Solicitation_140R6024Q0050.pdf

U.S. Department of the Interior

Bureau of Reclamation

Technical Service Center

Denver, Colorado April 2024

Guernsey Power Plant Access Road and Parking Lot Repairs North Platte Project, Wyoming

Request for Quoation/Solicitation No. 140R6024Q0050

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION CALL

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040657720

Bureau of Reclamation

Great Plains Region

Regional Office PO Box 36900

R60

Billings MT 59107

DOI - Bureau of Reclamation

Darlene Dillon, Contracting Officer

DDillon@usbr.gov

Darlene Dillon 406-247-4037

104/18/2024

140R6024Q0050

INVITATION FOR BID

REQUEST FOR PROPOSAL

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Guernsey Power Plant Access Road and Parking Lot Repairs

Request for Quotation

The set-aside is Total Small Business.

Contract/Purchase Order Type: Firm Fixed Price (FFP)

The magnitude of the project is less than $25,000.

Product Service Code (PSC): Z1LZ Maintenance Parking Structures

North American Industry Classification System (NAICS): 237310 Highway, Street, and Bridge Construction with a size standard of $45.0 million.

Taxpayer Identification Number (TIN): _________________________

Unique Entity ID (UEI): ________________________________________

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 90 calendar days and complete it within ________________ ________________ calendar days after receiving

PWS Paragraph 6 negotiable. (See ________________________________________________.)

05/17/2024

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 12/2022)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

I

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

Bureau of Reclamation Great Plains Region

Regional Office PO Box 36900

R60

Billings MT 59107

Darlene Dillon

28. NEGOTIATED AGREEMENT 29. AWARD

and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations,certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

10 U.S.C. 3204(a) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 12/2022) BACK

Continued...

and return

(Contractor is not required to sign this document.) Your offer on this

Invoice Processing Platform System US Department of the Treasury http://www.ipp.govv

X

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140R6024Q0050

00010

SECTION B Supplies or Services and Prices

FOB: Destination

Guernsey Power Plant Access Road and 1 AU Parking Lot Repairs

(Price Schedule CLINS 1 through 3)

See following continuation page(s).

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Supplies or Services and Price

1. Price Schedule

(a) Offers will be considered for award on the following price schedule, but no offer will be considered for award on only a part of the price schedule.

(b) Offers are subject to the terms and conditions of this solicitation.

(c) Quantities in the price schedule are estimated quantities for comparison of offers only. Except as provided in the contract clause at FAR 52.211‐18, Variation in Estimated Quantity, no claim shall be made against the Government for overruns and underruns. The Contract Clause at FAR

52.211‐18, Variation in Estimated Quantity does not apply to the lump sum items.

(d) Each Line Item is inclusive of Mobilization and Preparation.

(e) Locations/Quantities may be increased or decreased

(f) Award will be transmitted electronically

(g) The Government intends to make one award for all line items.

(h) Definitions:

(1) CLIN‐Contract Line Item Number

CLIN SECTION SUPPLIES

OR

SERVICES

QUANTITY UNIT UNIT

PRICE

AMOUNT

(U.S. Dollars)

1 3 Dam and

Warehouse 1800 Cubic

Yards

2 3 Recreation

Area

850 Cubic

Yards

3 3 Power Plant area

500 Cubic

Yards

Total Firm Fixed Price of Schedule $________________

PWS - 1

PERFORMANCE WORK STATEMENT (PWS)

Guernsey Power Plant Access Road and Parking Lot Repairs

1.0 Scope

The Bureau of Reclamation (BOR) Wyoming Area Office (WYAO) has a need to provide roadway crack sealing and parking lot seal coating services. The principal components of work include the following:

1) grouting of asphalt and concrete pavement cracks,

1) cleaning of grouted cracks,

3) provision of crack sealant compound,

4) installation of the compound within routed and cleaned cracks, and

5) seal coating of parking lot(s).

The Contractor shall provide seal coating in accordance with the Wyoming Department of

Transportation’s (WYDOT) specifications provided in section 403 of its “Standard

Specifications for Road and Bridge Construction,” 2021 Edition.

2.0 Background

The Guernsey Dam and Power Plant are located on the North Platte River in Platte County, 7 miles northeast of Guernsey, Wyoming. The roadway areas at the base of the dam and near the picnic area, Guernsey Powerplant, and Reclamation maintenance building need repair by seal coating and grouting of cracks.

3.0 Locations of Project Work

The locations of repair work are at the Guernsey Dam and Warehouse, Recreation area, and

Power Plant area.

4.0 Project Deliverables

The Contractor shall submit certification the sealant complies with WYDOT regulations, prior to proceeding with the project work. The Contractor shall clean cracks, seal coat and grout cracks, provide and install crack sealant compound to the grouted and cleaned cracks. The contractor shall not work in the rain. Sealant shall not be installed in cracks where water is present.

5.0 Sweeping and Collection of Debris

The Contractor shall mechanically sweep all roadways with a street sweeper or equipment agreeable to the Contracting Officer Representative (COR) within 48 hours after it has been crack-sealed. The removal of any excess debris blown or deposited onto areas such as parking lot, sidewalks, etc., shall be included. Upon completion of sweeping and collection of debris, all roadways and adjacent areas must present a satisfactory appearance to the COR.

6.0 Period of Performance

The period of performance is within 90 days of Notice to Proceed.

PWS - 2

HOURS OF OPERATION: The Contractor shall only perform work from 8:00 AM to 5:00 PM, Monday thru Friday, unless otherwise authorized by the Contracting Officer and/or Contracting

Officer’s Representative.

7.0 Environmental Protection

The contractor shall comply with all federal, state, and local laws, regulations, and standards.

All environmental protection matters shall be coordinated with the Contracting Officer or

Contracting Officer’s Representative.

8.0 Contractor Personnel

All contractor employees must be U.S. citizens or have a valid Immigrant Visa Number, Permanent Resident Card, or Resident Alien Card authorizing them to work in the U.S. The contractor shall abide by all Federal, State, and Local laws pertaining to hiring and assigning tasks to personnel.

In accordance with GP-7 Site Security and WBR 1452.237-80 Security Requirements – Bureau of Reclamation, the contractor shall provide a listing of all personnel performing work under the contract prior to performance. Copies of state issued licenses that pertain to work related tasks may be required. The contractor shall notify the CO or the COR in writing of any personnel change to this list prior to the implementation of such change(s).

The contractor shall report to the Contracting Officer (CO), by telephone or email, any accidents involving injury, death, damage to Government property, or accidental loss of

Government property resulting from the activities of the contractor, their subcontractors, their agents, or their employees. A report shall be forwarded to the CO within 2 working days after the date of the accident. All accident records required by the Occupational Safety and Health

Act shall be maintained in accordance with OSHA guidelines. In addition, the contractor shall cooperate and provide data to follow-up investigation of an accident by Reclamation.

All personnel employed by the contractor for performance of the purchase order, or any representative of the contractor entering the Government installation, shall abide by all security regulations of the installation.

9.0 Furnished by Contractor

The contractor is to provide all labor, equipment, materials, supplies, and permits (if applicable) necessary to meet the requirements of the purchase order. Trucks, vehicles, and personnel will be licensed, insured, and certified as required by the appropriate governing agencies.

10.0 Safety and Health

The contractor shall comply with the Occupational Safety and Health Administration’s (OSHA) rules and regulations. The contractor shall also submit a safety plan in accordance with

Reclamation’s Safety and Health Standards at http://www.usbr.gov/safety/rshs/index.html. The contractor is required to practice safety in accordance with Reclamation’s Safety and Health

Standards when carrying out purchase order requirements. The safety and health standards include, but are not limited to the following:

http://www.usbr.gov/safety/rshs/index.html

PWS - 3

a. A high degree of safety and health standards shall be exercised when carrying out the contract in the public recreation area.

b. The contractor shall contact the COR if these potential conflicts affect, or are anticipated to affect, contract requirements.

c. The contractor shall use extra caution when operating vehicles to ensure the safety of the contractor and the public.

d. The contractor shall operate vehicles at or below the posted speed limits.

e. The onsite contractor/subcontractor personnel shall be certified in First Aid and

Cardiopulmonary Resuscitation (CPR). Certification of First Aid and CPR shall be submitted to the COR.

f. Approved first aid kits shall be carried in all vehicles.

g. The contractor shall be responsible for supplying personal protective equipment for all the employees.

h. The contractor shall keep the premises free from debris and accumulated waste.

i. Any vandalism, security, safety, or health issues shall be reported within 24 hours to the

COR. Any crimes against property or people, or need for emergency services, shall first be reported to the appropriate County Sheriff’s Office or emergency medical provider. If possible, also provide the COR any information pertaining to the condition, time, date, place, and description of damages, witnesses, suspects, or other information.

11.0 Government Furnished Equipment / Information

The government will not furnish any equipment or materials.

12.0 Contractor Quality Control Plan (QCP)

The contractor shall develop and maintain a Quality Control Plan. The contractor is responsible for the management and quality control to meet industry standards for the roadway repair.

Each phase of the service rendered under the contract is subject to Government inspection by the COR during any or all times of the contractor’s work. The Government’s Quality Assurance program is not a substitute for the contractor’s Quality Control Plan (QCP). The Government will monitor the contractor’s performance. Non-compliance with the purchase ordert will result in a required service being re-performed to the performance standards as stated in the PWS, without additional expense to the Government. The Government reserves the right to utilize any method of inspection.

13.0 Performance Standards

The designated Contracting Officer Representative (COR) will document acceptable and unacceptable contract performance. The following table summarizes the performance standards:

Task Description Performance

Standard

Method of

Monitoring

Disincentive Incentive

Condition Road work is completed properly

100%

Inspection

Re-work at contractor’s expense

Exceptional contractor performance will be documented

PWS - 4

14.0 Required Submittals

The contractor shall provide submittals in accordance with the submittal table. The

Government has 10 days to review and approve each submittal or request a revision to the submittal. Note: The submittal submission and review/approval process are inclusive in the

Period of Performance.

RSN

Clause Or

Section Title Submittals Required

Due date or delivery time

No. of sets to be sent to:

CO COR

Liability Insurance

1452.228-70

Acceptable certificate of liability insurance

Within 10 calendar days after award

1 0

Site Security

– GP-7 and WBR

1452.237-80

Security

Requirements –

Bureau of

Reclamation

1. List of all contractor and subcontractor employees performing work under this purchase order with supporting documentation

2. List of all vehicles and equipment to be brought on site with supporting documentation

Within 10 calendar days after Notice to

Proceed and prior to onsite work

Hazardous

Material

Identification and

Material Safety

Data

52.223-3 A1

List of chemicals to be used for this contract and their associated SDS

Within 10 calendar days after Notice to

Proceed and prior to onsite work

4 Section 3 of PWS Certification the sealant complies with WYDOT

Within 10 calendar days after Notice to

Proceed and prior to onsite work

5 Section 9 of PWS

Certification of First

Aid/CPR

Within 10 calendar days after Notice to

Proceed and prior to onsite work

6 WBR 1452.223-81 Contractor’s safety plan

Within 15 calendar days after Notice to

Proceed and prior to onsite work

PWS - 5

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

1 (Clauses)

CLAUSES

52.252-2 Clauses Incorporated by Reference Feb 1998 This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov .

52.204-19 Incorporation by Reference of Representations and Certifications Dec 2014

52.211-18 Variation in Estimated Quantity Apr 1984

52.222-6 Construction Wage Rate Requirements Aug 2018

52.222-7 Withholding of Funds May 2014

52.222-8 Payrolls and Basic Records Jul 2021

52.222-9 Apprentices and Trainees Jul 2005

52.222-10 Compliance with Copeland Act Requirements Feb 1988

52.222-11 Subcontracts (Labor Standards) May 2014

52.222-12 Contract Termination-Debarment May 2014

52.222-13 Compliance with Construction Wage Rate Requirements and

Related Regulations

May 2014

52.222-14 Disputes Concerning Labor Standards Feb 1988

52.222-15 Certification of Eligibility May 2014

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While

Driving

Jun 2020

52.232-39 Unenforceability of Unauthorized Obligations Jun 2013

52.236-7 Permits and Responsibilities Nov 1991

52.213-4 Terms and Conditions – Simplified Acquisitions (Other than Feb2024

Commercial Products and Commercial Services)

The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further

Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L.

115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and

Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-

232).

https://www.acquisition.gov/ https://www.acquisition.gov/far/52.203-19#FAR_52_203_19 https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

2 (Clauses)

(iv) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section

102 of Division R of Pub. L. 117-328), unless the agency grants an exception - see paragraph (b) of 52.204-27.

(v) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—

Prohibition. (DEC 2023) (Pub. L. 115–390, title II).

(vi) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

(vii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(viii) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

(ix) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the

Department of the Treasury).

(x) 52.232-40, Providing Accelerated Payments to Small Business

Subcontractors (MAR 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(xi) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C.3553).

(xii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) ( Pub. L.

108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.233-1, Disputes (MAY 2014).

(vii) 52.244-6, Subcontracts for Commercial Products and Commercial Services (DEC

2023).

(viii) 52.253-1, Computer Generated Forms (JAN 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

https://www.acquisition.gov/far/52.204-27#FAR_52_204_27 https://www.acquisition.gov/far/52.204-30#FAR_52_204_30 https://www.acquisition.gov/far/52.222-3#FAR_52_222_3 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.225-13#FAR_52_225_13 https://www.acquisition.gov/far/52.232-40#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/52.233-3#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.233-4#FAR_52_233_4 https://www.govinfo.gov/link/plaw/108/public/77 https://www.govinfo.gov/link/plaw/108/public/77 https://www.govinfo.gov/link/uscode/19/3805 https://www.acquisition.gov/far/52.232-1#FAR_52_232_1 https://www.acquisition.gov/far/52.232-8#FAR_52_232_8 https://www.acquisition.gov/far/52.232-11#FAR_52_232_11 https://www.acquisition.gov/far/52.232-25#FAR_52_232_25 https://www.acquisition.gov/far/52.232-39#FAR_52_232_39 https://www.acquisition.gov/far/52.233-1#FAR_52_233_1 https://www.acquisition.gov/far/52.244-6#FAR_52_244_6 https://www.acquisition.gov/far/52.253-1#FAR_52_253_1

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

3 (Clauses)

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C.

4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

(ii) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract

Awards (JUN 2020)(Pub. L. 109-282) ( 31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(iii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (FEB

2024) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in 2.101 on the date of award of this contract).

(iv) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment., Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) ( 41 U.S.C.chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(v) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vi) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) ( 29

U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vii) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212)

(Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(viii) 52.222-41, Service Contract Labor Standards (AUG

2018) ( 41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the

Service Contract Labor Standards statute and will be performed in the United States, District of

Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin

Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(ix)

(A) 52.222-50, Combating Trafficking in Persons (NOV

2021) ( 22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/3.900#FAR_3_900 https://www.acquisition.gov/far/52.204-10#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/4.1403#FAR_4_1403 https://www.acquisition.gov/far/52.222-19#FAR_52_222_19 https://www.acquisition.gov/far/2.101#FAR_2_101 https://www.acquisition.gov/far/52.222-20#FAR_52_222_20 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/22.1303#FAR_22_1303 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/22.1408#FAR_22_1408 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/22.1303#FAR_22_1303 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-chapter67-front&num=0&edition=prelim https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

4 (Clauses)

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(x) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order

14026 (JAN 2022) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States, the District of Columbia, Puerto Rico, the

Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands

Act (43 U.S.C. 1331, et seq.))).

(xi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O.

13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xii) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY

2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xiii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential

Hydrofluorocarbons (JUN 2016) (E.O. 13693)(applies to contracts for products as prescribed at

FAR 23.804(a)(1)).

(xiv) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration

Equipment and Air Conditioners (JUN 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xv) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) ( 42

U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program

(FEMP)) will be-

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xvi) 52.223-20, Aerosols (JUN 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

https://www.acquisition.gov/far/52.222-55#FAR_52_222_55 https://www.acquisition.gov/far/52.222-6#FAR_52_222_6 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 https://www.acquisition.gov/far/52.222-62#FAR_52_222_62 https://www.acquisition.gov/far/52.222-6#FAR_52_222_6 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 https://www.acquisition.gov/far/52.223-5#FAR_52_223_5 https://www.acquisition.gov/far/52.223-11#FAR_52_223_11 https://www.acquisition.gov/far/23.804#FAR_23_804 https://www.acquisition.gov/far/52.223-12#FAR_52_223_12 https://www.acquisition.gov/far/52.223-15#FAR_52_223_15 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/23.204#FAR_23_204 https://www.acquisition.gov/far/52.223-20#FAR_52_223_20

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

5 (Clauses)

(xvii) 52.223-21, Foams (JUN 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xviii)

(A) 52.225-1, Buy American-Supplies (OCT 2022) ( 41 U.S.C. chapter 67)

(Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in 2.101 on the date of award of this contract, and the acquisition-

(1) Is set aside for small business concerns; or

(2) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $50,000).

(B) Alternate I (OCT 2022) (Applies if the Contracting Officer has filled in the domestic content threshold below, which will apply to the entire contract period of performance.

Substitute the following sentence for the first sentence of paragraph (1)(ii)(A) of the definition of domestic end product in paragraph (a) of 52.225-1: (A) The cost of its components mined, produced, or manufactured in the United States exceeds ____ percent of the cost of all its components. [ Contracting officer to insert the percentage per instructions at 13.302-5(d)(4). ])

(xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations., Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C. 1792)

(Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xx) 52.232-33, Payment by Electronic Funds Transfer-System for Award

Management (OCT 2013)(Applies when the payment will be made by electronic funds transfer

(EFT) and the payment office uses the System for Award Management (SAM) as its source of

EFT information).

(xxi) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award

Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

(xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial

Vessels (NOV 2021) ( 46 U.S.C. 55305)(Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

(2) Listed below are additional clauses that may apply:

https://www.acquisition.gov/far/52.223-21#FAR_52_223_21 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/2.101#FAR_2_101 https://www.acquisition.gov/far/19.502-2#FAR_19_502_2 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 https://www.acquisition.gov/far/13.302-5#FAR_13_302_5 https://www.acquisition.gov/far/52.226-6#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/26.404#FAR_26_404 https://www.acquisition.gov/far/52.232-33#FAR_52_232_33 https://www.acquisition.gov/far/52.232-34#FAR_52_232_34 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm https://www.acquisition.gov/far/47.504#FAR_47_504

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

6 (Clauses)

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (NOV

2021) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.)

(ii) 52.209-6, Protecting the Government’s Interest When Subcontracting with

Contractors Debarred, Suspended, or Proposed for Debarment (NOV 2021) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (Sept 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b.

origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b.

destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its post acceptance rights-

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the

Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting

Officer of the cessation of such occurrence.

https://www.acquisition.gov/far/52.204-21#FAR_52_204_21 https://www.acquisition.gov/far/52.209-6#FAR_52_209_6 https://www.acquisition.gov/far/9.405-2#FAR_9_405_2 https://www.acquisition.gov/far/52.211-17#FAR_52_211_17 https://www.acquisition.gov/far/52.247-29#FAR_52_247_29 https://www.acquisition.gov/far/52.247-34#FAR_52_247_34

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

7 (Clauses)

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the

Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The

Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the

Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.219-6 Notice of Total Small Business Set-Aside Nov 2020

(a) Definition. Small business concern, as used in this clause—

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the size standards in this solicitation.

(2) Affiliates, as used in paragraph (a)(1) of this clause, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) Applicability. This clause applies only to-

(1) Contracts that have been totally set aside for small business concerns; and

(2) Orders set aside for small business concerns under multiple-award contracts as described in 8.405- 5 and 16.505(b)(2)(i)(F).

https://www.acquisition.gov/far/8.405-5#FAR_8_405_5 https://www.acquisition.gov/far/8.405-5#FAR_8_405_5 https://www.acquisition.gov/far/16.505#FAR_16_505

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

8 (Clauses)

(c) General.

(1) Offers are solicited only from small business concerns. Offers received from concerns that are not small business concerns shall be considered nonresponsive and will be rejected.

(2) Any award resulting from this solicitation will be made to a small business concern.

52.223-3 Alt I Hazardous Material Identification and Material Safety Data Alt I Jul 1995

(a) "Hazardous material," as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No.313 (including revisions adopted during the term of the contract).

(b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number.

This information shall also be included on the Material Safety Data Sheet submitted under this contract.

Material (If none, insert None) Identification No.

(c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous.

(d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No.313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No.313, whether or not the apparently successful offeror is the actual manufacturer of these items. Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

9 (Clauses)

(e) If, after award, there is a change in the composition of the item(s) or a revision to Federal

Standard No.313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.

(f) Neither the requirements of this clause nor any act or failure to act by the

Government shall relieve the Contractor of any responsibility or liability for the safety of

Government, Contractor, or subcontractor personnel or property.

(g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.

(h) The Government’s rights in data furnished under this contract with respect to hazardous material are as follows:

(1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to-

(i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials;

(ii) Obtain medical treatment for those affected by the material; and

(iii) Have others use, duplicate, and disclose the data for the Government for these purposes.

(2) To use, duplicate, and disclose data furnished under this clause, in accordance with paragraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data.

(3) The Government is not precluded from using similar or identical data acquired from other sources.

(i) Except as provided in paragraph (i)(2), the Contractor shall prepare and submit a sufficient number of Material Safety Data Sheets (MSDS's), meeting the requirements of 29 CFR

1910.1200(g) and the latest version of Federal Standard No.313, for all hazardous materials identified in paragraph (b) of this clause.

(1) For items shipped to consignees, the Contractor shall include a copy of the MSDS's with the packing list or other suitable shipping document which accompanies each shipment.

Alternatively, the Contractor is permitted to transmit MSDS's to consignees in advance of receipt of shipments by consignees, if authorized in writing by the Contracting Officer.

(2) For items shipped to consignees identified by mailing address as agency depots, distribution centers or customer supply centers, the Contractor shall provide one copy of the

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

10 (Clauses)

MSDS's in or on each shipping container. If affixed to the outside of each container, the

MSDS's must be placed in a weather resistant envelope.

52.225-9 Buy American-Construction Materials Oct 2022

(a) Definitions. As used in this clause—

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

https://www.acquisition.gov/far/2.101#FAR_2_101

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

11 (Clauses)

Critical component means a component that is mined, produced, or manufactured in the United

States and deemed critical to the U.S. supply chain. The list of critical components is at

FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if–

(A)The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except https://www.acquisition.gov/far/25.105#FAR_25_105

WY Guernsey Powerplant Access Road Solicitation No. 140R6024Q0050

12 (Clauses) metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means…