Solicitation - FA469023Q0012.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

Created On: 26 Apr 2023, 06:39 AM Mountain Standard Time

Solicitation/Contract Form

SPORTS OFFICIAL SERVICES

Proposal Identifier: FA469023Q0012 Date: 26 Apr 2023

FA469023Q0012

Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 Base Sports Officials - Games 01 June 2023 through 30 September 2023

0001AA

Softball Games - one (1) official per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

0001AB

Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

0002 Base Sports Officials - Championship Games 01 June 2023 through 30 September 2023

0002AA

Championship Softball Games - two (2) officials

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

0002AB

Championship Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

Option Year I Sports Officials - Games 01 October 23 through 30 September 2024

Option Line Item

1001AA

Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

1001AB

Soccer Indoor/Outdoor - two (2) officials per game

Product Service Code: G003 65 Each

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

Option Line Item

1001AC

Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

1001AD

Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

1001AE

Softball Games - one (1) official per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

Option Year I Sports Officials - Championship Games 01 October 23 through 30 September 2024

Option Line Item

1002AA

Championship Basketball Games - three (3) officials per game

Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

1002AB

Championship Soccer Indoor/Outdoor Games - two (2) officials per game

Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

1002AC

Championship Football Games - three (3) officials per game

Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

1002AD

Championship Volleyball Games - two (2) officials per game

Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

1002AE

Championship Softball Games - two (2) officials per game

Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

Option Year II Sports Officials 01 October 24 through 30 September 2025

Option Line Item

2001AA

Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

2001AB

Soccer Indoor/Outdoor - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

2001AC

Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

2001AD

Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

2001AE

Softball Games - one (1) official per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

Option Year II Sports Officials 01 October 24 through 30 September 2025

Option Line Item

2002AA

Championship Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

2002AB

Championship Soccer Indoor/Outdoor Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

2002AC

Championship Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

2002AD

Championship Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

2002AE

Championship Softball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

Option Year III Sports Officials 01 October 25 through 30 September 2026

Option Line Item

3001AA

Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

3001AB

Soccer Indoor/Outdoor - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

3001AC

Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

3001AD

Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

3001AE

Softball Games - one (1) official per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

Option Year III Sports Officials

01 October 25 through 30 September 2026

3002AA

Championship Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

3002AB

Championship Soccer Indoor/Outdoor Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

3002AC

Championship Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

3002AD

Championship Volleyball Games - two (2) officials per game

Product Service Code: G003 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

3002AE

Championship Softball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

Option Year IV Sports Officials 01 October 26 through 30 September 2027

Option Line Item

4001AA

Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

4001AB

Soccer Indoor/Outdoor - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

4001AC

Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

4001AD

Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

4001AE

Softball Games - one (1) official per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

65 Each

Option Line Item

Option Year IV Sports Officials 01 October 26 through 30 September 2027

Option Line Item

4002AA

Championship Basketball Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

4002AB

Championship Soccer Indoor/Outdoor Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

4002AC

Championship Football Games - three (3) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

4002AD

Championship Volleyball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Option Line Item

4002AE

Championship Softball Games - two (2) officials per game

Product Service Code: G003 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

14 Each

Description/Specifications/Statement of Work

Requirements

SPORTS OFFICIAL SERVICES

Packaging and Marking

Inspection and Acceptance

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished Property. Apr 2012

Overall Contract Inspection/Acceptance Locations

0001AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mmil Telephone: 605-385-2263

0001AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

0002AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

0002AB

Inspection and Acceptance Location

Both

Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1001AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2236

Option Line Item

1001AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-3326

Option Line Item

1001AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artheron Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

1001AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1001AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1002AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1002AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton

Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1002AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1002AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

1002AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2001AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2001AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

Option Line Item

2001AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2001AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2001AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9

CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2002AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2002AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2002AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2002AD

Inspection and Acceptance Location

Both

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

2002AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

Option Line Item

3001AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3001AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

3001AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3001AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3001AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3002AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton

Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3002AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3002AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3002AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

3002AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

Option Line Item

4001AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4001AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

Option Line Item

4001AC

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4001AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9

CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4001AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4002AA

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4002AB

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4002AC

Inspection and Acceptance Location

Both

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4002AD

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.3@us.af.mil Telephone: 605-385-2263

Option Line Item

4002AE

Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1V3J9 CountryCode: USA

28 FSS FSVC

AF BPN NO MILSBILLS PROCESSES, 2838 ARNOLD DR

ELLSWORTH AFB, SD 57706-4815

UNITED STATES

Sarah Artherton Email: Sarah.Artherton.2@us.af.mil Telephone: 605-385-2263

Deliveries or Performance

Contractor Destination

Line Item Delivery Schedule Quantity Address and POC

0001AA

Period of Performance From 01 Jun 2023 To 30 Sep 2023

65 Each

0001AB

Period of Performance From 01 Jun 2023 To 30 Sep 2023

65 Each

0002AA

Period of Performance From 01 Jun 2023 To 30 Sep 2023

14 Each

0002AB

Period of Performance From 01 Jun 2023 To 30 Sep 2023

14 Each

Option Line Item

1001AA

Period of Performance From 01 Oct 2023 To 30 Sep 2024

65 Each

Option Line Item

1001AB

Period of Performance From 01 Oct 2023 To 30 Sep 2024

65 Each

Option Line Item

1001AC

Period of Performance From 01 Oct 2023 To 30 Sep 2024

65 Each

Option Line Item

1001AD

Period of Performance From 01 Oct 2023 To 30 Sep 2024

65 Each

Option Line Item

1001AE

Period of Performance From 01 Oct 2023 To 30 Sep 2024

65 Each

1002AA

Period of Performance From 01 Oct 2023 To 30 Sep 2024

14 Each

Option Line Item

1002AB

Period of Performance From 01 Oct 2023 To 30 Sep 2024

14 Each

Option Line Item

1002AC

Period of Performance From 01 Oct 2023 To 30 Sep 2024

14 Each

Option Line Item

1002AD

Period of Performance From 01 Oct 2023 To 30 Sep 2024

14 Each

Option Line Item

1002AE

Period of Performance From 01 Oct 2023 To 30 Sep 2024

14 Each

Option Line Item

2001AA

Period of Performance From 01 Oct 2024 To 30 Sep 2025

65 Each

Option Line Item

2001AB

Period of Performance From 01 Oct 2024 To 30 Sep 2025

65 Each

Option Line Item

2001AC

Period of Performance From 01 Oct 2024 To 30 Sep 2025

65 Each

Option Line Item

2001AD

Period of Performance From 01 Oct 2024 To 30 Sep 2025

65 Each

Option Line Item

2001AE

Period of Performance From 01 Oct 2024 To 30 Sep 2025

65 Each

Period of Performance From

65 Each

2002AA

01 Oct 2024 To 30 Sep 2025

Option Line Item

2002AB

Period of Performance From 01 Oct 2024 To 30 Sep 2025

14 Each

Option Line Item

2002AC

Period of Performance From 01 Oct 2024 To 30 Sep 2025

14 Each

Option Line Item

2002AD

Period of Performance From 01 Oct 2024 To 30 Sep 2025

14 Each

Option Line Item

2002AE

Period of Performance From 01 Oct 2024 To 30 Sep 2025

14 Each

Option Line Item

3001AA

Period of Performance From 01 Oct 2025 To 30 Sep 2026

65 Each

Option Line Item

3001AB

Period of Performance From 01 Oct 2025 To 30 Sep 2026

65 Each

Option Line Item

3001AC

Period of Performance From 01 Oct 2025 To 30 Sep 2026

65 Each

Option Line Item

3001AD

Period of Performance From 01 Oct 2025 To 30 Sep 2026

65 Each

Option Line Item

3001AE

Period of Performance From 01 Oct 2025 To 30 Sep 2026

65 Each

Option Line Item

3002AA

Period of Performance From 01 Oct 2025

14 Each

To 30 Sep 2026

Option Line Item

3002AB

Period of Performance From 01 Oct 2025 To 30 Sep 2026

14 Each

Option Line Item

3002AC

Period of Performance From 01 Oct 2025 To 30 Sep 2026

14 Each

Option Line Item

3002AD

Period of Performance From 01 Oct 2025 To 30 Sep 2026

14 Each

Option Line Item

3002AE

Period of Performance From 01 Oct 2025 To 30 Sep 2026

14 Each

Option Line Item

4001AA

Period of Performance From 01 Oct 2026 To 30 Sep 2027

65 Each

Option Line Item

4001AB

Period of Performance From 01 Oct 2026 To 30 Sep 2027

65 Each

Option Line Item

4001AC

Period of Performance From 30 Oct 2026 To 30 Sep 2027

65 Each

Option Line Item

4001AD

Period of Performance From 31 Oct 2026 To 30 Sep 2027

65 Each

Option Line Item

4001AE

Period of Performance From 01 Oct 2026 To 30 Sep 2027

65 Each

Option Line Item

4002AA

Period of Performance From 01 Oct 2026 To 30 Sep 2027

14 Each

4002AB

Period of Performance From 01 Oct 2026 To 30 Sep 2027

14 Each

Option Line Item

4002AC

Period of Performance From 01 Oct 2026 To 30 Sep 2027

14 Each

Option Line Item

4002AD

Period of Performance From 01 Oct 2026 To 30 Sep 2027

14 Each

Option Line Item

4002AE

Period of Performance From 01 Oct 2026 To 30 Sep 2027

14 Each

Contract Administration Data

Number Title Effective Date 252.204-7006 Billing Instructions. Oct 2005 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. Jan 2023

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF payment instructions.

WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

N/A

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

2 in 1

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF Document routing.

when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F1V3J9

Issue By DoDAAC FA4690

Admin DoDAAC FA4690

Inspect By DoDAAC F1V3J9

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) F1V3J9

Service Acceptor (DoDAAC) F1V3J9

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Amanda M. McGovern at Amanda.McGovern.1@us.af.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

252.232-7007 Limitation of Government's Obligation. Apr 2014

As prescribed in 232.706-70, use the following clause:

LIMITATION OF GOVERNMENT'S OBLIGATION (APR 2014)

(a) Contract line item(s) is/are incrementally funded. For this/these item(s), the sum of $ [Contracting Officer insert after negotiations] of the total price is presently available for payment and allotted to this contract. An allotment schedule [Contracting Officer insert after negotiations] is set forth in paragraph (j) of this clause.

(b) For item(s) identified in paragraph (a) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of those item(s) for the Government's convenience, approximates the total amount currently allotted to the contract. The Contractor is not authorized to continue work on those item(s) beyond that point. The Government will not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for those item(s) regardless of anything to the contrary in the clause entitled "Termination for Convenience of the Government." As used in this clause, the total amount payable by the Government in the event of termination of applicable contract line item(s) for convenience includes costs, profit, and estimated termination settlement costs for those item(s).

(c) Notwithstanding the dates specified in the allotment schedule in paragraph (j) of this clause, the Contractor will notify the Contracting Officer in writing at least ninety days prior to the date when, in the Contractor's best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 85 percent of the total amount then allotted to the contract for performance of the applicable item(s). The notification will state (1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of applicable line items up to the next scheduled date for allotment of funds identified in paragraph (j) of this clause, or to a mutually agreed upon substitute date. The notification will also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of the item(s) funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (j) of this clause or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor's notification, or by an agreed substitute date, the Contracting Officer will terminate any item(s) for which additional funds have not been allotted, pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(d) When additional funds are allotted for continued performance of the contract line item(s) identified in paragraph (a) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraphs (b) through (d) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly.

(e) If, solely by reason of failure of the Government to allot additional funds, by the dates indicated below, in amounts sufficient for timely performance of the contract line item(s) identified in paragraph (a) of this clause, the Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the item(s), or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder will be a dispute concerning a question of fact within the meaning of the clause entitled "Disputes."

(f) The Government may at any time prior to termination allot additional funds for the performance of the contract line item(s) identified in paragraph (a) of this clause.

(g) The termination provisions of this clause do not limit the rights of the Government under the clause entitled "Default." The provisions of this clause are limited to the work and allotment of funds for the contract line item(s) set forth in paragraph (a) of this clause. This clause no longer applies once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (d) and (e) of this clause.

(h) Nothing in this clause affects the right of the Government to terminate this contract pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(i) Nothing in this clause shall be construed as authorization of voluntary services whose acceptance is otherwise prohibited under 31 U.S.C.

1342.

(j) The parties contemplate that the Government will allot funds to this contract in accordance with the following schedule:

On execution of contract $ 15000

(month) (day), (year) $ ____

(month) (day), (year) $ ____

(month) (day), (year) $ ____

(End of clause)

Special Contract Requirements

Contract Clauses

5352.201-9101 AFGSC Ombudsman Oct 2019

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, for AFGSC (Air Force Global Strike Command) acquisitions please contact the Director of Contracts, Air Force Installation Contracting Center, Operating Location - Global Strike (AFICC/KG OL-GSC) via the following e-mail workflow address: ig.afica_kg.workflow@us.af.mil. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the contracting officer.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.212-4 Contract Terms and Conditions-Commercial Products and Commercial Services. Dec 2022 52.223-5 Pollution Prevention and Right-to-Know Information. May 2011 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Nov 2021 52.245-1 Government Property. Sep 2021

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. Jan 2023 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. Jan 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.211-7007 Reporting of Government-Furnished Property. Mar 2022 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.232-7010 Levies on Contract Payments. Dec 2006

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

Jan 2023

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. Jan 2023 252.243-7002 Requests for Equitable Adjustment. Dec 2022 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Jan 2023 252.245-7002 Reporting Loss of Government Property Jan 2021 252.245-7003 Contractor Property Management System Administration Apr 2012

FAR Clauses Incorporated by Full Text

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders-Commercial Products and Commercial Services. Dec 2022

As prescribed in , insert the following clause:12.301(b)(4)

CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES (DEC 2022)

The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by (a) reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (section 743 of Division E, (1) (JAN 2017) Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other (2) Covered Entities (Section 1634 of Pub. L. 115-91).(NOV 2021)

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (3) (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

52.209-10, Prohibition on Contracting with Inverted Domestic Corporations .(4) (NOV 2015)

52.233-3, Protest After Award (31 U.S.C. 3553).(5) (AUG 1996)

52.233-4, Applicable Law for Breach of Contract Claim (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).(6) (OCT 2004)

The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in (b) this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[ .]Contracting Officer check as appropriate

52.203-6, Restrictions on Subcontractor Sales to the Government with (41 U.S.C. 4704 and [ ] (1) (JUN 2020), Alternate I (NOV 2021) 10 U.

S.C. 4655).

52.203-13, Contractor Code of Business Ethics and Conduct (41 U.S.C. 3509)). [X] (2) (NOV 2021)

52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Section 1553 of Pub. [X] (3) (JUN 2010)

L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Pub. L. 109-282) ( 31 U.S. [ ] (4) (JUN 2020)

C. 6101 note).

[Reserved]. [ ] (5)

52.204-14, Service Contract Reporting Requirements (Pub. L. 111-117, section 743 of Div. C). [ ] (6) (OCT 2016)

52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Pub. L. 111-117, section 743 of [ ] (7) (OCT 2016)

Div. C).

52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for [X] (8)

Debarment. (31 U.S.C. 6101 note).(NOV 2021)

52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (41 U.S.C. 2313). [X] (9) (OCT 2018)

[Reserved]. [ ] (10)

52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award ( ) (15 U.S.C. 657a). [ ] (11) OCT 2022

52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns ( ) (if the offeror elects to waive [ ] (12) OCT 2022 the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[Reserved] [ ] (13)

[X] (14) 52.219-6, Notice of Total Small Business Set-Aside (15 U.S.C. 644).(i) (NOV 2020)

Alternate I of 52.219-6. [ ] (ii) (MAR 2020)

[ ] (15) 52.219-7, Notice of Partial Small Business Set-Aside (15 U.S.C. 644).(i) (NOV 2020)

Alternate I of 52.219-7. [ ] (ii) (MAR 2020)

52.219-8, Utilization of Small Business Concerns ( ) (15 U.S.C. 637(d)(2) and (3)). [X] (16) OCT 2022

[ ] (17) 52.219-9, Small Business Subcontracting Plan ( ) (15 U.S.C. 637(d)(4)).(i) OCT 2022

Alternate I of 52.219-9. [ ] (ii) (NOV 2016)

Alternate II of 52.219-9. [ ] (iii) (NOV 2016)

Alternate III of 52.219-9. [ ] (iv) (JUN 2020)

Alternate IV of 52.219-9. [ ] (v) (SEP 2021)

[ ] (18) 52.219-13, Notice of Set-Aside of Orders (15 U.S.C. 644(r)).(i) (MAR 2020)

Alternate I of 52.219-13. [ ] (ii) (MAR 2020)

52.219-14, Limitations on Subcontracting ( ) (15 U.S.C. 637s). [ ] (19) OCT 2022

52.219-16, Liquidated Damages-Subcontracting Plan (15 U.S.C. 637(d)(4)(F)(i)). [ ] (20) (SEP 2021)

52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside ( ) (15 U.S.C. 657f). [ ] (21) OCT 2022

[ ] (22) 52.219-28, Post Award Small Business Program Rerepresentation ( ) (15 U.S.C. 632(a)(2)).(i) OCT 2022

Alternate I of 52.219-28. [ ] (ii) (MAR 2020)

52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns [ ] (23)

( ) (15 U.S.C. 637(m)).OCT 2022

52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women- [ ] (24)

Owned Small Business Program ( ) (15 U.S.C. 637(m)).OCT 2022

52.219-32, Orders Issued Directly Under Small Business Reserves (15 U.S.C. 644(r)). [ ] (25) (MAR 2020)

52.219-33, Nonmanufacturer Rule (15U.S.C. 637(a)(17)). [ ] (26) (SEP 2021)

52.222-3, Convict Labor (E.O.11755). [X] (27) (JUN 2003)

52.222-19, Child Labor-Cooperation with Authorities and Remedies (E.O.13126). [X] (28) (DEC 2022)

52.222-21, Prohibition of Segregated Facilities . [X] (29) (APR 2015)

[X] (30) 52.222-26, Equal Opportunity (E.O.11246).(i) (SEP 2016)

Alternate I of 52.222-26. [ ] (ii) (FEB 1999)

[X] (31) 52.222-35, Equal Opportunity for Veterans (38 U.S.C. 4212).(i) (JUN 2020)

Alternate I of 52.222-35. [ ] (ii) (JUL 2014)

[X] (32) 52.222-36, Equal Opportunity for Workers with Disabilities (29 U.S.C. 793).(i) (JUN 2020)

Alternate I of 52.222-36. [ ] (ii) (JUL 2014)

52.222-37, Employment Reports on Veterans ( ) (38 U.S.C. 4212). [X] (33) JUN 2020

52.222-40, Notification of Employee Rights Under the National Labor Relations Act (E.O. 13496). [X] (34) (DEC 2010)

[X] (35) 52.222-50, Combating Trafficking in Persons (22 U.S.C. chapter 78 and E.O. 13627).(i) (NOV 2021)

Alternate I of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). [ ] (ii) (MAR 2015)

52.222-54, Employment Eligibility Verification (Executive Order 12989). (Not applicable to the acquisition of [X] (36) (MAY 2022) commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

[ ] (37) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(i)

(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

Alternate I of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the- [ ] (ii) (MAY 2008) shelf items.)

52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693). [ ] (38)

52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (E.O. 13693). [ ] (39) (JUN 2016)

[ ] (40) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (E.O.s 13423 and 13514).(i) (JUN 2014)

Alternate I of 52.223-13. [ ] (ii) (OCT 2015)

[ ] (41) 52.223-14, Acquisition of EPEAT®-Registered Televisions (E.O.s 13423 and 13514).(i) (JUN 2014)

Alternate I (Jun2014) of 52.223-14. [ ] (ii)

52.223-15, Energy Efficiency in Energy-Consuming Products (42 U.S.C. 8259b). [ ] (42) (MAY 2020)

[ ] (43) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (E.O.s 13423 and 13514).(i) (OCT 2015)

Alternate I of 52.223-16. [ ] (ii) (JUN 2014)

52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (E.O. 13513). [X] (44) (JUN 2020)

52.223-20, Aerosols (E.O. 13693). [ ] (45) (JUN 2016)

52.223-21,…