REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

THIS RFQ IS IS NOT A SMALL BUSINESS SET-ASIDE

15. DATE OF QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

b. TELEPHONE

AREA CODE

NUMBER

STANDARD FORM 18 (REV. 6/1995)

Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

8. TO:

b. COMPANYa. NAME

c. STREET ADDRESS

d. CITY e. STATE f. ZIP CODE

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

d. STATE e. ZIP CODE

7. DELIVERY

FOB DESTINATION

OTHER

(See Schedule)

10. PLEASE FURNISH QUOTATIONS TO THE

ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS (Date)

IMPORTANT: This is a request for information and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or service. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

ITEM NUMBER

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

a. NAME OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

PAGE OF PAGES

1. REQUEST NUMBER 2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NUMBER 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG. 1

RATING

5a. ISSUED BY 6. DELIVER BY (Date)

NAME TELEPHONE NUMBER

AREA CODE NUMBER

c. CITY

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

1315 E-W HWY., SSMC-3 RM 14820

/F/HC

NMFS Field Delegates

601 EAST 12TH STREET SUITE 1746

KANSAS CITY MO 64106

143013-26-00251333MF26Q0053

SHAWANA RANDOLPH

OFC OF HABITAT CONSERVATION

20910

06/25/2026

07/06/2026 1300 ED

10 Days After Award

SILVER SPRING

MD

1 42

1333MF26Q0053 BASE

Section II - Supplies or Services and Price/Costs Section III - Description/Specifications Section IX - Contract Clauses Section X - List of Attachments

Section II - Supplies or Services and Price/Costs

Item/Sub Number Description Quantity Unit of

Issue Unit Price Total Item Amount

Services, non-personal, to provide all labor, equipment and materials (unless otherwise provided herein) in accordance with the Statement of Work and the following: Disconnect a walk-in freezer, a standby diesel generator, and automatic transfer switch from commercial power in accordance with the attached statement of work.

DELIVERY SCHEDULE: Within 10 days of Award. DELIVERY LOCATION: Louisiana Department of Wildlife and Fisheries, 2000 Quail Dr, Baton Rouge, LA 70808

Section III - Description/Specifications

STATEMENT OF NEED (SON)

STATEMENT OF NEED

National Oceanic and Atmospheric Administration (NOAA) NOAA Fisheries, Office of Habitat Conservation (OHC) Deepwater Horizon (DWH) Louisiana Marine Mammals Stranding Network

PURPOSE: Disconnect a walk-in freezer, a standby diesel generator, and automatic transfer switch from commercial power.

SCOPE OR MISSION: For the past three years, the Louisiana Marine Mammal Stranding Network (LA- MMSN) has leased a walk-in freezer connected to commercial power. The freezer is also connected to an emergency standby generator and automatic transfer switch (ATS) to power the freezer during power outages. This freezer is used to store and preserve stranded cetacean (whales and dolphins) tissue samples, carcasses, and other parts for future analyses and testing. It has been determined that there is no longer a need for a freezer in Baton Rouge. Per the conditions of the freezer lease, the unit must be disconnected from all power (commercial and backup) prior to being removed at the end of the lease period. As this equipment is no longer needed in Baton Rouge, the entire setup—the freezer, generator, and ATS—must be disconnected prior to removal.

BACKGROUND: The Louisiana Trustee Implementation Group (TIG) developed a Final Restoration Plan/Environmental Assessment (RP/EA) #5: Living Coastal and Marine Resources (LCMR) - Marine Mammals and Oysters in an effort to contribute to the restoration of lost natural resources in the Louisiana restoration area as a result of the DWH oil spill. This plan includes the project "Increasing Capacity and Expanding Partnerships along the Louisiana Coastline for Marine Mammal Stranding Response". A key gap to address is the lack of adequate sample storage freezers in the state. A contract had been awarded and a freezer was delivered to the Louisiana Department of Wildlife and Fisheries (LDWF) facility in August 2022, which was connected in 2023. Since there is no longer a need for a freezer in Baton Rouge, the freezer, as well as the generator and automatic transfer switch, need to be disconnected from electrical service so the freezer can be removed at the end of the lease period. The generator and ATS will be processed together through GSA as excess property.

TECHNICAL SPECIFICATIONS:

• Disconnection Requirements:

• Disconnect and secure electrical connection and cabling between freezer, generator, and automatic transfer switch

• Existing Electrical Connection:

• Freezer located approximately 15 ft from electrical panel; Stand-by generator is located 5-10 ft behind freezer.

• Freezer Electrical specs:

• Polar King Model DT810

• Voltage: 208-230/110V

• Phase: 1

• Cycle: 60 Hz

• MCA: 19.6 A

• Generator Electrical specs:

• Kohler Model 15REOZK

• Alternator: 4D3.8

• Voltage: 120/240V, 1Ph, 3W, 1.0PF

• kW/kVA: 16/16

• Amps: 66.7

• ATS specs o Kohler Model KSS-AFNC-0104S o Amps: 104 o Volts: 240V/60Hz o 2-Pole/3Wire, Solid Neutral o Nema 3R Enclosure, Standard Connection

• Contractor must remove all excess materials and trash from worksite upon completion.

Figure 1 - Generator and ATS

Figure 2 - Freezer Disconnect Box

Figure 3 - Freezer Wiring Diagram

SPECIAL REQUIREMENTS: Electricians must be licensed and insured.

DELIVERY SCHEDULE: Within 10 days of Award.

DELIVERY LOCATION: Louisiana Department of Wildlife and Fisheries, 2000 Quail Dr, Baton Rouge, LA 70808

CONTRACTORS INVOICE:.INVOICES MUST BE SUBMITTED UPON COMPLETION AND ACCEPTANCE OF

WORK IN ARREARS

Per NAM 1330-52.232-71 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (FEB 2023) The Contractor must submit payment requests electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP). The Contractor must use the IPP website to register, access, and submit payment requests. The IPP website address ishttps://www.ipp.gov.

"Payment request" means any request for contract financing payment or invoice payment to the Contractor. To be considered proper, invoices must be prepared in accordance with, and contain all elements specified in, the contract payment clause (e.g., FAR 52.212-4(g), FAR 52.232-25(a)(3), FAR 52.232-26(a)(2), FAR 52.232-27(a)(2)). All invoices are to be submitted in arrears per 31 U.S.C. § 3324.

Advance payments are prohibited by 31 U.S.C. § 3324, which provides that, except as provided by a specific appropriation or other law, “a payment under a contract to provide a service or deliver an article for the United States Government may not be more than the value of the service already provided or the article already delivered.” The primary purpose of 31 U.S.C. § 3324 is to protect the Government against the risk of nonperformance (or refusal to refund moneys) by the contractor after receipt of payment. See 22 Comp. Gen. 834, 835 (1946). In its simplest terms, the statute prohibits the Government from paying for goods before they have been received or for services before they have been rendered.

The Contractor must include the following documents as attachments to payment requests submitted through the IPP: none If the Contractor is unable to comply with the requirement to submit payment requests through the IPP due to a threat to national security; a matter of unusual or compelling urgency; or because the political, financial, or communications infrastructure of a foreign country does not support access to the IPP, the Contractor must request an exception in writing. Contact the Contracting Officer for more information about requesting an exception.

(End of Clause) https://www.ipp.gov/

Section IX - Contract Clauses

Clause List

Standard Language UTILIZATION OF FEDCONNECT FOR CONTRACT ADMINISTRATION

The Department of Commerce will utilize the FedConnect® web portal in administering this award. The contractor must be registered in FedConnect® and have access to the FedConnect® website located at https://www.fedconnect.net/Fedconnect/. For assistance in registering or for other FedConnect® questions please call the FedConnect® Help Desk at (800) 899-6665 or email at support@fedconnect.net. There is no charge for registration in or use of FedConnect®.

FAR 52.222-3 Convict Labor. (JUN 2003)

FAR 52.222-41 Service Contract Labor Standards. (AUG 2018)

FAR 52.222-62 Paid Sick Leave Under Executive Order 13706. (JAN 2022)

CAR 1352.201-70 Contracting Officer's Authority. (MAR 2010)

CAR 1352.209-73 Compliance with the laws. (APR 2010)

CAR 1352.209-74 Organizational conflict of interest. (APR 2010)

CAR 1352.233-70 Agency protests. (APR 2010)

(a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999).

(b) Agency protests filed with the Contracting Officer shall be sent to the following address:

National Marine Fisheries Service Attn: Branch Chief MB Field Delegates, Acq. Services Division 1315 East West Highway, Floor 14 Silver Spring, MD 20910

(c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: NOAA Acquisition and Grants Office Policy and Oversight Division Field Delegate Program Manager 601 E 12th St. Suite 1746, Kansas City, MO 64106

(d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority.

(e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

CAR 1352.233-71 GAO and Court of Federal Claims protests. (APR 2010)

(a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed.

(b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims.

(c) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

NOAA Acquisition Manual 1330-52.222-70 NOAA SEXUAL ASSAULT AND SEXUAL HARASSMENT

PREVENTION AND RESPONSE POLICY (MAY 2018)

In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA.

(a) Definitions.

Contractor Employees - The term “contractor employees,” as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members.

Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim.

Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true:

● Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment;

● Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual;

● The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment.

The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient’s sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures.

(b) Requirements.

1. It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment.

2. The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor.

3. If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the COR, subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6.07, Reporting from Remote Locations.

4. Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants’ needs are addressed.

5. The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor’s written policy (where applicable).

6. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within [ ] business days (30 unless a different number is inserted) of contract award or the date a contractor employee is assigned to perform under the contract, as applicable.

Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion.

Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance.

7. The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA’s Workplace Violence Program Manager. A link to the website including the required elements of the training is provided at https://www.noaa.gov/organization/acquisition-grants/noaa-workplace-harassment-training-for-contractors-and-financial. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed.

8. The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training.

9. NOAA’s Workplace Violence Program Manager, COR, or CO may periodically review the contractor’s training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor.

10. Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106.

11. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees.

(c) Sexual Assault/Sexual Harassment (SASH) Helpline.

For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee.

All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including:

● Phone: 1-866-288-6558

● Website & Online Chat: https://www.noaasashhelpline.org/

● Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores)

● Text: (202) 335-0265

(d) Confidentiality.

Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. “Confidentiality” means that the information shall only be shared with others who have a need to know the information to conduct their official duties.

(e) Remedies.

In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in:

1. Requiring the contractor to remove a contractor employee or employees from the performance of the contract;

2. Requiring the contractor to terminate a subcontract;

3. Suspension of contract payments until the Contractor has taken appropriate remedial action;

4. Termination of the contract for default or cause, in accordance with the termination clause of this contract;

5. Suspension or debarment; or

6. Other appropriate action.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-70 CONTRACTOR COMMUNICATIONS

(a) A contractor employee shall be identified both by the individual’s name and the contractor’s name when:

● Included in NOAA’s locator, and

● When submitting any type of electronic correspondence to any NOAA employee or stakeholder.

(b) Any written correspondence from a contractor or any contractor employee shall be printed on company/organization letterhead or otherwise clearly identify the sender as an employee of the company or organization and shall identify the contract number.

(c) Contractors and/or contractor employees shall clearly identify themselves as such in any verbal communications, whether in informal discussion or a formal meeting.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-71 NOAA GOVERNMENT-CONTRACTOR RELATIONS - NON-

PERSONAL SERVICES CONTRACT (SEPT 2017)

(a) The Government and the contractor understand and agree that the services to be delivered under this contract by the contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the contractor’s personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations.

(b) Contractor personnel under this contract shall not:

1. Be placed in a position where they are under relatively continuous supervision and control of a Government employee.

2. Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other contractors performing under other NOAA contracts.

(c) The services to be performed under this contract do not require the contractor or the contractor’s personnel to exercise personal judgment and discretion on behalf of the Government. Rather, the contractor’s personnel will act and exercise personal judgment and discretion on behalf of the contractor.

(d) Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract.

(e) Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies:

1. The contractor shall notify the contracting officer in writing within 5 business days from the date of any situation or occurrence where the contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance.

2. The contracting officer will review the information provided by the contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the contractor. The contracting officer’s response will provide a decision on whether the contracting officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the issue.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-72 CONTRACTOR ACCESS TO NOAA FACILITIES (SEPT 2017)

(a)

1. The performance of this contract requires employees of the prime contractor or its subcontractors, affiliates, consultants, or team members (“contractor employees”) to have access to and to the extent authorized, mobility within, a NOAA facility.

2. NOAA may close and or otherwise deny contractor employees access to a NOAA facility for a portion of a business day or longer for various reasons including, but not limited, to the following events:

i. Federal public holidays for Federal employees in accordance with 5 U.S.C. 6103;

ii. Fires, floods, earthquakes, and unusually severe weather, including but not limited to snow storms, tornadoes, and hurricanes;

iii. Occupational safety or health hazards;

iv. Lapse in Appropriations; or

v. Federal Statute, Executive Order, Presidential Proclamation, or any other unforeseen reason.

3. In such events, the contractor employees may be denied access to a NOAA facility that is ordinarily available for the contractor to perform work or make delivery, as required by the contract.

(b) In all instances where contractors are denied access or required to vacate a NOAA facility, in part or in whole, the contractor shall be responsible to ensure contractor personnel working under the contract comply. If the circumstances permit, the contracting officer will provide direction to the contractor, either directly or through the COR, which could include continuing on-site performance during the NOAA facility closure period; however, if Government oversight is required and is not available, on-site performance shall not be allowed. In the absence of such direction, the contractor shall exercise sound judgment to minimize unnecessary contract costs and performance impacts, for example, performing required work off- site if possible or reassigning personnel to other activities if appropriate.

(c) The contractor shall be responsible for monitoring the Office of Personnel Management at opm.gov, the local radio, television stations, NOAA web sites, and other communication channels. Once the facility is accessible, the contractor shall resume contract performance as required by the contract.

(d) For the period that NOAA facilities were not accessible to contractors who required access in order to perform the services, the contracting officer may—

1. Adjust the contract performance or delivery schedule for a period equivalent to the period the NOAA facility was not accessible;

2. Forego the work; or

3. Reschedule the work by mutual agreement of the parties.

(e) Notification procedures of a NOAA facility closure, including contractor denial of access, are as follows:

1. The contractor shall be responsible for notification of its employees of the NOAA facility closure to include denial of access to the NOAA facility. The dismissal of NOAA employees in accordance with statute and regulations providing for such dismissals shall not, in itself, equate to a NOAA facility closure in which contractors are denied access. Moreover, the leave status of NOAA employees shall not be conveyed or imputed to contractor personnel. Accordingly, unless a NOAA facility is closed and the contractor is denied access to the facility, the contractor shall continue performance in accordance with the contract.

2. Access to Government facilities and resources, including equipment and systems, will be limited and personnel necessary to administer contract performance may not be available. Generally, supply and service contracts that are funded beyond the date of the lapse in appropriation and do not require access to Government facilities, active administration by Government personnel or the use of Government resources in a manner that would cause the Government to incur additional obligations during the lapse in appropriation may continue. If a delivery date for a contract falls during the period of a lapse in appropriations, Government personnel may not be available to receive delivery. Contractors are directed to consult with a contracting officer before attempting to make a delivery. Contracting officers will be available throughout the lapse in appropriation period to provide guidance.

Once OMB guidance is given, CORs, in consultation with the contracting officer, will notify those contractors that are deemed by the Program Office to be performing excepted work and identify the contractor personnel requiring access to NOAA facilities. CORs will also coordinate directly with facility management or physical security personnel at respective locations to ensure that the names of contractor personnel requiring access to Government facilities during the lapse in appropriations are provided to physical security personnel.

Contractors who are not designated as performing excepted work are not allowed access to Government facilities or to utilize Government resources in a manner that would incur any additional obligation of funding on behalf of the Government during the lapse in appropriation.

3. Unless otherwise specified within the contract award, contractors requiring access to NOAA facilities outside normal business hours or outside the normal workweek shall submit a written request in writing through the COR to the contracting officer. The written request shall provide justification supporting the required access and be submitted [ ] hours/days (contracting officer insert number of days. If blank, 72 hours applies) before access to the NOAA facility is needed.

(End of solicitation and contract language)

RFO 52.203-17 Contractor Employee Whistleblower Rights. (NOV 2023)

RFO 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. (JAN 2017)

RFO 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

(JAN 2017)

RFO 52.204-7 SYSTEM FOR AWARD MANAGEMENT-REGISTRATION. (NOV 2024) (Deviation JAN 2026)

RFO 52.204-13 SYSTEM FOR AWARD MANAGEMENT-MAINTENANCE. (OCT 2018) (Deviation JAN 2026)

RFO 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS. (NOV 2015) (Deviation JAN 2026)

RFO 52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE. (NOV 2020) (Deviation JAN 2026)

RFO 52.222-42 Statement of Equivalent Rates for Federal Hires. (MAY 2014)

In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor (29 CFR part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C. 5341 or 5332.

This Statement is for Information Only: It Is Not A Wage Determination

Employee class Monetary wage - Fringe benefits

WG-2805-10 (Electrician) $29.23 $10.65

(End of clause)

RFO 52.222-50 COMBATING TRAFFICKING IN PERSONS. (OCT 2025) (Deviation JAN 2026)

RFO 52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (JAN 2022)

RFO 52.223-5 Pollution Prevention and Right-to-Know Information. (MAY 2024)

RFO 52.223-23 SUSTAINABLE PRODUCTS AND SERVICES. (MAY 2024) (Deviation JAN 2026)

RFO 52.226-8 Encouraging Contractor Policies To Ban Text Messaging While Driving. (MAY 2024)

RFO 52.232-33 Payment by Electronic Funds Transfer - System for Award Management. (OCT 2018)

RFO 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (MAR 2023)

RFO 52.233-3 PROTEST AFTER AWARD. (AUG 1996) (Deviation JAN 2026)

RFO 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM. (OCT 2004) (Deviation JAN 2026)

RFO 52.237-2 Protection of Government Buildings, Equipment, and Vegetation. (APR 1984)

RFO 52.240-90 SECURITY PROHIBITIONS AND EXCLUSIONS REPRESENTATIONS AND CERTIFICATIONS.

(Deviation JAN 2026)

RFO 52.240-91 SECURITY PROHIBITIONS AND EXCLUSIONS. (Deviation JAN 2026)

RFO 52.240-92 Security Requirements. (Deviation JAN 2026)

RFO 52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES. (OCT

2025) (Deviation JAN 2026)

RFO 52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW. (FEB 2016) (Deviation JAN 2026)

(a) The Government will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that-

(1) It is ___ is not ___ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is ___ is not ___ a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

RFO 52.212-1 INSTRUCTIONS TO OFFERORS-COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES.

(SEP 2023) (Deviation JAN 2026)

(a) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. As a minimum, offers shall include-

(1) The solicitation number;

(2) The name, address, telephone number of the Offeror;

(3) The Offeror's Unique Entity Identifier (UEI) and, if applicable, Electronic Funds Transfer (EFT) indicator;

(4) Information necessary to evaluate the factors contained in the provision at 52.212-2 or as described in the solicitation;

(5) Responses to provisions that require Offeror completion of information, representations, and certifications (other than those collected via the System for Award Management (SAM)); and

(6) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and any solicitation amendments.

(b) Period for acceptance of offers. The Offeror agrees to hold the prices in its offer firm for 60 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(c) Late submissions, modifications, revisions, and withdrawals of offers.

(1) Offerors are responsible for submitting offers and any modifications or revisions to the Government office designated in the solicitation by the time specified in the solicitation.

(2) Any offer, modification, or revision received after the time specified for receipt of offers is "late" and will not be considered unless it is received before award is made and the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition. However, a late modification of an otherwise successful offer that makes its terms more favorable to the Government will be considered at any time it is received and may be accepted.

(3) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(4) Offerors may withdraw their offers by written notice to the Government received at any time before award.

(d) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with Offerors. Therefore, the Offeror's initial offer should contain the Offeror's best terms. However, the Government reserves the right to conduct discussions, if necessary. The Government may reject any or all offers if such action is in the public interest, accept other than the lowest offer, and waive informalities and minor irregularities in offers received.

(e) Debriefings. If a postaward debriefing is given to requesting Offerors, the Government will disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed Offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful Offeror and the debriefed Offeror and past performance information on the debriefed Offeror.

(3) The overall ranking of all Offerors when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award.

(5) For acquisitions of commercial products, the make and model of the product to be delivered by the successful Offeror.

(6) Reasonable responses to relevant questions posed by the debriefed Offeror as to whether the agency followed source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities.

(End of provision)

RFO 52.212-2 EVALUATION-COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES. (NOV 2021)

(Deviation JAN 2026)

(a) Evaluation factors. This requirement will be awarded to the offeror with the lowest price technically acceptable (LPTA) quote. Technically acceptable means the items quoted match the specified requirement of the RFQ. Failure to include all required items in the quote will render the quote ineligible for award. The criteria listed is all of equal value and will be evaluated on the basis of pass or fail. Please ensure to include details about what is being offered as just providing a price does not give enough information to deem technically acceptable or not.

1. The quote shall meet the Technical Specifications identified in the Statement of Need.

Electricians license and insurance must be provided with the package.

2. Firm-Fixed price to include FOB Destination.

(b) Options (if applicable). The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. The evaluation of options does not obligate the Government to exercise the option(s).

(c) Notice of award. A written notice of award or acceptance of an offer furnished to the successful Offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

RFO 52.212-4 TERMS AND CONDITIONS-COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES. (NOV 2023) (Deviation JAN 2026)

(a) Definitions. The clause at Federal Acquisition Regulation (FAR) 52.202-1, Definitions, is incorporated by reference.

(b) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post acceptance rights-

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(c) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.

3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(d) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(e) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal, or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause FAR 52.233-1, Disputes, which is incorporated in this contract by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence. Examples of occurrences include acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. When an excusable delay occurs, the Contractor shall-

(1) Notify the Contracting Officer in writing as soon as possible;

(2) Remedy the delay as quickly as possible; and

(3) Notify the Contracting Officer when the occurrence is over.

(g) Invoice. The Government will handle invoices according to the Prompt Payment Act (31 U.S.C. 3903) and 5 CFR part 1315. The Contractor shall submit invoices to the address designated in the contract to receive invoices. An invoice must include the information required by 5 CFR part 1315.9(b).

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees, and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark, or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment-

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act ( 31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date that appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(4) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable;

(D) Contractor point of contact; and

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(5) Interest.(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by FAR part 33 if-

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see FAR part 32).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a termination for cause.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures for interest credits prescribed in FAR part 32 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon-

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. The Government will send a cure notice to the Contractor, unless the reason for the termination is late delivery. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law.