Sol_140F0221R0001.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

FWS, DIVISION OF CONTRACTING AND GE

P.O. BOX 1306

500 GOLD AVENUE SW

ALBUQUERQUE NM 87102-3118

F02

Tom Ketcham 505 248-6844

1x 10/02/2020

140F0221R0001

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Solicitation Notice Number 140F0221R0001

DUNS_____________Project Name: Crocodile Lake NWR Road(s) Removal Project

This synopsis/solicitation is to the public the U.S. Fish and Wildlife Service, Crocodile Lake National Wildlife Refuge, Monroe County, Key Largo, Florida has a construction project to remove asphalt, concrete and other materials as per the

Performance Work Statement. Project is for small business set-aside. Applicable

NAICS code is 238190 Other Foundation, Structure, and Building Exterior

Constractors, Standard Size $15M.

Davis Bacon Wages for Monroe County Apply.

Magnitude of this project is between $100,000 and $250,000.

Payment and Performance Bond are required as well as Liability Insurance.

Bid Guarantee is required.

All proposals are due by: 30 October 2020 at 1700 MT by email to tom_ketcham@fws.gov.

Questions regarding clarification on this solicitation are to be directed to tom_ketcham@fws.gov

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 180 calendar days and complete it within ________________ ________________ calendar days after receiving

Per FAR Clause 52.211-10

10/30/2020

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

FWS, DIVISION OF CONTRACTING AND GE

P.O. BOX 1306

500 GOLD AVENUE SW

ALBUQUERQUE NM 87102-3118

F02

Tom Ketcham

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140F0221R0001

Site Visit: Site visits are highly encouraged prior to submitting a proposal. Visits may be arranged during normal duty hours by contacting:

Jeremy Dixon at (305) 451-4223 or email

Jeremy_dixon@fws.gov

Legacy Doc #: FWS

Delivery: 180 Days After Notice to Proceed

Delivery Location Code: 0008349697

FWS CROCODILE LAKE NWF

10750 COUNTY RD 905

KEY LARGO FL 33037-0370 US

00010 Remove concrete and asphalt roads from Nike

Missile Road

Alternative Item II Based on availability of funding

Period of Performance: 11/09/2020 to 09/30/2021

00020 Remove concrete and asphalt roads at Car Dump Road

Alternative Bid Item I Base on availability of funding

Period of Performance: 11/09/2020 to 09/30/2021

00030 Remove concrete and asphalt roads from Banyan

Road

Base Bid

Period of Performance: 11/09/2020 to 09/30/2021

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

TABLE OF CONTENTS

SECTION A - Solicitation/Contract Form 52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) 52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015) 52.232-5 Payments under Fixed-Price Construction Contracts. (MAY 2014) 52.236-1 Performance of Work by the Contractor. (APR 1984) 52.236-2 Differing Site Conditions. (APR 1984) 52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984) 52.236-6 Superintendence by the Contractor. (APR 1984) 52.236-15 Schedules for Construction Contracts. (APR 1984) 52.236-17 Layout of Work. (APR 1984) 52.249-10 Default (Fixed-Price Construction). (APR 1984) 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999)

SECTION B – BID SCHEDULE

SECTION C - Description/Specifications SECTION D - Packaging and Marking SECTION E - Inspection and Acceptance 52.236-5 Material and Workmanship. (APR 1984) 52.236-7 Permits and Responsibilities. (NOV 1991) 52.246-12 Inspection of Construction. (APR 1996) 52.246-21 Warranty of Construction. (MAR 1994) SECTION F - Deliveries or Performance 52.242-14 Suspension of Work. (APR 1984)

1452.211-71 CONTRACT WORK HOURS (NOV 2007)

1452.211-72 COMPLETION DATE (NOV 2007)

SECTION G - Contract Administration Data FWS Construction Progress Payment Procedures Clause

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

SECTION H - Special Contract Requirements 1452.236-82 Location and Protection of Utilities and other Improvements (NOV 2007) 1452.236-83 Equipment Responsibility (NOV 2007) 1452.236-85 Rights of Entry - Project Site Area (NOV 2007) 1452.236-86 Storage Areas - Waste Areas - Borrow Areas (NOV 2007) 1452.236-88 Detours, Traffic Control Plan, Traffic Barricades, Warning and Safety Protection Devices (NOV 2007) 1452.237-80 Safety, Regulations, Laws to be Observed (NOV 2007) SECTION I - Contract Clauses 52.252-2 Clauses Incorporated by Reference. (FEB 1998) 52.202-1 Definitions (NOV 2013) 52.203-3 Gratuities (APR 1984) 52.203-5 Covenant Against Contingent Fees. (MAY 2014) 52.203-7 Anti-Kickback Procedures. (MAY 2014) 52.203-8 Cancellation, Rescission and Recovery of Funds for Illegal or Improper Activity (MAY 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (OCT 2010) 52.203-12 52.203-16 Preventing Personal Conflicts of Interest (DEC 2011) 52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees to Whistleblower Rights (APR 2014) 52.204-1 Approval of Contract. (DEC 1989) 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Page (MAY 2011) Contractor Performance Assessment Reporting System (CPARS) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (OCT 2018) 52.204-13 System for Award Management Maintenance (OCT 2018)

52.204-22 Alternative Line Item Proposal. (JAN 2017) 52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (OCT 2015) 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (OCT 2018) 52.209-10 Prohibition on Contracting with Inverted Domestic Corporation (NOV 2015) 52.211-5 Material Requirements. (AUG 2000) 52.211-12 -- Liquidated Damages – Construction 52.211-18 Variation in Estimated Quantity, (APR 1984) 52.215-2 Audit and Records –Negotiation (OCT 2010) 52.215-8 Order of Precedence - Uniform Contract Format. (OCT 1997) 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data. (AUG 2011) 52.215-12 Subcontractor Certified Cost or Pricing Data. (OCT 2010) 52.215-15 Pension Adjustments and Asset Reversions. (OCT 2010) 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions. (JUL 2005) 52.215-19 Notification of Ownership Changes. (OCT 1997) 52.216-24 Limitation of Government Liability. (APR 1984) 52.219-6 Notice of Total Small Business Set-Aside. (NOV 2011) 52.219-8 Utilization of Small Business Concerns. (OCT 2018) 52.219-14 Limitations on Subcontracting (JAN 2017) 52.219-28 Post-Award Small Business Program Representation (JUL 2013) 52.222-1 Notice to the Government of Labor Disputes (FEB 1997) 52.222-3 Convict Labor. (JUN 2003) 52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation. (MAR 2018) 52.222-6 Construction Wage Rate Requirements. (AUG 2018) 52.222-7 Withholding of Funds. (MAY 2014) 52.222-8 Payrolls and Basic Records. (AUG 2018) 52.222-9 Apprentices and Trainees. (JUL 2005) 52.222-10 Compliance with Copeland Act Requirements. (FEB 1988) 52.222-11 Subcontracts (Labor Standards). (MAY 2014) 52.222-12 Contract Termination - Debarment. (MAY 2014) 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. (MAY 2014) 52.222-14 Disputes Concerning Labor Standards. (FEB 1988) 52.222-15 Certification of Eligibility. (MAY 2014) 52.222-20 Contracts for Materials, Supplies, Articles and Equipment Exceeding $15,000 (MAY 2014) 52.222-21 Prohibition of Segregated Facilities. (APR 2015) 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999) 52.222-26 Equal Opportunity. (SEPT 2016) 52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015) 52.222-35 Equal Opportunity for Veterans. (OCT 2015) 52.222-36 Affirmative Action for Workers with Disabilities. (Jul 2014) 52.222-37 Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans. (FEB 2016) 52.222-50 Combating Trafficking in Persons. (Jan 2019) 52.222-54 Employment Eligibility Verification. (OCT 2015) 52.222-55 Minimum Wages Under Executive Order (DEC 2015) 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts. (SEPT 2013) 52.223-5 Pollution Prevention and Right-to-Know Information. (MAY 2011) 52.223-6 Drug-Free Workplace. (MAY 2001) 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons. (JUN 2016) 52.223-15 Energy Efficiency in Energy-Consuming Products. (DEC 2007) 52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts. (AUG 2018)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011) 52.223-20 Aerosols. (JUN 2016) 52.223-21 Foams. (JUN 2016) 52.225-9 Buy American—Construction Materials 52.225-10 Notice of Buy American Requirement—Construction Materials 52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008) 52.225-22 Notice of Required Use of American Iron, Steel, and Manufactured Goods—Buy American Statute—Construction Materials 52.225-25 Prohibition on Contracting with Entities Engaging in Sanctioned Activities Relating to Iran-- Representation and Certification. (AUG 2018) 52.227-1 Authorization and Consent. (DEC 2007) 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. (DEC 2007) 52.228-1 Bid Guarantee (Sep 1996) 52.228-2 Additional Bond Security (OCT 1997) 52.228-5 Insurance - Work on a Government Installation. (JAN 1997) 52.228-11 Pledges of Assets. (AUG 2018) 52.228-12 Prospective Subcontractor Requests for Bonds. (MAY 2014) 52.228-13 Alternative Payment Protections. (JUL 2000) 52.228-14 Irrevocable Letter of Credit. (NOV 2014) 52.228-15 Performance and Payment Bonds-Construction (OCT 2010) 52.229-3 Federal, State, and Local Taxes (FEB 2013) 52.232-5 Payments under Fixed-Price Construction Contracts. (MAY 2014) 52.232-16 Progress Payments (APR 2012) 52.232-17 Interest (MAY 2014) 52.232-23 Assignment of Claims. (MAY 2014) 52.232-27 Prompt Payment For Construction Contracts. (JAN 2017) 52.232-33 Payment by Electronic Funds Transfer- System for Award Management (OCT 2018) 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) 52.232-40 Providing Accelerated Payment to Small Business Subcontractors. (DEC 2013) 52.233-1 Disputes. (MAY 2014) 52.233-1 Disputes. (MAY 2014) - Alternate I (DEC 1991) 52.233-3 Protest after Award. (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984) 52.236-5 Material and Workmanship, (APR 1984) 52.236-7 Permits and Responsibilities (NOV 1991) 52.236-8 Other Contracts. (APR 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities and Improvements.(APR 1984) 44 52.236-10 Operations and Storage Areas. (APR 1984) 52.236-11 Use and Possession Prior to Completion. (APR 1984) 52.236-12 Cleaning Up. (APR 1984) 52.236-13 Accident Prevention. (NOV 1991) 52.236-14 Availability and Use of Utility Services. (APR 1984) 52.236-21 Specifications and Drawings for Construction. (FEB 1997) 52.236-26 Preconstruction Conference. (FEB 1995) 52.242-13 Bankruptcy. (JUL 1995) 52.242-14 Suspension of Work (APR 1984) 52.242-15 Stop-Work Order (AUG 1989) 52.243-5 Changes and Changed Conditions. (APR 1984) 52.244-6 Subcontracts for Commercial Items 52.249-2 Termination for Convenience of the Government (Fixed Price) (APR 2012) 52.249-10 Default (Fixed –Price Construction) (APR 1984) 52.252-1 Solicitation Provisions Incorporated By Reference. (FEB 1998) 52.252-2 Clauses Incorporated By Reference. (Feb 1998) 52.252-4 Alterations in Contract. (APR 1984) 52.252-6 Authorized Deviations in Clauses (APR 1984)

52.253-1 Computer Generated Forms. (JAN 1991) 1452.204-70 Release of Claims. (JUL 1996) 1452.228-70 Liability Insurance. (JUL 1996) SECTION J - List of Documents, Exhibits and Other Attachments Attachment #1 Performance Work Statement 20 Pages Attachment #2 Performance Relevancy Survey 2 Pages Attachment #3 Davis Bacon Wages 05 Pages SECTION K - Representations, Certifications, and Other Statements of Bidders 52.204-7 -- System for Award Management 52.204-8 -- Annual Representations and Certifications 52.209-5 Certification Regarding Responsibility Matters 52.209-7 Information Regarding Responsibility Matters 52.223-1 Biobased Product Certification. (May 2012) 52.223-4 Recovered Material Certification. (MAY 2008) SECTION L - Instructions, Conditions, and Notices to Bidders 52.215-1 Instruction to Offerors – Competitive Acquisition. (JAN 2017) 52.216-1 Type of Contract. (APR 1984) 52.236-27 Site Visit (Construction). (FEB 1995) Section M--Evaluation Factors for Award

SECTION A - Solicitation/Contract Form

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [10] ten calendar days after the date the Contractor receives the notice to proceed and complete the entire work ready for use not later than one hundred eighty days [180]. The time stated for completion shall include final cleanup of the premises.

(End of Clause)

52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015)

52.232-5 Payments under Fixed-Price Construction Contracts. (MAY 2014)

52.236-1 Performance of Work by the Contractor. (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least [15%] fifteen percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.236-2 Differing Site Conditions. (APR 1984)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of -

(1) Subsurface or latent physical conditions at the site which differ materially from those indicated in this contract;

or

(2) Unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.

(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. If the conditions do materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, an equitable adjustment shall be made under this clause and the contract modified in writing accordingly.

(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in paragraph (a) of this clause for giving written notice may be extended by the Contracting Officer.

(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.

52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to (1) conditions bearing upon transportation, disposal, handling, and storage of materials; (2) the availability of labor, water, electric power, and roads; (3) uncertainties of weather, river stages, tides, or similar physical conditions at the site; (4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

52.236-6 Superintendence by the Contractor. (APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-15 Schedules for Construction Contracts. (APR 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval one copy of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

52.236-17 Layout of Work. (APR 1984)

The Contractor shall lay out its work from Government established base lines and bench marks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

52.249-10 Default (Fixed-Price Construction). (APR 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor's refusal or failure to complete the work within the specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if -

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include -

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade: 9%

Goals for Female Participation for Each Trade: 6.9% as per Department of Labor Construction Contractor Nationwide Goals.

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled Affirmative Action Compliance Requirements for Construction, and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the covered area is Crocodile Lake National Wildlife Refuge, Key Largo, Florida, Monroe County

SECTION B – BID SCHEDULE

BID SCHEDULE

The undersigned hereby proposes and agrees that an award by the Government under this Bid, and in accordance with the provisions therein stated, to execute the Agreement, with necessary bonds, to furnish and install any and all supervision, labor, materials, expenses, fees, and taxes plus permitting costs, overhead and profit associated with each bid item below for our Crocodile Lake National Wildlife Refuge, Key Largo, FL, in accordance with the Contract Documents therefore adopted and on file with the Government within the time hereinafter set forth and at prices named in this bid.

Bid Item Estimated Extended No. Description Quantity Unit_____ Price_____

BASE BID

00030 BANYAN ROAD: 1 LS $ _____________

Remove/ Dispose Asphalt and Concrete Road/Slabs and other material as per Performance Work Statement

ALTERNATIVE BID ITEM I BASE ON AVAILABILITY

OF FUNDING

00020 CAR DUMP ROAD: 1 LS $ __________

ALTERNATIVE BID ITEM II BASE ON AVAILABILITY

OF FUNDING

00010 NIKE MISSILE LAUNCH SITE: ______ 1 LS $ ________

00000 PROJECT OVERHEAD AND PROFIT:____________ 1 LS $ ________

Mobilization, Profit Overhead and General & Administrative

Total BASE Price $_______________ Alternative Bid item I $_______________ Alternative Bid item II $_______________

BID SCHEDULE:

1. * Indicates quantity is an estimated amount. See Section 00700, FAR 52.211-18, for variation in estimated quantity contract clause.

2. Prices must be submitted on all individual items of this Bid Schedule. Failure to do so may cause the proposal to be determined “unacceptable”.

3. If a modification to a price based on unit price is submitted which provides for a lump sum adjustment to the total estimated price, the applications of the lump sum adjustment to each unit price in the Bid Schedule must be stated. If it is not stated, the bidder/offeror agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the Bid Schedule.

4. All extensions of the unit prices shown will be subject to verification by the Government. In the case of variation between the unit price and extension, the unit price will be considered to be the price.

5. The bidder/offeror shall distribute his indirect costs (home office overhead and profit) over all the items in the Bid Schedule. The Government will review all submitted Bid Schedules for any unbalancing of the items. Any submitted Bid Schedule determined to be unbalanced may be considered nonresponsive and cause the bidder to be ineligible for award.

6. The Lump Sum, “LS”, line items above are not "estimated quantity" line items and therefore are not subject to the Variation in Quantity contract clause.

7. EFARS 52.214-5000 - APPARENT CLERICAL MISTAKES - ARITHMETIC

DISCREPANCIES (DEC 1995) – EFARS

a. For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the Bid Schedules as submitted by bidders:

i. Obvious misplaced decimal points will be corrected;

ii. Discrepancies between unit price and extended price, the unit price will govern;

iii. Apparent errors in extension of unit prices will be corrected;

iv. Apparent errors in addition of lump-sum and extended price will be corrected.

b. For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends the bid to be evaluated in the basis of the unit prices, the total arrived at by resolution of arithmetic discrepancies as provided above and the bid/offer will be so reflected on the abstract of bids/offers.

c. These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

SECTION C - Description/Specifications

The Fish and Wildlife Service is seeking proposals which shall consist of labor, equipment, supplies, and materials from a company who has experience with removing and disposal of asphalt, concrete and other materials as per the our Performance Work Statement (PWS) at our Crocodile Lake National Wildlife Refuge, Key Largo, Florida.

Work under this Contract is located in Monroe County, Florida. For a comprehensive list of work, see the PWS and pictures included with the PWS. Work under this contract is located on the Crocodile Lake National Wildlife Service located 85941 Alchesay Road, White River, Arizona in Navajo County10750 County Rd 905, Key Largo, FL, Monroe County.

52.236-21 Specifications and Drawings for Construction. (FEB 1997)

(a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to the Contracting Officer, who shall promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.

(b) Wherever in the specifications or upon the drawings the words directed, required, ordered, designated, prescribed, or words of like import are used, it shall be understood that the direction, requirement, order, designation, or prescription, of the Contracting Officer is intended and similarly the words approved, acceptable, satisfactory, or words of like import shall mean approved by, or acceptable to, or satisfactory to the Contracting Officer, unless otherwise expressly stated.

(c) Where as shown, as indicated, as detailed, or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word provided as used herein shall be understood to mean provide complete in place that is furnished and installed.

(d) Shop drawings means drawings, submitted to the Government by the Contractor, subcontractor, or any lower tier subcontractor pursuant to a construction contract, showing in detail (1) the proposed fabrication and assembly of structural elements, and (2) the installation (i.e., fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials furnished by the contractor to explain in detail specific portions of the work required by the contract. The Government may duplicate, use, and disclose in any manner and for any purpose shop drawings delivered under this contract.

(e) If this contract requires shop drawings, the Contractor shall coordinate all such drawings, and review them for accuracy, completeness, and compliance with contract requirements and shall indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the Contracting Officer without evidence of the Contractor's approval may be returned for resubmission. The Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government's reasons therefor.

Any work done before such approval shall be at the Contractor's risk. Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements of this contract, except with respect to variations described and approved in accordance with (f) below.

(f) If shop drawings show variations from the contract requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Contracting Officer approves any such variation, the Contracting Officer shall issue an appropriate contract modification, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.

(End of clause)

SECTION D - Packaging and Marking

PAYMENT OF POSTAGE AND FEES

All postage and fees related to submitting information including submittals, forms, reports, etc., to the Contracting Officer or the Contracting Specialist shall be paid by the Contractor.

CORRESPONDENCE/SUBMITTALS

Contractor initiated correspondence and submittals shall identify the contract number. All information shall be emailed to the addresses found in Section G. Correspondence shall be provided by email to the Contracting Officer (CO), including all RFI’s. Product and Material Submittals: During construction, Contractor shall provide Contracting Officer Technical Representative, Jeffrey Johns, the products and material submittals for all items requiring submittals in the contract specifications.

SECTION E - Inspection and Acceptance

52.236-5 Material and Workmanship. (APR 1984)

52.236-6 Superintendence by the Contractor, (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.246-12 Inspection of Construction. (APR 1996)

QUALITY CONTROL RESPONSIBILITIES

(a) General

The quality control of services provided under this contract shall be based on: (i) operational requirements and standards contained in this contract; (ii) work performance; and (iii) productivity requirements and standards, and (iv) data base information resource development and maintenance standards.

(b) Contractor Quality Control Responsibility

The Contractor shall implement and adhere to the quality control plan provided as part of its Technical Proposal. The quality control plan shall be written by the Contractor’s Quality Control Manager and approved by his/her immediate supervisor.

The Contractor is solely responsible for quality control of services that it provides. The Contractor’s quality control program, which is embodied in the quality control plan, shall include, but not be limited to, the following. A monitoring and inspection system covering all the services listed in the Performance Requirements Summary. It must specify the elements of work performance to be monitored and inspected, either on a scheduled or unscheduled basis;

the methods to be used; frequency of monitoring and inspection; the format and content of records and reports to be generated; and the title(s) of the individual(s) who will perform the monitoring and inspection. It shall include, but is not limited to:

o the method for identifying and preventing deficiencies in the quality of services performed before the level of performance can become unsatisfactory;

o the administrative procedures to be followed for reporting to the Contracting Officer’s Technical

Representative (COTR); and for responding to operational problems or complaints concerning work performance, qualifications, or other complaints about Contractor personnel; and o preparation of system of on-site records of all inspections conducted by the Contractor and the corrective action(s) taken.

This documentation shall be presented to the Government on a weekly bases (Mondays) during the term of the contract. The Contractor shall have the COTR sign the documents at least weekly and provide a detailed monthly summary of all quality control actions, including descriptions of events which require quality control activity, and the corrective action taken.

(c) Government Quality Assurance Responsibilities

The Government will monitor the Contractor’s performance using predetermined quality assurance surveillance procedures to examine and determine compliance with contract performance requirements. A copy of these procedures will be provided to the Contractor prior to the start of contract performance. In keeping with the Government’s responsibility for quality assurance, the Government reserves the right to review all administrative, managerial, and statistical reports; telecommunications services; publicity materials and resource library materials using the Performance Requirements Summary. A copy of the Performance Requirements Summary will be provided to the Contractor prior to the start of contract performance. Final determination that reports, resource and publicity materials, and services rendered meet the requirements is solely the responsibility of the Government. All surveillance observations will be recorded by the Government. When an observation indicates defective performance, the Quality Assurance Evaluator (QAE) will request that the Contract Manager or designee initial the observation record. The Contractor shall, within 48 hours, notify the Contracting Officer, or his/her technical representative if so directed by the Contracting Officer, of the corrective action(s) taken in accordance with methods and techniques specified by the Contractor in its quality control plan. If the Contractor disputes any part of the QAE’s observation, he/she shall request that the Contracting Officer hold a Performance Evaluation Meeting.

(d) Performance Evaluation Meetings

The Contract Manager may be required to meet with the COTR, the QAE, and the Contracting Officer whether by telephone or at a designated Contractor-operated location on at least a weekly basis during the first month after the issuance of a Task Order under this contract. Meetings will be held as often as necessary thereafter at the discretion of the Contracting Officer or the COTR. However, a meeting will be held whenever a contract discrepancy report is issued. A mutual good faith effort will be made to resolve all problems identified.

The COTR will write the minutes of these meetings, and the minutes will be signed by the Contract Manager and the COTR. The attendee will, within three (3) business days, identify any areas wherein he/she does not agree by proving written notice to the COTR.

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not -

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes re-inspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may -

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

52.246-21 Warranty of Construction. (MAR 1994)

Pre-Final Inspection

The Contractor shall give written notice to the Contracting Officer at least 15 calendar days before the date the construction work will be completed and ready for final inspection. The contractor shall conduct a pre-final and final inspection in the presence of the Contracting Officer’s Representative (COR) and/or Site Representative (SR).

Other Government personnel may attend both inspections. A Government Pre-Final Punch List may be developed as result of this inspection of any items not meeting Contract requirements for final acceptance. The list of deficiencies may include the estimated date by which the deficiencies will be corrected. Any discrepancies noted shall be corrected prior to final inspection. The Government reserves the right to request a pre-final Inspection or final inspection.

Final Inspection

(a) The Contracting Officer shall be notified in writing by the Contractor when the final inspection can be conducted. The final inspection shall be requested ten (10) calendar days before the desired date or required completion date of the contract.

(b) The final inspection shall be performed with the Contractor by the Contracting Officer's Technical Representative and/or…