Solicitation 140R6021R0006.pdf

U.S. Department of the Interior February 2021

Solicitation Number: 140R6021R0006

Supply of Solids Contact Clarifier Equipment

Leadville Mine Treatment Plant and Facilities Leadville Mine Drainage Tunnel Project, Colorado

This page intentionally left blank.

SUPPLY OF SOLIDS CONTACT CLARIFIER EQUIPMENT

LEADVILLE MINE DRAINAGE TUNNEL PROJECT, COLORADO

FOREWORD

Work is for a water treatment plant located approximately 1 mile north of Leadville, Colorado in Lake County. The work consists of design, fabrication, storage, delivery, field startup, testing, commissioning, training, and associated services for solids contact clarifier water treatment equipment to be installed as part of a future water treatment plant replacement project.

The Principal components of work to be performed under these specifications include the following:

A. Design, fabricate, store, and deliver solids contact clarifier system. Work includes:

1. Solids Contact Clarifier system capable of treating maximum flow of 3.67 million gallons per day (mgd) with all trains in service and average day flow of 2.95 mgd with one train out of service. Minimum of 2 treatment trains.

2. Access platforms.

3. Sludge recycle and sludge waste systems.

4. Control panel(s), including communication components compatible with future

Water Treatment Plant Control System.

5. Storage of equipment until delivery to project location.

6. Delivery of equipment to project location.

7. Field startup or testing services, participation in Water Treatment Plant commissioning.

8. Training.

9. Warranty.

B. Work does not include:

1. Field installation.

2. Controls not listed above.

3. Chemical storage or feed systems.

INQUIRIES REGARDING THIS SOLICITATION SHOULD BE MADE TO:

Contractual Matters: Michael Birkland Contracting Officer Billings, Montana mbirkland@usbr.gov mailto:mbirkland@usbr.gov

FOR DATE AND PLACE OF BID OPENING, SEE “SOLICITATION, OFFER, AND

AWARD,” STANDARD FORM 1447.

Leadville Mine Treatment Plant and Facilities Supply of Solids Contact Clarifiers Equipment Leadville Mine Drainage Tunnel Project, Colorado Solicitation No. 140R6021R0006

TABLE OF CONTENTS

FORWARD

PART I – THE SCHEDULE

SECTION A - SOLICITATION, OFFER, AND AWARD (STANDARD FORM 1442)

SECTION B - THE SCHEDULE

SECTION C - DESCRIPTION / SPECIFICATIONS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 10 OTHER CONTRACTS

01 33 00 SUBMITTALS

01 33 26 ELECTRICAL AND CONTROL DRAWINGS AND DATA

01 42 10 REFERENCE STANDARDS

01 60 00 PRODUCT REQUIREMENTS

01 78 30 PROJECT RECORD DOCUMENTS

01 79 20 TRAINING

DIVISION 05 - METALS

05 51 30 SOLIDS CONTACT CLARIFIER (SCC) ACCESS PLATFORMS

DIVISION 26 - ELECTRICAL

26 05 02 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 10 CONDUCTORS AND CABLES

26 05 33 RACEWAYS AND BOXES

26 24 20 ELECTRICAL AND CONTROL PANELS

DIVISION 46 - WATER AND WASTEWATER EQUIPMENT

46 43 53 SOLIDS CONTACT CLARIFIER EQUIPMENT (SCC)

DIVISION 52 - DRAWINGS

52 00 00 DRAWINGS

SECTION D – RESERVED

SECTION E - INSPECTION AND ACCEPTANCE

E.1 INSPECTION OF SUPPLIES – FIXED PRICE

E.2 RESPONSIBILITY FOR SUPPLIES

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No. 140R6021R0006

E.3 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE

SECTION F - DELIVERIES OR PERFORMANCE

F.1 TIME F DELIVERY

F.2 LIQUIDATED DAMAGES

F.3 STOP WORK ORDER

F.4 GOVERNMENT DELAY OF WORK

F.5 F.O.B. DESTINATION

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 AUTHORITIES AND DELEGATIONS

G.2 CONTRACTING OFFICER’S REPRESENTATIVE’S AUTHORITIES AND

LIMITATIONS

G.3 POSTAWARD CONFERENCE

G.4 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS

G.5 NOTICE TO CONTRACTORS – CPARS

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 SITE SECURITY

H.2 PAYMENT FOR TECHNICAL DATA

H.3 SCHEDULE OF VALUES

PART II – CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1 CLAUSES INCORPORATED BY REFERENCE

I.2 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE

I.3 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION

SYSTEMS

I.4 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS

AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT

I.5 ORDER OF PRECEDENCE – UNIFORM CONTRACT FORMAT

I.6 MINIMUM WAGES UNDER EXECUTIVE ORDER 13658

I.7 TRADE AGREEMENTS

I.8 BID GUARANTEE

I.9 ADDITIONAL BOND SECURITY

I.10 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS

I.11 FEDERAL, STATE, AND LOCAL TAXES

I.12 PAYMENTS

I.13 PROGRESS PAYMENTS

I.14 PROMPT PAYMENT

I.15 CHANGES-FIXED PRICE

I.16 AUTHORIZED DEVIATIONS IN CLAUSES

I.17 RESTRICTIONS ON ENDORSEMENTS

I.18 RELEASE OF CLAIMS

I.19 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR

I.20 INCORPORATION OF TECHNICAL PROPOSAL

I.21 ASBESTOS-FREE WARRANTY

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No. 140R6021R0006

I.22 PROTECTING FEDERAL EMPLOYEES AND THE PUBLIC FROM EXPOSURE

TO TOBACCO SMOKE IN THE FEDERAL WORKPLACE

I.23 CERTIFICATION OF REPRESENTATIVES FOR CORPORATE SURETIES

I.24 CLAIMS ACCOUNTING

I.25 OTHER CONTRACTS

I.26 RESTRICTION ON SUBMISSION AND USE OF EQUAL PRODUCTS

I.27 SECURITY REQUIREMENTS

I.28 MODIFICATION OF PROPOSALS

I.29 OPTION FOR INCREASED QUANTITY-SEPARATELY PRICED LINE ITEM

I.30 PAYMENT FOR MOBILIZATION AND PREPARATORY WORK

PART III – DOCUMENTS, EXHIBITS, AND OTHER

SECTION J - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

Attachment No. 1 ...........................................................................................Standard Form 24 – Bid Bond Attachment No. 2 ................................................................................. Small Business Subcontracting Plan

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K - REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS

OF OFFERORS

K.1 ANNUAL REPRESENTATIONS AND CERTIFICATIONS

K.2 INFORMATION REGARDING RESPONSIBILITY MATTERS

K.3 CERTIFICATION REGARDING TAX MATTERS

K.4 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING

SECTION L - INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

L.1 SYSTEM FOR AWARD MANAGEMENT

L.2 ALTERNATIVE LINE ITEM PROPOSAL

L.3 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF

FEDERAL SPECIFICATIONS

L.4 AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM

DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND

STANDARDIZATION INFORMATION SYSTEM (ASSIST)

L.5 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE

L.6 SUBMISSION OF OFFERS IN U.S. CURRENCY

L.7 INSTRUCTIONS TO OFFERORS

L.8 TYPE OF CONTRACT

L.9 TRADE AGREEMENTS CERTIFICATE

L.10 AUTHORIZED DEVIATIONS IN PROVISIONS

L.11 USE AND DISCLOSURE OF PROPOSAL INFORMATION

L.12 SERVICE OF PROTEST

L.13 SOURCE EVALUATION AND SELECTION PROCEDURES

L.14 GENERAL PROPOSAL INSTRUCTIONS

L.15 TECHNICAL PROPOSAL INSTRUCTIONS

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No. 140R6021R0006

L.16 PRICING PROPOSAL INSTRUCTIONS

L.17 NOTICE OF PROPOSED PARTNERING

L.18 INSTRUCTION FOR MOBILIZATION AND PREPARATORY WORK

SCHEDULE LINE ITEM

L.19 NOTICE OF PROGRESS PAYMENTS

SECTION M - EVALUATION FACTORS FOR AWARD

M.1 EVALUATION FACTORS FOR AWARD – QUALITY COST/PRICE

APPROXIMATELY EQUAL

M.2 NOTICE OF WORLD TRADE ORGANIZATION GOVERNMENT

PROCUREMENT AGREEMENT EVALUATIONS

M.3 OPTION FOR INCREASED QUANTITY-SEPARATELY PRICED LINE ITEM

END OF CONTENTS

PART I -- THE SCHEDULE

This Page Intentionally Left Blank

SECTION A

SOLICITATION, OFFER, AND

AWARD (STANDARD FORM 1447)

SOLICITATION/CONTRACT 1. THIS CONTRACT IS A RATED

5. SOLICITATION TYPE2. CONTRACT NO. 4. SOLICITATION NUMBER

PAGE OF PAGES

7. ISSUED BY CODE 8. THIS ACQUISITION IS

BIDDER/OFFEROR TO COMPLETE BLOCKS 11, 13, 15, 21, 22, & 27

RATING

ORDER UNDER DPAS (15 CFR 700)

3. AWARD/

EFFECTIVE DATE ISSUE DATE

6. SOLICITATION

UNRESTRICTED OR SET ASIDE:

SMALL BUSINESS

SIZE STANDARD:

9. (AGENCY USE)

NO COLLECT CALLS

10. ITEMS TO BE PURCHASED (BRIEF DESCRIPTION)

SUPPLIES SERVICES

11. IF OFFER IS ACCEPTED BY THE GOVERNMENT WITHIN

CALENDAR DAYS (60 CALENDAR DAYS UNLESS OFFEROR INSERTS A DIFFERENT

PERIOD) FROM THE DATE SET FORTH IN BLOCK 9 ABOVE, THE CONTRACTOR

AGREES TO HOLD ITS OFFERED PRICES FIRM FOR THE ITEMS SOLICITED

HEREIN AND TO ACCEPT ANY RESULTING CONTRACT SUBJECT TO THE TERMS

AND CONDITIONS STATED HEREIN.

CODE 12. ADMINISTERED BY

13. CONTRACTOR FACILITY 14. PAYMENT WILL BE MADE BY CODE CODE

OFFEROR CODE

TELEPHONE NO.

UNIQUE ENTITY IDENTIFER

CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK:

15. PROMPT PAYMENT DISCOUNT 16. AUTHORITY FOR USING OTHER

THAN FULL AND OPEN COMPETITION

10 U.S.C. 2304 41 U.S.C. 253

NEGOTIATED

(RFP)

SEALED BIDS

(IFB)

1 3

02/11/2021

Bureau of Reclamation Great Plains Region Regional Office PO Box 36900 Billings MT 59107

Bureau of Reclamation Great Plains Region Regional Office PO Box 36900

R60

Billings MT 59107

333318

% FOR:X

x x

R60

140R6021R0006

NAICS:

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS

8(A)

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOSB PROGRAM

EDWOSB

17.

ITEM NO.

18.

SCHEDULE OF SUPPLIES/SERVICES

19.

QUANTITY

20.

UNIT

21.

UNIT PRICE

22.

AMOUNT

27. SIGNATURE OF OFFEROR/CONTACTOR 28. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

NAME AND TITLE OF SIGNER (TYPE OR PRINT) DATE SIGNED NAME OF CONTRACTING OFFICER DATE SIGNED

25. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET

FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY CONTINUATION SHEETS

SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

26. AWARD OF CONTRACT: YOUR OFFER ON SOLICITATION

NUMBER SHOWN IN BLOCK 4 INCLUDING ANY ADDITIONS

OR CHANGES WHICH ARE SET FORTH HEREIN, IS

ACCEPTED AS TO ITEMS:

23. ACCOUNTING AND APPROPRIATION DATA 24. TOTAL AWARD AMOUNT

(FOR GOVERNMENT USE ONLY)

Michael L. Birkland

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION NOT USABLE

STANDARD FORM 1447 (REV. 8/2016)

Prescribed by GSA - FAR (48 CFR) 53.214(d)

COPIES TO

TYPE OR PRINT NAME AND TITLE OF SIGNER

SIGNATURENAME AND ADDRESS OF FIRM (Include ZIP Code)

WE DO NOT, DESIRE TO BE RETAINED ON THE MAILING LIST FOR FUTURE PROCUREMENT OF THE TYPE OF ITEMS INVOLVEDWE DO

DO NOT REGULARLY MANUFACTURE OR SELL THE TYPE OF ITEMS INVOLVED

CANNOT MEET DELIVERY REQUIREMENT

OTHER (Specify)

UNABLE TO IDENTIFY THE ITEM(S)

CANNOT COMPLY WITH SPECIFICATIONS

PAGE

NO RESPONSE FOR REASONS CHECKED

3 2 OF

DATE AND LOCAL TIME

AFFIX

STAMP

HERE

TO:

FROM:

SOLICITATION NO.

Billings MT 59107

Bureau of Reclamation Great Plains Region Regional Office PO Box 36900

R60

140R6021R0006

STANDARD FORM 1447 (REV. 8/2016) BACK

3:00 P.M. on 3/18/2021

(A)

ITEM NO.

(B)

SUPPLIES/SERVICES

(C)

QUANTITY

(D)

UNIT

(E)

UNIT PRICE

(F)

AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140R6021R0006

00010 1 LSSolids Contact Clarifiers

NSN 7540-01-218-4386 STANDARD FORM 1447 (REV. 8/2016)

Prescribed by GSA - FAR (48 CFR) 53.214(d)

See Continuation of Section B - Schedules 1, 2 and 3

SECTION B

THE SCHEDULE

Supply of Solids Contact Clarifier Equipment Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.140R6021R0006

Price Schedule B - 1

CONTINUATION OF

SECTION B – SUPPLIES OR SERVICES AND COSTS

LEADVILLE MINE TREATMENT PLANT AND FACILITIES

SUPPLY OF SOLIDS CONTACT CLARIFIER EQUIPMENT

LEADVILLE MINE DRAINAGE TUNNEL PROJECT, COLORADO

B.1 PRICE SCHEDULES

(a) Offers will be considered for award on the following Price Schedules, but no offer will be considered for award on only part of the Price Schedules:

(1) Offerors shall complete Price Schedules 1 through 3. Offers for less than the total of Schedules 1 through 3 will be considered nonresponsive and will not be evaluated for award.

(2) Offers will be evaluated based on the total of Price Schedule 1 and based on pricing offered in Optional Price Schedule 2 and in Optional Price Schedule 3.

(3) Government will award Price Schedule 1, may also award Optional Price Schedule 2, and may also award Optional Price Schedule 3; award of Optional Price Schedule 2 or Optional Price Schedule 3 will depend on the timing at award of the associated contract for the Water Treatment Plant Replacement project.

(b) Offers are subject to terms and conditions of this solicitation.

(c) Quantities in the Price Schedule are estimated quantities for comparison of offers only.

Except as provided in contract clause at FAR 52.211-18, Variation in Estimated Quantity, no claim shall be made against Government for overruns or underruns.

(d) See contract clause at WBR 1452.232-81, Payment for Mobilization and Preparatory Work, for CLIN 1.

(e) Definitions:

(1) CLIN – Contract Line Item Number.

PRICE SCHEDULE 1

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

1 WBR

1452.232-81

Mobilization and Preparatory Work

For the lump sum of $

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.140R6021R0006

Price Schedule B - 2

PRICE SCHEDULE 1

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

2 46 43 53 Solids Contact Clarifier Equipment – Fabrication

For the lump sum of $

3 46 43 53 Solids Contact Clarifier Equipment – Storage

38-months $ $

4 46 43 53 Solids Contact Clarifier Equipment – Delivery

For the lump sum of $

5 46 43 53 Solids Contact Clarifier Equipment – Spare Parts

For the lump sum of $

6 46 43 53 Solids Contact Clarifier Equipment – Base Warranty

For the lump sum of $

TOTAL FOR PRICE SCHEDULE 1 $_________________

OPTIONAL PRICE SCHEDULE 2

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

7 46 43 53 Solids Contact Clarifier Equipment – Warranty Extension 1

For the lump-sum of $

TOTAL FOR OPTIONAL PRICE SCHEDULE 2 $_________________

OPTIONAL PRICE SCHEDULE 3

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

8 46 43 53 Solids Contact Clarifier Equipment – Warranty Extension 2

For the lump-sum of $

TOTAL FOR OPTIONAL PRICE SCHEDULE 3 $_________________

TOTAL FOR ALL SCHEDULES (1, 2 AND 3) $__________________

SECTION C

THE STATEMENT OF WORK

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Summary of Work 01 11 00 - 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.01 LOCATION

A. Leadville Mine Drainage Tunnel Water Treatment Plant is located approximately 1 mile north of Leadville, Colorado in Lake County at 749 North Highway 91, Leadville, CO 80461.

1.02 PRINCIPAL COMPONENTS OF WORK

A. Design, fabricate, store, and deliver solids contact clarifier system. Work includes:

1. Solids Contact Clarifier system capable of treating maximum flow of 3.67 million gallons per day (mgd) with all trains in service and average day flow of 2.95 mgd with one train out of service. Minimum of 2 treatment trains.

2. Access platforms.

3. Sludge recycle and sludge waste systems.

4. Control panel(s), including communication components compatible with future

Water Treatment Plant Control System.

5. Storage of equipment until delivery to project location.

6. Delivery of equipment to project location.

7. Field startup or testing services, participation in Water Treatment Plant commissioning.

8. Training.

9. Warranty.

B. Work does not include:

1. Field installation.

2. Controls not listed above.

3. Chemical storage or feed systems.

1.03 SPECIFICATIONS REQUIREMENTS

A. Requirements in Division 1 and General Requirements apply to Divisions 2 through 52.

B. Imperative statements in these specifications are Contractor requirements, unless otherwise stated.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Summary of Work 01 11 00 - 2

C. Where specifications are written in streamlined form, words “shall be” are included by inference where a colon (:) is used within sentence or phrase.

1.04 DEFINITIONS

A. When specifications use word or term defined in Federal Acquisition Regulations (FAR), definition of word or term shall be in accordance with FAR sections in effect at time solicitation was issued.

1.05 ACRONYMS

A. The following acronyms apply to specifications Divisions 1 through 52:

1. CO: Contracting Officer.

2. COR: Contracting Officer’s Representative.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

END OF SECTION

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Other Contracts 01 12 10 - 1

SECTION 01 12 10

OTHER CONTRACTS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 OTHER WORK

A. During work under this contract, other work that may be performed in vicinity of work by other contractors includes the following:

1. Water Treatment Plant Replacement.

B. Cooperate and coordinate with other Contractors on:

1. Access to and use of work areas and Contractor use areas. Comply with clause at

FAR 52.236-8, Other Contracts.

2. Use of temporary utilities.

3. Maintaining dust-free operations.

4. Facility operating and maintenance personnel.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Other Contracts 01 12 10 - 2

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in lump-sum price offered in the Price Schedule for other items of work.

1.02 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittals: Considered “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction.

1.03 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal Inch Drawing Sheet Size and

Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-14 United States National CAD Standards, Version 6

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, the more stringent requirements take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title and RSN.

3. Measurement Units: US Customary Units.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 2

C. Drawings:

1. Minimum Identification in Title Block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3- by 3-inch space next to title block for review stamps.

3. Print Size: ANSI D size (22- by 34-inches).

4. Draw to scale using computer drafting:

a. In accordance with NIBS NCS.

b. Electronic file format: Compatible with AutoCAD version 2019 or later.

c. Compile using “eTransmit” utility in AutoCAD.

d. Government will provide electronic AutoCAD format template.

e. Title block and sheet format:

1) As shown on Standard Drawing 40-D-7102.

2) Government will supply template.

3) Government will supply specific title block information to be used.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets:

a. Identify manufacturer's name, type, model, size, materials of construction, and characteristics.

b. Illustrate product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 3

b. Electronic copies: Adobe pdf on thumb drive. Bookmark longer files to assist in navigating file.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

d. Manufacturer’s drawings, photographs, and test records or reports if required by specification.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will not be reviewed.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A – List of Submittals. Complete set includes all listed items for RSNs with multiple parts.

C. Submit sets specified in “Sets to be sent:” columns in Table 01 33 00A – List of Submittals.

1. Electronic Submittals:

a. In Portable Document Format (.pdf):

1) Optical Character Recognition (OCR).

2) Compliant with Section 508 of the Rehabilitation Act.

3) RSNs having more than one requirement shall be bookmarked.

4) RSNs with requirements for files other than .pdf (e.g., .xer, .plf, .dwg, etc.) shall be combined using WinZip.

b. Include RSN transmittal letter.

c. Personally Identifiable Information (PII) shall be encrypted using WinZip or Adobe Acrobat before transmitting electronically.

2. Submit electronic submittals via electronic mail or thumb drive based on size:

a. Government can receive electronic mails up to 25 MB. However, e-mail over 10 MB should be considered extra-large. E-mailing of electronic submittals exceeding 10 MB should only occur after transmittal of extra-large size e-mail has been verified.

b. Address e-mail of electronic submittals less than extra-large size to:

sha-GPR-CONSTSVCS@usbr.gov.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 4

c. Electronic submittals that are too large to e-mail shall be submitted on thumb drive.

d. Submittals received after 5:00 p.m. Mountain Time shall be documented as received the next business day.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe and link the changes (i.e. with bookmarks) in transmittal letter.

3. Resubmit returned submittals within 14-days after receiving comments.

4. Requirements for initial submittals apply to resubmittals.

5. Resubmittals shall be complete submittals without reference to original submittal.

F. Submit each RSN under separate transmittal letter. Multiple RSNs submitted under single letter will not be reviewed.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 42-days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return e-mail postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time:

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of 2 or more separate submittals or resubmittals will be counted only once in extending contract completion date.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 5

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract,

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of clause at

FAR 52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as term is used in clauses.

C. Submittal Response:

1. Response letter will indicate whether submittal is acceptable, not acceptable, approved, not approved, or acknowledged receipt:

a. Submittals not approved shall be revised and resubmitted.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

2. RSNs reviewed by CO may not be responded to unless considered deficient.

1.07 TRANSMITTAL

A. Addresses for codes receiving paper copy submittals listed in Table 01 33 00A – List of Submittals:

1. CO: Contracting Officer, Bureau of Reclamation, Attention: GP-5000, P.O.

Box 36900, Billings, MT 59107-6900. Physical address is 2021 4th Avenue North, Billings, MT 59101.

2. COR: Contracting Officer’s Representative, Bureau of Reclamation, Attention:

GP-2600, P.O. Box 36900, Billings, MT 59107-6900. Physical address is 2021 4th Avenue North, Billings, MT 59101.

B. Electronic mail address for electronic submittals listed in Table 01 33 00A – List of Submittals: sha-GPR-CONSTSVCS@usbr.gov:

1. Submit electronic submittals that are too large for e-mail to the physical address above.

C. Submittals required by specifications, but not listed in Table 01 33 00A – List of Submittals:

1. Submit in accordance with this section.

2. Submit to COR unless otherwise specified.

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals

01 33 00 - 6

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Table 01 33 00A – List of Submittals

* CO indicates Contracting Officer; COR indicates Contracting Officer’s Representative.

RSN Clause or Section Title Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: *

CO COR

1 Performance and Payment Bonds – Other Than Construction

FAR 52.228-16

Performance and Payment Bonds

Within 10 calendar days after award

CO 1 electronic 0

2 Additional Bond Security

FAR 52.228-02

Evidence of Increase in Bond Security

Within 10 calendar days after modifications increasing contract value

CO 1 electronic 0

3 Insurance-Work on a Government Installation

WBR 1452.228-70

1) Written certification that required insurance has been obtained

2) Current certification of insurance for each subcontractor

Before commencing onsite work

CO 1 electronic

4 Liability Insurance

WBR 1452.228-70

Acceptable Certificate of Liability Insurance

Prior to commencement of work under the contract

CO 1 electronic 0

5 Equal Opportunity

FAR 52.222-26

Information required by Executive Order

112246 (SF-100)

Within 30-days following award

CO 1 electronic 0

6 Reporting Executive Compensation and First Tier Subcontract Awards

FAR 52.204-10

Certification that executive compensation and subcontract awards were reported

Within 10-days of each report being submitted

CO 1 electronic 0

7 Release of Claims

WBR 1452.204-70

Release of Claims (DI-137) against the Government

After completion of work and prior to final payment

CO 1 electronic 0

8 Schedule of Values H.3

Schedule of Values for lump-sum CLINs

Submitted and approved before payment aside from bonds and insurance

COR 0 1 electronic

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Submittals 01 33 00 - 7

Table 01 33 00A – List of Submittals

* CO indicates Contracting Officer; COR indicates Contracting Officer’s Representative.

RSN Clause or Section Title Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: *

CO COR

01 78 30-1 Project Record Documents

Extra Materials Within 14-days of completion of work

COR 0 1 electronic

01 78 30-2 Project Record Documents

Warranties Within 14-days of completion of work

COR 0 1 electronic

01 79 20-1 Training Instructor’s Qualifications

Submitted and approved at least 42-days prior to training

COR 0 1 electronic

01 79 20-2 Training Training Outline Submitted and approved at least 42-days prior to procurement or fabrication

COR 0 1 electronic

01 79 20-3 Training Approval Training Materials

At least 42-days before training

COR 0 1 electronic

01 79 20-4 Training Final Training Materials

Within 14-days after training

COR 0 1 electronic + 2 paper copies 05 51 30-1 Solids Contact

Clarifier (SCC) Access Platforms

Approval Drawings Submitted and approved at least 42-days prior to procurement or fabrication

COR 0 1 electronic

05 51 30-2 Solids Contact Clarifier (SCC) Access Platforms

Calculations and Product Data

Submitted and approved at least 42-days prior to procurement or fabrication

COR 0 1 electronic

05 51 30-3 Solids Contact Clarifier (SCC) Access Platforms

Test Reports Submitted and approved at least 42-days after completion of tests

COR 0 1 electronic

05 51 30-4 Solids Contact Clarifier (SCC) Access Platforms

Final Drawings Within 42-days after installation

COR 0 1 electronic

46 43 53-1 Solids Contact Clarifier Equipment

Approval Drawings and Data

42-days before starting fabrication

COR 0 1 electronic

46 43 53-2 Solids Contact Clarifier Equipment

Material Certification Within 14-days after procurement of material

COR 0 1 electronic

46 43 53-3 Solids Contact Clarifier Equipment

Final Drawings and Data

Within 42-days after installation

COR 0 1 electronic

46 43 53-4 Solids Contact Clarifier Equipment

Storage Plan Within 42-days after

RSN 46 43 53-1

approval

COR 0 1 electronic

46 43 53-5 Solids Contact Clarifier Equipment

End of Warranty Inspection Letter

Within 7-days after inspection

COR 0 1 electronic

Submittals

01 33 00 - 8

Electrical and Control Drawings and Data

01 33 26 - 1

SECTION 01 33 26

ELECTRICAL AND CONTROL DRAWINGS AND DATA

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in lump-sum price offered in the Price Schedule for Solids Contact

Clarifier Equipment – Fabrication.

1.02 REFERENCE STANDARDS

A. Code of Federal Regulations (CFR)

1. 29 CFR 1910, Subpart I Personal Protective Equipment

B. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-2012 Decimal Inch Drawing Sheet Size and

Format

C. Institute of Electrical and Electronic Engineers (IEEE)

1. IEEE 315-1975(1993) Graphic Symbols for Electrical and

Electronics Diagrams (Including Reference Designation Letters)

2. IEEE C37.2-2008 Electrical Power System Device Function Numbers, Acronyms, and Contact Designations

3. IEEE Y32.9-1972(R1989) Graphic Symbols for Electrical Wiring and Layout Diagrams Used in Architecture and Building Construction

D. International Society of Automation

1. ISA 5.1-2009 Instrumentation Symbols and Identification

2. ISA 5.4-1991 Instrument Loop Diagrams

E. National Electrical Manufacturers Association (NEMA)

1. NEMA ICS 1-2000(2008) Industrial Control and Systems: General

Requirements

Leadville Mine Drainage Tunnel Project, Colorado Solicitation No.

Electrical and Control Drawings and Data 01 33 26 - 2

1.03 SUBMITTAL PROCEDURES

A. In addition to the requirements in Section 01 33 00 – Submittals, prepare electrical drawings and data submittals in accordance with the following.

B. Drawings, General:

1. Device designations and symbols:

a. Conform to IEEE 315, ISA 5.1, IEEE C37.2, IEEE Y32.9, and NEMA

ICS-1.

b. As indicated on Standard Drawings 104-D-757 and 104-D-1150.

2. Size: ANSI D-size prints as defined in ASME Y14.1 made from original drawings.

3. Indicate changes on revised drawings to distinguish them from previous submittals. Describe reasons for significant changes in submittal letters.

4. Identify all symbols, abbreviations, etc., used on drawing either on drawing or on drawing legend sheets. If drawing legend sheets are used, they should be referenced on each drawing.

5. All drawings, regardless of native drawing size, shall be legible when scaled and printed to 11- x 17-inch size on standard office printers.

6. Drawing boundaries shall be chosen to allow for logical groupings of components on drawings, without excessive fragmentation or piping and instrumentation diagrams, loop diagrams, or electrical schematic diagrams.

7. Provide list of reference drawings and notes on drawings, as appropriate.

8. Conductor Designations: Show and label each conductor (wire) with a designation.

C. Approval Drawings in Government Format:

1. General:

a. Furnish with Government title block and in form as indicated on Standard Drawing 40-D-7102.

b. Government will provide specific title block information when drawings are submitted.

2. Schematic Diagrams:

a. In accordance with Standard Drawing 104-D-1150.

b. Format:

1) Vertical ladder diagram form.

2) Label rungs with sequential numbers starting with number 1.

3) Locate rung numbers adjacent and to left of associated rung.

4) Provide unique rung numbers for each circuit.

01 33 26 - 3

c. Conductor designations: As indicated on drawings.

d. Indicate:

1) Device terminal designations.

2) Functional operation.

3) Ratings and/or values of devices.

4) Contacts, including spare contacts, for motor contactors, auxiliary relays, timers, and protective relays.

5) Cross-referencing between other schematic and wiring diagrams.

e. Describe unusual or nonstandard operation.

f. Conductor Designations: As indicated on drawings or as developed by

Contractor. Contractor-developed conductor designations shall consist of:

1) Circuit prefix.

2) Rung number.

3) Unique rung wire letter such as 5P15C (“5” - Unit Number, “P” -

Protection Circuit, “15” - Rung Number, “C” - Unique Rung Wire Letter).

g. Show switch developments for control, selector, and limit switches.

h. Show device and terminal block designations.

3. Wiring Diagram Drawings:

a. Match with schematic diagram drawings.

b. Indicate:

1) Point-to-point wiring in accordance with Standard Drawing 104-D-1165.

2) Equipment as mounted on back, side, swing, and door panels.

Show panel as viewed from wiring side of panel.

3) Wiring of devices and items of equipment including terminal number.

4) Cables, cable and individual wire designations, and connections to external circuits.

c. Identify:

1) Each item of equipment with designation indicated on schematic diagram.

2) Control and protective devices with IEEE device number as indicated on specifications drawings or on Standard Drawing 104-D-1150.

3) Components such as fuses and resistors by value.

01 33 26 - 4

d. Cable Designations: Similar to designations on Standard Drawing 104-D-1165.

e. Show no more than one panel per drawing.

4. Sample Wiring Diagram: Sample of actual wiring diagram that will be submitted as check print and final drawing.

D. Approval Drawings and Data in Manufacturer’s Format:

1. General: Furnish with manufacturer’s standard format, except as noted below.

2. Equipment Layout Drawings:

a. Indicate:

1) Dimensions of equipment.

2) Location of devices and items of equipment including nameplates, terminal blocks, wiring ducts, bus, conduit entries, and other features in their relative physical location.

3) Method of securing equipment to deck, floor, or wall.

b. Identify each device and item of equipment with a bill of material reference number.

3. Bill of Material List:

a. Provide:

1) Information on manufacturer, style, type, rating, quantity, and other identifying information for each device or item of equipment.

2) Unique reference number for each device or item of equipment listed on bill of material.

4. Nameplate Lists: Provide information on type of material, size, and engraved lettering.

5. Schematic Diagrams:

a. Format:

1) Vertical ladder diagram form.

2) Label rungs with sequential numbers starting with number 1.

3) Locate rung numbers adjacent and to left of associated rung.

4) Provide unique rung numbers for each circuit.

b. Indicate:

1) Functional operation.

2) Ratings and/or values of devices.

3) Contacts, including spare contacts, for each motor contactor coil, auxiliary relay, and timer.

01 33 26 - 5

4) Complete cross-reference between other schematic and wiring diagrams.

5) Switch developments for each selector switch and limit switch.

c. Describe unusual or nonstandard operation.

d. Identify devices and items of equipment by reference to bill of materials item number and with appropriate device number in IEEE and NEMA standards.

6. Wiring Diagrams:

a. Indicate:

1) Equipment as mounted on each back panel, side panel, and door.

Each panel shall be indicated as viewed from wiring side of panel.

2) Point-to-point wiring in accordance with Standard Drawing 104-D-1165.

3) Cables, cable and individual wire designations, and connections to all external circuits.

4) No more than one panel per drawing.

b. Identify each item of equipment with the device designation indicated on schematic diagrams.

7. Manufacturer’s Technical Catalog Data:

a. Provide technical data for each device or item of equipment.

b. Include manufacturer’s name and address; catalog number, type, style, or model number; electrical ratings; and dimensions.

c. Where several items are listed on same sheet, indicate items being submitted for approval.

d. Demonstrate proposed device or item of equipment meets specifications requirements.

e. Mark catalog data sheet with appropriate bill of material item number.

f. Assemble catalog data sheet into one enclosing cover with bill of material index.

8. Time-Current Characteristic and Equipment Coordination Curves:

a. Provide time-current characteristic curves for adjustable and non-adjustable protective devices.

b. Provide equipment coordination curves for:

1) Transformer inrush current.

2) Transformer full load current.

3) Transformer thermal and mechanical damage.

01 33 26 - 6

4) Motor inrush current.

5) Motor full load current.

c. Original plot on log-log graph paper.

d. Illustrate degree of selectivity being provided.

9. Job Hazard Analysis (JHA):

a. Provide when the Government will be performing factory inspection.

b. Prepare JHA in accordance with 29 CFR 1910, Subpart I.

c. As a minimum include the following in JHA:

1) Factory address and name of site visit contact person.

2) Date of JHA.

3) Purpose of JHA, for example “Visitor Safety Procedures”.

4) Hazards:

a) Types of hazards at factory.

b) Safety procedures in or around high-voltage test labs.

c) Safety procedures on factory floor.

5) Personal Protective Equipment:

a) List of equipment required.

b) List of equipment provided by factory.

6) Emergency Response:

a) Name and phone number of Factory Safety Officer.

b) Employees trained in emergency conditions (CPR and first aid).

c) Factory fire protection/evacuation procedures.

d) Nearest hospital or emergency room.

7) Name, title and signature of factory official approving JHA.

E. Loop Diagrams:

1. General:

a. In accordance with ISA 5.4.

b. Devices, including instruments:

1) Include device designations.

2) Indicate device terminal designations.

c. Indicate functional operation.

01 33 26 - 7

d. Indicate test switch and terminal block designations.

e. Indicate cross-referencing between loop diagrams, and other associated drawings and diagrams.

f. Typical references to devices or wiring will not be acceptable. Each device shall have a unique designation and shall be shown on the diagrams as a unique device.

g. Indicate ratings and/or values of devices, providing:

1) Ampere rating for fuses and circuit breakers.

2) Ohm rating and power rating for resistors.

3) Timer setting and range.

4) Capacitor and inductor ratings.

F. Check Prints:

1. Schematic and wiring diagrams which indicate “final” condition of equipment at time of shipment.

2. Mark as changes and revisions are made during assembly and checkout of equipment.

3. Keep drawings at the jobsite and mark as work progresses

4. Maintain separate, identical set of prints for use in preparing final drawings.

5. Include revision dates.

6. Mark the drawings in the following colors:

a. Red - Additions to original drawings.

b. Green - Deletions to original drawings.

c. Blue - Notations necessary for explanation of final markings.

G. Final Drawings:

1. Revised to reflect approval comments and final condition of assembled equipment at time of fabrication completion.

2. Provide original plot of schematic and wiring diagrams, equipment layout drawings, bill of materials, and nameplate drawings/lists.

3. Provide computer drawing files on thumb drive in AutoCAD (*.dwg).

4. Provided on Government title block and in form as indicated on Standard

Drawing 40-D-7102.

H. Test Reports:

1. Typed, 8 1/2- by 11-inch sheets.

2. Certified.

3. Submit multi-page reports in bound folder or three-ring binder.

01 33 26 - 8

I. Operation and Maintenance Manuals:

1. Print copies:

a. Assemble each set of material into one or more books with enclosing covers.

2. Electronic copies:

a. Adobe Acrobat (.pdf) format on thumb drive.

b. Conform to print copies.

c. Bookmark file(s) to aid in navigating.

3. Provide the following items:

a. Index sheet at front of each book which provides page or index tab number information for each device or item of equipment in book.

b. Manufacturer’s operation and maintenance procedures; installation details, as necessary; and catalog data sheets for each device or item of equipment.

c. List of recommended spare parts and components.

d. Parts lists for replacement parts.

e. Manufacturer’s full-size circuit breaker and fuse time-current curves.

f. Copies of factory test reports.

g. Copies of bills of materials.

h. Copies of drawings:

1) Revised to reflect approval comments.

2) Maximum size: 11- by 17-inch.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Reference Standards

01 42 10 - 1

SECTION 01 42 10

REFERENCE STANDARDS

PART 1 GENERAL

1.01 REFERENCE STANDARDS

A. Referenced editions of standard specifications, codes, and manuals form a part of this specification to the extent referenced.

B. These specifications take precedence when conflicting requirements occur between specifications and referenced standard.

1.02 JOBSITE REFERENCE STANDARDS

A. Maintain at fabrication site, access to referenced standard specifications, codes, and manuals required for work in progress at fabrication site. Make available for use by the Government.

B. Maintain onsite, access to referenced standard specifications, codes, and manuals required for onsite work in progress. Make available for use by Government.]

1.03 AVAILABILITY

A. Code of Federal Regulations (CFR):

1. Available online, authorized by the National Archives and Records

Administration (NARA) and the Government Printing Office (GPO), at http://www.gpo.gov/fdsys/search/home.action

B. Federal Specifications, Standards, and Commercial Item Descriptions; and Military Specifications:

1. Copies of Federal Specifications, Standards, and Commercial Item Descriptions may be obtained from GSA Federal Supply Service, see the provision at FAR 52.211-1, Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29.

2. Copies of Military Specifications may be obtained from Department of Defense, see the provision at FAR 52.211-2, Availability of Specifications, Standards, and Data Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST).

C. Bureau of Reclamation Documents:

1. Reclamation Safety and Health Standards (RSHS) may be downloaded at www.usbr.gov/ssle/safety/RSHS/rshs.html.

http://www.gpo.gov/fdsys/search/home.action http://www.usbr.gov/ssle/safety/RSHS/rshs.html

01 42 10 - 2

a. Hard copies of RSHS, stock number 024-003-00204-6, may be purchased from The Superintendent of Documents at the U.S. Government Printing Office (GPO), phone number 202-512-1800. Hard copies of RSHS are subject to revisions posted on the site shown above.

1) GPO online bookstore:

http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber= 024-003-00204-6.

2. Bureau of Reclamation manuals and other publications including significant scientific, technical, and engineering works are available from the National Technical Information Service (NTIS). Information regarding availability and pricing may be obtained by contacting NTIS at the following address:

United States Department of Commerce National Technical Information Service 5285 Port Royal Road Springfield, VA 22161 Telephone: 703-487-4650 or 1-800-553-6847

D. Industrial and Governmental Documents:

1. When a reference has a joint designation (e.g. ANSI/IEEE) these specifications generally cite the proponent organization (e.g. IEEE).

2. Addresses for obtaining industrial and governmental (other than Federal and

Bureau of Reclamation specifications and standards) specifications, standards, and codes are listed in Table 01 42 10A – Addresses for Specifications, Standards, and Codes.

Table 01 42 10A – Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

AA Aluminum Association 1400 Crystal Drive, Suite 430 Arlington, VA 22202 www.aluminum.org

703-358-2960

AGMA American Gear Manufacturers Association 130 East Randolph, Suite 2000 Chicago, IL 60601 www.aisc.org

312-670-2400

AISC American Institute of Steel Construction One East Wacker Drive, Suite 3100 Chicago, IL 60601-2001 www.aisc.org

312-670-2400 http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber=024-003-00204-6 http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber=024-003-00204-6 http://www.aluminum.org/ http://www.aisc.org/ http://www.aisc.org/

01 42 10 - 3

Table 01 42 10A – Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

ANSI American National Standards Institute 1819 L. Street, NW.

Washington, DC 20036 www.ansi.org

202-293-8020

ASCE American Society of Civil Engineers 1801 Alexander Bell Drive Reston, VA 20191 www.asce.org

800-548-2723

ASME American Society of Mechanical Engineers 3 Park Avenue New York, NY 10016-5990 www.asme.org

800-843-2763

ASTM ASTM International P.O. Box C700 100 Barr Harbor Drive West Conshohocken, PA 19428-2959 www.astm.org

610-832-9585

AWS American Welding Society 550 NW LeJeune Road Miami, FL 33126 www.amweld.org

800-443-9353 305-443-9353

AWWA American Water Works Associations 6666 W. Quincy Ave.

Denver, CO 80235 www.awwa.org

303-794-7711 800-926-7337

ICC International Code Council Western Regional Office (LA) 3060 Saturn Street, Suite 100 Brea, CA 92821 www.iccsafe.org

888-422-7233 Press 0

ICEA Insulated Cable Engineers Association P.O. Box 2694 Alpharetta, GA 30023 http://www.icea.net/ http://www.ansi.org/ http://www.asce.org/ http://www.asme.org/ http://www.astm.org/ http://www.amweld.org/ http://www.awwa.org/ http://www.iccsafe.org/

01 42 10 - 4

Table 01 42 10A – Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

IEC International Electrotechnical Commission 3 rue de Varembé, 1st Floor PO Box 131 CH-1211 Geneva 20, Switzerland www.iec.ch

+41 22 919 0211

IEEE Institute of Electrical and Electronics Engineers 3 Park Avenue,17th Floor New York, NY 10016-5997 www.ieee.org

212-419-7900

ISA International Society of Automation 67 T.W. Alexander Drive PO Box 12277 Research Triangle Park, NC 27709 www.isa.org

919-549-8411

MSS Manufacturers Standardization Society of the Valve and Fittings Industry 127 Park St. NE Vienna, VA 22180-4602 www.msshq.org

703-281-6613

NAAMM National Association of Architectural Metal Mfrs.

800 Roosevelt Rd. Bldg. C, Suite 312 Glen Ellyn, IL 60137 www.naamm.org

630-942-6591

NEMA National Electrical Manufacturers Association 1300 N 17th Street, Suite 1847 Rosslyn, VA 22209 www.nema.org

703-841-3200

NETA International Electrical Testing Association Inc.

3050 Old Centre Ave., Suite 102 Portage, MI 49024 http://www.netaworld.org/

269-488-6382

NFPA National Fire Protection Association One Batterymarch Park P.O. Box 9101 Quincy, MA 02269-9101 www.nfpa.org

800-344-3555 617-770-3000 http://www.iec.ch/ http://www.ieee.org/ http://www.isa.org/ http://www.msshq.org/ http://www.naamm.org/ http://www.nema.org/ http://www.netaworld.org/ http://www.nfpa.org/

01 42 10 - 5

Table 01 42 10A – Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

NIBS National Institute of Building Sciences 1090 Vermont Avenue, NW., Suite 700 Washington, DC 20005-4905 www.nibs.org

202-289-7800

TIA/EIA Telecommunications Industry Association/Electronic Industries Alliance 2500 Wilson Boulevard, Suite 300 Arlington, VA 22201 www.tiaonline.org

703-907-7700

UL Underwriters Laboratories, Inc.

333 Pfingsten Road Northbrook, IL 60062-2096 www.ul.com

847-272-8800

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

END OF SECTION

http://www.nibs.org/ http://www.ul.com/

01 42 10 - 6

Product Requirements

01 60 00 - 1

SECTION 01 60 00

PRODUCT REQUIREMENTS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. When the Price Schedule includes a separate item for furnishing a material, include cost of furnishing, hauling, storing, and handling in the price offered in the Price Schedule for the item.

2. When the Price Schedule does not include a separate item for furnishing a material, include cost of furnishing, hauling, storing, and handling in the price offered in the Price Schedule for work for which the material is required.

1.02 DEFINITIONS

A. Essential Characteristics: As used in these specifications, the term "essential characteristics" is synonymous with the term "salient characteristics."

B. Salient Characteristics: Those qualities of an item that are essential to ensure the intended use of the item can be satisfactorily realized.

1.03 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME B1.1-2003(R2008) Unified Inch Screw Threads, (UN and UNR

Thread Form)

2. ASME B1.20.1-2013(R2018) Pipe Threads, General Purpose, Inch

B. Bureau of Reclamation (Reclamation)

1. RSHS Reclamation Safety and Health Standards, including revisions posted at:

https://www.usbr.gov/ssle/safety/RSHS/rshs .html

1.04 DELIVERY, STORAGE, AND HANDLING

A. Transport and handle manufactured products in accordance with manufacturer's instructions.

https://www.usbr.gov/ssle/safety/RSHS/rshs.html https://www.usbr.gov/ssle/safety/RSHS/rshs.html

01 60 00 - 2

B. Store and protect manufactured products in accordance with manufacturer's instructions, RSHS, and the following at a minimum:

1. Shrink wrapping around all skid-mounted and ancillary equipment.

2. Stored in covered, temperature-controlled facility to protect equipment from weather elements, sunlight, humidity and freezing.

3. Include a copy of the manufacturer’s delivery, storage, and handling instructions with the stored and delivered materials.

4. Provide a copy of the manufacturer’s delivery, storage, and handling instructions to the recipient upon delivery.

C. Protect materials from adverse effects of moisture, sunlight, ultraviolet light, or weather during storage.

D. Remove and replace damaged items with new items.

E. Store curing compounds, sealants, adhesives, paints, coatings, sealers, joint compounds, grouts, and similar products at the temperature and environmental conditions recommended by manufacturer.

1.05 MAINTENANCE

A. Extra Materials:

1. Furnish additional maintenance materials specified as "extra materials" in specifications. Provide maintenance material identical to installed material and provide from same manufacturer's production lot as installed material.

2. Package extra materials for storage and label with complete product identification on packaging.

3. Deliver extra materials to Government…