Solicitation 127EAX23Q0007.pdf

CONSTRUCTION RFP SOL NO: 127EAX23Q0007

UNIT: GILA NATIONAL FOREST

PROJECT NAME: INSTALL NEW REPLACEMENT PUMP SYSTEM

1. Introduction. The USDA Forest Service, Gila National Forest, has a requirement for Well Pump Replacement project at Grant County Air Tanker Base to include the removal and disposal of one existing 5 horsepower well pumping system followed by the installation of one new 5 HP pumping system complete with new piping, wiring, and valves as needed.

Location and Description: This project will take place at the Grant County Airport Firebase 188 Airport Road, Hurley, NM 88043. Approximately six miles south of the town of Hurley, NM.

All questions shall be submitted in writing to the Contracting Officer (CO): michael.carico@usda.gov. In order to be eligible for award of a Federal contract, vendors need to maintain registration as active in the System for Award Management (SAM) at https://www.sam.gov .

2. Type of Award. As a result of this solicitation, Government anticipates awarding a Firm Fixed-Price contract using Lowest Price-Technically Acceptable. This is a 100% Small Business Set Aside to NAICS code 237110. PSC code F015.

Magnitude is less than $25,000

3. Basis for Award – Offerors must comply with the detailed instructions for the format and content of this Request for Quotations (RFQ); if the submitted offer does not comply with the detailed instructions for the format and content, the offer may be considered non-responsive and may render the Offeror ineligible for award.

4. How to submit your Offer. Submit RFQ pages 2 through 4 as your business proposal (pricing). Section M (Evaluation Factor Response) -- shall be submitted as outlined in Section M (last section in this solicitation).

Offers should be sent by email and should contain the Solicitation Number 12EAX23Q0007 in the subject line for the email. Email: michael.carico@usda.gov on or before:

March 30, 2023 at 0800 MST

Offers shall only be sent to the Contracting Officer: michael.carico@usda.gov mailto:michael.carico@usda.gov https://www.sam.gov/

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

1086628

USDA-FS CSA SOUTHWEST 7

333 BROADWAY BLVD SE

ALBUQUERQUE NM 87102-3498

7EAX

MICHAEL CARICO 602-225-5330

103/15/2023

127EAX23Q0007

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

INSTALL NEW REPLACEMENT PUMP FOR WELL - GRANT COUNTY AIR TANKER BASE - GILA NATIONAL

FOREST

MAGNITUDE OF THIS PROJECT IS LESS THAN $25,000

NAICS: 237110

DAVIS-BACON WAGES APPLIES - SEE ATTACHED WAGE DETERMINATION

BONDS ARE NOT REQUIRED

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 15 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR 52.211-10

03/30/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA-FS CSA SOUTHWEST 7

333 BROADWAY BLVD SE

ALBUQUERQUE NM 87102-3498

7EAX

MICHAEL E. CARICO

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

127EAX23Q0007

Delivery: 06/30/2023

Delivery Location Code: 83J3

USDA FS GILA NATIONAL FOREST

SILVER CITY FIRE CACHE

PO BOX 931

HURLEY NM 88043-0931 US

0001 Install new replacement pump for well

Period of Performance: 03/31/2023 to 06/30/2023

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SECTION C – STATEMENT OF WORK

GRANT COUNTY AIR TANKER BASE WELL PUMP REPLACEMENT

GRANT COUNTY AIRPORT

HURLEY, NEW MEXICO

SCOPE OF WORK

Work for the Air Tanker Base Well Pump Replacement project shall include the removal and disposal of one existing 5 horsepower well pumping system followed by the installation of one new 5 HP pumping system complete with new piping, wiring, and valves as needed.

BACKGROUND:

Currently there are two pumps being used at the airport firebase for its potable water system. This water system provides water for mixing retardant as well as water for restrooms, drinking, and other daily operations. The pump in question is beginning to show signs that it is nearing the operational life span and thus needing replacement. Pump is at a depth of approximately 420 feet below ground surface. This secondary pump helps to fill the retardant mixing tanks faster during high use periods and supply other areas of the compound. Without this secondary pump in place to assist with water demand other fire operations in the fire cache, heli-base, and air tanker base may be temporarily shut down due to lack of water. With both pumps in place working there is a sufficient supply of water for all firefighting operations even during high use periods.

LOCATION:

This project will take place at the Grant County Airport Firebase 188 Airport Road, Hurley, NM 88043.

Approximately six miles south of the town of Hurley, NM.

TASKS:

The contractor shall provide all labor, materials, tools, equipment, services, testing, supervision, and incidentals necessary to perform the work as described:

DEMOLITION: Work shall include the removal of the existing pump, drop pipe segments, control wiring, and any other components needed to facilitate the installation of the new system components. Contractor may use Forest Service owned dumpsters for disposal if desired.

PUMP INSTALLATION: Contractor shall install a new 5 HP Grundfos 25S50-26 pump, new 1-1/2” NPT galvanized T and C drop pipe, new 2 AWG 3 wire pump wire from pump-to-pump controller, and two stainless steel inline check valves. Contractor shall ensure all electrical and plumbing connections are tight, leak free, and conform to current local electrical and plumbing codes. Contractor will ensure proper system operation prior to acceptance and payment by the government. Contractor shall work carefully and take care to not damage any adjacent building or infrastructure.

Any accidental damage to government property shall be corrected by the contractor at no additional cost to the government. Contractor shall keep their workspace neat and tidy and clean up after themselves after project is completed. Contractor shall also provide any operation and maintenance documentation for use of the new system prior to acceptance and payment.

CONTRACT TIME

Contractor will be expected to be available to perform field work within 10 days of Notice to Proceed. This project requires the contractor to finish all field work within 15 calendar days after commencing field work.

Contractor shall procure all necessary construction items and equipment prior to commencing site work to minimize disruption to service.

All requirements and deliverables within the statement of work shall be completed within 15 calendar days of Notice to Proceed.

Technical Point-Of-Contacts Contracting Officer’s Representative: Harley Allsup, RHELM Staff Officer Email: Harley.allsup@usda.gov: Phone: 575-388-8261 FS-R3-Gila NF 3005 E. Camino del Bosque Silver City, NM 88061

SECTION D – SPECIFICATIONS

Specifications and Drawings / Photographs

See Section J attachments

Government furnished property / Contractor furnished property

GOVERNMENT FURNISHED PROPERTY

No furnished property

CONTRACTOR-FURNISHED SERVICES AND PROPERTY

The contractor shall be responsible for furnishing all labor, equipment to build fence, transportation, and miscellaneous supplies (contractor shall supply all items as described in the item list) necessary to complete the project in conformance with the specifications.

PRE-BID and PRE-WORK MEETING

No pre bid meeting will be offered. Interested contractors may visit the site on their own or use available online mapping applications to understand the project’s location and proximity to available resources. Contractor is also encouraged to visit the site to make any detailed measurements and familiarize with existing conditions. Any questions about the location and or logistics can be asked during the solicitation period.

PROTECTION AND SAFETY MEASURES

The contractor shall take precaution to protect all work and workmen during the construction period and shall provide and maintain adequate precautions during severe weather conditions. Electrical storms and flash flooding are predictable hazards in the summer months. Care should be taken as well to prevent damage to the work or theft of the materials.

SECTION E - INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes re-inspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

52.246-13 INSPECTION—DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS (AUG 1996)

(a) Unless otherwise designated by the specifications, all workmanship performed under the contract is subject to Government inspection at all times and places where dismantling or demolition work is being performed. The Contractor shall furnish promptly, and at no increase in contract price, all reasonable facilities, labor, and materials necessary for safe and convenient inspection by the Government.

The Government shall perform inspections in a manner that will not unduly delay the work.

(b) The Contractor is responsible for damage to property caused by defective workmanship. The Contractor shall promptly segregate and remove from the premises any unsatisfactory facilities, materials, and equipment used in contract performance, and promptly replaces them with satisfactory items. If the Contractor fails to proceed at once in a workmanlike manner with performance of the work or with the correction of defective workmanship, the Government may—

(1) By contract or otherwise, replace the facilities, materials, and equipment or correct the workmanship and charge the cost to the Contractor; and

(2) Terminate for default the Contractor’s right to proceed. The Contractor and any surety shall be liable, to the extent specified in the contract for any damage or cost of repair or replacement. (End of clause)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor’s expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor’s expense any damage to Government-owned or controlled real or personal property, when that damage is the result of—

(1) The Contractor’s failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor’s warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor’s expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall—

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor’s warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor’s, manufacturers, or supplier’s warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government’s rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud.

(End of clause)

SECTION F - DELIVERIES OR PERFORMANCE

FAR 52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives notice-to-proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 15 calendar days from issuance of notice-to-proceed. The time stated for completion shall include final cleanup of the premises.

AGAR 452.236-75 MAXIMUM WORK WEEK – CONSTRUCTION SCHEDULE (NOV 1996)

Within 5 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following information in writing for approval:

(a) A schedule as required by FAR 52.236-15, Schedules for Construction Contracts, and

SECTION G - Contract Administration Data

Government Furnished Items: See Section D Specifications, for Government furnished materials.

SECTION H - SPECIAL CONTRACT REQUIREMENTS

SECTION I - CONTRACT CLAUSES AND PROVISIONS

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/agar

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.202-1 Definitions (JUN 2020) 52.203-3 Gratuities (APR 1984) 52.203-5 Covenant Against Contingent Fees (MAY 2014) 52.203-6 Restrictions on Subcontractor Sales to the Government (SEP 2006) 52.203-7 Anti-Kickback Procedures (MAY 2014) 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (MAY 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (OCT 2010) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) 52.204-13 System for Award Management Maintenance (OCT 2018) 52.204-14 Service Contract Reporting Requirements (OCT 2016) 52.204-16 Commercial and Government Entity Code Reporting (AUG 2020).

52.204-17 Ownership or Control of Offeror (AUG 2020) 52.204-18 Commercial and Government Entity Code Maintenance (AUG 2020) 52.204-20 Predecessor of Offeror (AUG 2020) 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (JUL 2018) 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment

(AUG 2020)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

(AUG 2020)

52.204-26 Covered Telecommunications Equipment or Services-Representation (AUG 2020)

52.209-6 Protecting the Government’s Interest when Subcontracting with Contractors Debarred, Suspended, or

Proposed for Debarment (OCT 2015) 52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) 52.211-18 Variation in Estimated Quantity (APR 1984) 52.215-2 Audit and Records -- Negotiation (OCT 2010) 52.219-6 Notice of Total Small Business Set-Aside (MAR 2020) 52.219-8 Utilization of Small Business Concerns (OCT 2018) 52.219-14 Limitations on Subcontracting (MAR 2020) 52.222-3 Convict Labor (JUN 2003) 52.222-4 Contract Work Hours and Safety Standards Act -- Overtime Compensation (MAY 2018) 52.222-6 Construction Wage Rate Requirements (AUG 2018) 52.222-7 Withholding of Funds (MAY 2014) 52.222-8 Payrolls and Basic Records (AUG 2018) 52.222-9 Apprentices and Trainees (JUL 2005) 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) 52.222-11 Subcontracts (Labor Standards) (MAY 2014) 52.222-12 Contract Termination - Debarment (MAY 2014) 52.222-13 Compliance with Davis-Bacon and Related Act Regulations (MAY 2014) 52.222-14 Disputes Concerning Labor Standards (FEB 1988) 52.222-15 Certification of Eligibility (MAY 2014)

52.222-21 Prohibition of Segregated Facilities (APR 2015) 52.222-26 Equal Opportunity (APR 2016) 52.222-27 Affirmative Action Compliance Requirements for Construction (APR 2015) 52.222-35 Equal Opportunity for Veterans (JUN 2020) 52.222-36 Equal Opportunity for Workers With Disabilities (JUN 2020) 52.222-37 Employment Reports on Veterans (OCT 2015) 52.222-50 Combating Trafficking in Persons (MAR 2015) 52.223-1 Biobased Product Certification (MAY 2012) 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (SEP 2013) 52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011) 52.223-6 Drug-Free Workplace (MAY 2001) 52.223-15 Energy Efficiency in Energy-Consuming Products (DEC 2007) 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving 52.225-1 Buy American—Supplies (MAY 2014) 52.225-9 Buy American—Construction Materials (MAY 2014) 52.225-10 Notice of Buy American Requirement-Construction Materials (MAY 2014) 52.225-13 Restrictions on Certain Foreign Purchases (JUN 2008) 52.225-25 Prohibition on Contracting With Entities Engaging in Certain Activities or Transactions Relating to Iran—

Representation and Certifications (JUN 2020) 52.227-1 Authorization and Consent (DEC 2007) 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (DEC 2007) 52.227-4 Patent Indemnity -- Construction Contracts (DEC 2007) 52.229-4 Federal, State, and Local Taxes (State and Local Adjustments) (FEB 2013) 52.232-5 Payments Under Fixed-Price Construction Contracts (MAY 2014) 52.232-17 Interest (MAY 2014) 52.232-23 Assignment of Claims (MAY 2014) 52.232-27 Prompt Payment (JAN 2017) 52.232-33 Payment by Electronic Funds Transfer –System for Award Management (OCT 2018) 52.232-39 Unenforceability of Unauthorized Obligations 52.233-1 Disputes (MAY 2014) 52.233-3 Protest After Award (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) 52.236-5 Material and Workmanship.

52.236-6 Superintendence by The Contractor (APR 1984) 52.236-7 Permits and Responsibilities.

52.236-8 Other Contracts (APR 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (APR 1984) 52.236-10 Operations and Storage Areas (APR 1984) 52.236-11 Use and Possession Prior to Completion (APR 1984) 52.236-12 Cleaning Up (APR 1984) 52.236-13 Accident Prevention (NOV 1991) Alternate I (NOV 1991) 52.236-15 Schedules for Construction Contracts (APR 1984) 52.236-16 Quantity Surveys (APR 1984) 52.236-17 Layout of Work (APR 1984) 52.236-19 Organization and Direction of the Work 52.236-21 Specifications and Drawings for Construction (FEB 1997) 52.236-26 Preconstruction Conference (FEB 1995) 52.236-27 Site Visit (Construction) 52.242-13 Bankruptcy (JUL 1995) 52.243-1 Changes (AUG 1987) 52.243-5 Changes and Changed Conditions (APR 1981) 52.244-6 Subcontracts for Commercial Items (DEC 2015) 52.246-21 Warranty of Construction (MAR 1994) 52.248-3 Value Engineering – Construction (OCT 2015)

52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012)--Alternate I (SEP 1996) 52.249-10 Default (Fixed-Price Construction) (APR 1984)

452.211-73 Attachments to Statements of Work/Specifications 452.232-70 Reimbursement for Bond Premiums – Fixed-Price Construction Contracts (NOV 1996) 452.236-71 Prohibition Against the Use of Lead-Paint (NOV 1996) 452.236-72 Use of Premises (NOV 1996) 452.236-73 Archeological or Historic Sites (FEB 1988) 452.236-74 Control of Erosion, Sedimentation and Pollution (NOV 1996) 452.236-76 Samples and Certificates (FEB 1988) 452.236-77 Emergency Response (NOV 1996) 452.236-78 Fire Suppression and Liability (MAY 2014)

52.204-6 UNIQUE ENTITY IDENTIFIER (OCT 2016)

(a) Definition. As used in this provision- Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company headquarters name and address (reporting relationship within your entity).

(End of provision)

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

(a) Definitions. As used in this provision— “Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Registered in the System for Award Management (SAM) means that–

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into SAM

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record “Active”.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or

Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) https://www.acquisition.gov/far/part-32#FAR_Subpart_32_11 http://www.sam.gov/ http://www.sam.gov/ https://www.acquisition.gov/content/part-32-contract-financing#i1080713 https://www.acquisition.gov/content/part-4-administrative-and-information-matters#i1121746 http://www.sam.gov/

(1) An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state, and Zip Code.t

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company headquarters name and address (reporting relationship within your entity).

(d) Processing time should be taken into consideration when registering. Offerors who are not registered in SAM should consider applying for registration immediately upon receipt of this solicitation. See https://ww.sam.gov for information on registration.

(End of provision)

452.228-71 INSURANCE COVERAGE (NOV 1996)

Pursuant to FAR clause 52.228-5, Insurance-Work on a Government Installation, the Contractor will be required to present evidence to show, as a minimum, the amounts of insurance coverage indicated below:

(a) Workers Compensation and Employer's Liability. The Contractor is required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage.

Employer's liability coverage of at least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit worker's compensation to be written by private carriers.

(b) General Liability. The Contractor shall have bodily injury liability insurance coverage written on a comprehensive form of policy of at least $500,000 per occurrence

(c) Automobile Liability. The Contractor shall have automobile liability insurance written on a comprehensive form of policy.

The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and 500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage or loss.

(d) Aircraft Public and Passenger Liability. When aircraft are used in connection with performing the contract, the Contractor shall have aircraft public and passenger liability insurance. Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger injury. Coverage for passenger injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

(End of Clause)

Order of Precedence--Construction

Any inconsistency in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The Schedule (excluding the specifications)

(2) Representations and Other Instructions

(3) Contract Clauses

(4) Other Documents, Exhibits, and Attachments

(5) The Specifications

(6) Drawings

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

EXHIBIT 1 Photographs

EXHIBIT 2 General Decision Number NM20230012 03/03/2023

PART IV– REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF OFFERORS OR

RESPONDENTS

NOTE: Offerors should address questions concerning VETS-100 reporting and reporting requirements to the Office of Veterans Employment and Training Services offices at the following address:

U. S. Department of Labor VETS-100 Reporting 4200 Forbes Blvd., Suite 202 Lanham, MD 20703 Telephone: (301) 306-6752

Website: www.vets100.cudenver.edu Reporting Questions: HelpDesk@vets100.com

Reporting Verification: Verify@vets100.com

AGAR 452.219-70 SIZE STANDARD AND NAICS CODE INFORMATION (JANUARY 2005)

The North American Industrial classification System Code(s) and business size standard(s) describing the products and/or services to be acquired under this solicitation are listed below:

Contract line item(s): ALL --NAICS Code 237110 --Size Standard $39.5 Million

The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is 237110.

(2) The small business size standard is $39.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) □ Paragraph (d) applies.

(ii) □ Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063268 https://www.acquisition.gov/content/part-13-simplified-acquisition-procedures#i1112458 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063408

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast

Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.)

This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_203-18 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063736 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063796 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#id19CAC0P0ESS https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1062479 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1062558 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#id165RA0UH01A https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1059991 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1059247 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1057235 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1057302 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055729 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055793 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055782 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055793 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1056289 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1052963 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1052973 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053040 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#CDCHDCIFF4 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053411 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053372 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053526 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053446 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053693 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053648 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1054426

(xxiv) on Contracting With Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications., Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran- Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.] _x_ (i) 52.204-17, Ownership or Control of Offeror.

_x_ (ii) 52.204-20, Predecessor of Offeror.

_x_ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

__ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services-Certification.

__ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA–Designated

Products (Alternate I only).

__ (vii) 52.227-6, Royalty Information.

__ (A) Basic.

__ (B) Alternate I.

__ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and…