Solicitation SPMYM125Q0102.pdf

SEE ADDENDUM

(No Collect Calls)

SPMYM125Q0102 20-May-2025

b. TELEPHONE NUMBER 8. OFFER DUE DATE/LOCAL TIME

03:00 PM 26 May 2025

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

SPMYM19. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

LATOYA C. HAYWOOD

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

N4215851213075

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

DLA MARITIME NORFOLK

LATOYA HAYWOOD,

CODE NMAB U1

757-278-5082

PORTSMOUTH VA 23709-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS AX

13b. RATING

DO-C9

CODE15. DELIVER TO CODE N42158 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

NORFOLK NAVAL SHIPYARD

NO POINT OF CONTACT (RECEIVING DEPT)

RECEIVING OFFICER

BLDG 276

PORTSMOUTH VA 23709-5000

TEL: FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

326122

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF91

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

SPMYM125Q0102

Section SF 1449 - CONTINUATION SHEET

ORDERING DATA

Document # 51213075

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 4 CS STD WLD TEE

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213076

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 3 CS STD WLD TEE

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213077

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 2 CS STD WLD TEE

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213078

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 1 CS STD WLD TEE

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213079

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 4 CS 150# RF SO FLANGE

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213080

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 4 150# ZN NA 1/16 RNG NBG SET

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213081

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 CS 150# RF SO FLG

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213088

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 4 S40 ERW SRL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213089

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 3 S40 ERW SRL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213090

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 2 S40 ERW SRL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

Document # 51213091

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 1 S40 ERW SRL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213092

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 4 CS STD WELD LR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213093

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 3 CS STD WELD LR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213094

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 2 CS STD WELD LR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213095

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 1 CS STD WELD LR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

Document # 51213096

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 4 CS STD WLD SR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213097

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 3 CS STD WLD SR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213098

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 2 CS STD WLD SR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51213099

6.2 ACQUISITION REQUIREMENTS

(A) pipe, 1 CS STD WLD SR 90 ELL

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223075

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 150# ZN NA 1/16 RNG NBG SET

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

Document # 51223076

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 CS 150# RF SO FLG

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223077

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 150# ZN NA 1/16 RNG NBG SET

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223078

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 1 CS 150# RF SO FLG

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223079

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 1 150# ZN NA 1/16 RNG NBG SET

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223080

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 4 A106B 5D 90 4.5 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

Document # 51223081

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 A106B 5D 90 3.5 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223082

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 A106B 5D 90 2.375 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223083

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 1 A106B 5D 90 1.315 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223084

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 4 A106B 3D 90 4.5 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223085

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 A106B 3D 90 3.5 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

Document # 51223086

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 A106B 3D 90 2.375 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223087

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 1 A106B 3D 90 1.315 OD

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223088

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 4 CS 150# BW OS&Y GATE VLV

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223089

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 CS 150# BW OS&Y GATE VLV

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223090

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 CS 150# BW OS&Y GATE VLV

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

Document # 51223091

(A) PIPPING, 1 FS 800# SW BB T8 GATE VLV BAA

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223092

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 4 F126 STD RSR CLMP

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223093

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 3 CS 150# BW OS&Y GATE VLV

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51223094

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 2 F126 STD RSR CLMP

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51233075

6.2 ACQUISITION REQUIREMENTS

(A) PIPPING, 1 F126 STD RSR CLMP

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

Document # 51233076

(A) 1-1/2X1/4 ZINC BOLT W/ NUTS/WSHRS

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51233077

6.2 ACQUISITION REQUIREMENTS

(A) 1-1/2X3/8 ZINC BOLT W/ NUT/WSHR

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

(F) CONTAINER SELECTION TO BE AT THE CONTRACTORS OPTION

(G) NO SPECIAL MARKING REQUIRED

Document # 51233078

6.2 ACQUISITION REQUIREMENTS

(A) 1-1/2X1/2 ZINC BOLT W/ NUT/WSHR

(B) PER LATEST REVISION

(C) INSPECTIONS TO BE PER PARA 4.2.1

(D) NAVY FIRE RETARDANT REQUIREMENTS (LEVELS A WEATHER

RESISTANT AND B GENERAL USE)

(E) Level of packing required (GENERAL REQUIREMENTS)

CONTACT INFORMATION

CONTACT INFORMATION, PALLETIZATION AND SHIPPING INSTRUCTIONS

CONTACT INFORMATION

If your company encounters any problems with this purchase order/contract, please contact Latoya Haywood by email at latoya.haywood@dla.mil or by telephone at (757) 396-8009.

PALLET REQUIREMENT

Contractors (drivers) delivering material to the Norfolk Naval Shipyard must come with two forms of Identification, one being a driver license or picture ID card issued by a State. The other form required is a SSN card, birth certificate issued by a state, Native American document or US citizen card. Driver(s) will not be escorted unless they have to go into the CIA.

All items/boxes over 40 lbs under this solicitation and/or contract is required to be palletized. Delivery will not be accepted to any material that IS NOT palletized. The shipment will not be offloaded and will be returned.

Material sourced or otherwise procured from NUFLO, Inc. (Cage Code: 3BZG7) and/or Synergy Flow Systems (Cage Code: 4GP29) are prohibited to be offered, sold, exchanged, or delivered to Norfolk Naval Shipyard.

Contract Number MUST be noticeable on the outside of the package and on the packing documents. All shipments must have the Contact Number or the Lead JML number labeled on the outside of all boxes. If not labeled the Warehouse may at the time of delivery turn the material away at the company's cost for not being able to identify the material.

MARKING OF SHIPMENTS (COMMERCIALLY PACKAGED ITEMS)

(i) Marking shall be in accordance with ASTM-D-3951 (most current edition) and with the information set forth in paragraph (ii) below. Unless specified elsewhere in this contract/order, bar coding is not required.

(ii) All UNIT AND EXTERIOR CONTAINERS/PACKS ARE REQUIRED TO BE MARKED AS FOLLOWS:

1. Applicable National stock number (NSN), Federal stock number (FSN), Local Stock Number (LSN), or

Part Number when neither NSN, FSN, LSN are available

2. Noun nomenclature cited on contract or order

3. Quantity and unit of issue

4. QA Designator:

5. Government Contract, or Purchase Order Number (incl. Delivery Order No.)

6. From:_______________________________________________

(Contractor's Name)

(Contractor’s Address)

7. To: (See delivery address on page 1 or in Section F)

(iii) Markings may be applied by any means which provide legibility.

(iv) Additional markings required as stated below:

SHIPPING LABEL INSTRUCTIONS

All shipments must have a label on the outside of each box, clearly providing the following information, in addition to packing slips inside the box:

Document Numbers: N4215851213075 Contract or Purchasing Number: TO BE GIVEN AT TIME OF AWARD Government Purchasing Agent’s Name and Phone Number (if known): Latoya Haywood, (757) 396-8009 Post Award Action/Contract Issues: Post Awards NNSY, PostAwardsNNSY@dla.mil

If a label cannot be generated, the info must be clearly marked on the outside of each container.

PREPARATION FOR DELIVERY (COMMERCIALLY PACKAGED ITEMS)

Preservation, packaging and packing shall be in accordance with ASTM Designation D-3951(Latest Revision), “Standard Practice for Commercial Packaging Address all questions or concerns regarding the labeling or shipping documents with the government purchasing agent before confirming acceptance of the order.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 6 Each N4215851213075

FFP

PART NAME - 4 CS STD WLD TEE

PART DESCRIPTION - DWTP 4 CS STD WLD TEE

PART NUMBER - DWTP

FOB: Destination

MILSTRIP: N4215851213075

PURCHASE REQUEST NUMBER: N4215851213075

PROJECT: YY9

PSC CD: 4710

NET AMT

0002 6 Each N4215851213076

FFP

PART NAME - 3 CS STD WLD TEE

PART DESCRIPTION - DWTM 3 CS STD WLD TEE

PART NUMBER - DWTM 3

FOB: Destination

MILSTRIP: N4215851213076

PURCHASE REQUEST NUMBER: N4215851213075

0003 6 Each N4215851213077

FFP

PART NAME - 2 CS STD WLD TEE

PART DESCRIPTION - DWTK 2 CS STD WLD TEE

PART NUMBER - DWTK 2

FOB: Destination

MILSTRIP: N4215851213077

PURCHASE REQUEST NUMBER: N4215851213075

0004 6 Each N4215851213078

FFP

PART NAME -1 CS STD WLD TEE

PART DESCRIPTION -DWTG 1 CS STD WLD TEE

PART NUMBER -DWTG

FOB: Destination

MILSTRIP: N4215851213078

PURCHASE REQUEST NUMBER: N4215851213075

0005 6 Each N4215851213079

FFP

PART NAME -4 CS 150 RF SO FLG

PART DESCRIPTION -DRFSOFP 4 CS 150 RF

SO FLG

PART NUMBER -DRFSOFP

FOB: Destination

MILSTRIP: N4215851213079

PURCHASE REQUEST NUMBER: N4215851213075

0006 6 Each N4215851213080

FFP

PART NAME -0.0625 RNG NBG SET

PART DESCRIPTION -FNWNBGZ1NAR6P 4 150

ZN NA 0.0625 RNG NBG SET

PART NUMBER - FNWNBGZ1NAR6P

FOB: Destination

MILSTRIP: N4215851213080

PURCHASE REQUEST NUMBER: N4215851213075

0007 6 Each N4215851213081

FFP

PART NAME -3 CS 150 RF SO FLG

PART DESCRIPTION -DRFSOFM 3 CS 150 RF

SO FLG

PART NUMBER -DRFSOFM

FOB: Destination

MILSTRIP: N4215851213081

PURCHASE REQUEST NUMBER: N4215851213075

0008 126 Each N4215851213088

FFP

PART NAME -4 S40 ERW SRL PIPE

PART DESCRIPTION -DBPPEA53BP 4 BLK BE

A53B S40 ERW SRL PIPE

PART NUMBER -DBPPEA53BP

FOB: Destination

MILSTRIP: N4215851213088

PURCHASE REQUEST NUMBER: N4215851213075

0009 126 Each N4215851213089

FFP

PART NAME -3 S40 ERW SRL PIPE

PART DESCRIPTION -3 BLK BE

A53B S40 ERW SRL PIPE

PART NUMBER -DBPPEA53BM

FOB: Destination

MILSTRIP: N4215851213089

PURCHASE REQUEST NUMBER: N4215851213075

0010 126 Each N4215851213090

FFP

PART NAME -2 S40 ERW SRL PIPE

PART DESCRIPTION -2 BLK BE

A53B S40 ERW SRL PIPE

PART NUMBER -DBPPEA53BK

FOB: Destination

MILSTRIP: N4215851213090

PURCHASE REQUEST NUMBER: N4215851213075

0011 126 Each N4215851213091

FFP

PART NAME -1 S40 ERW SRL PIPE

PART DESCRIPTION -1 BLK BE A53

S40 PIPE

PART NUMBER -DBPPEA53G

FOB: Destination

MILSTRIP: N4215851213091

PURCHASE REQUEST NUMBER: N4215851213075

0012 9 Each N4215851213092

FFP

PART NAME -4 CS STD WLD LR

PART DESCRIPTION -4 CS STD WLD LR

90 ELL

PART NUMBER -DW9P

FOB: Destination

MILSTRIP: N4215851213092

PURCHASE REQUEST NUMBER: N4215851213075

0013 9 Each N4215851213093

FFP

PART NAME -3 CS STD WLD LR

PART DESCRIPTION -3 CS STD WLD LR

90 ELL

PART NUMBER -3 CS STD WLD LR

FOB: Destination

MILSTRIP: N4215851213093

PURCHASE REQUEST NUMBER: N4215851213075

0014 9 Each N4215851213094

FFP

PART NAME -2 CS STD WLD LR

PART DESCRIPTION -2 CS STD WLD LR

90 ELL

PART NUMBER -DW9K

FOB: Destination

MILSTRIP: N4215851213094

PURCHASE REQUEST NUMBER: N4215851213075

0015 9 Each N4215851213095

FFP

PART NAME -1 CS STD WLD LR

PART DESCRIPTION -1 CS STD WLD LR

90 ELL

PART NUMBER -DW9G

FOB: Destination

MILSTRIP: N4215851213095

PURCHASE REQUEST NUMBER: N4215851213075

0016 9 Each N4215851213096

FFP

PART NAME -4 CS STD WLD SR

PART DESCRIPTION -4 CS STD WLD

SR 90 ELL

PART NUMBER -DWSR9P

FOB: Destination

MILSTRIP: N4215851213096

PURCHASE REQUEST NUMBER: N4215851213075

0017 9 Each N4215851213097

FFP

PART NAME -3 CS STD WLD SR

PART DESCRIPTION -3 CS STD WLD

SR 90 ELL

PART NUMBER -DWSR9M

FOB: Destination

MILSTRIP: N4215851213097

PURCHASE REQUEST NUMBER: N4215851213075

0018 9 Each N4215851213098

FFP

PART NAME -2 CS STD WLD SR

PART DESCRIPTION -2 CS STD WLD

SR 90 ELL

PART NUMBER -DWSR9K

FOB: Destination

MILSTRIP: N4215851213098

PURCHASE REQUEST NUMBER: N4215851213075

0019 9 Each N4215851213099

FFP

PART NAME -1 CS STD WLD SR

PART DESCRIPTION -1 CS STD WLD

SR 90 ELL

PART NUMBER -DWSR9G

FOB: Destination

MILSTRIP: N4215851213099

PURCHASE REQUEST NUMBER: N4215851213075

0020 10 Each N4215851222704

FFP

PART NAME -CALIBRATION GAS

PART DESCRIPTION -CALIBRATION GAS 100PPM ISOBUTYLENE-AIR

58L -X02AI99CP581430

PART NUMBER -58L-248-100

MFR- AIRGAS, INC

- MUST NOT CONTAIN -METHYLENE CHLORIDE

- ALL MATERIAL FOR THIS LINE ITEM MUST BE MARKED AND

IDENTIFIED CLEARLY ON EACH INDIVIDUAL CONTAINER AND LABEL

IAW CFR29.1910.1200.

- DATE MANUFACTURED SHALL BE MARKED AND IDENTIFIED

CLEARLY ON EACH INDIVIDUAL UNIT’S LABEL, REGARDLESS OF ITS

INCLUSION IN BATCH NUMBERS.

- SHELF LIFE EXPIRATION DATE SHALL BE CLEARLY MARKED ON

EACH INDIVIDUAL UNIT, MUST HAVE 85 PERCENT OF SHELF LIFE

REMAINING UPON RECEIPT.

- 7 COPIES OF NEWEST MANUFACTURER’S SAFETY DATA SHEET

REQUIRED WITH MATERIAL.

- PLEASE PROVIDE CERTIFICATE OF COMPLIANCE AND CERTIFICATE

OF ANALYSIS IF APPLICABLE

FOB: Destination

NSN: 6830-HM-CN1-0495

MILSTRIP: N4215851222704

PURCHASE REQUEST NUMBER: N4215851213075

PSC CD: 6830

0021 6 Each N4215851223075

FFP

PART NAME -0.0625 RNG NBG SET

PART DESCRIPTION -3 150 ZN NA 0.0625 RNG NBG SET

PART NUMBER -FNWNBGZ1NAR6M

FOB: Destination

MILSTRIP: N4215851223075

PURCHASE REQUEST NUMBER: N4215851213075

0022 6 Each N4215851223076

FFP

PART NAME -2 CS 150 RF SO FLG

PART DESCRIPTION -2 CS 150 RF SO FLG

PART NUMBER -DRFSOFK

FOB: Destination

MILSTRIP: N4215851223076

PURCHASE REQUEST NUMBER: N4215851213075

0023 6 Each N4215851223077

FFP

PART NAME -0.0625 RNG NBG SET 2

PART DESCRIPTION -2 150 ZN NA 0.0625 RNG NBG SET

PART NUMBER -FNWNBGZ1NAR6K

FOB: Destination

MILSTRIP: N4215851223077

PURCHASE REQUEST NUMBER: N4215851213075

0024 6 Each N4215851223078

FFP

PART NAME -1 CS 150 RF SO FLG

PART DESCRIPTION -1 CS 150 RF SO FLG

PART NUMBER -DRFSOFG

FOB: Destination

MILSTRIP: N4215851223078

PURCHASE REQUEST NUMBER: N4215851213075

0025 6 Each N4215851223079

FFP

PART NAME -0.0625 RNG NBG SET

PART DESCRIPTION -1 150 ZN NA 0.0625 RNG NBG SET

PART NUMBER -FNWNBGZ1NAR6G

FOB: Destination

MILSTRIP: N4215851223079

PURCHASE REQUEST NUMBER: N4215851213075

0026 3 Each N4215851223080

FFP

PART NAME -5D 90 4.5 OD

PART DESCRIPTION -4 A106B 5D 90 4.5 OD

PART NUMBER -SP-T4405DA106B

FOB: Destination

MILSTRIP: N4215851223080

PURCHASE REQUEST NUMBER: N4215851213075

0027 3 Each N4215851223081

FFP

PART NAME -5D 90 3.5 OD

PART DESCRIPTION -3 A106B 5D 90 3.5 OD

PART NUMBER -SP-T4405DA106M

FOB: Destination

MILSTRIP: N4215851223081

PURCHASE REQUEST NUMBER: N4215851213075

0028 3 Each N4215851223082

FFP

PART NAME -5D 90 2.375 OD

PART DESCRIPTION -2 A106B 5D 90 2.375 OD

PART NUMBER -SP-T4405DA106K

FOB: Destination

MILSTRIP: N4215851223082

PURCHASE REQUEST NUMBER: N4215851213075

0029 3 Each N4215851223083

FFP

PART NAME -5D 90 1.315 OD

PART DESCRIPTION -1 A106B 5D 90 1.315 OD

PART NUMBER -SP-T4405DA106G

FOB: Destination

MILSTRIP: N4215851223083

PURCHASE REQUEST NUMBER: N4215851213075

0030 3 Each N4215851223084

FFP

PART NAME -3D 90 4.5 OD

PART DESCRIPTION -4 A106B 3D 90 4.5 OD

PART NUMBER -SP-DW3D90P

FOB: Destination

MILSTRIP: N4215851223084

PURCHASE REQUEST NUMBER: N4215851213075

0031 3 Each N4215851223085

FFP

PART NAME -3D 90 3.5 OD

PART DESCRIPTION -3 A106B 3D 90 3.5 OD

PART NUMBER -SP-DW3D90M

FOB: Destination

MILSTRIP: N4215851223085

PURCHASE REQUEST NUMBER: N4215851213075

0032 3 Each N4215851223086

FFP

PART NAME -3D 90 2.375 OD

PART DESCRIPTION -2 A106B 3D 90 2.375 OD

PART NUMBER -SP-DW3D90K

FOB: Destination

MILSTRIP: N4215851223086

PURCHASE REQUEST NUMBER: N4215851213075

0033 3 Each N4215851223087

FFP

PART NAME -3D 90 1.315 OD

PART DESCRIPTION -1 A106B 3D 90 1.315 OD

PART NUMBER -SP-DW3D90G

FOB: Destination

MILSTRIP: N4215851223087

PURCHASE REQUEST NUMBER: N4215851213075

0034 3 Each N4215851223088

FFP

PART NAME -4CS BW OS AND Y GATE VLV

PART DESCRIPTION -4 CS 150 BW OS AND Y GATE VLV

PART NUMBER -P1503IC8GXXXP

FOB: Destination

MILSTRIP: N4215851223088

PURCHASE REQUEST NUMBER: N4215851213075

0035 3 Each N4215851223089

FFP

PART NAME -3CS BW OS AND Y GATE VLV

PART DESCRIPTION -3 CS 150 BW OS AND Y GATE VLV

PART NUMBER -P1503IC8GXXXM

FOB: Destination

MILSTRIP: N4215851223089

PURCHASE REQUEST NUMBER: N4215851213075

0036 3 Each N4215851223090

FFP

PART NAME -2CS BW OS AND Y GATE VLV

PART DESCRIPTION -2 CS 150 BW OS AND Y GATE VLV

PART NUMBER -P1503IC8GXXXK

FOB: Destination

MILSTRIP: N4215851223090

PURCHASE REQUEST NUMBER: N4215851213075

PROJECT: Y99

0037 3 Each N4215851223091

FFP

PART NAME -1FS SW BB T8 GATEVLV

PART DESCRIPTION -1 FS 800 SW BB T8 GATE VLV BAA

PART NUMBER -PGA08SA58GBG

FOB: Destination

MILSTRIP: N4215851223091

PURCHASE REQUEST NUMBER: N4215851213075

0038 18 Each N4215851223092

FFP

PART NAME -4 F126 STD RSR CLMP

PART DESCRIPTION -4 F126 STD RSR CLMP

PART NUMBER -SP-CF126P

FOB: Destination

MILSTRIP: N4215851223092

PURCHASE REQUEST NUMBER: N4215851213075

0039 18 Each N4215851223093

FFP

PART NAME -3 CS BW OS AND Y GATE V

PART DESCRIPTION -3 CS 150 BW OS AND Y GATE VLV

PART NUMBER -SP-CF126M

FOB: Destination

MILSTRIP: N4215851223093

PURCHASE REQUEST NUMBER: N4215851213075

0040 18 Each N4215851223094

FFP

PART NAME -2 F126 STD RSR CLMP

PART DESCRIPTION -2 F126 STD RSR CLMP

PART NUMBER -SP-CF126K

FOB: Destination

MILSTRIP: N4215851223094

PURCHASE REQUEST NUMBER: N4215851213075

0041 18 Each N4215851233075

FFP

PART NAME -1 F126 STD RSR CLMP

PART DESCRIPTION -1 F126 STD RSR CLMP

PART NUMBER -SP-CF126G

FOB: Destination

MILSTRIP: N4215851233075

PURCHASE REQUEST NUMBER: N4215851213075

0042 300 Each N4215851233076

FFP

PART NAME -1-0.5 X 0.25 ZINC BOLT

PART DESCRIPTION -1-0.5 X 0.25 ZINC BOLT WITH NUTS-WSHRS

PART NUMBER -SP-FTHRDNBWJB

FOB: Destination

MILSTRIP: N4215851233076

PURCHASE REQUEST NUMBER: N4215851213075

0043 300 Each N4215851233077

FFP

PART NAME -1-0.5 X 0.375 ZINC BOLT

PART DESCRIPTION -1-0.5 X 0.375 ZINC BOLT WITH NUT-WSHR

PART NUMBER -SP-FTHRDNBWJC

FOB: Destination

MILSTRIP: N4215851233077

PURCHASE REQUEST NUMBER: N4215851213075

0044 300 Each N4215851233078

FFP

PART NAME -1-0.5 X 0.5 ZINC BOLT

PART DESCRIPTION -1-0.5 X 0.5 ZINC BOLT WITH NUT-WSHR

PART NUMBER -SP-FTHRDNBWJD

FOB: Destination

MILSTRIP: N4215851233078

PURCHASE REQUEST NUMBER: N4215851213075

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government 0012 Destination Government Destination Government 0013 Destination Government Destination Government 0014 Destination Government Destination Government 0015 Destination Government Destination Government 0016 Destination Government Destination Government 0017 Destination Government Destination Government 0018 Destination Government Destination Government 0019 Destination Government Destination Government 0020 Destination Government Destination Government 0021 Destination Government Destination Government 0022 Destination Government Destination Government 0023 Destination Government Destination Government 0024 Destination Government Destination Government 0025 Destination Government Destination Government 0026 Destination Government Destination Government 0027 Destination Government Destination Government 0028 Destination Government Destination Government 0029 Destination Government Destination Government 0030 Destination Government Destination Government 0031 Destination Government Destination Government 0032 Destination Government Destination Government 0033 Destination Government Destination Government 0034 Destination Government Destination Government 0035 Destination Government Destination Government 0036 Destination Government Destination Government 0037 Destination Government Destination Government 0038 Destination Government Destination Government 0039 Destination Government Destination Government 0040 Destination Government Destination Government 0041 Destination Government Destination Government 0042 Destination Government Destination Government 0043 Destination Government Destination Government 0044 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 20-JUN-2025 6 NORFOLK NAVAL SHIPYARD

NO POINT OF CONTACT (RECEIVING

DEPT)

RECEIVING OFFICER

BLDG 276

PORTSMOUTH VA 23709-5000

FOB: Destination

N42158

0002 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0003 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0004 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0005 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0006 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0007 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0008 20-JUN-2025 126 (SAME AS PREVIOUS LOCATION)

0009 20-JUN-2025 126 (SAME AS PREVIOUS LOCATION)

0010 20-JUN-2025 126 (SAME AS PREVIOUS LOCATION)

0011 20-JUN-2025 126 (SAME AS PREVIOUS LOCATION)

0012 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0013 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0014 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0015 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0016 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0017 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0018 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0019 20-JUN-2025 9 (SAME AS PREVIOUS LOCATION)

0020 20-JUN-2025 10 (SAME AS PREVIOUS LOCATION)

0021 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0022 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0023 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0024 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0025 20-JUN-2025 6 (SAME AS PREVIOUS LOCATION)

0026 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0027 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0028 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0029 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0030 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0031 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0032 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0033 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0034 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0035 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0036 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0037 20-JUN-2025 3 (SAME AS PREVIOUS LOCATION)

0038 20-JUN-2025 18 (SAME AS PREVIOUS LOCATION)

0039 20-JUN-2025 18 (SAME AS PREVIOUS LOCATION)

0040 20-JUN-2025 18 (SAME AS PREVIOUS LOCATION)

0041 20-JUN-2025 18 (SAME AS PREVIOUS LOCATION)

0042 20-JUN-2025 300 (SAME AS PREVIOUS LOCATION)

0043 20-JUN-2025 300 (SAME AS PREVIOUS LOCATION)

0044 20-JUN-2025 300 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management NOV 2024 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.211-14 Notice Of Priority Rating For National Defense, Emergency Preparedness, and Energy Program Use

APR 2008

52.212-1 Instructions to Offerors--Commercial Products and Commercial Services

SEP 2023

52.219-1 Alt I Small Business Program Representations (FEB 2024) Alternate I

FEB 2024

52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.242-15 Stop-Work Order AUG 1989 52.243-1 Changes--Fixed Price AUG 1987 52.246-1 Contractor Inspection Requirements APR 1984 52.247-34 F.O.B. Destination JAN 1991 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023 252.204-7017 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services -- Representation

MAY 2021

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.204-7024 Notice on the Use of the Supplier Performance Risk System MAR 2023 252.211-7003 Item Unique Identification and Valuation JAN 2023 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JAN 2023 252.225-7000 Buy American--Balance Of Payments Program Certificate FEB 2024 252.225-7060 Prohibition on Certain Procurements from the Xinjiang

Uyghur Autonomous Region

JUN 2023

252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.239-7017 Notice of Supply Chain Risk DEC 2022 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Products or Commercial

Services

NOV 2023

252.246-7003 Notification of Potential Safety Issues JAN 2023 252.247-7023 Transportation of Supplies by Sea OCT 2024

CLAUSES INCORPORATED BY FULL TEXT

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015)

(a) Definitions. As used in this clause--

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Subsidiary means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the Government may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary. The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause.

(c) Exceptions to this prohibition are located at 9.108-2.

(d) In the event the Contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the Contractor shall give written notice to the Contracting Officer within five business days from the date of the inversion event.

(End of clause)

52.211-15 DEFENSE PRIORITY AND ALLOCATION REQUIREMENTS (APR 2008)

This is a rated order certified for national defense, emergency preparedness, and energy program use, and the Contractor shall follow all the requirements of the Defense Priorities and Allocations System regulation (15 CFR 700).

(End of clause)

52.211-17 DELIVERY OF EXCESS QUANTITIES (SEP 1989)

The Contractor is responsible for the delivery of each item quantity within allowable variations, if any. If the Contractor delivers and the Government receives quantities of any item in excess of the quantity called for (after considering any allowable variation in quantity), such excess quantities will be treated as being delivered for the convenience of the Contractor. The Government may retain such excess quantities up to $250 in value without compensating the Contractor therefor, and the Contractor waives all right, title, or interests therein. Quantities in excess of $250 will, at the option of the Government, either be returned at the Contractor's expense or retained and paid for by the Government at the contract unit price.

52.212-2 EVALUATION--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (NOV 2021)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

i. Technical capability of the item offered meets the Government requirement

ii. Price

iii. Delivery

iv. Supplier Performance Risk System (SPRS) and Federal Awardee Performance and

Integrity System (FAPPIS) will be reviewed to determine vendor responsibility The relative order of importance of the evaluation factors are in descending order of importance. Technical capability and price when combined are evaluated as being substantially more significant than all other factors combined.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (MAY 2024) ALTERNATE I (FEB 2024)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (v) of this provision.

(a) Definitions. As used in this provision --

"Covered telecommunications equipment or services" has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

"Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

"Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

"Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

"Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

"Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

"Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

"Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor.

"Reasonable inquiry" has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

"Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

"Sensitive technology"--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

"Service-disabled veteran-owned small business (SDVOSB) concern" means a small business concern--

(1)(i) Not less than 51 percent of which is owned and controlled by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran; or

(2) A small business concern eligible under the SDVOSB Program in accordance with 13 CFR part 128 (see subpart 19.14).

(3) Service-disabled veteran, as used in this definition, means a veteran as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16), and who is registered in the Beneficiary Identification and Records Locator Subsystem, or successor system that is maintained by the Department of Veterans Affairs' Veterans Benefits Administration, as a service-disabled veteran.

"Service-disabled veteran-owned small business (SDVOSB) concern eligible under the SDVOSB Program" means an SDVOSB concern that--

(1) Effective January 1, 2024, is designated in the System for Award Management (SAM) as certified by the Small Business Administration (SBA) in accordance with 13 CFR 128.300; or

(2) Has represented that it is an SDVOSB concern in SAM and submitted a complete application for certification to SBA on or before December 31, 2023.

"Service-disabled veteran-owned small business (SDVOSB) Program" means a program that authorizes contracting officers to limit competition, including award on a sole-source basis, to SDVOSB concerns eligible under the SDVOSB Program.

"Small business concern"--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part…