Solicitation Released- W15QKN25QA026.pdf

PDF 3 MB Posted Jan 6, 2025

Attached to: Snow & Ice Removal Services Supporting U. S. Army Reserve Center in Beaver, WV
Solicitation number: W15QKN-25-Q-A026
Issued by: Department of the Army Materiel Command Contracting Command Picatinny Arsenal

About this file

Written by GovTribe AI · Jan 7, 2025

This is a Request for Quote (RFQ) solicitation document for snow and ice removal services at the Cornelius H. Charlton U.S. Army Reserve Center in Beaver, WV. The solicitation (W15QKN-25-Q-A026) is issued by the Department of the Army Materiel Command Contracting Command Picatinny Arsenal using FAR Part 12 and 13 procedures.

The contract will be a single firm-fixed-price requirements contract with a 12-month base period and four 12-month option periods. The work includes snow removal for accumulations of 3"-6", 6"-10", 10"-14", and 14"+, as well as ice melt/sand services and sidewalk clearing. This is a 100% small business set-aside opportunity. Quotes are due by the date specified in Block 8 of the SF1449 form. A site visit is highly encouraged and available on January 9, 2025 (primary) and January 10, 2025 (alternate) from 10:00 AM to 12:00 PM EST. Questions are due by 1:00 PM EST on January 13, 2025. Required insurance includes workers compensation ($100,000), general liability ($500,000 per occurrence), and automobile liability ($200,000 per person/$500,000 per occurrence for bodily injury, $20,000 per occurrence for property damage).

View the file

Other files

File	Type	Posted
SCA WD No. 2015-4295 Rev. 25 Dated Jul 22 2024.docx	DOCX document	Jan 6, 2025
WV002_SNOWREMOVALMAP_20240103-CUI.pdf	PDF	Jan 6, 2025
Beaver WV002PWS-Snow Removal-FY25-Version 1-No CMR.docx	DOCX document	Jan 6, 2025

On GovTribe

Work with this file

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

calls)

Solicitation/Contract Form Continuation

FY25 Snow and Ice Removal Services Requirement Supporting Facility WV002 in Beaver, WV

Instruction to Offerors-W15QKN-25-Q-A026

THIS REQUIREMENT IS SET-ASIDE 100% FOR SMALL BUSINESS CONCERNS

THIS REQUIREMENT IS SUBJECT TO THE AVAILABILITY OF FUNDS

IN ACCORDANCE WITH FAR 52.232-18

This requirement is being solicited, utilizing the procedures set forth in FAR Part 12, Acquisition of Commercial Items and FAR Part 13, Simplified Acquisition Procedures.

1. The purpose of this solicitation is to procure Snow and Ice Removal services in support of the 99th Readiness Division. Services shall be performed at the Cornelius H. Charlton U.S. Army Reserve Center (USARC) (Facility WV002), 201 Industrial Park Road, Beaver WV 25813-9780.

2. The Government intends to award a single, firm-fixed-price (FFP) requirements contract. The period of performance for this effort shall be a 12-month base period and four (4), 12-month option periods from date of award.

3. The Offeror must have an "Active" registration in System for Award Management (SAM) to be considered for award. To obtain information on SAM or to register with SAM visit the web site at: https://www.sam.gov/.

4. See Federal Acquisition Regulation (FAR) Clause 52.212-1,"Instructions to Offerors - Commercial Items" and FAR 52.212-1, Addendum for additional information.

5. See FAR Clause 52.212-2, "Evaluation -- Commercial Items" and FAR 52.212-2, Addendum for additional information and evaluation criteria.

6. See FAR provision 52.204-24, "Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment," FAR clause 52.204-25, "Prohibition on Contracting for Certain Telecommunications and

Video Surveillance Service or Equipment" and FAR provision52.204-26, "Covered Telecommunications Equipment or Services- Representation." As a result of interim FAR Rule 2019-0009, published on 14 July 2020, and effective on 13 August 2020, Section 889(a)(1)(B) Prohibition on Contracting with Entities Using Certain Telecommunications and Video Surveillance Services or Equipment Clauses, these provision and clauses are

W15QKN25QA026

https://www.sam.gov/ included within this solicitation in full text. When submitting a response to this solicitation, FAR provision 52.204-24 and FAR provision 52.204-26 shall be completed and included by the Offeror.

7. A site visit is highly encouraged. All requests to attend a site visits shall be submitted via e-mail at least 24 hours prior to the scheduled site visit date and time to the following: Jason M. Belcher, Regional Facilities Operations Specialist via e-mail: jason.m.

belcher.civ@army.mil, Amy M. Brooks, Area Facilities Operations Specialist via e-mail: , Amber L. Mears, amy.m.brooks.ctr@army.mil Contracting Officer via e-mail: and Nancy M. Zeng, Contract Specialist via e-mail: . amber.l.mears.civ@army.mil Nancy.m.zeng.civ@army.mil Offerors are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

Site Visits are available at the following date(s)/time(s):

Address:

Cornelius H. Charlton USARC, 201 Industrial Park Road, Beaver WV 25813-9780

a. Primary Site Visit:

i. 09 January 2025, Thursday 10:00AM EST through 12:00PM EST (Eastern Standard Time)

b. Alternate Site Visit:

i. 10 January 2025, Friday 10:00AM EST through 12:00PM EST

8. Questions regarding this solicitation shall be submitted in writing via e-mail no later than 1:00 PM EST on 13 2025 January to both, Nancy M. Zeng, Contract Specialist, e-mail: nancy.m.zeng.civ@army.mil and Amber L Mears, Contracting Officer, e-mail: amber.l.mears.civ@army.mil.

9. Completing a Quote for Submittal:

and(a) Quotes are due no later than the date and time listed in Standard Form (SF) 1449, Block 8 shall be submitted via email to , and BOTH: Nancy Zeng, Contract Specialist at nancy.m.zeng.civ@army.mil Amber Mears, Contracting Officer at amber.l.mears.

. Updates to this solicitation will be civ@army.mil posted on the SAM website (www.sam.gov/). Local time for this requirement is EST.

No other forms of delivery proposal will be accepted or reviewed by the Government other than those delivered by means expressed in Solicitation W15QKN-25-Q-A026 (SUCH AS E-MAIL DELIVERY ONLY.)

(b) Offeror(s) shall provide with their offer, the name, title, address, email address and telephone number of the company/division point of contact regarding business decisions made with respect to the proposal and who can contractually obligate the company.

W15QKN25QA026

.(c) Offeror(s) shall submit a signed Standard Form (SF) 1449 (Blocks 30a through 30c)

(d) Offeror(s) shall provide a price for all FFP Contract Line Item Number (CLIN) for the base period and option periods on the SF 1449 Continuation Sheets of the solicitation.

(e) Pricing for each CLIN shall be submitted in the proper format. The proper format consists of QUANTITY times (x) UNIT PRICE equals (=) AMOUNT/NET AMOUNT. In the event there isa discrepancy in the calculation, the

UNIT PRICE will be held to the intended price multiplied by the QUANTITY. If the offeror shows only the AMOUNT/NET AMOUNT, but fails to enter a UNIT PRICE, the AMOUNT/NETAMOUNT divided (/) by thew QUANTITY will be held to be the intended price.

(f) Offerors shall submit with their offer, their valid Certificate of Insurance, as prime contractor, in accordance with the requirements and applicable insurance amounts set forth within the solicitation at FAR clause 52.228-5, "Insurance- Work on a Government Installation," and "Insurance Requirements."

(g) Offerors shall provide their UEID Number, CAGE Code, Federal Tax Identification Number and any small business preference or socioeconomic designations (8a Certified, HUBZone Certified, WOSB, etc.) that are applicable to this NAICS Code stated at .Block10 of this SF 1449

(h) Offeror shall complete all "fill-ins" in provisions and clauses that apply and include with submission response to this solicitation.

(i) Failure to provide any applicable information required by this solicitation may result in the Offeror being deemed non-responsive and ineligible for award.

10.All services shall be performed in accordance with the Performance Work Statement (PWS).

11.All offers shall remain valid for 120 calendar days.

12.Attachment(s):

Attachment0001 - PWS-Snow Removal-FY25-Version 1-No CMR

Attachment0002 - WV002_SNOWREMOVALMAP_JAN2024

Attachment 0003 - SCA Wage Determination 2015-4295 - Rev 25 - Dated 22 July 2024

SOLICITATION ADMINISTRATION

1. Inquiries concerning all contractual actions after award shall be directed first to the Contract Specialist. In my absence, please .contact the Contracting Officer

2. CHANGES: The will incorporate all changes and other administrative actions to the Contract Specialist contract as directed and authorized by the Contracting Officer.

3. POINTS OF CONTACT:

Contracting Officer

Amber L. Mears

Phone: 609-562-2567

Email: Amber.l.mears.civ@army.mil

Contract Specialist

Nancy M. Zeng

Phone: 609-562-5165

Email: nancy.m.zeng.civ@army.mil

Government Point of Contact

Regional Facility Operations Specialist (RFOS)

Jason M. Belcher

Phone: 919-802-7094

Email: jason.m.belcher.civ@army.mil

Area Facility Operations Specialist (AFOS)

Amy M. Brooks

Phone: 407-350-0048

Email: amy.m.brooks.ctr@army.mil

SERVICE LOCATION:

Cornelius H. Charlton U.S. Army Reserve Center mailto:Amber.l.mears.civ@army.mil mailto:nancy.m.zeng.civ@army.mil mailto:jason.m.belcher.civ@army.mil mailto:amy.m.brooks.ctr@army.mil

201 Industrial Park Road

Beaver WV 25813-9780

PERIOD OF PERFORMANCE:

12-monthbase period and four, 12-month option periods from date of contract award.

REQUIRED INSURANCE

INSURANCEREQUIREMENT:

Contractor shall comply with insurance requirements listed in FAR Subpart 28.307-2 as follows:

Workers Compensation and Employer's Liability

-At least $100,000 coverage

General Liability

-Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least $500,000 per occurrence.

Automobile Liability:

-Shall provide automobile liability insurance written on the comprehensive form policy

-At least $200,000 per person for bodily injury

-$500,000 per occurrence for bodily injury

- $20,000 per occurrence for property damage

HQ AMC LEVELPROTEST

HQ AMC-level Protest

If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible contracting officer.

However, you can also protest to Headquarters, AMC. The HQ, AMC-Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with the General Accounting Office or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. The AMC protest decision goal is to resolve protests within 20 working days from filing. To be timely, protests must be filed within the periods specified in FAR 33.103.

Send protests (other than protests to the contracting officer) to:

Address:

Headquarters U.S. Army Materiel Command

Office of Command Counsel-Deputy Command Counsel

4400 Martin Road

Rm: A6SE040.001

Redstone Arsenal, AL 35898-5000

Fax: (256) 450-8840

Email: usarmy.redstone.usamc.mbx.protests@army.mil

The AMC-level protest procedures are found at:

Web Address: http://www.amc.army.mil/amc/commandcounsel.html

If Internet access is not available contact the contracting officer or HQ, AMC to obtain the AMC-Level Protest Procedures.

DISCLOSOURE OF UNIT PRICE INFO

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices in response to any request under the Freedom of Information Act, 5 USC 552.Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such posting prior to submission of initial proposals.

Continuation of Supplies or Services and Prices/Costs

Additional Information/Notes

Item Supplies/Service Estimated Quantity

Unit Unit Price Amount

BASE YEAR SNOW REMOVAL SERVICES 3" -

6" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

8 Each

BASE YEAR SNOW REMOVAL SERVICES 6" -

10" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

5 Each

BASE YEAR SNOW REMOVAL SERVICES 10"

- 14" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

3 Each

BASE YEAR SNOW REMOVAL SERVICES 14"

+ SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and

0004 transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

2 Each

BASE YEAR ICE MELT AND SAND SERVICES

SUPPORTING FACILITY WV002 IN BEAVER,

WV.

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H. Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

BASE YEAR CLEAR SIDEWALKS SERVICES

SUPPORTING FACILITY WV002 IN BEAVER,

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 1-SNOW REMOVAL SERVICES

3" - 6" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

8 Each

Option Year 1 SNOW REMOVAL SERVICES

6" - 10" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and

Option Line Item transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

5 Each

Option Line Item

Option Year 1 SNOW REMOVAL SERVICES

10" - 14" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

3 Each

Option Line Item

Option Year 1 SNOW REMOVAL SERVICES

14" + SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Option Year 1 ICE MELT AND SAND

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Year 1 CLEAR SIDEWALKS

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 2 SNOW REMOVAL SERVICES

3" - 6" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

8 Each

Option Line Item

Option Year 2 SNOW REMOVAL SERVICES

6" - 10" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

5 Each

Option Line Item

Option Year 2 SNOW REMOVAL SERVICES

10" - 14" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

3 Each

Option Year 2 SNOW REMOVAL SERVICES

14" + SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Option Year 2 ICE MELT AND SAND

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 2 CLEAR SIDEWALKS

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 3 SNOW REMOVAL SERVICES

3" - 6" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

8 Each

Option Year 3 SNOW REMOVAL SERVICES

6" - 10" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

5 Each

Option Line Item

Option Year 3 SNOW REMOVAL SERVICES

10" - 14" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

3 Each

Option Line Item

Option Year 3 SNOW REMOVAL SERVICES

14" + SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Option Year 3 ICE MELT AND SAND

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Year 3 CLEAR SIDEWALKS

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 4 SNOW REMOVAL SERVICES

3" - 6" SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

8 Each

Option Line Item

Option Year 4 SNOW REMOVAL SERVICES

6" - 10" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

5 Each

Option Line Item

Option Year 4 SNOW REMOVAL SERVICES

10" - 14" SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

3 Each

Option Year 4 SNOW REMOVAL SERVICES

14" + SUPPORTING FACILITY WV002 IN

BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

2 Each

Option Line Item

Option Year 4 ICE MELT AND SAND

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Option Line Item

Option Year 4 CLEAR SIDEWALKS

SERVICES SUPPORTING FACILITY WV002

IN BEAVER, WV

Contractor shall furnish all plant, labor, materials, equipment, supervision and transportation necessary to provide snow maintenance at Cornelius H.

Charlton U.S. Army Reserve Center at 201 Industrial Park Road, Beaver, WV 25813-9307 in accordance with the Performance Work Statement.

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

20 Each

Continuation of Description

Requirements 99th Readiness Division Region C09 NEW SNOW AND ICE REMOVAL SERVICE REQUIREMENT SUPPORTING FACILITY WV002 in Beaver, WV 25813-9307.

Place of Performance DODAAC: W81GMK Period of Performance: 13 DEC 2024 - 12 DEC 2029 New Base Year + 4 Option Years.

COR POC: Jason M Belcher, Phone No. 919-802-7094

Product Service Code: S218