Sol_140L5725Q0060.pdf

140L5725Q0060

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

08/08/2025 0044025901

1 37

440 WEST 200 SOUTH, SUITE 500

SALT LAKE CITY UT 84101

BLM UT-STATE OFC ADM SVCS BR(UT952)

05/22/2026

McCoy Flats Campgrounds

McCoy Flats Rd 40.36983, -109.59102

VERNAL

UT 84078

334 846-2890Mark Renforth

08/20/2025 1500 MD

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

McCoy Campground Phase 1 Concrete Supply and Delivery

Award is Subject to the Availability of Funds IAW FAR Part 52.232-18 AVAILABILITY OF FUNDS (APR 1984) Period of Performance: 08/21/2025 to 05/22/2026

00010 Concrete - Base Quantity 90 CD

00020 Concrete - Optional Quantity 16 CD (Option Line Item) Continued ...

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 37

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Request for Quotation

McCoy Flat Campground Construction Concrete

Type of Contract: Supplies, Firm Fixed Priced (FFP), Single Award Contract Place of Performance: Emery County, UT Period of Performance: 08/21/2025 – 05/22/2026

NAICS: 327320 SIZE STD: 500 employees SET-ASIDE: Total Small Business

Bureau of Land Management Contacts Contracting Officer (CO)

Contract Specialist (Primary POC)

Name: Tori Blunt Mayes Mark Renforth

Email: tbluntmayes@blm.gov mrenforth@blm.gov

Quote Submittal Information:

Questions Due Date: August 13, 2025, by 3:00 PM Mountain Time All questions must be submitted in writing via email to mrenforth@blm.gov and tbluntmayes@blm.gov with subject line: RFQ 140L5725P0060 – McCoy Flats Campground Construction Concrete. No questions will be accepted via phone calls.

Quote Due Date: August 20, 2025, by 3:00 PM Mountain Time via email to tbluntmayes@blm.gov. (See Quotation Submittal below)

Basis For Award: Quotes will be evaluated using a LPTA approach under FAR Part 13. (See Basis for Contract Award below) mailto:mrenforth@blm.gov mailto:tbluntmayes@blm.gov mailto:tbluntmayes@blm.gov

SOLICITATION NO: 140L5725P0060

PROJECT DESCRIPTION: McCoy Flats Campground Construction Concrete

GENERAL

(a) The Bureau of Land Management (BLM) is seeking quotations for supplies listed in the SOW and as attached in the accompanying documentation (see attachments). The BLM intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13. A single contract award will be made to the responsible quoter whose quotation represents the best value in accordance with the evaluation methodology outlined in the “basis for contract award.”

(b) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quote. Respondents are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and any stated technical requirements. Failure to adhere to solicitation requirements, at the time of submission, may result in a respondent’s quote being deemed unacceptable to the Government and the respondent may be eliminated from award consideration. It is the responsibility of respondents to ensure their quote is received by the Government at the designated due date and time.

(c) Quoters are cautioned to submit adequate information to enable the Government to fully ascertain each respondent’s capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ).

(d) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the contracting officer via email with supporting rationale prior to the question deadline specified on the cover page of this document.

(e) This RFQ does not commit the Government to any costs incurred during the preparation and submission of quotes or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the respondent will not be participating in a sealed bid procurement process. Issuance of this RFQ does not constitute an award commitment on behalf of the Government.

(f) Quotations must be valid for a minimum of 60 days.

(g) Respondents must complete and maintain an active registration in the System for Award Management (SAM) at SAM.gov prior to close of solicitation. The Government will obtain representations and certifications through this system.

System Considerations Be aware that system updates may lag behind policy changes:

• SAM Representations: Entities are still required to complete certain representations in SAM that are not included in agency solicitations, including 52.223-22 and paragraph (t) of 52.212-3.

• Impact on Agencies: Agencies will not consider these representations in award decisions, and entities are not required to update their registrations to remove them.

(h) All questions should be emailed directly to the contracting office primary POC by the deadline listed on the first page of this document. Only written questions will be considered and responded to by the Government. Responses to questions will be posted as an amendment to the solicitation. Respondents shall not contact any Government personnel related to this requirement other than contracting office personnel.

QUOTATION SUBMITTAL

Quotes must be in accordance with and in the order detailed in this section. Quotes must be submitted via email to the contract specialist and contracting officer by the due date and time specified on the cover page of this document.

REQUIRED DOCUMENTATION

Respondents shall submit the following information in response to this RFQ:

1) Short Cover Letter:

a. Company name, address, DUNS, SAM Unique Entity Identifier (UEI) number, and phone number

b. Point of contact for individuals within the company (phone number and email address)

c. A statement that the quote is valid for 60 days.

d. A response to the following questions:

https://sam.gov/content/home

i. Judgments, Claims, and Lawsuits: Are there any judgments, claims, and/or lawsuits pending or outstanding against or involving entity or partners comprising your entity?

• No ___, Yes ___. If “Yes,” submit details of all judgments or claims against either parent office or division/branch that will be responsible for the accomplishment of this project on a separate sheet.

ii. Is your entity or partners comprising your entity under suspension or debarment by any Federal, state or local agency, or been terminated on any past projects (Federal or others)?

• No ___, Yes ___. If “Yes,” submit details on a separate sheet.

e. Answers to the following statement: IAW FAR 52.204-26, the Offeror represents that it [ ] does, [ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument. After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ] does, [ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

i. PLEASE NOTE, responses of “does” require additional information to be submitted as outlined in FAR 52.204- 26 and 52.204-24 of the provisions section within this solicitation.

2) Sign Standard Form (SF) 18, Solicitation/Contract/Order for Commercial Items. Please complete blocks 8a, 8b, 8c, 8d, 8e, 8f, 11e, 11f, 13a, 13b, 13c, 13d, 13e, 13f, 14, 15, and 16a. An official having the authority to contractually bind the quoter’s company must sign the SF 18 in accordance with the procedures prescribed in the Federal Acquisition Regulation Subpart 4.102.

3) Acknowledgement of Amendments: Acknowledge all solicitation amendments (if issued by the Government) by signing and returning all individual SF30s with your quote.

4) Provide Commercial Quote Schedule

5) Technical Package – see evaluation factors below. Quoters must ensure that no pricing information is displayed in the technical volume.

BASIS FOR CONTRACT AWARD

The Government anticipates awarding a firm-fixed price supplies contract to a registered/certified small business concern, using FAR Part 13 Simplified Acquisition Procedures. The Government contemplates a single award contract resulting from this solicitation. Quotes will be evaluated using a LPTA approach. Award will be made to the responsible quoter whose quote conforms with all solicitation requirements to include terms and conditions, representations & certifications, technical requirements, and also provides the lowest total price.

Quotes will be evaluated using the criteria listed in this section. Noncompliance with the Request for Quote (RFQ) requirements may be grounds to eliminate the quote from consideration for contract award. Failure to include all information requested may adversely affect the evaluation. A quote that is orderly and sufficiently documented will enable the Government to perform a thorough and fair evaluation.

After solicitation closing, the Contracting Officer will conduct quote compliance review for determination of basic quote adequacy prior to providing commencing evaluation. Failure to provide a complete quote identified in the solicitation may result in the quote being removed from further consideration for award.

EVALUATION FACTORS FOR CONTRACT AWARD

Technical:

• Criteria: The offeror’s quote must demonstrate compliance with the technical requirements specified in the Statement of Need.

• Delivery Requirements:

Ability to deliver 8 to 20 cubic yards per load to various campsites within one mile of coordinates 40.36983, -

109.59102, Monday through Thursday, 7:00 AM to 3:00 PM.

Compliance with delivery time limits (90 minutes from cement introduction to discharge, or 45 minutes if concrete temperature is 85°F or higher).

• Certification:

Submission of a letter certifying that the concrete mix design meets the specified compressive strength and includes evidence satisfactory to the Engineer that the materials and proportions will produce conforming concrete.

Evaluation: The Government will assess whether the offeror’s proposed concrete mix and delivery plan fully meet these specifications.

Only quotes deemed technically acceptable will proceed to price evaluation.

PRICE

• The proposed price will be evaluation for reasonableness.

Statement of Need for BLM Green River District McCoy Campground Phase 1 Concrete

The Bureau of Land Management (BLM) Green River District (GRD) requires concrete for the McCoy Flats Campground project located near Vernal, Utah.

Delivery Information:

The product delivery shall be to the McCoy Flats Campgrounds McCoy Flats Rd, Vernal, UT 84078 Various camp sites around the camp loop less than one mile travel distance from 40.36983, -109.59102.

Deliveries will be made Monday – Thursday between 7am and 3pm.

The Government does not anticipate any short loads (4 cubic yards or less) and will avoid short loads to the maximum extent possible. Typical load requirements will be 8 to 20 cubic yards per request.

Base Bid Items:

90 cubic yards of the specific concrete mix

Optional Bid Items:

16 cubic yards of the specific concrete mix

Period of Performance:

Deliveries will vary between August 18, 2025 or 7 days within the notice to proceed, whichever is later, and May 22, 2026. Deliveries will be scheduled by the COR.

Specifications:

The contractor shall be responsible for the design of the concrete mix and for providing a letter certifying that the concrete materials and mix proportions (including admixtures if used) will provide the required compressive strength and include evidence satisfactory to the Engineer that the materials and proportions (the “job mix”) will produce concrete conforming to this specification. After a job mix has been approved, neither the source, character, or grading of the aggregates nor the type or brand of cement or admixture shall be changed without prior notice to the COR.

The proportions of the aggregates shall be such as to produce a concrete mixture that works readily into the corners and angles of the forms and around reinforcement when consolidated but will not segregate or exude free water during consolidation. The Maximum Size Aggregate (MSA) shall be 3/4 inches.

The maximum water to cement ratio (w/c) shall be 0.45 unless otherwise specified. The concrete mix shall have a 28-day compressive strength of 4,000 psi or greater. The minimum cement content shall be

6.5 bags (611 lbs.) per cubic yard. Use Type I or Type II portland cement meeting the requirements of ASTM C150. Water used in mixing and curing concrete shall be clean and free from injurious amounts of oil, salt, acid, alkali, organic matter, or other deleterious substances. Wash water shall not be used as part of the mixing water for succeeding batches.

The entrained air content by volume shall be 3% to 7% of the volume of the concrete. Air entraining admixtures shall conform to the requirements of ASTM C260.

Unless otherwise specified, the slump shall be within the range of 3 inches minimum to 5 inches (maximum).

Chemical admixtures, if used shall conform to the requirements of ASTM C494 and be of the types in the list below. Admixtures containing calcium chloride shall not be used.

• Type A- Water-reducing admixture

• Type B- Retarding admixture

• Type C- Accelerating admixture

• Type D- Water-reducing and retarding admixture

• Type E- Water-reducing and accelerating admixture

• Type F- Water-reducing, high range admixture

• Type G- Water-reducing, high range, and retarding admixture

Superplasticizers (ASTM C494 Types F and G) may be used to increase workability and reduce the water content required to produce a concrete mix within the slump range shown above. The use of superplasticizers will be approved by the Engineer at the pre-construction meeting. Superplasticizers shall be used according to manufacturer’s recommendations. The maximum slump before adding superplasticizers shall be within the range of 3 to 5 inches. The maximum slump after adding superplasticizer and prior to placement of the concrete shall be 7 ½ inches.

All materials used in concrete construction shall meet the applicable ASTM standards and/or ACI specifications.

Ready-mixed concrete shall be mixed, transported, and placed in a freshly mixed and unhardened state and meet the requirements as described in ASTM C94 “Standard Specification for Ready-Mixed Concrete”.

No mixing water in excess of the amount called for by the job mix shall be added to the concrete during mixing or hauling or after arrival at the delivery point. Withholding some of the water until the concrete arrives on the job and then adding the remaining water and turning the mixer 30 revolutions at mixing speed is allowed to overcome transporting conditions. Water to compensate for up to a 1-inch loss in slump may be added one time prior to discharging any of the load, not to exceed the design maximum water cement (w/c) ratio.

A delivery ticket for each batch of concrete shall be provided to the COR by the concrete supplier prior to the concrete being unloaded at the work site. Upon completion of the placement of all concrete, copies of all batch tickets shall be provided to the landowner. The following minimum information shall be included on each Batch Ticket:

a. Name of purchaser and the work location (address)

b. Name of the concrete supplier (ready-mix batch plant)

c. Batch plant location

d. Ticket serial number

e. Design mix designation

f. Delivery date

g. Time the concrete was loaded onto the truck at the plant

h. Time the concrete arrived at the site

i. Amount of concrete delivered to the site (batch size)

j. Time the concrete was unloaded at the site

k. Actual weight of Cement (also Fly Ash and/or other mineral admixtures if used)

l. Actual weight of Aggregates (Coarse and Fine)

m. Actual weight of Water added at the plant

n. Actual volume of Admixture(s) – Type(s) and Quantity(s) added at the plant (if used)

o. Actual weight and type of fiber reinforcement (if used)

p. Water/Cement ratio of batch leaving the plant

q. Quantity of water added at the site by the receiver of the concrete

r. Admixture(s) added at the site – type(s), quantity(s), and time admixture(s) added to the concrete

The contractor shall be responsible for any changes to the certified design mix.

Concrete shall be delivered to the site and discharged into the forms within 90 minutes after the introduction of the cement to the aggregates. In hot weather or under conditions contributing to quick stiffening of the concrete or when the temperature of the concrete is 85° F or above, the time between the introduction of the cement to the aggregates and discharge shall not exceed 45 minutes. Concrete shall be conveyed from the mixer to the forms as rapidly as practicable by methods that will prevent segregation of the aggregates or the loss of mortar.

Testing:

Testing will be performed by the Government.

Quote Requirements: Submit a firm fixed price, stating the total amount and unit price per cubic yard.

The bidder shall include any additional costs beyond the concrete price in the quote, i.e. “environmental fees, hourly fees, fuel surcharge, etc.” Include a letter certifying the concrete design mix will meet the specified compressive strength.

Award Basis: Quotes will be evaluated using the Lowest Price, Technically Acceptable method. The Government will award a purchase order resulting from this solicitation to the responsible offeror whose quote conforming to the solicitation will be most advantageous to the Government.

Payment and Invoicing: Contractor may invoice monthly. For each invoice, copies of batch tickets shall be provided representing the quantity delivered and payment requested. See DOI-AAAP-0028

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS-INVOICE PROCESSING

PLATFORM (IPP) (FEB 2021) for invoicing instructions.

Clauses

52.212-4 CONTRACT TERMS AND CONDITIONS –COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (NOV 2023)

---Addendum to 52.212-4---

DIAR 1452.201-70 AUTHORITIES AND DELEGATIONS (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries.

The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of Clause)

52.217-7 OPTION FOR INCREASED QUANTITY-SEPERATELY PRICED LINE ITEM (MAR 1989)

the Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 15 days. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of clause)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation: https://www.acquisition.gov/far Department of the Interior Acquisition Regulation: https://www.acquisition.gov/diar

(End of clause)

DOI-AAAP-0028 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS-INVOICE

PROCESSING PLATFORM (IPP) (FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

'Payment request' means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

Contractor's Commercial Invoice to include all elements of a Proper Invoice pursuant to FAR 52.212-4(g)

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone

(866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

Funds are not presently available for this contract. The Government’s obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

--- End of Addendum to 52.212-4---

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS—COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (JAN

2025) (DEVIATION FEB 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or

Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance

Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31

U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and

10878 ( 19 U.S.C. 3805 note)).

The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[ ] (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

[ ] (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

[ ] (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

(4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

[X] (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

[ ] (6) [Reserved].

[ ] (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

[ ] (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

[X] (9) 52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023)

(10) 52.204–28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) ( Pub. L. 115–390, title II).

https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/3.900#FAR_3_900 https://www.govinfo.gov/link/plaw/115/public/390

[X] (11)(i) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

(ii) Alternate[ ] I (Dec 2023) of 52.204–30.

[X](12)52.209-6, Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (JAN 2025) (31 U.S.C. 6101 note).

[ ] (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313). [ ] (14) [Reserved] [ ] (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15 U.S.C. 657a).

[ ] (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C.

657a).

(17) [Reserve[ ]d]

[X] (18) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

[ ] (ii) Alternate I (Mar 2020) of 52.219-6.

[ ] (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

[ ] (ii) Alternate I (Mar 2020) of 52.219-7.

[ ](20) 52.219-8, Utilization of Small Business Concerns (JAN 2025) (15 U.S.C. 637(d)(2) and (3)).

[ ](21) (i) 52.219-9, Small Business Subcontracting Plan (JAN 2025) (15 U.S.C. 637(d)(4)).

[ ] (ii) Alternate I (Nov 2016) of 52.219-9.

[ ] (iii) Alternate II (Nov 2016) of 52.219-9.

[ ] (iv) Alternate III (Jun 2020) of 52.219-9.

[ ](v) Alternate IV (JAN 2025) of 52.219-9

[ ] (22) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

[ ] (ii) Alternate I (Mar 2020) of 52.219-13.

[ ](23) 52.219-14, Limitations on Subcontracting (OCT 2022) Limitations on Subcontracting (Oct 2022) (15 U.S.C. 637s).

[ ] (24) 52.219-16, Liquidated Damages-Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)). [ ] (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (FEB 2024) (15 U.S.C.

657f).

[X](26) (i) 52.219-28, Postaward Small Business Program Representation (JAN 2025) (15 U.S.C.

632(a)(2)).

[ ] (ii) Alternate I (MAR 2020) of 52.219-28.

[ ] (27) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

[ ] (28) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

[ ] (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C.

644(r)).

[ ](30) 52.219-33, Nonmanufacturer Rule (Sep 2021) ( 15 U.S.C. 637(a)(17)).

[X] (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

[X](32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (JAN 2025) (E.O.13126).

[X] (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

[X] (34) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

[ ] (ii) Alternate I (Feb 1999) of 52.222-26.

[ ] (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

[ ] (ii) Alternate I (Jul 2014) of 52.222-35.

https://www.acquisition.gov/far/part-52#FAR_52_209_6 https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637&num=0&edition=prelim https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637&num=0&edition=prelim

[ ] (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

[ ] (ii) Alternate I (Jul 2014) of 52.222-36.

[ ] (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

[ ] (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

[X] (39) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O.

13627).

[ ] (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

[ ](40) 52.222-54, Employment Eligibility Verification (Jan 2025) ( Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

[ ] (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ] (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ](42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](44) 52.223-20, Aerosols (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](45) 52.223-21, Foams (May 2024) ( 42 U.S.C. 7671, et seq.).

[ ](46) 52.223-23, Sustainable Products and Services (May 2024) (DEVIATION Feb 2025) (7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

[ ] (47) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

[ ] (ii) Alternate I (Jan 2017) of 52.224-3.

[X] (48) (i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

[ ] (49) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) (19 U.S.C.

3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

[ ] (ii) Alternate I [Reserved].

[ ](iii) Alternate II (JAN 2025) of 52.225-3.

[ ] (iv) Alternate III (NOV 2023) of 52.225-3.

[ ] (50) 52.225-5, Trade Agreements (NOV 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). [X]

(51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). [ ]

(52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

[ ] (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). [ ]

(54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

[X](55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) ( E.O. 13513).

[ ] (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

[ ] (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

[ ] (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

[X] (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2018) (31 U.S.C. 3332).

https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.federalregister.gov/executive-order/12989 https://www.acquisition.gov/far/part-22#FAR_22_1803 https://www.acquisition.gov/far/part-52#FAR_52_223_11 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_20 https://www.acquisition.gov/far/part-52#FAR_52_223_20 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_21 https://www.acquisition.gov/far/part-52#FAR_52_223_21 https://www.govinfo.gov/link/uscode/42/7671 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_23 https://www.acquisition.gov/far/part-52#FAR_52_223_23 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/42/6962 https://www.govinfo.gov/link/uscode/42/8259b https://www.govinfo.gov/link/uscode/42/7671l https://www.govinfo.gov/link/uscode/42/7671l https://www.acquisition.gov/far/part-52#FAR_52_226_8 https://www.federalregister.gov/executive-order/13513 https://www.federalregister.gov/executive-order/13513

[ ] (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

[ ] (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

[ ] (62) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

[ ](64) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)). [ ](65) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631).

[ ] (ii) Alternate I (Apr 2003) of 52.247-64.

[ ] (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[ ] (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter67).

[ ] (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

This Statement is for Information Only: It is not a Wage Determination

Employee Class Monetary Wage-Fringe Benefits

[List as necessary] [ ] (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67). [ ] (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

[ ] (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C.

chapter 67).

[ ] (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

[ ] (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

[ ] (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

[ ] (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C.

1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement.

Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) ( 41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division Rof Pub. L. 117-328).

(vii) (A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

(B) Alternate I (Dec 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (JAN 2025) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(x) 52.222-26, Equal Opportunity (Sep 2015) (E.O.11246).

(xi) 52.222-35, Equal Opportunity for Veterans (Jun 2020) ( 38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) ( 29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (Jun 2020) ( 38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (Aug 2018) ( 41 U.S.C. chapter 67).

(xvi) (A) 52.222-50, Combating Trafficking in Persons (Nov 2021) ( 22 U.S.C. chapter 78 and E.O13627).

(B) Alternate I (Mar 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C.

chapter 67).

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(xix) 52.222-54, Employment Eligibility Verification (JAN 2025) (E.O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

(xxii) (A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10

U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) ( 42 U.S.C.1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

(xxvii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) ( 46 U.S.C.55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.24764.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

Federal Acquisition Supply Chain Security Act Orders—Representation and Disclosures (Dec 2023) https://www.acquisition.gov/far/part-52#FAR_52_240_1 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section3901&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section3901&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section3901&num=0&edition=prelim

Contract Documents, Exhibits, or Attachments

Provisions

52.212-1 INSTRUCTIONS TO OFFERORS–COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES (SEP 2023)

---Addendum to 52.212-1---

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

Federal Acquisition Regulation: https://www.acquisition.gov/far Department of the Interior Acquisition Regulation: https://www.acquisition.gov/diar

(End of provision)

52.204-7 SYSTEM FOR AWARD MANAGEMENT (AUG 2024)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Department of the Interior Acquisition Regulation (48 CFR Chapter14) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

---End of Addendum to 52.212-1---

---End of Addendum to 52.212-2---

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS-COMMERCIAL PRODUCTS

AND COMMERCIAL SERVICES (MAY 2024) (DEVIATION FEB 2025)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (v) of this provision.

(a) Definitions. As used in this provision—

Covered telecommunications equipment or services has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the…