Sol_140R1725Q0006.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

R17

See Schedule

0011285556 CODE 16. ADMINISTERED BYCODE

X

X

X

335311

SIZE STANDARD:

100.00 % FOR:SET ASIDE:UNRESTRICTED ORR17

REQUEST FOR

PROPOSAL

(RFP)

INVITATION

FOR BID (IFB)

10. THIS ACQUISITION ISCODE

REQUEST FOR

QUOTE (RFQ)

14. METHOD OF SOLICITATION

13b. RATING

NORTH AMERICAN INDUSTRY

CLASSIFICATION STANDARD

(NAICS):

SMALL BUSINESS

09/12/2025 1200 PD

08/27/2025

5096339327Terry Mest (No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBER a. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

140R1725Q0006

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 52 0044013933OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

TELEPHONE NO.

17a. CONTRACTOR/

See Schedule

15. DELIVER TO

Grand Coulee WA 99133 Hwy 155, PO Box 620 Grand Coulee Acquisition Group Pacific Northwest Region

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FREE ON BOARD

(FOB) DESTINATION UNLESS

BLOCK IS MARKED

11.

SEE SCHEDULE

12. DISCOUNT TERMS THIS CONTRACT IS A RATED

ORDER UNDER THE DEFENSE

PRIORITIES AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

8(A)

Bureau of Reclamation

WOMEN-OWNED SMALL

BUSINESS (WOSB)

ECONOMICALLY DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

ADMINISTERED BY:

Bureau of Reclamation Pacific Northwest Region Grand Coulee Acquisition Group Hwy 155, PO Box 620 Grand Coulee WA 99133 US

DELIVER TO:

Bureau of Reclamation-PN-GCPO Grand Coulee - Receiving Hwy 155 - Warehouse B - Door 6 Continued ...

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

XX

DATED

Terry Mest

. YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Government Use Only)

OFFER

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT: REFERENCE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 11/2021) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

Industrial Area

Grand Coulee WA 99133 US

Delivery: 08/26/2027

00010 Portable Transformer pursuant to the attached 1 EA specifications.

Product/Service Code: 6150

Product/Service Description: MISCELLANEOUS

ELECTRIC POWER AND DISTRIBUTION EQUIPMENT

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

52 2 of

CONTINUATION OF FORM 1449, SCHEDULE OF SUPPLIES/SERVICES

PORTABLE OUTDOOR UNIT SUBSTATION

PART 1 – GENERAL

1.1 REQUIREMENT

A. The Contractor shall furnish one (1) skid mounted, outdoor, portable unit substation (Unit Substation) complete from the incoming line terminals to the outgoing circuit breaker load terminals as specified herein.

B. The Unit Substation shall consist of transformer and secondary equipment as specified below. The manufacturer of the Unit Substation shall furnish and coordinate all major components of the substation, including incoming primary cable section, transformer, and low-voltage section.

1.2 REFERENCE SPECIFICATIONS, CODES AND STANDARDS

A. The Unit Substation shall be designed, assembled, and tested in accordance with latest applicable standards of NEMA, IEEE and ANSI, applicable to its two major sections.

B. Transformer

1. IEEE C57.12.01, General Requirements for Dry Type Distribution and

Power Transformers, Including Those with Solid cast and/or Resin

Encapsulated Windings.

2. IEEE C57.12.91, Test Code for Dry Type Distribution and Power

Transformers.

3. NEMA TR 1, Transformers, Regulators, and Reactors.

4. IEEE 62.11, Metal Oxide Surge arresters for AC Power Circuits.

C. LV Switchboard

1. NEMA PB 2, Dead Front Distribution Switchboards.

2. NEMA PB 2.1, Proper Handling, Installation, Operation and Maintenance of Dead Front Switchboards.

D. Power Circuit Breakers

1. IEEE C37.13, Low Voltage AC Power Circuit Breakers Used in

Enclosures.

2. IEEE C37.16, Preferred Ratings, Related Requirements, and Application

Recommendations for Low Voltage AC and DC Power Circuit Breakers.

3. C37.17, Standard for Trip Systems for Low Voltage AC and General-

Purpose DC Power Circuit Breakers.

4. C37.50, Low Voltage AC Power Circuit Breakers Used in Enclosures -

Test Procedures.

E. Molded Case Circuit Breakers

1. NEMA AB 3, Molded Case Circuit Breakers and Their Application.

2. NEMA AB 4, Guidelines for Inspection and Preventive Maintenance of

Molded Case Circuit Breakers Used in Commercial and Industrial

Applications.

F. National Fire Protection Association (NFPA):

1. NFPA 70-2023 National Electrical Code (NEC)

1.3 SUBMITTALS

The following requirements/qualifications will be submitted along with contractor’s quote. Technical evaluation of offeror’s ability to provide the final product meeting the specifications in Part 2 of this Performance Work Statement will be considered in award selection.

A. Contractor will submit a technical description of the equipment being offered in sufficient detail to evaluate compliance with the requirements in the solicitation

B. Contractor will describe in their quote how the power substation is designed and assembled as a complete integrated system by a manufacture who specializes in the manufacturer of power substations. All components for the Portable Power

Substation must be integrated well and purposely designed in the final assembly.

C. Contractor will provide the manufacturer’s ISO 9001 or 9002 certification.

D. Contractor will provide a list of the manufacturer’s commercially fabricated power substations with similar equipment during the past five (5) years which demonstrates previous experience with this type of requirement.

1.4 DELIVERABLES

A. The following deliverables are required to be delivered concurrent with delivery of the Portable Outdoor Unit Substation.

1. Manufacturer’s data sheets for all components used in the system including but not limited to: medium voltage switches, fuses, low voltage circuit breakers, power transformer, metering, etc.

2. Manufacturer’s data sheets for all of the control components including but not limited to: control switches, pushbuttons, indicating meters, indicating lights, auxiliary control relays, power supplies, etc.

3. Plan, elevation, and detail drawings of the Unit Substation showing arrangement of the transformer section, and low voltage distribution sections. Drawings shall be drawn to scale. Drawing legends shall be furnished to identify all components. The following minimum information shall be included:

a. Front view elevation.

b. Floor plan.

c. Single line.

d. Schematic diagram.

e. Nameplate schedule.

f. Component list.

g. Conduit entry/exit locations.

h. Assembly ratings including:

1) Short-circuit rating.

2) Voltage.

3) Continuous current.

4) Basic Impulse level for equipment over 600 volts.

5) kVA.

i. Major component ratings including:

1) Voltage.

2) Continuous current.

3) Interrupting ratings.

j. Cable terminal sizes.

k. Connection details between close-coupled assemblies.

l. Composite front view and floor plan of close-coupled assemblies.

4. Schematic and wiring diagrams for the Unit Substation. Schematic diagrams for component interconnections for the control, monitoring, and protective circuits shall be included. Drawing legends shall be furnished to identify all components and wiring.

5. Equipment elevation drawings showing arrangement of all control and monitoring devices for the Unit Substation. Drawing legends shall be furnished to identify all components.

B. Unit Substation skid drawings, detailing locations for skid handling and anchoring of the unit Substation components.

C. Certified production test reports.

D. Operation and maintenance instructions for the Unit Substation. Instructions shall include transformer, and low voltage circuit breaker operation and maintenance requirements.

PART 2 SPECIFICATIONS

2.1 SUBSTATION TRANSFORMER

A. The ratings of the transformer shall be as follows:

1. kVA rating 3000 kVA

2. Cooling class AA (Ventilated Self Cooled)

3. Phase 3

4. Temperature rise 115 C by Resistance

5. Impedance 5.75%, ±7.5%

6. Angular displacement IEC Vector Dy1

7. HV winding 13.8 kV, Delta

8. HV BIL 95 kV

9. HV de energized taps 14.490 kV

14.145 kV

13.800 kV

13.455 kV

13.110 kV

10. LV winding 480V, Wye (solid grounded)

11. LV BIL 10 kV

B. Construction

1. Transformer shall be cooled by natural air convection (AA).

2. The electrical insulation system shall utilize class H material in a fully rated 220 degrees C system. Transformer design temperature rise shall be based on a 30 degrees C average ambient over a 24-hour period with a maximum of 40 degrees C. Solid insulation in the transformer shall consist of inorganic materials such as porcelain, glass fiber, electrical grade glass polyester, or Nomex. All insulating materials must be rated for continuous

220 degree C duty.

3. The transformer shall be designed for a temperature rise of 115ºC and shall be capable of operating at 17% above base nameplate kVA capacity continuously without any loss of life.

4. The transformer shall be designed to meet the sound level standards for dry-type transformers as defined in NEMA TR1. The measurement procedure shall be as specified in ANSI C57.12.90.

5. The transformer shall be UL labeled.

6. The transformer shall be of explosion-resistant, fire-resistant, air-insulated, ventilated dry-type construction, and cooled by the natural circulation of air through the windings.

7. High-voltage and low-voltage windings shall be copper. Insulation between layers of the windings shall be by Insuldur paper or equal.

8. The high- and low-voltage coil assembly shall be Vacuum Pressure

Impregnated (VPI) polyester. The high- and low-voltage coil assembly shall be preheated to evaporate any moisture, then placed into a vacuum pressure tank. The air in the tank shall be evacuated; and at extremely low absolute pressure, all air bubbles are to be drawn out of the insulating materials. The resin shall be introduced to a level that submerges all parts while the vacuum is maintained. Then the vacuum shall be released and pressure applied, after which the coil shall be removed and placed in an oven in order for the resin to catalyze into a composite mass, completely sealing and binding the winding.

9. The transformer shall be provided with a NEMA 3R rated outdoor enclosure. The transformer shall be of heavy gauge sheet steel construction, equipped with removable panels for access to the core and coils. Front and rear panels shall incorporate louvered ventilating grills.

C. Accessories

1. Transformer shall include:

a. Diagram instruction plate.

b. Provisions for lifting and jacking.

c. Removable center panel for access to high-voltage strap-type connector taps for de-energized tap changing.

d. Two ground pads with continuous ground bus.

2. A temperature monitoring panel with display of winding temperature for each phase shall be provided. An adjustable high temperature alarm and high-high temperature trip contact shall be provided for remote alarm and trip functions.

3. Station class, metal oxide varistor (MOV) surge arresters shall be furnished for the high voltage winding. The arresters shall be suitable for operation under standard service conditions as defined in IEEE 62.11. The surge arresters shall have a voltage rating of 18 kV with a maximum continuous operating voltage (MCOV) of 15.3 kV.

D. Finish

1. The paint shall be applied using an electrostatically deposited dry powder system to a minimum of three (3) mils average thickness. Units shall be painted ANSI 61 and shall match the secondary equipment.

E. Terminal Compartments/Flange Connections

1. The transformer unit supplied shall include a HV cable connection compartment and a LV close coupled flange. Connections between the transformer and secondary shall be solid copper bar and flexible bus braid.

2. The high voltage connection compartment shall be sized to accommodate standard 15kV stress cone cable terminations. The high voltage winding surge arresters shall be mounted in the high voltage connection compartment.

2.2 LOW VOLTAGE SECONDARY SWITCHBOARD

A. The Low Voltage Switchboard shall be standard NEMA PB 2, NEMA 3R outdoor construction.

B. Ratings

1. Voltage rating shall be 480/277V, Grounded Wye, 4000 A. The entire assembly shall be suitable for operation on a 480 V, 3 phase, 60 Hz, wye connected, grounded system.

2. The bus system shall have a minimum short circuit withstand rating of

65,000A rms symmetrical.

3. All circuit breakers shall have a minimum symmetrical interrupting capacity of 65,000A.

4. The assembly shall meet NEMA PB 2 standards.

C. Construction

1. The switchboard shall consist of the required number of vertical sections bolted together to form a rigid assembly. The sides shall be covered with removable bolt-on covers. All edges of front covers or hinged front panels shall be formed. Provide ventilators located on the top of the switchboard over the breaker and bus compartments to ensure adequate ventilation within the enclosure. The rear covers shall be fabricated in two, or more, pieces for ease of handling and shall be mounted using captive hardware.

2. The assembly shall be provided with adequate lifting means and shall be capable of being moved into installation position and bolted directly to the skid assembly mounting sills.

3. The main circuit breaker shall be individually mounted in a single section.

The feeder circuit breakers shall be group mounted in a panelboard type arrangement.

D. Bus

1. All bus bars shall be silver-plated copper. Main horizontal bus bars shall be mounted with all three phases arranged in the same vertical plane. Bus sizing shall be based on ANSI standard temperature rise criteria of 65°C over a 40°C ambient (outside the enclosure).

2. A copper ground bus shall be furnished firmly secured to each vertical section structure and shall extend the entire length of the switchboard. The ground bus short-time withstand rating shall meet that of the largest circuit breaker within the assembly.

3. All hardware used on conductors shall be high-tensile strength and zinc-plated. All bus joints shall be provided with Belleville-type washers.

E. Wiring/Terminations

1. Small wiring, necessary fuse blocks and terminal blocks within the switchboard shall be furnished as required. Control components mounted within the assembly shall be suitably marked for identification corresponding to the appropriate designations on manufacturer’s wiring diagrams.

2. Provide a front accessible, isolated vertical wireway for routing of factory and field wiring. Factory provisions shall be made for securing field wiring without the need for adhesive wire anchors.

3. Front access to all circuit breaker secondary connection points shall be provided for ease of troubleshooting and connection to external field connections without the need of removing the circuit breaker for access.

4. All control wire shall be type SIS. Control wiring shall be 14 AWG for control circuits and 12 AWG for current transformer circuits. Wire bundles shall be secured with nylon ties and anchored to the assembly with the use of pre-punched wire lances or nylon non-adhesive anchors. All current transformer secondary leads shall first be connected to conveniently accessible shorting terminal blocks before connecting to any other device.

Shorting screws with provisions for storage shall be provided. All groups of control wires leaving the switchboard shall be provided with terminal blocks with suitable numbering strips and provisions for #10 AWG field connections. Each control wire shall be marked with nylon sleeve type wire markers. Provide wire markers at each end of all control wiring.

Plug-in terminal blocks shall be provided for all shipping split wires.

Terminal connections to remote devices or sources shall be front accessible via doors above each circuit breaker.

F. Main Circuit Breaker

1. The main protective device shall be a 4,000 A low voltage power circuit breaker. Breaker shall be UL listed for application in their intended enclosures for 100% of their continuous ampere rating.

2. Power circuit breakers shall be constructed and tested in accordance with

ANSI C37.13, C37.16, C37.17, and C37.50. The breaker shall carry a UL label.

3. Breaker shall be provided in fixed mounted configuration.

4. Power circuit breaker shall utilize a two step stored energy mechanism to charge the closing springs. The closing of the breaker contacts shall automatically charge the opening springs to ensure quick break operation.

5. Breaker shall be electrically operated.

6. The electrically operated breakers shall be complete with 120V, 60 Hz motor operators. The charging time of the motor shall not exceed 6 seconds. The breaker shall also include provisions for manually charging the stored energy system.

7. The power circuit breaker shall have a closing time of not more than three cycles.

8. The primary contacts shall have an easily accessible wear indicator to indicate contact erosion.

9. The power circuit breaker shall have windows in the front cover to clearly view any electrical accessories that are mounted in the breaker. The accessory shall have a label that will indicate its function and voltage. The accessories shall be plug and lock type and UL listed for easy field installation. They shall be modular in design and shall be common to all frame sizes and ratings.

10. The breaker control interface shall have color coded visual indicators to indicate contact open or closed positions, as well as mechanism charged and discharged positions. Manual control pushbuttons on the breaker face shall be provided for opening and closing the breaker. The power circuit breaker shall have a "Positive On" feature. The breaker flag shall read

"Closed" if the contacts are welded and the breaker is tripped or opened.

11. Breaker shall be provided with position indicating lights; Green Open, Red

Closed.

12. Breaker shall be provided with a control switch for manually opening and closing the breaker. The switch shall be spring return to center position with "Trip" to the left and "Close" to the right.

13. Trip units

a. Low voltage power circuit breaker shall be equipped with a solid state tripping system consisting of three 4,000 A current sensors, microprocessor based trip device and flux transfer shunt trip.

Current sensors shall provide operation and signal function. The trip unit shall use microprocessor based technology to provide the basic adjustable time current protection functions. True rms sensing circuit protection shall be achieved by analyzing the secondary current signals received from the circuit breaker current sensors and initiating trip signals to the circuit breaker trip actuators when predetermined trip levels and time delay settings are reached.

Interchangeable current sensors with their associated rating plug shall establish the continuous trip rating of each circuit breaker.

b. The trip unit shall have an information system that utilizes battery backup LEDs to indicate mode of trip following an automatic trip operation. The indication of the mode of trip shall be retained after an automatic trip. A reset button shall be provided to turn off the

LED indication after an automatic trip. A test pushbutton shall energize a LED to indicate the battery status.

c. The trip unit shall be provided with a display panel, including a representation of the time/current curve that will indicate the protection functions. The unit shall be continuously self checking and provide a visual indication that the internal circuitry is being monitored and is fully operational.

d. System coordination shall be provided by the following microprocessor based programmable time current curve shaping adjustments. The short time pick up adjustment shall be dependent on the long delay setting.

1) 4000 A sensor rating

2) Programmable long time setting.

3) Programmable long time delay with selectable I²t curve shaping.

4) Programmable short time setting.

5) Programmable short time delay with selectable flat or I²t curve shaping.

6) Programmable instantaneous setting.

7) Programmable ground fault pickup

8) Programmable ground fault delay

G. Molded Case Feeder Section Circuit Breakers

1. Provide a total of ten (10) 400A, 480 V, 3-pole rated molded case feeder circuit breakers. Breakers shall have a minimum interrupting rating of

65,000 A rms symm at 480 V.

2. Furnish bolt on type fully rated circuit breakers. Provide circuit breakers marked with ampere trip rating.

3. Furnish all breakers with quick make, quick break, toggle mechanisms; and microprocessor trip units. Circuit breakers shall meet NEMA AB 3 criteria. Provide indication of automatic tripping by the breaker handle assuming a distinctive position from the manual ON and OFF position.

Furnish breaker handles that are trip free on overloads.

4. Breaker trip units shall adjustable electronic type. Trip units shall include the following features:

a. 400 A rating plug

b. Adjustable long time pickup

c. Adjustable long time pickup delay

d. Adjustable short time pickup

e. Adjustable short time pickup delay

f. Adjustable instantaneous pickup

g. Adjustable ground fault pickup

h. Adjustable ground fault delay

H. Metering

1. Provide a separate metering compartment with front hinged door.

2. Provide a Meter Monitor (MM) device having the features and functions specified herein.

3. The MM shall monitor and display the functions listed herein with the accuracy indicated. The MM shall be UL listed and meet ANSI standard

C37.90.1 for surge withstand.

4. Metered Values shall be as follows with accuracy in percent of full scale as indicated:

a. AC Phase Voltage and Amperes +/- 0.5%

b. Watts, VA, Vars 1.0%

c. Power Factor 2.0%

d. Frequency +/- 0.1 Hz

e. Watthours, VA, Varhours +/- 1.0%

f. Peak Demand.

5. The MM shall be supplied with three (3) current transformers sized as required. Potential transformers shall be self-included and fused for up to

600 volts with potential connections suitable for 3-phase 480/277V.

6. The MM control power shall be capable of being supplied from the monitored incoming AC line.

I. Switchboard Enclosure

1. NEMA 3R enclosure construction. Provide full height doors over the switchboard front sections. The doors shall be provided with 3-point latches.

2. Nameplates

a. Engraved nameplates, mounted on the face of the assembly, shall be furnished for all main and feeder circuits as indicated on the

Drawings. Nameplates shall be laminated plastic, white characters on black background, and secured with screws. Characters shall be

3/16-inch high, minimum.

b. Furnish master nameplate giving switchboard designation, voltage ampere rating, short-circuit rating, and manufacturer’s name.

c. Control components mounted within the assembly, such as fuse blocks, relays, pushbuttons, switches, etc., shall be suitably marked for identification corresponding to appropriate designations on manufacturer’s drawings.

3. Provisions shall be made for routing the feeder cables into the bottom of the switchboard up to the feeder circuit breakers. Furnish provisions for anchoring/support of the feeder circuit breaker cable connections.

4. All exterior and interior steel surfaces of the switchboard shall be properly cleaned and provided with a rust-inhibiting phosphatized coating. Color and finish of the switchboard shall be ANSI 61.

2.3 MOUNTING SKID

A. Provide a structural steel skid for mounting the Unit Substation equipment. The skid shall be designed for easily relocating the Unit Substation using an overhead crane.

B. Provisions shall be made for routing the feeder circuit breaker cables under the skid and up into the low voltage switchboard sections.

C. The skid shall be provided with permanent lifting provisions for relocating the

Unit Substation within the powerhouse using an overhead crane. Spreader bars and sling assembly shall be provided for attaching the Unit Substation assembly skid lifting points to the powerhouse crane hook.

D. The Unit Substation components shall be permanently anchored to the skid assembly at the factory prior to shipment. The assembly center of gravity shall be marked on the assembled unit. Total gross weight shall be clearly marked on the

Unit Substation assembly.

E. All exterior and interior steel surfaces of the skid shall be properly cleaned and provided with a rust-inhibiting phosphatized coating. Color and finish of the skid shall be ANSI 61.

PART 3 EXECUTION

3.1 FACTORY TESTING

A. Standard factory tests shall be performed on the primary equipment provided under this section. All tests shall be in accordance with the latest version of ANSI and NEMA standards.

B. The following factory tests shall be made on the power transformer. All tests shall be in accordance with the latest revision of ANSI and NEMA standards.

1. Resistance measurements of all windings on the rated voltage connection of the transformer and at the tap extremes of the transformer.

2. Ratio tests on the rated voltage connection and on all tap connections.

3. Polarity and phase-relation tests on the rated voltage connections.

4. No-load loss at rated voltage on the rated voltage connection.

5. Exciting current at rated voltage on the rated voltage connection.

6. Impedance and load loss at rated current on the rated voltage connection of the transformer and at the tap extremes of the transformer.

7. Applied potential test.

8. Induced potential tests.

9. ANSI impulse test on all primary windings.

C. The following standard factory tests shall be performed on the secondary equipment provided under this section. All tests shall be in accordance with the latest version of ANSI and NEMA standards.

1. The switchboard shall be completely assembled, wired, adjusted and tested at the factory. After assembly, the complete switchboard shall be tested to ensure the accuracy of the wiring and the functioning of all equipment.

The main bus system shall be given a dielectric test of 2500 volts for one minute between live parts and ground and between opposite polarities.

2. The wiring and control circuits shall be given a dielectric test of 1500 volts for one minute or 1800 volts for one second between live parts and ground, in accordance with ANSI C37.20.1.

D. The Manufacturer shall provide three (3) certified copies of factory test reports.

E. Factory tests as outlined above shall be witnessed by the contractor’s representative.

1. The manufacturer shall notify the contractor two (2) weeks prior to the date the tests are to be performed.

PART 4 SHIPPING

1. Material shall be covered during transport from manufacturer to site to protect from elements and debris, and road grime.

END OF SECTION

Clauses

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation: https://www.acquisition.gov/far Department of the Interior Acquisition Regulation: https://www.acquisition.gov/diar

(End of clause)

The following clauses are incorporated by reference.

52.212-4 CONTRACT TERMS AND CONDITIONS –COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (NOV 2023)

Addendum to 52.212-4, Sub-clause (o), Warranty, is tailored to read as follows: (o) Warranty:

Manufacture’s Standard Warranty is required.

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.242-15 STOP-WORK ORDER (AUG 1989)

The following clauses are incorporated in full text.

DOI-AAAP-0028 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS-INVOICE

PROCESSING PLATFORM (IPP) (MAR 2023)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's

Invoice Processing Platform System (IPP).

'Payment request' means any request for contract financing payment or invoice payment by the

Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4

Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Concurrent to submitting an invoice in IPP, the contractor may submit any supporting documentation to bor-sha-Invoices@usbr.gov and tmest@usbr.gov. Contractors are cautioned that supporting documentation e-mailed to the contracting officer and contract specialist must not conflict with the IPP submission. Conflicts between the IPP submission and supporting documentation may result in a delay in approval and/or rejection of submitted invoices.

When e-mailing supporting documentation, the subject line of the email shall be formatted as follows:

Contract Number, Invoice Number, Contracting Officer's last name (e.g., 140R2018R00000_Invoice No.

1_Smith). The invoice shall be attached to the email and named using the following format: Contract http://www.acquisition.gov/far http://www.acquisition.gov/diar http://www.ipp.gov/ mailto:bor-sha-Invoices@usbr.gov mailto:tmest@usbr.gov

Number, Contractor Name, Invoice Number, Invoice Amount (e.g., 140R2022R00000_World Test, Inc. -

Inv. No. 1 - $5,678). Invoices shall not include information that would compromise Personally

Identifiable Information, such as full social security numbers, dates of birth, etc. The final invoice shall be submitted and will be approved in accordance with payment terms and conditions contained in the contract, after all, if any, settlement actions are complete. The contractor must clearly identify the last payment as the ‘Final Invoice’.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone

(866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

DOI-AAAP-0050 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (DEC

2015)

1) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3) We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4) When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5) Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

mailto:IPPCustomerSupport@fiscal.treasury.gov http://www.cpars.gov/ http://www.cpars.gov/

a) Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b) Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c) All information provided should be reviewed for accuracy prior to submission.

d) If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e) Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f) If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6) The following guidelines apply concerning your use of the past performance evaluation:

a) Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b) Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c) Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7) If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8) A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Department of the Interior Acquisition Regulation (48 CFR Chapter 14) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS—COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (JAN

2025) (DEVIATION FEB 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31

U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-

78 ( 19 U.S.C. 3805 note)).

The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[X] (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

[ ] (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

[ ] (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

[X](4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

[X] (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

[ ] (6) [Reserved].

[ ] (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

[ ] (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/3.900#FAR_3_900

[X] (9) 52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023) [ ](10) 52.204–28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) ( Pub. L. 115–390, title II).

[X] (11)(i) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

[ ](ii) Alternate I (Dec 2023) of 52.204–30.

[X](12)52.209-6, Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (JAN 2025) (31 U.S.C. 6101 note).

[ ] (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

[ ] (14) [Reserved]

[ ] (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15 U.S.C. 657a).

[ ] (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[ ](17)[Reserved]

[X] (18) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

[ ] (ii) Alternate I (Mar 2020) of 52.219-6.

[ ] (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

[ ] (ii) Alternate I (Mar 2020) of 52.219-7.

[X](20) 52.219-8, Utilization of Small Business Concerns (JAN 2025) (15 U.S.C. 637(d)(2) and (3)).

[ ](21) (i) 52.219-9, Small Business Subcontracting Plan (JAN 2025) (15 U.S.C. 637(d)(4)).

[ ] (ii) Alternate I (Nov 2016) of 52.219-9.

[ ] (iii) Alternate II (Nov 2016) of 52.219-9.

[ ] (iv) Alternate III (Jun 2020) of 52.219-9.

[ ](v) Alternate IV (JAN 2025) of 52.219-9

[ ] (22) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

[ ] (ii) Alternate I (Mar 2020) of 52.219-13.

[ ](23) 52.219-14, Limitations on Subcontracting (OCT 2022) Limitations on Subcontracting (Oct 2022) (15 U.S.C. 637s).

[ ] (24) 52.219-16, Liquidated Damages-Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

[ ] (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (FEB 2024) (15 U.S.C.

657f).

[X](26) (i) 52.219-28, Postaward Small Business Program Representation (JAN 2025) (15 U.S.C.

632(a)(2)).

[ ] (ii) Alternate I (MAR 2020) of 52.219-28.

[ ] (27) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

[ ] (28) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

[ ] (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C.

644(r)).

[ ](30) 52.219-33, Nonmanufacturer Rule (Sep 2021) ( 15 U.S.C. 637(a)(17)).

[X] (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

[X](32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (JAN 2025) (E.O.13126).

https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_209_6 https://uscode.house.gov/view.xhtml?req=granuleid%3AUSC-prelim-title15-section637&num=0&edition=prelim

[ ] (33) - Reserved [ ] (34) - Reserved

[X] (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

[ ] (ii) Alternate I (Jul 2014) of 52.222-35.

[X] (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

[ ] (ii) Alternate I (Jul 2014) of 52.222-36.

[X] (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

[X] (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

[X] (39) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O.

13627).

[ ] (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

[ ](40) 52.222-54, Employment Eligibility Verification (Jan 2025) ( Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

[ ] (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ] (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ](42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](44) 52.223-20, Aerosols (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](45) 52.223-21, Foams (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](46) 52.223-23, Sustainable Products and Services (May 2024) (DEVIATION Feb 2025) (7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

[ ] (47) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

[ ] (ii) Alternate I (Jan 2017) of 52.224-3.

[X] (48) (i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

[ ] (49) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) (19 U.S.C.

3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

[ ] (ii) Alternate I [Reserved].

[ ](iii) Alternate II (JAN 2025) of 52.225-3.

[ ] (iv) Alternate III (NOV 2023) of 52.225-3.

[ ] (50) 52.225-5, Trade Agreements (NOV 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

[X] (51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

[ ] (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

[ ] (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

[ ] (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.federalregister.gov/executive-order/12989 https://www.acquisition.gov/far/part-22#FAR_22_1803 https://www.acquisition.gov/far/part-52#FAR_52_223_11 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_20 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_21 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_23 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/42/6962 https://www.govinfo.gov/link/uscode/42/8259b https://www.govinfo.gov/link/uscode/42/7671l

[X](55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) ( E.O. 13513).

[ ] (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

[ ] (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

[ ] (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

[X] (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2018) (31 U.S.C. 3332).

[ ] (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

[ ] (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

[ ] (62) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

[X](b)(63) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118- 31, 41 U.S.C. 3901 note prec.).

[ ](64) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

[ ](65) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631).

[ ] (ii) Alternate I (Apr 2003) of 52.247-64.

[ ] (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[ ] (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter67).

[ ] (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[ ] (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[ ] (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

[ ] (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C.

chapter 67).

[ ] (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

[ ] (7) 52.222-55,…