Sol_140F0120Q0148.pdf

United States Department of the Interior

FISH AND WILDLIFE SERVICE

APO, Construction/AE Operations Joint Administrative Operactions

Team 3

NOTICE TO OFFERORS

Solicitation Number: 140F0120Q0148

Description: Water Treatment System Upgrade

Location: Humboldt National Wildlife Refuge (NWR) 1020 Ranch Road, Loleta, CA 95551

Project Magnitude: Between $25,000 and $100,000

Bonding Requirements:

Payment Bond or Irrevocable Letter of Credit

Site Visit: Will be available by appointment only during the weeks of August 10th or August 17th Participants will meet at Humboldt National Wildlife Refuge (NWR) 1020 Ranch Road, Loleta, CA 95551 (Humboldt County). Please contact either Justine Pasiecnik

Instruction to Offerors:

Before submitting an offer, please read the entire solicitation package carefully. Return the following items with your response:

SF18 or Official Quote Technical Response information

Interested contractors must be registered in SAM (System for Award Management, www.sam.gov) and complete online representations and certifications before the solicitation response due date.

Solicitation Question Due Date: Friday, August 28, 2020

Response Due Date: Friday, September 4, 2020 at 5PM EST

Please email all questions/responses to: Justine Pasiecnik at Justine_pasiecnik@fws.gov – questions and quotes will only be accepted via email.

140F0120Q0148

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

08/05/2020 0040498134

1 33

EASTSIDE FEDERAL COMPLEX

911 NE 11TH AVENUE

PORTLAND OR 97232-4181

FWS, DIVISION OF CONTRACTING AND GE

FWS HUMBOLDT BAY NWR

PO BOX 576

LOLETA

CA 95551-9633

413 253-8287Justine Pasiecnik

09/04/2020 1700 ET

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

This opportunity is only available to Small Business. The U.S. Fish and Wildlife Service has a requirement to replace the current water treatment system which provides potable water to a visitor's center at Humboldt National Wildlife Refuge (NWR) 1020 Ranch Road, Loleta, CA 95551 (Humboldt County). Award will be based a lowest price technically acceptable evaluation method as detailed in Section M of the solicitation.

Interested contractors must be registered in SAM (System for Award Management, www.sam.gov) and complete Online Representations and Certifications. This will be a Firm-Fixed Priced Contract.

A pre-bid site visit will be held as detailed in Continued ...

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 33

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140F0120Q0148 clause 52.236-27 during the weeks of August 10th and 17th by appointment only.

The NAICS code is 221310 - Water Supply and

Irrigation Systems and the size standard is $30 million. The project magnitude is between $25,000 and $100,000.

The work will commence within 15 days of Notice to Proceed and be completed within 75 days.

All technical questions and contractual questions shall be directed to Justine Pasiecnik at

Justine_pasiecnik@fws.gov. All questions should be submitted in writing via email. All answers will be posted in the form of an amendment to the solicitation.

Bonds: For any proposals that exceed $35,000 the contractor shall furnish either a payment bond or irrevocable letter of credit (ILC)

Legacy Doc #: FWS

Period of Performance: 09/15/2020 to 11/15/2020

00010 Water Treatment System Upgrade in accordance with the attached Statement of Work

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

SOLICITATION PROVISIONS AND CLAUSES

TABLE OF CONTENTS

Section Title Part I—The Schedule

A Solicitation Form B Quote Schedule C Specifications/Drawings D Packaging and Marking E Inspection and Acceptance F Deliveries or Performance G Contract Administration Data H Special Contract Requirements

Part II—Contract Clauses I Contract Clauses

Part III—List of Documents, Exhibits, and Other Attachments J List of Attachments

Part IV—Representations and Instructions K Representations, certifications, and other statements of offerors L Instructions, conditions, and notices to offerors M Evaluation Method

SECTION C:

DESCRIPTION/SPECIFICATIONS

The Contractor shall furnish all labor, materials, equipment, and supervision required to install the water treatment system upgrade as shown in the contract drawings and specifications attached.

SECTION D:

PACKAGING AND MARKING

1. Payment of Postage and Fees All postage and fees related to submitting information forms, reports, etc., to the CO or the COR shall be paid by the contractor.

2. Marking All information submitted to the Contracting Officer or the Contracting Officer's Representative shall clearly indicate the Contract Number of the contract for which the information is being submitted.

SECTION E:

INSPECTION AND ACCEPTANCE

52.246-12 Inspection of Construction. (Aug 1996) 52.246-21 Warranty of Construction. (MAR 1994)

SECTION F:

DELIVERIES OR PERFORMANCE

52.242-14 Suspension of Work. (APR 1984)

52.211-10 -- Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to

(a) commence work under this contract within 15 days of the notice to proceed being issued,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use no later than 60 days after work has begun. The time stated for completion shall include final cleanup of the premises.

(End of Clause)

SECTION G:

CONTRACT ADMINISTRATION DATA

1. CONTRACT REPRESENTATIVE

Contracting Officer (CO) responsible for this contract:

Justine Pasiecnik Contract Specialist Acquisition Construction/A&E Operations Joint Administrative Operations U.S. Fish & Wildlife Service

Contracting Officer's Representative (COR) for this contract: NAME

CO will act as COR until further notice.

2. CONTRACTING OFFICER’S REPRESENTATIVE – LIAISON

The COR will act like as a liaison between the U.S. Fish & Wildlife Service herein referred to as “Service” and the Contractor, and, when necessary, will provide technical direction to the Contractor. The COR, however, is not authorized to change any of the terms and conditions of the contract, issue new assignments of work, make decisions concerning disputes arising under the contract, or resolve differing site condition matters. Neither the presence nor absence of the government representative shall relieve the Contractor of its responsibilities under the contract.

3. JOB SITE ADMINISTRATION

Government inspections do not relieve the Contractor of responsibility for providing adequate quality control measures. No one but the CO and COR is authorized to make technical decisions or give technical directions; the Contractor or the Contractor’s Superintendent must contact the COR regarding such decision and direction. The Contractor shall have a competent superintendent (hereinafter referred to as the “Contractor’s Superintendent” who is (i) deemed acceptable to the Government; (ii) authorized to act on the Contractor’s behalf; and (iii) be present on the job site at all times when contract work is being performed. (See Superintendence by the Contractor, Section I, Federal Acquisition Regulations (FAR) Clause 52.236-6.)

4. DOI ELECTRONIC INVOICING Electronic Invoicing and Payment Requirements-Invoice Processing Platform (IPP) (SEPTEMBER 2011)

Payment requests must be submitted electronically through the U.S. Department of the Treasury’s Invoice Processing Platform System (IPP).

“Payment request” means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract or the clause 52.212-4 Contract Terms and Conditions-Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov . Under this contract, the following documents are required to be submitted to the Contracting Officer before the electronic invoice is submitted into IPP:

Hardcopy invoice is to be submitted to Contracting Officer for review and approval before electronic invoice is entered.

Prime contractor and subcontract payrolls Payment Request Certification Release of Claims (final invoice)

SF 1413 – Statement and Acknowledgment (if applicable) Warranty Certificates (if applicable)

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in CCR) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3-5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Template)

SECTION H:

SPECIAL CONTRACT REQUIREMENTS

1. UTILITIES

The Contractor, at its expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of each utility used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

2. GENERIC GENDER TERMINOLOGY

Except where stipulated by the Federal Acquisition Regulations, the use of terms such as he, she, his, and her are not to be interpreted as implying other than neutral gender terms such as "it" or "their"

3. SAFETY

a. The Contractor shall have the ultimate responsibility for safety on the project site at all times until final completion and acceptance of the project.

b. The Contractor shall comply with all Occupational Safety and Health Administration (OSHA) regulations, as found in 29 CFR 1910 and 1926, which are applicable to the construction project, including requirements set forth within solicitation provisions and contract clauses. In addition to OSHA safety standards, the Contractor shall also adhere to all current local, federal, and state safety requirements. In the event where any safety standard referenced herein conflicts with another, the more stringent shall govern.

c. The Contractor shall initiate and maintain an effective safety program that provides adequate systematic policies, procedures, and practices to protect their employees from and allow them to recognize, job-related safety and health hazards. The program shall include provisions for the systematic identification, evaluation, prevention and control of general work site hazards, specific job hazards, and potential hazards that may arise from foreseeable construction methods and conditions, as well as providing a competent person to conduct frequent and regular inspections. Each employee must be instructed in the recognition and avoidance of unsafe conditions and the regulations applicable to the work environment.

d. The Contractor shall immediately notify the CO of any accident, incident, or exposure resulting in a fatality, lost-time injury, or property loss/damage of $2,500 or more arising out of work performed under this contract. The Contractor shall investigate all work-related accidents/incidents to the extent necessary to determine their cause(s) and furnish the CO an investigative report outlining findings and proposed or completed corrective actions. The contractor shall, when required by the CO, have a separate and complete independent investigation of the accident/incident, and submit a comprehensive report of findings and recommendations to the CO. The CO shall consult with the COR and Service safety personnel in reviewing the investigation report and corrective actions. If the contractor fails or refuses to institute prompt corrective action, the CO may invoke the suspension-of-work clause in this contract or any other remedy available to the government. Any delay or cost resulting from a safety-related suspension of work will be borne by the Contractor.

e. In the event of an accident/incident, the Contractor shall be responsible for providing and obtaining appropriate medical and emergency assistance. Except for rescue and emergency measures, the scene of the accident/incident shall not be disturbed or the operation resumed until the on-site aspect of the investigation has been completed.

f. Service safety personnel and representatives from Federal, State, and local government agencies shall have the right to examine and conduct an investigation at sites or areas where work under this contract is being performed.

The absence of such investigations shall not relieve the contractor of their safety program responsibilities.

4. ENVIRONMENTAL

The contractor is responsible for establishing and maintaining compliance with all applicable laws, regulations, rules, and standards, including without limitation, those regulations, rules, and standards, promulgated for the administration and enforcement of the following laws: the Comprehensive Environmental Response, Compensation and Liability Act (CERCLA) as amended by Superfund Amendments and Reauthorization Act (SARA); Emergency Planning and Community Right-to-Know Act (EPCRA); Clean Air Act (CAA); Clean Water Act (CWA); Toxic Substances Control Act (TSCA); and Solid Waste Disposal Act (SWDA), as amended by Resource Conservation and Recovery Act (RCRA).

5. PROGRESS MEETINGS (if applicable)

a. The Contractor’s representative shall be available to meet with the CO or his/her representative at the job site during construction to discuss work progress.

b. Meetings will be scheduled by the CO or COR with timely notification to the Contractor.

c. At the progress meetings, the Contractor shall give oral reports of the progress on the project to the CO or COR.

If the work is behind schedule, the Contractor shall be prepared to (i) discuss the work and any causes of work delay(s); (ii) present a plan to bring the work back into conformance with the schedule; or, if necessary (iii) to propose a revised work schedule.

6. SUBMITTALS

a. It is the responsibility of the contractor to identify all submittals required by the specifications, referencing the Subdivision applicable, and submit the list to the CO and COR within 14 calendar days after contract award. Failure to list a submittal will not relieve the contractor from submission of required information. A Submittal Register will be provided for completion.

b. All submittals requiring approval shall be submitted by the Contractor using a government-approved submittal form. The form must include the contract number and description of contents. All submittals shall be submitted for a 14 calendar day review by the COR, to allow adequate review prior to commencement of work in that area. (See Materials and Workmanship, Section I, FAR Clause 52.236-5.)

7. CONTRACT DRAWINGS AND SPECIFICATIONS

a. The Government will provide to the Contractor, without charge, one set of contract drawings and specifications (if applicable), except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the CO.

b. The Contractor shall:

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the CO of ambiguities, contradictions, gaps in information, if any;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph

(5) Reproduce and print contract drawings and specifications as needed. (After award, if additional copies of specifications and drawings are available, they will be provided to the contractor.)

c. Omissions from the drawings or specifications or the mis-description of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or mis-described details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

d. The work shall conform to the specifications and the contract drawings identified in Section J.

8. "AS BUILT" RECORD DRAWINGS (if applicable)

a. Contractor shall maintain in proper order, one (1) complete set of clean prints of all drawings on the project site.

b. The Contractor shall neatly inscribe, in red ink or pencil, all changes in work, and the dates of such changes, on the prints. The changes shall be noted in sufficient detail and clarity to accurately portray all "as built" conditions.

c. At the time of final inspection, the Contractor shall present the "as built" drawings to the CO.

9. APPLICABLE WAGE RATE DECISION

The Secretary of Labor has made a determination of the minimum prevailing wage rates which are to be paid to the classes of labor to be employed on this project. The decision number and date with minimum rates for this project are shown in Section J. The Contractor must furnish copies of their payrolls to the CO, weekly, seven (7) days after close of payroll period.

10. WORK HOURS

Working hours for the Contractor must be in accordance with the operational hours of each site being worked on., Monday thru Friday, excluding Saturdays, Sundays, and legal holidays. Advance coordination with the CO is required prior to working at any other time.

11. PRECONSTRUCTION CONFERENCE

a. After award, the Contractor shall attend a preconstruction conference with representatives of the Government at a time and place mutually agreed upon. (See Preconstruction Conference, Section I, FAR Clause 52.236-26.)

12. CHANGES

During the performance of this contract, various Government personnel will periodically appear on the job site to inspect contractor performance. The contractor is advised that ONLY the CO has the authority to direct or approve any change for work that will affect the price, quality, quantity, or performance time.

13. COST BREAKDOWN OF CONTRACT PAYMENTS

a. Contractors must furnish a cost breakdown of any lump sum items which will provide the basis for progress payments. The cost breakdown shall be submitted in a format acceptable to the Contracting Officer and each item shall include overhead and profit. Contractor and COR must agree on the percentage of work completed at the end of each month. Contractor will submit an invoice monthly for payment to the CO. This invoice must be signed by the COR or it will be returned to the Contractor and will delay payment. A correctly signed invoice is reviewed by the COR who prepares a contract progress report, and returns the payment request to the CO who approves and processes for payment.

b. Payments are authorized by FAR Clause 52.232-5, which requires that the Contractor certify with each payment request that he has paid or will pay with the proceeds of the payment his employees and subcontractors.

14. PROGRESS SCHEDULE/REPORTS

A contract progress schedule is required within 10 days after work commences. Actual progress must be reported on a contract progress report every two weeks. A copy of these forms shall be provided to you. (See Schedules for Construction Contracts, Section I, FAR Clause 52.236-15.)

15. MODIFICATION PROPOSALS-PRICE BREAKDOWN

a. The Contractor shall furnish an itemized price breakdown, within the time specified by the Contracting Officer, with any proposal for a contract modification.

b. The price breakdown:

c. Must include sufficient detail of all costs for—

(1) Material;

(2) Labor;

(3) Equipment;

(4) Subcontracts; and

(5) Overhead and Profit; and

d. Must cover all work involved in the modification, whether the work was deleted, added, or changed.

e. The Contractor shall provide similar price breakdowns to support any amounts claimed for subcontracts.

f. The Contractor's proposal shall include a justification for any time extension proposed. A revised progress schedule will be required if time is adjusted.

16. QUALITY CONTROL

The Contractors Quality Control Inspector and/or Superintendent shall ensure all items on the Pre-Final Punch List, rejected and nonconforming work, along with all remaining work conforms to the contract terms, construction documents and industry standards, prior to the final inspection. The Contractor is responsible for maintaining its own pre final and final inspection records. The Contractor will be legally and financially responsible for not completing all of the contract requirements in accordance with the contract terms.

17. BENEFICIAL USE OR OCCUPANCY

The Contractor shall complete all inspections and commissioning requirements prior to final inspection. The warranty shall be issued in accordance with FAR 52.246.21. Extended warranties offered by the contractor and its subcontractors or suppliers may be accepted at the Government’s discretion.

18. REPEAT INSPECTIONS

In the event the Contracting Officer finds that the project is not ready for the applicable inspections, (too many discrepancies) the contractor may be held liable for the cost of a repeat inspection. If the inspection involves the Contracting Officer, Contract Specialist, COR, Safety Officer or other key members, these cost may include additional labor, travel and miscellaneous expense.

SECTION I:

CONTRACT CLAUSES

52.204-13 -- System for Award Management Maintenance. (Oct 2018) 52.204-18 -- Commercial and Government Entity Code Maintenance. (Jul 2016) 52.204-19 -- Incorporation by Reference of Representations and Certifications. (Dec 2014) 52.204-23 -- Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities. (JUL 2018) 52.204-25 -- Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) 52.209-10 -- Prohibition on Contracting With Inverted Domestic Corporations. (Nov 2015) 55.213-4 -- Terms and Conditions –Simplified Acquisitions (Other Than Commercial Items) (OCT 2019) 52.215-8 -- Order of Precedence - Uniform Contract Format. (OCT 1997) 52.219-6 -- Notice of Total Small Business Set-Aside. (Nov 2011) 52.219-28 -- Post-Award Small Business Program Representation. (Jul 2013) 52.222-6 -- Construction Wage Rate Requirements (AUG 2018) 52.222-7 -- Withholding of Funds. (MAY 2014) 52.222-8 -- Payrolls and Basic Records. (AUG 2018) 52.222-9 -- Apprentices and Trainees. (JUL 2005) 52.222-10 -- Compliance with Copeland Act Requirements. (FEB 1988) 52.222-11 -- Subcontracts (Labor Standards). (May 2014) 52.222-12 -- Contract Termination - Debarment. (May 2014) 52.222-13 --Compliance with Construction Wage Rate Requirements and Related Regulations. (May 2014) 52.222-14 -- Disputes Concerning Labor Standards. (FEB 1998) 52.222-15 -- Certification of Eligibility. (May 2014) 52.222-27 -- Affirmative Action Compliance Requirements for Construction. (Apr 2015) 52.223-2 -- Affirmative Procurement of Biobased Products Under Service and Construction Contracts. (Sep 2013) 52.223-6 -- Drug-Free Workplace. (May 2001) 52.223-17 -- Affirmative Procurement of EPA-designated Items in Service and Construction Contracts. (AUG 2018) 52.223-18 -- Encouraging Contractor Policies to Ban Text Messaging While Driving. (Aug 2011) 52.227-1 -- Authorization and Consent. (Dec 2007) 52.227-2 -- Notice and Assistance Regarding Patent and Copyright Infringement. (Dec. 2007) 52.227-4 -- Patent Indemnity -- Construction Contracts. (Dec 2007) 52.228-2 -- Additional Bond Security (Oct 1997) 52.228-5 -- Insurance - Work on a Government Installation. (Jan 1997) 52.228-11-- Pledges of Assets. (AUG 2018) 52.228-14 -- Irrevocable Letter of Credit. (Nov 2014) 52.232-5 -- Payments Under Fixed-Price Construction Contracts. (May 2014) 52.232-16 -- Progress Payments. (Apr 2012) Alternate I 52.232-23 -- Assignment of Claims. (May 2014) 52.232-27 -- Prompt Payment For Construction Contracts. (Jan 2017) 52.233-1 -- Disputes (May 2014) 52.236-7 -- Permits and Responsibilities. (Nov 1991) 52.236-9 -- Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984) 52.236-10 -- Operations and Storage Areas. (APR 1984) 52.236-11 -- Use and Possession Prior to Completion. (APR 1984) 52.236-12 -- Cleaning Up. (APR 1984) 52.236-13 -- Accident Prevention. (NOV 1991) 52.236-14 -- Availability and Use of Utility Services. (Apr 1984) 52.236-21 -- Specifications and Drawings for Construction. (FEB 1997) 52.236-26 -- Preconstruction Conference. (Feb 1995) 52.243-5 -- Changes and Changed Conditions (Apr 1984) 52.248-3 -- Value Engineering – Construction. (Oct 2015)

52.249-1 -- Termination for Convenience of the Government (Fixed-Price) (Short Form). (Apr 1984) 52.249-10 -- Default (Fixed-Price Construction). (Apr 1984)

CLAUSES IN FULL TEXT

52.225-9 -- Buy American–Construction Materials (May 2014)

(a) Definitions. As used in this clause--

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: NONE

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of measure Quantity Price (dollars) *

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.]

[*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

(End of Clause)

52.213-4 -- Terms and Conditions—Simplified Acquisitions (Other Than Commercial Items) (Jan 2018)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN

2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (Jun 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(iv) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19

U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

(ii) 52.232-8, Discounts for Prompt Payment (Feb 2002).

(iii) 52.232-11, Extras (Apr 1984).

(iv) 52.232-25, Prompt Payment (Jan 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)

(vii) 52.233-1, Disputes (May 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (Nov 2017).

(ix) 52.253-1, Computer Generated Forms (Jan 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (OCT 2016) (Pub. L.

109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126)

(Applies to contracts for supplies exceeding the micro-purchase threshold.)

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (May 2014)

(41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S.

Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (Jul 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, “United States” includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (Applies when 52.222- 6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP)) will be—

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (JUN 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (JUN 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American—Supplies (May 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition—

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C.

1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (Jul 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information).

(xx) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (JUL

2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (JUN 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (OCT 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (Sept 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (Nov 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://acquisition.gov/browse/index/far

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights—

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work.

Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records.

The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of Clause)

52.228-13 – Alternative Payment Protections (Jul 2000)

(a) The Contractor shall submit one of the following payment protections:

Payment Bond Irrevocable Letter of Credit

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of contract award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

(End of Clause)

52.236-1 Performance of Work by the Contractor. (APR 1984) The Contractor shall perform on the site, and with its own organization, work equivalent to at least 15 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

52.236-6 – Superintendence by the Contractor (Apr 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

(End of Clause)

52.243-7 Notification of Changes (Jan 2017)

(a) Definitions. “Contracting Officer,” as used in this clause, does not include any representative of the Contracting Officer.

“Specifically Authorized Representative (SAR),” as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within 5 calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state --

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including --

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the…