Sol_1305M326Q0489.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3.AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 29. AWARD OF CONTRACT: REFERENCE

. YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4.

FAR 52.212-3 AND 52.212-5 ARE ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED.

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

DATED.

OFFER

ADDENDA

ADDENDA

1305M326Q0489

SANTA CRUZ LAB

NOAA/NMFS 110 MCALLISTER WAY

/F/SWC5

SANTA CRUZ CA 95060

WAD-SAP

7600 Sand Point Way NE

SEATTLE WA 98115

WAD-SAP

7600 Sand Point Way NE

SEATTLE WA 98115

08/28/2026 1300 ED

JENNA TAULMAN

WAD-SAP-S

WAD-SAP-S

JENNA L. TAULMAN

562112

$47

08/21/2026

FR750031

* Please review the entirety of this Request

For Quotes (RFQ) and its attachments to ensure your eligibility for contract award.

** It is highly recommended that all offerors

Continued...

STOCK RECORD (S/R)

STANDARD FORM 1449 (REV. 11/2021) BACK

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE RECEIVED (MM/DD/YYYY) 42d. TOTAL CONTAINERS

40. PAID BY

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32g. EMAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

PARTIAL FINAL

37. CHECK NUMBER

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER

36. PAYMENT

COMPLETE PARTIAL FINAL

ACCEPTED,

carefully review and comply with Revolutionary

FAR Overhaul (RFO) Provisions: 52.212-1 -

Instructions to Offerors—Commercial Products and Commercial Services, 52.212-2 -

Evaluation—Commercial Products and Commercial

Services. These provisions contain very important information related to this RFQ.

1. Regulations. Revolutionary FAR Overhaul

(RFO) Effective April 17, 2026 applies to this acquisition.

2. Solicitation Questions and Answers, Requests

For Information (RFIs), (Inquiries). Questions regarding this solicitation shall be submitted electronically to Jenna Taulman at jenna.taulman@noaa.gov by 12:00 PM Eastern Time on Tuesday, August 25, 2026. Any responses to questions will be made in writing, without identification of the questioner, and will be included in an amendment to the solicitation.

Even if provided in another form, only the question responses included in the amendment to the solicitation will govern performance of the contract.

3. Quote Submission Due Date. Quotations shall be submitted via email, directly to jenna.taulman@noaa.gov no later than the date and time specified in Page 1, Block 8 of the SF

Continued...

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

1305M326Q0489

1449.

4. Validity of quotes. The Government intends to award this requirement, pending the availability of funding, before September 30, 2026. Offerors shall hold their quotations valid through September 30, 2026.

5. Service Contract Act. Attachment 2 -

Service Contract Act WD # 2015-5649 Rev 26 and

Service Contract Act WD # 1996-0223 Rev 69

6. Solicitation instructions and evaluation criteria for quotes. Again, see the following provisions of this RFQ: RFO Provisions 52.212-1 and 52.212-2.

0001 Santa Cruz, CA Lab Hazardous Waste Removal

Services - See solicitation's Pricing Schedule

Firm-fixed-price

Eastimated PoP: 9/3/2026 to 9/2/2027

Product/Service Code: F108

Period of Performance: 09/03/2026 to

09/02/2027

1305M326Q0489 BASE

Section II - Supplies or Services and Price/Costs Section IX - Contract Clauses Section X - List of Attachments Section XII - Instructions, Conditions, and Notices

Section II - Supplies or Services and Price/Costs

CLIN List

Item Number Description Quantity Unit Unit Price Amount

Santa Cruz, CA Lab Hazardous Waste Removal Services - See solicitation's Pricing Schedule Firm-fixed-price Eastimated PoP: 9/3/2026 to 9/2/2027 Award Type: Firm-fixed-price Product/Service Code: F108 Period of Performance: 09/03/2026 to 09/02/2027

Section IX - Contract Clauses

Clauses Incorporated by Reference Clause Number Clause Title

52.203-17 Contractor Employee Whistleblower Rights. (NOV 2023)

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. (JAN 2017)

52.204-9 Personal Identity Verification of Contractor Personnel.

(JAN 2011)

52.204-13 System for Award Management-Maintenance. (OCT 2018) (Deviation JAN 2026)

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (FEB 2016) (Deviation JAN 2026)

52.212-4 Terms and Conditions-Commercial Products and Commercial Services. (NOV 2023) (Deviation JAN 2026)

52.222-3 Convict Labor. (JUN 2003)

52.222-41 Service Contract Labor Standards. (AUG 2018) (Not for DOC Use)

52.222-42 Statement of Equivalent Rates for Federal Hires. (MAY 2014)

52.222-50 Combating Trafficking in Persons. (OCT 2025) (Deviation

JAN 2026)

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (JAN 2022)

52.222-62 Paid Sick Leave Under Executive Order 13706. (JAN 2022)

52.222-90 Addressing DEI Discrimination by Federal Contractors ((DEVIATION April 2026))

52.223-5 Pollution Prevention and Right-to-Know Information.

(MAY 2024)

52.225-1 Buy American-Supplies (OCT 2022) (Deviation JAN 2026)

52.226-8 Encouraging Contractor Policies To Ban Text Messaging While Driving. (MAY 2024)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (MAR 2023)

52.233-3 Protest after Award. (AUG 1996) (Deviation JAN 2026)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004) (Deviation JAN 2026)

52.237-2 Protection of Government Buildings, Equipment, and Vegetation. (APR 1984)

52.244-6 Subcontracts for Commercial Products and Commercial Services. (OCT 2025) (DEVIATION April 2026)

52.247-34 F.o.b. Destination. (JAN 1991)

52.253-1 Computer Generated Forms. (JAN 1991) (Deviation JAN 2026)

1352.209-74 Organizational conflict of interest. (APR 2010)

1 DOC 2026 REAL ID ENFORCEMENT

REAL ID Act Enforcement As of January 1, 2026, all Department of Commerce–owned or leased facilities will only accept a REAL ID-compliant form of identification. Visitors with state-issued identification must now present a REAL ID or a different form of government-issued photo identification, such as: A passport, an Enhanced Driver's License, or a federal employee, military, or veteran identification card (this list is not all-inclusive).

Additional information about the Department’s implementation plan may be found at https://www.commerce.gov/OSY/REAL-ID.

Standard Language UTILIZATION OF FEDCONNECT FOR CONTRACT ADMINISTRATION

The Department of Commerce will utilize the FedConnect® web portal in administering this award. The contractor must be registered in FedConnect® and have access to the FedConnect® website located at https://www.fedconnect.net/Fedconnect/. For assistance in registering or for other FedConnect® questions please call the FedConnect® Help Desk at (800) 899-6665 or email at support@fedconnect.net. There is no charge for registration in or use of FedConnect®.

RFO 52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far-overhaul/far-part-deviationguide

(End of clause)

RFO 52.252-6 Authorized Deviations in Clauses. (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the clause.

(b) The use in this solicitation or contract of any Commerce Acquisition Regulation (48 CFR 13) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of clause)

CAR 1352.201-70 Contracting Officer's Authority. (MAR 2010)

The Contracting Officer is the only person authorized to make or approve any changes in any of the requirements of this contract, and, notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely in the Contracting Officer. In the event the contractor makes any changes at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract terms and conditions, including price.

(End of clause)

CAR 1352.209-73 Compliance with the laws. (APR 2010)

The contractor shall comply with all applicable laws, rules and regulations which deal with or relate to performance in accord with the terms of the contract.

(End of clause)

CAR 1352.233-71 GAO and Court of Federal Claims protests. (APR 2010)

(a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed.

(b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims.

(c) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)

CAR 1352.246-70 Place of acceptance. (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

NOAA Fisheries SWFSC Santa Cruz Laboratory 110 McAllister Way Santa Cruz, CA 95060

(End of clause)

CAR 1352.270-70 Period of performance. (APR 2010)

(a) The base period of performance of this contract is from Est 9/3/2026 through 9/2/2027. If an option is exercised, the period of performance shall be extended through the end of that option period.

(b) The option periods that may be exercised are as follows:

N/A

(c) The notice requirements for unilateral exercise of option periods are set out in FAR 52.217-9.

(End of clause)

NOAA Acquisition Manual 1330-52.222-70 NOAA SEXUAL ASSAULT AND SEXUAL HARASSMENT

PREVENTION AND RESPONSE POLICY (MAY 2018)

In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA.

(a) Definitions.

Contractor Employees - The term “contractor employees,” as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members.

Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim.

Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true:

● Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment;

● Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual;

● The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment.

The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient’s sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures.

(b) Requirements.

1. It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment.

2. The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor.

3. If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the COR, subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6.07, Reporting from Remote Locations.

4. Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants’ needs are addressed.

5. The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor’s written policy (where applicable).

6. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within 30 business days (30 unless a different number is inserted) of contract award or the date a contractor employee is assigned to perform under the contract, as applicable.

Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion.

Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance.

7. The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA’s Workplace Violence Program Manager. A link to the website including the required elements of the training is provided at https://www.noaa.gov/organization/acquisition-grants/noaa-workplace-harassment-training-for-contractors-and-financial. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed.

8. The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training.

9. NOAA’s Workplace Violence Program Manager, COR, or CO may periodically review the contractor’s training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor.

10. Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106.

11. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees.

(c) Sexual Assault/Sexual Harassment (SASH) Helpline.

For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee.

All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including:

● Phone: 1-866-288-6558

● Website & Online Chat: https://www.noaasashhelpline.org/

● Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores)

● Text: (202) 335-0265

(d) Confidentiality.

Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. “Confidentiality” means that the information shall only be shared with others who have a need to know the information to conduct their official duties.

(e) Remedies.

In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in:

1. Requiring the contractor to remove a contractor employee or employees from the performance of the contract;

2. Requiring the contractor to terminate a subcontract;

3. Suspension of contract payments until the Contractor has taken appropriate remedial action;

4. Termination of the contract for default or cause, in accordance with the termination clause of this contract;

5. Suspension or debarment; or

6. Other appropriate action.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.232-71 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (FEB 2023)

The Contractor must submit payment requests electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP). The Contractor must use the IPP website to register, access, and submit payment requests. The IPP website address is https://www.ipp.gov.

"Payment request" means any request for contract financing payment or invoice payment to the Contractor. To be considered proper, invoices must be prepared in accordance with, and contain all elements specified in, the contract payment clause (e.g., FAR 52.212-4(g), FAR 52.232-25(a)(3), FAR 52.232-26(a)(2), FAR 52.232-27(a)(2)).

The Contractor must include the following documents as attachments to payment requests submitted through the IPP: vendor's invoice.

If the Contractor is unable to comply with the requirement to submit payment requests through the IPP due to a threat to national security; a matter of unusual or compelling urgency; or because the political, financial, or communications infrastructure of a foreign country does not support access to the IPP, the Contractor must request an exception in writing. Contact the Contracting Officer for more information about requesting an exception.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-70 CONTRACTOR COMMUNICATIONS

(a) A contractor employee shall be identified both by the individual’s name and the contractor’s name when:

● Included in NOAA’s locator, and

● When submitting any type of electronic correspondence to any NOAA employee or stakeholder.

(b) Any written correspondence from a contractor or any contractor employee shall be printed on company/organization letterhead or otherwise clearly identify the sender as an employee of the company or organization and shall identify the contract number.

(c) Contractors and/or contractor employees shall clearly identify themselves as such in any verbal communications, whether in informal discussion or a formal meeting.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-71 NOAA GOVERNMENT-CONTRACTOR RELATIONS - NON-

PERSONAL SERVICES CONTRACT (SEPT 2017)

(a) The Government and the contractor understand and agree that the services to be delivered under this contract by the contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the contractor’s personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations.

(b) Contractor personnel under this contract shall not:

1. Be placed in a position where they are under relatively continuous supervision and control of a Government employee.

2. Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other contractors performing under other NOAA contracts.

(c) The services to be performed under this contract do not require the contractor or the contractor’s personnel to exercise personal judgment and discretion on behalf of the Government. Rather, the contractor’s personnel will act and exercise personal judgment and discretion on behalf of the contractor.

(d) Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract.

(e) Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies:

1. The contractor shall notify the contracting officer in writing within 5 business days from the date of any situation or occurrence where the contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance.

2. The contracting officer will review the information provided by the contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the contractor. The contracting officer’s response will provide a decision on whether the contracting officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the issue.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-72 CONTRACTOR ACCESS TO NOAA FACILITIES (SEPT 2017)

(a)

1. The performance of this contract requires employees of the prime contractor or its subcontractors, affiliates, consultants, or team members (“contractor employees”) to have access to and to the extent authorized, mobility within, a NOAA facility.

2. NOAA may close and or otherwise deny contractor employees access to a NOAA facility for a portion of a business day or longer for various reasons including, but not limited, to the following events:

i. Federal public holidays for Federal employees in accordance with 5 U.S.C. 6103;

ii. Fires, floods, earthquakes, and unusually severe weather, including but not limited to snow storms, tornadoes, and hurricanes;

iii. Occupational safety or health hazards;

iv. Lapse in Appropriations; or

v. Federal Statute, Executive Order, Presidential Proclamation, or any other unforeseen reason.

3. In such events, the contractor employees may be denied access to a NOAA facility that is ordinarily available for the contractor to perform work or make delivery, as required by the contract.

(b) In all instances where contractors are denied access or required to vacate a NOAA facility, in part or in whole, the contractor shall be responsible to ensure contractor personnel working under the contract comply. If the circumstances permit, the contracting officer will provide direction to the contractor, either directly or through the COR, which could include continuing on-site performance during the NOAA facility closure period; however, if Government oversight is required and is not available, on-site performance shall not be allowed. In the absence of such direction, the contractor shall exercise sound judgment to minimize unnecessary contract costs and performance impacts, for example, performing required work off- site if possible or reassigning personnel to other activities if appropriate.

(c) The contractor shall be responsible for monitoring the Office of Personnel Management at opm.gov, the local radio, television stations, NOAA web sites, and other communication channels. Once the facility is accessible, the contractor shall resume contract performance as required by the contract.

(d) For the period that NOAA facilities were not accessible to contractors who required access in order to perform the services, the contracting officer may—

1. Adjust the contract performance or delivery schedule for a period equivalent to the period the NOAA facility was not accessible;

2. Forego the work; or

3. Reschedule the work by mutual agreement of the parties.

(e) Notification procedures of a NOAA facility closure, including contractor denial of access, are as follows:

1. The contractor shall be responsible for notification of its employees of the NOAA facility closure to include denial of access to the NOAA facility. The dismissal of NOAA employees in accordance with statute and regulations providing for such dismissals shall not, in itself, equate to a NOAA facility closure in which contractors are denied access. Moreover, the leave status of NOAA employees shall not be conveyed or imputed to contractor personnel. Accordingly, unless a NOAA facility is closed and the contractor is denied access to the facility, the contractor shall continue performance in accordance with the contract.

2. Access to Government facilities and resources, including equipment and systems, will be limited and personnel necessary to administer contract performance may not be available. Generally, supply and service contracts that are funded beyond the date of the lapse in appropriation and do not require access to Government facilities, active administration by Government personnel or the use of Government resources in a manner that would cause the Government to incur additional obligations during the lapse in appropriation may continue. If a delivery date for a contract falls during the period of a lapse in appropriations, Government personnel may not be available to receive delivery. Contractors are directed to consult with a contracting officer before attempting to make a delivery. Contracting officers will be available throughout the lapse in appropriation period to provide guidance.

Once OMB guidance is given, CORs, in consultation with the contracting officer, will notify those contractors that are deemed by the Program Office to be performing excepted work and identify the contractor personnel requiring access to NOAA facilities. CORs will also coordinate directly with facility management or physical security personnel at respective locations to ensure that the names of contractor personnel requiring access to Government facilities during the lapse in appropriations are provided to physical security personnel.

Contractors who are not designated as performing excepted work are not allowed access to Government facilities or to utilize Government resources in a manner that would incur any additional obligation of funding on behalf of the Government during the lapse in appropriation.

3. Unless otherwise specified within the contract award, contractors requiring access to NOAA facilities outside normal business hours or outside the normal workweek shall submit a written request in writing through the COR to the contracting officer. The written request shall provide justification supporting the required access and be submitted 72 hours hours/days (contracting officer insert number of days. If blank, 72 hours applies) before access to the NOAA facility is needed.

(End of solicitation and contract language)

Section X - List of Attachments

Attachment Number Title

1 Attachment 1 - SOW Santa Cruz Hazardous Waste Removal 2 Attachment 2_ Service Contract Act WD 2015-5649 Rev 26 3 Attachment 3 Service Contract Act WD 1996-0223 Rev 69

4 1305M326Q0489 SC Lab Hazardous Waste List Pricing Schedule

5 Past Performance Questionnaire 1305M326Q0489

Section XII - Instructions, Conditions, and Notices

RFO 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. (JAN 2017)

RFO 52.204-7 System for Award Management-Registration. (NOV 2024) (Deviation JAN 2026)

RFO 52.209-2 Prohibition on Contracting With Inverted Domestic Corporations-Representation. (NOV 2015) (Deviation JAN 2026)

RFO 52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015) (Deviation JAN 2026)

RFO 52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation JAN 2026)

RFO 52.212-1 Instructions to Offerors-Commercial Products and Commercial Services. (SEP 2023) (Deviation JAN 2026)

(a) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. As a minimum, offers shall include—

(1) The solicitation number;

(2) The name, address, email address, telephone number of the Offeror;

(3) The Offeror’s Unique Entity Identifier (UEI) and, if applicable, Electronic Funds Transfer (EFT) indicator;

(4) Information necessary to evaluate the factors contained in the provision at 52.212-2 or as described in the solicitation -

a. Technical Approach and Capability

b. Price Quote

c. Past Performance Questionnaire(s)

(5) Responses to provisions that require Offeror completion of information, representations, and certifications (other than those collected via the System for Award Management (SAM)); and

(6) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and any solicitation amendments.

(b) Period for acceptance of offers. The Offeror agrees to hold the prices in its offer firm for 60 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(c) Late submissions, modifications, revisions, and withdrawals of offers.

(1) Offerors are responsible for submitting offers and any modifications or revisions to the Government office designated in the solicitation by the time specified in the solicitation.

(2) Any offer, modification, or revision received after the time specified for receipt of offers is “late” and will not be considered unless it is received before award is made and the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition. However, a late modification of an otherwise successful offer that makes its terms more favorable to the Government will be considered at any time it is received and may be accepted.

(3) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(4) Offerors may withdraw their offers by written notice to the Government received at any time before award.

(d) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with Offerors. Therefore, the Offeror’s initial offer should contain the Offeror’s best terms. However, the Government reserves the right to conduct discussions, if necessary. The Government may reject any or all offers if such action is in the public interest, accept other than the lowest offer, and waive informalities and minor irregularities in offers received.

(e) Debriefings. If a postaward debriefing is given to requesting Offerors, the Government will disclose the following information, if applicable:

(1) The agency’s evaluation of the significant weak or deficient factors in the debriefed Offeror’s offer.

(2) The overall evaluated cost or price and technical rating of the successful Offeror and the debriefed Offeror and past performance information on the debriefed Offeror.

(3) The overall ranking of all Offerors when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award.

(5) For acquisitions of commercial products, the make and model of the product to be delivered by the successful Offeror.

(6) Reasonable responses to relevant questions posed by the debriefed Offeror as to whether the agency followed source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities.

(End of provision)

RFO 52.212-2 Evaluation-Commercial Products and Commercial Services. (NOV 2021) (Deviation JAN 2026)

(a) Evaluation factors. The Government will award a contract resulting from this solicitation to the responsible Offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The Government may utilize a comparative evaluation during the evaluation process. The following factors, listed in order of importance, will be used to evaluate quotes:

1. Technical Approach and Capability: The Government will evaluate the Vendor’s Technical Approach and Capability approach, as defined in FAR 52.212-1, to determine its level of confidence based on the following four ratings:

Highly Confident: The Government has high confidence that the Vendor understands the requirement and will be successful in performing the contract with no Government intervention. The Vendor provided a Technical Approach that exceeds the Government’s minimum requirements.

Confident: The Government has confidence that the Vendor understands the requirement and will be successful in performing the contract with little to no Government intervention. The Vendor provided a Technical Approach that clearly meets the Government’s minimum requirements.

Some Confidence: The Government has some confidence that the Vendor understands the requirement and may be successful in performing the contract with some Government intervention. The Vendor provided a Technical Approach that doesn’t clearly meet all of the Government’s minimum requirements.

Low Confidence: The Government has low confidence that the Vendor understands the requirement or will be successful in performing the contract even with Government intervention. The Vendor provided a Technical Approach that does not meet the Government’s minimum requirements.

2. Price: The Government will evaluate the Offeror’s pricing. The total evaluated price will include the sum of the Offeror’s price for each Line Item and will be evaluated for reasonableness and completeness.

3. Past Performance: The Government’s evaluation of Past Performance will be used, as appropriate, to determine successful performance of contract requirements, quality and timeliness of delivery of goods, services and/or construction, cost management, communications between contracting parties, proactive management and/or customer satisfaction.

The Government will evaluate all Past Performance Questionnaire(s) received in response to this solicitation.

The Government may also consider past performance information from a wide variety of sources both inside and outside the Government. This may include reviewing performance information reported to the Contractor Performance Assessment Reporting System, as well as other sources of information. For some commercial products or services, such as emerging technology, this should include consideration of commercial market experience. Contracting officers may consider an offeror’s experience as a subcontractor.

Vendors lacking relevant past performance history, or for whom past performance information is either not available or has not been submitted to the Government, will receive a rating of “Neutral” for past performance. Neutral ratings will not be considered negatively, but may be considered less favorably when compared to higher rated past performance ratings.

The government will then assign one of the following Past Performance ratings, as an overall rating, for each vendor:

Favorable: The vendor submitted positive past performance relevant to the requirement in this solicitation.

Neutral: The vendor lacks relevant past performance history, past performance questionnaire(s) were not received by the Government, or past performance information received did not permit the government to assign a favorable or unfavorable rating.

Unfavorable: The vendor submitted negative past performance relevant to the requirement in this solicitation.

(c) Notice of award. A written notice of award or acceptance of an offer furnished to the successful Offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

RFO 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (OCT 2022) (Deviation JAN 2026)

(a) Evaluation preference. (1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(b) Waiver of evaluation preference. A HUBZone small business concern may choose to waive the evaluation preference. If the concern waives the preference, the factor will be added to its offer for evaluation purposes.

[ ] Offeror chooses to waive the evaluation preference.

(c) Joint venture. A HUBZone joint venture agrees that, in the performance of the contract, at least 40 percent of the aggregate work performed by the joint venture shall be completed by the HUBZone small business parties to the joint venture. Work performed by the HUBZone small business parties to the joint venture must be more than administrative functions.

(End of provision)

RFO 52.225-2 Buy American Certificate. (OCT 2022)

(a)(1) The Offeror certifies that each end product, except those listed in paragraph (b) of this provision, is a domestic end product and that each domestic end product listed in paragraph (c) of this provision contains a critical component.

(2) The Offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products. For those foreign end products that do not consist wholly or predominantly of iron or steel or a combination of both, the Offeror shall also indicate whether these foreign end products exceed 55 percent domestic content, except for those that are COTS items. If the percentage of the domestic content is unknown, select "no".

(3) The Offeror shall separately list the line item numbers of domestic end products that contain a critical component (see FAR 25.105).

(4) The terms "commercially available off-the-shelf (COTS) item," "critical component," "domestic end product," "end product," and "foreign end product" are defined in the clause of this solicitation entitled "Buy American-Supplies."

(b) Foreign End Products:

Line item No. Country of origin Exceeds 55% domestic content (yes/no)

(b) [List as necessary]

(c) Domestic end products containing a critical component:

Line Item No. ____________

[List as necessary]

(d) The Government will evaluate offers in accordance with the policies and procedures of part 25 of the Federal Acquisition Regulation.

(End of provision)

RFO 52.252-1 Solicitation Provisions Incorporated by Reference. (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov/far-overhaul/far-part-deviationguide

(End of provision)

RFO 52.252-5 Authorized Deviations in Provisions. (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR chapter 1) provision with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the provision.

(b) The use in this solicitation of any Commerce Acquisition Regulation (48 CFR chapter 13) provision with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of provision)

CAR 1352.233-70 Agency protests. (APR 2010)

(a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999).

(b) Agency protests filed with the Contracting Officer shall be sent to the following address:

Jenna Taulman, Contracting Officer jenna.taulman@noaa.gov

(c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: Aakanksha Bhargava, Branch Chief aakanksha.bhargava@noaa.gov

(d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority.

(e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division, Room 5893, Herbert C.

Hoover Building, 14th Street and Constitution Avenue, NW., Washington, DC 20230. FAX: (202) 482-5858.

(End of clause)