 100% BLUE STAIN OR DYE IAW PARA

3.9 AND 3.13.2

F. 14% MOISTURE IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING IAW PARA'S 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNITIZING AND LOADING- LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

J. REQUIRED IAW PARA 6.3.1; MUST ACCOMANY MATERIAL

K. 3/8" THICK X 48" WIDTH X 96" LENGTH, 3 PLY, FIRE RETARDANT

NSN: 5530-LL-S05-0915

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

0024 528 Sheet

CONSTRUCTION PLYWOOD

66 SHEETS PER SLING

1/2" THK X 48" W X 96" LONG, 5-PLIES, FIRE RETARDANT WOOD, SOFT

IAW A-A-55057B TY-A, GRADE C-C EXTERIOR; MIL-L-19140E TY-2 CAT-

1/2 INCH THICK X 48 INCH WIDE X 96 INCH LONG PLYWOOD

GRADE CCX

A. LUMBER AND PLYWOOD, FIRE-RETARDANT TREATED MIL-L-

19140E

AMMENDMENT 02 01/29/97

B. TREATMENT - TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY -2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNTIZING AND LOADING - LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

J. VERIFICATION INFORMATION REQUIRED IAW PARA 6.3.1 & IS TO

ACCOMPANY MATERIAL

66 SHEETS PER PALLET

NSN: 5530-LL-S05-1152

MILSTRIP: N4523AIDIQLUMBER

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

00MG

MINIMUM GUARANTEE

FFP

CLIN it is a place holder for the minimum guarantee of $5,000.00. Delivery order 00MG will be used. The delivery order 00MG may not be invoiced against without a modification from the Contracting Officer approving invoice rights.

MILSTRIP: N4523AIDIQLUMBER

NET AMT

UNIT UNIT PRICE MAX AMOUNT

1001 9,450 Board

OPTION YEAR 1

PS 20 04/26/07

1. SPECIES: DOUGLAS FIR / WESTERN HEMLOCK

2. MOISTURE NOT TO EXCEED 26%

3. SIZE 4" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH 8' TO 14' LONG OR LONGER

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE CONSTRUCTION AND/OR #1, per WCLIB

7. PATTERN N/A

8. PRESERVATION N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1002 17,850 Board

PS 20 09/01/99

1. SPECIES: DOUGLAS FIR

2. MOISTURE: NOT TO EXCEED 19%

3. SIZE: 2" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH: 50% TO BE 16' LONG & 50% TO BE 20' LONG

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE: #2 OR STANDARD IAW PS 20 & WCLIB

7. PATTERN: N/A

8. PRESERVATION: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1003 16,179 Board

SPECIES - DOUGLAS FIR IAW PARA 3.2

MOISTURE - NOT TO EXCEED 19% IAW PARA 3.3

SIZE - 2" THK X 6" WIDE IAW PARA 3.4 3.4.4 & TABLE #3

LENGTH - 16' TO 20' LONG, MIN/MAX IAW PARA 3.4.4 (SEE NOTE A)

SURFACING - DRESSED, S4S IAW PARA 3.5

GRADE #2 OR STANDARD IAW PARA 3.6 & WCLIB (SEE PS-20)

PATTERN - N/A

PRESERVATIVE TREATMENT - N/A

FIRE RETARDANT TREATMENT - N/A

TEST METHOD - N/A

BUNDLING, UNITIZING & MARKING IAW PARA 5.1 & MIL-DTL-

14362H(1)

A. LENGTH EXCEPT TO NSN

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1004 378 Sheet

CONSTRUCTION PLYWOOD

C. DIMENSIONS: 1/4 INCH THICK X 48 INCH WIDE X 96 INCH LONG

D. 3 PLY, SANDED 2 SIDES

E. LEVEL C PACKING

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1005 189 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; 3 PLIES, SANDED 2 SIDES

(S2S), EXTERIOR, GRADE A-B EXTERIOR, 3/8" THICK X 48" WIDE X 96"

LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1006 1,155 Sheet

CONSTRUCTION PLYWOOD

44 SHEETS PER SLING, S2S SOFT WOOD

C. REGULAR SANDED TWO SIDES

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1007 416 Sheet

CONSTRUCTION PLYWOOD

SOFT, DOUGLAS FIR/WESTERN HEMLOCK

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1008 2,310 Board

B. TYPE 1 CUTTING GRADE IAW PARA 1.2

C. MAPLE, HARD, GRADE - SELECT IAW PARA 3.1.1 AND NHLA

D. 2" THK X 4" - 7" WIDE & WIDER X 6' - 14' LONG & LONGER

IAW PARA 3.2 & 6.3

E. SEASONED IAW PARA 3.3

F. 12% MOISTURE CONTENT IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

O. UNITIZING, MARKING & LOADING IAW PARA 5.1

********************* NOTE **********************

1. LENGTH: 6' AND LONGER, MAX OF 30% 6'- 11' LONG. 1/6 MAY BE 6' &

7' LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1009 157,500 Board

LUMBER, SPECIES: DOUGLAS FIR

MOISTURE: ANY STAGE OF SEASONING IS ACCEPTABLE

SIZE: 14" THICK X 14" WIDE IAW TABLE 3 OF PS20-70

LENGTH: 16' & 20' LONG

GRADE: NO. 1 STRUCTURAL IAW PS20-70 & WCLIB

DRESSED: STD ROUGH SAWN

PRESERVATION: N/A

FIRE RETARDANT: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1010 16 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; SOFT; 3 OR 4 PLY; ROUGH

SANDED; CDX, GRADE C-D INTERIOR W/ EXTERIOR GLUE. 3/8" THICK

X 48" WIDE X 96" LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1011 775 Sheet

CONSTRUCTION PLYWOOD

THICK X 48" WIDTH X 96" LENGTH

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1012 84 Sheet

CONSTRUCTION PLYWOOD

C. ROUGH SANDED

D. INTERIOR

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1013 26,612 Board

B. TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 19% IAW PARA 3.12, GRADE - SELECT STRUCTURAL WOOD

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1014 35,348 Board

B. TREATMENT- TY-2, WEATHER RESISTANT

C. CATEGORY- 2, NAVAL SHIPBUILDING AND REPAIR

D. INCISING- REQUIRED IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. MOISTURE- 19% IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING- IAW PARA 3.12.2 AND 6.4.5 FOR CATEGORY-2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1015 4,200 Each

SCAFFOLD LUMBER

19% MAXIMUM MOISTURE CONTENT AFTER TREATMENT AND AT

THE TIME OF SHIPMENT

2” THK X 12”W X 16’ LONG, ROUGH, SPRUCE; TY-II (EXTERIOR);

CATEGORY 2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1016 5,078 Each

SHOLE BLOCK

3" THICK X 12" WIDE X 14" LONG. FIR, ROUGH CUT, STRUCTURAL

GRADE, MAX 19% MOISTURE. "MUST BE SHRINK WRAPPED".

NSN: 5510-LL-S03-6939

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1017 420 Board

LUMBER

C. DOMESTIC BLACK CHERRY, GRADES 1 & 2 (FAS)

D. 1" THK, (4/4")WIDTH 8" UP TO AVG 10" WIDE, 8' TO 12' LG

E. N/A

F. 10% OR LESS MOISTURE

G. N/A

H. N/A

I. ROUGH

J. N/A

K. N/A

L. N/A

M. MILL CERTIFICATION OF GRADE TO ACCOMPANY MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1018 560 Board

C. CHERRY, DOMESTIC BLACK, GRADES 1 & 2 IAW PARA 3.1.1 &

N.H.L.A.

D. 2" THK X 6/8" WIDE W/AVE OF 8" W X 8/10' LG IAW PARA 3.2 & 6.3

SEASONED IAW PARA 3.3

E. N/A

F. 12% MOISTURE CONTENT OR LESS IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5 & 6.4

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1019 13,521 Each

WOOD WEDGE

CRACKS/CHECKS

MINIMUM ISSUE QUANTITY = 18 (900 PER PALLET)

FOB: Destination

NSN: 5510-LL-S04-7728

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1020 58,800 Board

C. OAK, RED OR WHITE, GRADE COMMON DIMENSION IAW PARA

3.1.1 AND NHLA

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION TO BE ISSUED BY CERTIFIED MILL

GRADER

N. REQUIREMENTS OF PARA 3.8 WAIVED FOR THIS ORDER

O. PREPARE LOAD FOR DELIVERY IAW BEST COMMERCIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1021 4,200 Sheet

CONSTRUCTION PLYWOOD

B. WOOD SOFT, 5 PLY IAW A-A55057B, TY-2, GRADE C-C WEATHER

RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. STANDARD COMMERCIAL UNITIZING & LOADING

J. VERIFICATION INFORMATION IS REQUIRED IAW PARA 6.3.1 AND IS

TO BE FORWARDED WITH MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1022 504 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARK IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. LEVEL-C IAW PARA 5.2.1 AND A-A-55057B

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1023 1,571 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING-PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. INDENTIFYING MARKING- 100% BLUE STAIN OR DYE IAW PARA

3.9 AND 3.13.2

F. 14% MOISTURE IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING IAW PARA'S 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNITIZING AND LOADING- LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

1024 555 Sheet

CONSTRUCTION PLYWOOD

AMMENDMENT 02 01/29/97

B. TREATMENT - TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY -2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNTIZING AND LOADING - LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

J. VERIFICATION INFORMATION REQUIRED IAW PARA 6.3.1 & IS TO

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2001 9,923 Board

OPTION YEAR 2

PS 20 04/26/07

1. SPECIES: DOUGLAS FIR / WESTERN HEMLOCK

2. MOISTURE NOT TO EXCEED 26%

3. SIZE 4" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH 8' TO 14' LONG OR LONGER

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE CONSTRUCTION AND/OR #1, per WCLIB

7. PATTERN N/A

8. PRESERVATION N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2002 18,743 Board

PS 20 09/01/99

1. SPECIES: DOUGLAS FIR

2. MOISTURE: NOT TO EXCEED 19%

3. SIZE: 2" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH: 50% TO BE 16' LONG & 50% TO BE 20' LONG

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE: #2 OR STANDARD IAW PS 20 & WCLIB

7. PATTERN: N/A

8. PRESERVATION: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2003 16,988 Board

SPECIES - DOUGLAS FIR IAW PARA 3.2

MOISTURE - NOT TO EXCEED 19% IAW PARA 3.3

SIZE - 2" THK X 6" WIDE IAW PARA 3.4 3.4.4 & TABLE #3

LENGTH - 16' TO 20' LONG, MIN/MAX IAW PARA 3.4.4 (SEE NOTE A)

SURFACING - DRESSED, S4S IAW PARA 3.5

GRADE #2 OR STANDARD IAW PARA 3.6 & WCLIB (SEE PS-20)

PATTERN - N/A

PRESERVATIVE TREATMENT - N/A

FIRE RETARDANT TREATMENT - N/A

TEST METHOD - N/A

BUNDLING, UNITIZING & MARKING IAW PARA 5.1 & MIL-DTL-

14362H(1)

A. LENGTH EXCEPT TO NSN

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2004 397 Sheet

CONSTRUCTION PLYWOOD

C. DIMENSIONS: 1/4 INCH THICK X 48 INCH WIDE X 96 INCH LONG

D. 3 PLY, SANDED 2 SIDES

E. LEVEL C PACKING

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2005 198 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; 3 PLIES, SANDED 2 SIDES

(S2S), EXTERIOR, GRADE A-B EXTERIOR, 3/8" THICK X 48" WIDE X 96"

LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2006 1,213 Sheet

CONSTRUCTION PLYWOOD

C. REGULAR SANDED TWO SIDES

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2007 437 Sheet

CONSTRUCTION PLYWOOD

SOFT, DOUGLAS FIR/WESTERN HEMLOCK

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2008 2,426 Board

B. TYPE 1 CUTTING GRADE IAW PARA 1.2

C. MAPLE, HARD, GRADE - SELECT IAW PARA 3.1.1 AND NHLA

D. 2" THK X 4" - 7" WIDE & WIDER X 6' - 14' LONG & LONGER

IAW PARA 3.2 & 6.3

E. SEASONED IAW PARA 3.3

F. 12% MOISTURE CONTENT IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

O. UNITIZING, MARKING & LOADING IAW PARA 5.1

********************* NOTE **********************

1. LENGTH: 6' AND LONGER, MAX OF 30% 6'- 11' LONG. 1/6 MAY BE 6' &

7' LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2009 165,375 Board

LUMBER, SPECIES: DOUGLAS FIR

MOISTURE: ANY STAGE OF SEASONING IS ACCEPTABLE

SIZE: 14" THICK X 14" WIDE IAW TABLE 3 OF PS20-70

LENGTH: 16' & 20' LONG

GRADE: NO. 1 STRUCTURAL IAW PS20-70 & WCLIB

DRESSED: STD ROUGH SAWN

PRESERVATION: N/A

FIRE RETARDANT: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2010 17 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; SOFT; 3 OR 4 PLY; ROUGH

SANDED; CDX, GRADE C-D INTERIOR W/ EXTERIOR GLUE. 3/8" THICK

X 48" WIDE X 96" LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2011 814 Sheet

CONSTRUCTION PLYWOOD

THICK X 48" WIDTH X 96" LENGTH

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2012 88 Sheet

CONSTRUCTION PLYWOOD

C. ROUGH SANDED

D. INTERIOR

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2013 27,943 Board

B. TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 19% IAW PARA 3.12, GRADE - SELECT STRUCTURAL WOOD

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2014 37,115 Board

B. TREATMENT- TY-2, WEATHER RESISTANT

C. CATEGORY- 2, NAVAL SHIPBUILDING AND REPAIR

D. INCISING- REQUIRED IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. MOISTURE- 19% IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING- IAW PARA 3.12.2 AND 6.4.5 FOR CATEGORY-2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2015 4,410 Each

SOFTWOOD LUMBER

19% MAXIMUM MOISTURE CONTENT AFTER TREATMENT AND AT

THE TIME OF SHIPMENT

2” THK X 12”W X 16’ LONG, ROUGH, SPRUCE

TY-II (EXTERIOR)

CATEGORY 2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2016 5,332 Each

SHOLE BLOCK

BE SHRINK WRAPPED".

156 PER PALLET

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2017 420 Board

C. DOMESTIC BLACK CHERRY, GRADES 1 & 2 (FAS)

D. 1" THK, (4/4")WIDTH 8" UP TO AVG 10" WIDE, 8' TO 12' LG

E. N/A

F. 10% OR LESS MOISTURE

G. N/A

H. N/A

I. ROUGH

J. N/A

K. N/A

L. N/A

M. MILL CERTIFICATION OF GRADE TO ACCOMPANY MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2018 560 Board

C. CHERRY, DOMESTIC BLACK, GRADES 1 & 2 IAW PARA 3.1.1 &

N.H.L.A.

D. 2" THK X 6/8" WIDE W/AVE OF 8" W X 8/10' LG IAW PARA 3.2 & 6.3

SEASONED IAW PARA 3.3

E. N/A

F. 12% MOISTURE CONTENT OR LESS IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5 & 6.4

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2019 14,197 Each

WOOD WEDGE

CRACKS/CHECKS

MINIMUM ISSUE QUANTITY = 18 (900 PER PALLET)

FOB: Destination

NSN: 5510-LL-S04-7728

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2020 61,740 Board

C. OAK, RED OR WHITE, GRADE COMMON DIMENSION IAW PARA

3.1.1 AND NHLA

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION TO BE ISSUED BY CERTIFIED MILL

GRADER

N. REQUIREMENTS OF PARA 3.8 WAIVED FOR THIS ORDER

O. PREPARE LOAD FOR DELIVERY IAW BEST COMMERCIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2021 4,410 Sheet

CONSTRUCTION PLYWOOD

B. WOOD SOFT, 5 PLY IAW A-A55057B, TY-2, GRADE C-C WEATHER

RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. STANDARD COMMERCIAL UNITIZING & LOADING

J. VERIFICATION INFORMATION IS REQUIRED IAW PARA 6.3.1 AND IS

TO BE FORWARDED WITH MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2022 529 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARK IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. LEVEL-C IAW PARA 5.2.1 AND A-A-55057B

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2023 1,650 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING-PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. INDENTIFYING MARKING- 100% BLUE STAIN OR DYE IAW PARA

3.9 AND 3.13.2

F. 14% MOISTURE IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING IAW PARA'S 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNITIZING AND LOADING- LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

2024 583 Sheet

CONSTRUCTION PLYWOOD

AMMENDMENT 02 01/29/97

B. TREATMENT - TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY -2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNTIZING AND LOADING - LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

J. VERIFICATION INFORMATION REQUIRED IAW PARA 6.3.1 & IS TO

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3001 10,419 Board

OPTION YEAR 3

PS 20 04/26/07

1. SPECIES: DOUGLAS FIR / WESTERN HEMLOCK

2. MOISTURE NOT TO EXCEED 26%

3. SIZE 4" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH 8' TO 14' LONG OR LONGER

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE CONSTRUCTION AND/OR #1, per WCLIB

7. PATTERN N/A

8. PRESERVATION N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3002 19,680 Board

PS 20 09/01/99

1. SPECIES: DOUGLAS FIR

2. MOISTURE: NOT TO EXCEED 19%

3. SIZE: 2" THICK X 4" WIDE IAW TABLE 3 OF PS 20

4. LENGTH: 50% TO BE 16' LONG & 50% TO BE 20' LONG

5. DRESSED: SANDED FOUR SIDES (S4S)

6. GRADE: #2 OR STANDARD IAW PS 20 & WCLIB

7. PATTERN: N/A

8. PRESERVATION: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3003 17,837 Board

SPECIES - DOUGLAS FIR IAW PARA 3.2

MOISTURE - NOT TO EXCEED 19% IAW PARA 3.3

SIZE - 2" THK X 6" WIDE IAW PARA 3.4 3.4.4 & TABLE #3

LENGTH - 16' TO 20' LONG, MIN/MAX IAW PARA 3.4.4 (SEE NOTE A)

SURFACING - DRESSED, S4S IAW PARA 3.5

GRADE #2 OR STANDARD IAW PARA 3.6 & WCLIB (SEE PS-20)

PATTERN - N/A

PRESERVATIVE TREATMENT - N/A

FIRE RETARDANT TREATMENT - N/A

TEST METHOD - N/A

BUNDLING, UNITIZING & MARKING IAW PARA 5.1 & MIL-DTL-

14362H(1)

A. LENGTH EXCEPT TO NSN

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3004 417 Sheet

CONSTRUCTION PLYWOOD

C. DIMENSIONS: 1/4 INCH THICK X 48 INCH WIDE X 96 INCH LONG

D. 3 PLY, SANDED 2 SIDES

E. LEVEL C PACKING

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3005 208 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; 3 PLIES, SANDED 2 SIDES

(S2S), EXTERIOR, GRADE A-B EXTERIOR, 3/8" THICK X 48" WIDE X 96"

LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3006 1,274 Sheet

CONSTRUCTION PLYWOOD

C. REGULAR SANDED TWO SIDES

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3007 459 Sheet

CONSTRUCTION PLYWOOD

SOFT, DOUGLAS FIR/WESTERN HEMLOCK

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3008 2,547 Board

B. TYPE 1 CUTTING GRADE IAW PARA 1.2

C. MAPLE, HARD, GRADE - SELECT IAW PARA 3.1.1 AND NHLA

D. 2" THK X 4" - 7" WIDE & WIDER X 6' - 14' LONG & LONGER

IAW PARA 3.2 & 6.3

E. SEASONED IAW PARA 3.3

F. 12% MOISTURE CONTENT IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

O. UNITIZING, MARKING & LOADING IAW PARA 5.1

********************* NOTE **********************

1. LENGTH: 6' AND LONGER, MAX OF 30% 6'- 11' LONG. 1/6 MAY BE 6' &

7' LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3009 173,644 Board

LUMBER, SPECIES: DOUGLAS FIR

MOISTURE: ANY STAGE OF SEASONING IS ACCEPTABLE

SIZE: 14" THICK X 14" WIDE IAW TABLE 3 OF PS20-70

LENGTH: 16' & 20' LONG

GRADE: NO. 1 STRUCTURAL IAW PS20-70 & WCLIB

DRESSED: STD ROUGH SAWN

PRESERVATION: N/A

FIRE RETARDANT: N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3010 18 Sheet

CONSTRUCTION PLYWOOD

7.2.2 DOUGLAS FIR/WESTERN HEMLOCK; SOFT; 3 OR 4 PLY; ROUGH

SANDED; CDX, GRADE C-D INTERIOR W/ EXTERIOR GLUE. 3/8" THICK

X 48" WIDE X 96" LONG

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3011 855 Sheet

CONSTRUCTION PLYWOOD

THICK X 48" WIDTH X 96" LENGTH

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3012 92 Sheet

CONSTRUCTION PLYWOOD

C. ROUGH SANDED

D. INTERIOR

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3013 29,340 Board

B. TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 19% IAW PARA 3.12, GRADE - SELECT STRUCTURAL WOOD

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. N/A

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3014 38,971 Board

B. TREATMENT- TY-2, WEATHER RESISTANT

C. CATEGORY- 2, NAVAL SHIPBUILDING AND REPAIR

D. INCISING- REQUIRED IAW PARA 3.2.3.1

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. MOISTURE- 19% IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING- IAW PARA 3.12.2 AND 6.4.5 FOR CATEGORY-2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3015 4,631 Each

SCAFFOLD PLANK LUMBER

19% MAXIMUM MOISTURE CONTENT AFTER TREATMENT AND AT

THE TIME OF SHIPMENT

2” THK X 12”W X 16’ LONG, ROUGH, SPRUCE

TY-II (EXTERIOR)

CATEGORY 2

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3016 5,599 Each

SHOLE BLOCK

BE SHRINK WRAPPED".

156 PER PALLET

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3017 441 Board

C. DOMESTIC BLACK CHERRY, GRADES 1 & 2 (FAS)

D. 1" THK, (4/4") WIDTH 8" UP TO AVG 10" WIDE, 8' TO 12' LG

E. N/A

F. 10% OR LESS MOISTURE

G. N/A

H. N/A

I. ROUGH

J. N/A

K. N/A

L. N/A

M. MILL CERTIFICATION OF GRADE TO ACCOMPANY MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3018 588 Board

C. CHERRY, DOMESTIC BLACK, GRADES 1 & 2 IAW PARA 3.1.1 &

N.H.L.A.

D. 2" THK X 6/8" WIDE W/AVE OF 8" W X 8/10' LG IAW PARA 3.2 & 6.3

SEASONED IAW PARA 3.3

E. N/A

F. 12% MOISTURE CONTENT OR LESS IAW PARA 3.3.2.1

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5 & 6.4

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION IAW PARA 3.7

N. MARKING IAW PARA 3.8

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3019 14,907 Each

WOOD WEDGE

CRACKS/CHECKS

MINIMUM ISSUE QUANTITY = 18 (900 PER PALLET)

NSN: 5510-LL-S04-7728

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3020 64,827 Board

C. OAK, RED OR WHITE, GRADE COMMON DIMENSION IAW PARA

3.1.1 AND NHLA

G. N/A

H. N/A

I. ROUGH IAW PARA 3.5

J. N/A

K. N/A

L. N/A

M. GRADE CERTIFICATION TO BE ISSUED BY CERTIFIED MILL

GRADER

N. REQUIREMENTS OF PARA 3.8 WAIVED FOR THIS ORDER

O. PREPARE LOAD FOR DELIVERY IAW BEST COMMERCIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3021 4,631 Sheet

CONSTRUCTION PLYWOOD

B. WOOD SOFT, 5 PLY IAW A-A55057B, TY-2, GRADE C-C WEATHER

RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.9

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 FOR CATEGORY-2

I. STANDARD COMMERCIAL UNITIZING & LOADING

J. VERIFICATION INFORMATION IS REQUIRED IAW PARA 6.3.1 AND IS

TO BE FORWARDED WITH MATERIAL

MILSTRIP: N4523AIDIQLUMBER

UNIT UNIT PRICE MAX AMOUNT

3022 555 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARK IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. LEVEL-C IAW PARA 5.2.1 AND A-A-55057B

MILSTRIP: N4523AIDIQLUMBER

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

3023 1,733 Sheet

CONSTRUCTION PLYWOOD

B. TREATMENT- TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW PARA 1.2.2

D. INCISING-PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. INDENTIFYING MARKING- 100% BLUE STAIN OR DYE IAW PARA 3.9

AND 3.13.2

F. 14% MOISTURE IAW PARA 3.12

G. INTERVAL MARKING- N/A

H. MARKING IAW PARA'S 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNITIZING AND LOADING- LEVEL-C IAW PARA 5.2.1 AND A-A-55057B

MILSTRIP: N4523AIDIQLUMBER

NET AMT

UNIT UNIT PRICE MAX AMOUNT

3024 612 Sheet

CONSTRUCTION PLYWOOD

AMMENDMENT 02 01/29/97

B. TREATMENT - TY-2, WEATHER RESISTANT IAW PARA 1.2.1

C. CATEGORY -2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2

D. PLYWOOD SHALL NOT BE INCISED IAW PARA 3.2.3.2

E. 100% BLUE STAIN OR DYE REQUIRED IAW PARA 3.2.3.2

F. 14% MOISTURE IAW PARA 3.12

G. N/A

H. MARKING IAW PARA 3.13.2 AND 6.4.5 FOR CATEGORY-2

I. UNTIZING AND LOADING - LEVEL-C IAW PARA 5.2.1 AND A-A-

55057B

J. VERIFICATION INFORMATION REQUIRED IAW PARA 6.3.1 & IS TO

MILSTRIP: N4523AIDIQLUMBER

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government 0012 Destination Government Destination Government 0013 Destination Government Destination Government