Shariki Communications Site.pdf

Project Manual Shariki Infrastructure Upgrades, Shariki Communications Site

U.S. Army Corps of Engineers Japan Engineering District Camp Zama, Japan

Specifications RTA Submittal June 30, 2022

DRAFT

00 01 05.doc

Shariki Infrastructure Upgrades, Shariki Communications Site

U.S. Army Corps of Engineers Japan Engineering District Camp Zama, Japan RTA Submittal June 30, 2022

00 01 05.doc

I hereby certify that this engineering document was prepared by me or under my direct personal supervision and that I am a duly licensed Professional Engineer under the laws of the State of Iowa.

Nathan J. Pierson

_______________________________________________06/30/2022 (signature) (date)

Discipline: Structural Engineer, License No. 20269.

License expires 12/31/2022.

Pages or sheets covered by this seal: Division 3.

I hereby certify that this plan, specification, or report was prepared by me or under my direct supervision and that I am a duly Licensed Professional Engineer under the laws of the state of Minnesota.

Signature: Typed or Printed Name: Carly R. Divine_______________

Date: June 30, 2022 License No: 57296_______________________________

Pages or sheets covered by this seal: Division 31, and Division 32.

Shariki Infrastructure Upgrades, Shariki Communications Site

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 STATEMENT OF WORK

01 11 00.00 10 GENERAL CONTRACT REQUIREMENTS

01 20 00 PRICE AND PAYMENT PROCEDURES

01 32 16.00 20 08/18 SMALL PROJECT CONSTRUCTION PROGRESS

SCHEDULES

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 10 11/16 QUALITY CONTROL

01 45 00.15 10 11/16 RESIDENT MANAGEMENT SYSTEM CONTRACTOR

MODE (RMS CM)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 03/21 TEMPORARY ENVIRONMENTAL CONTROLS -

MASTER DRAFT - Reduced Submittals

01 74 19 CONSTRUCTION AND DEMOLITION WASTE

MANAGEMENT

01 78 00 05/19 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 05/10, CHG 2: 02/19 DEMOLITION

DIVISION 03 - CONCRETE

03 30 00 02/19 CAST-IN-PLACE CONCRETE

03 45 33 05/16 PRECAST STRUCTURAL CONCRETE

DIVISION 26 - ELECTRICAL

26 12 19.10 05/19 THREE-PHASE, LIQUID-FILLED PAD-MOUNTED

TRANSFORMERS

26 20 00 02/14 ELECTRICAL DISTRIBUTION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 08/08 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 11 23 08/17 AGGREGATE BASE COURSES

32 12 13 05/17 BITUMINOUS TACK AND PRIME COATS

32 12 16.16 08/09 HOT-MIX ASPHALT (HMA) FOR ROADS

DIVISION 33 - UTILITIES

33 71 02 02/15 UNDERGROUND ELECTRICAL DISTRIBUTION

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

MS2197

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

STATEMENT OF WORK

PART 1 GENERAL

1.1 General

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

STATEMENT OF WORK

PART 1 GENERAL

1.1 General

The Contractor shall construct a new communications U-Trench from existing U-Trench to the shelter and trailer pads, including a duct bank under an existing road. Contractor shall provide a 208/120 V, 3-phase, 800A, 60Hz electrical service connection point with breaker for a future project (by others). Contractor shall also provide a 208/120 V, 3-phase, 200A, 60Hz service to the shelter pad and two 120V, 1-phase, 15A, 60Hz circuits. One of these will go to the Shelter pad and the other to the Trailer pad. All new power will be run underground in existing and new U-Trenches or duct bank. The project construction will be at Shariki Communication Site, Japan resulting in complete and usable facility.

The intent of this section is to specify the minimum design and construction requirements for quality, function, materials, and types of construction in sufficient detail for Contract completion.

Basis of design, design submittal requirements, construction document drawings, and specifications were prepared to comply with this section. No deviations from this section shall be allowed unless prior approval is obtained from the Contracting Officer. All questions or problems encountered by the Contractor in following the requirements in this section shall be promptly submitted with recommendations to the Contracting Officer for resolution.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 11 00 Page 2

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 10

GENERAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIONS

1.2 REFERENCES

1.3 SUBMITTALS

1.4 ACCEPTABLE ALTERNATIVES JAPANESE STANDARDS

1.5 KEY PERSONNEL QUALIFICATIONS

1.5.1 Project Superintendent (Supervisor)

1.5.2 English Speaking Representative (Interpreter)

1.5.3 Contractor Quality Control

1.5.3.1 Contractor Quality Control System Manager (CQCSM)

1.5.3.2 Contractor Quality Control Personnel

1.5.4 Site Safety and Health Officer (SSHO)

1.5.5 Pass Coordinator

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.7 PERMITS AND RESPONSIBILITIES

1.8 SPECIAL CONTRACT REQUIREMENTS

1.8.1 Meetings

1.8.2 Conformed Drawings Submittal

1.9 PROGRESS AND COMPLETION PHOTOGRAPHS

1.10 BASE REGULATIONS

1.10.1 Request for Contractor's Employee Passes and Vehicle Passes

1.10.2 No Smoking Policy

1.10.3 Munitions and Explosives of Concern (MEC)

1.11 ORDER OF WORK

1.11.1 Schedule

1.11.2 Working Hours

1.11.3 Noise and Vibration

1.11.4 Work Outside of Regular Hours

1.12 FIRE PREVENTION DURING CONSTRUCTION

1.12.1 General

1.12.2 Supply

1.12.3 Fire Extinguishers

1.12.4 Housekeeping

1.12.5 Handling of Gasoline

1.12.6 Notification of Fire

1.13 CONTRACTOR FURNISHED MATERIAL AND WORKMANSHIP

1.14 CORRESPONDENCE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00.00 10 Page 1

SECTION 01 11 00.00 10

GENERAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIONS

The term "Government" refers to "United States Government" whenever the term "Government" appears in this Contract, unless otherwise indicated within the Contract.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2013) Standard for Portable Fire Extinguishers

NFPA 241 (2013; Errata 2015) Standard for Safeguarding Construction, Alteration, and Demolition Operations

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. ARMY GARRISON JAPAN (USAG-J)

Regulation 190-13 (2013) Installation Access and Control Procedures

1.3 SUBMITTALS

Government approval is required for submittals with a "G"; submittals not having a "G" or "S" designation are for information only. When used, a code following the "G" classificaton identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Initial Site Conditions Photos

Key Personnel Qualifications; G

Conformed Drawings Submittal

SD-07 Certificates

Monthly Progress Photos

SECTION 01 11 00.00 10 Page 2

SD-11 Closeout Submittals

Construction Completion Photos

1.4 ACCEPTABLE ALTERNATIVES JAPANESE STANDARDS

Where indicated in the technical specifications REFERENCES paragraphs, acceptable Japanese standards are listed which are considered acceptable alternatives to the US Standards withing the Contract Specifications. The use of products not meeting the applicable US standards of the Contract or alternative Japanese standards specifically authorized by the Contract is prohibited unless authorized by the Contracting Officer. Japanese standards not identified in these specifications as being acceptable alternatives to US standards may be submitted to the Contracting Officer for consideration as acceptable alternatives after award using the variation request process set forth in Section 01 33 00 SUBMITTAL PROCEDURES. Prior to the use of such proposed additional alternative Japanese standards, written approval by the Contracting Officer is required. Incorporation of methods, materials, and equipment that will promote cost-effective and timely maintenance, and that are otherwise authorized by the contract, is highly encouraged.

1.5 KEY PERSONNEL QUALIFICATIONS

The Contractor's Project Key personnel shall not be assigned duties to any other Contracts (excluding the project manager) without approval from the Contracting Officer. One person may be assigned the duties of Project Superintendent and CQC System Manager provided they meet all qualification requirements and maintain presence on site as required for the various duties. The Site Safety Health Officer shall not be assigned other duties.

Within five (5) working days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer an organizational chart, the qualifications and background history of the proposed Key Personnel for approval. The Contracting Officer shall have the explicit right to determine acceptability (or rejection) of the proposed individuals. In addition, the Contractor shall be responsible to replace said individuals upon notification by the Government should performance become inadequate during the Contract period. Key Personnel shall attend the Preconstruction conference.

1.5.1 Project Superintendent (Supervisor)

The Project Superintendent shall be on the work site when on-site work is being performed and shall be available to the Contracting Officer or his representatives upon request. The Project Superintendent shall have overall responsibility for all operations at the job site and be authorized to make decisions, negotiate Contract terms and sign Contract documents on behalf of the Contractor. The Project Superintendent shall have a minimum of five (5) years experience as a superintendent on construction projects containing civil, structural, and electrical components similar in size and scope to this Contract, and have at least one the following qualifications:

a. U.S. Registered Electrical Engineer or 1 Kyu Denkikouji Sekou Kanrigishi (1st Class Electric Construction Management Engineer).

b. U.S. Bachelors Degree in Construction Management or 1 Kyu Kenchiku Sekou Kanrigishi (1st Class Building Construction Management Engineer)

SECTION 01 11 00.00 10 Page 3

1.5.2 English Speaking Representative (Interpreter)

At all times during the Contract period the Contractor shall have an employee capable of fluent bilingual speech in the Japanese and English languages at the job site. The bilingual interpreter shall have the capability to receive and issue concise and technical explanation and instructions between the Government representative(s) and Contractor supervisory personnel concerning all aspects of Contract administration and construction. Within fifteen (15) days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer's Representative the qualifications and background history of the proposed interpreter for approval. The Contracting Officer's Representative shall have the explicit right to determine acceptability or rejection of the proposed individual. In addition, the Contractor shall be responsible to replace said individual upon notification by the Government should performance become inadequate during the Contract period. The interpreter shall attend the preconstruction conference.

1.5.3 Contractor Quality Control

1.5.3.1 Contractor Quality Control System Manager (CQCSM)

The CQC System Manager is required to be a graduate of an accredited college with an engineering, architecture, or construction management degree, with a minimum of 5 years construction experience on construction of similar size and scope to this Contract. Refer to Section 01 45 00.00 10 QUALITY CONTROL, Paragraph "CQC System Manager" for additional requirements.

1.5.3.2 Contractor Quality Control Personnel

The following Contractor Quality Control (CQC) Personnel are required:

Civil, and Electrical.

See Section 01 45 00.00 10 QUALITY CONTROL for qualification requirements for CQC personnel. These individuals or specialized technical companies may be employed by the prime contractor or a subcontractor on this project. These individuals can perform other duties but need to be allowed sufficient time to perform the specialized personnel's assigned quality control duties as described in the Quality Control Plan. A single person can cover more than one area provided that the single person is qualified to perform quality control activities in each designated and that workload allows.

1.5.4 Site Safety and Health Officer (SSHO)

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.5.5 Pass Coordinator

A person on the contractor's staff who is familiar with the requirements of USAG-J Regulation 190-13, Individual and Vehicle Access Pass Procedures, and USAG-J vehicle security inspection procedures. The Pass Coordinator must be able to obtain a DBIDS access pass with escort privileges and may be required to escort other contract personnel. Although a TOEIC score is not required, the Pass Coordinator must be able to understand pass requirements and complete pass application forms in the English language.

SECTION 01 11 00.00 10 Page 4

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This paragraph specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract clause entitled "DEFAULT (FIXED-PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the Contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The listing below defines the monthly anticipated adverse weather days for the Contract period and is based upon 20th Weather Squadron (MAC), U.S. Air Force; Iwakuni U.S. Marine Corps Air Station, Weather Service;

Sasebo Naval Pacific Meteorology and Oceanography Detachment; JASDF (Japan Air Self Defense Force), or similar data for the geographic location of the project. (More specific information may be obtained as specified under Special Contract Requirements Clause entitled "Physical Data.")

MONTHLY ANTICIPATED ADVERSE WEATHER DELAYS

WORK DAYS BASED ON (5) DAY WORK WEEK

Misawa-area Kanto Plain Iwakuni Okinawa Sasebo Osaka

JAN 8 1 2 5 7 4

FEB 9 3 4 7 6 4

MAR 6 6 7 8 7 5

APR 3 6 6 6 7 4

MAY 4 4 6 6 6 4

JUN 5 9 8 6 12 5

JUL 6 6 6 6 9 4

AUG 6 6 5 9 9 3

SEP 6 7 6 7 9 4

OCT 4 5 4 4 8 4

NOV 6 4 4 4 5 3

DEC 7 1 3 5 5 3

The above schedule of anticipated adverse weather days shall constitute the base line for monthly (or portion thereof) weather time evaluations.

c. Upon acknowledgment of the Notice-to-Proceed (NTP) and continuing throughout the Contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days

SECTION 01 11 00.00 10 Page 5 anticipated in paragraph (b), above, the Contracting Officer shall convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Contract clause entitled "DEFAULT

(FIXED PRICE CONSTRUCTION)".

e. For all work under this Contract, adverse weather is defined as:

(1) Rainfall - Number of occurrences of precipitation greater than or equal to 0.10 inches (2.54mm).

(2) Snowfall - Number of occurrences of precipitation greater than or equal to 1.00 inches (25.4mm). (Not applicable to Okinawa Area)

(3) Cold Temperature - Number of occurrences when daily maximum temperature does not exceed the monthly mean low temperature or 32 degrees Fahrenheit (0 degrees Celsius), whichever is lower. (Not applicable to Okinawa Area)

(4) Concurrence between snowfall and cold temperature is 80 percent, i.e. 80 percent of the time snow falls, the temperature is "cold".

(5) Wind - Number of occurrences when the wind is gusting 30 knots (56 kilometers/hour) or greater.

f. The Contractor's schedule must reflect the above anticipated adverse weather delays on all weather-dependent activities.

1.7 PERMITS AND RESPONSIBILITIES

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any laws, codes, and regulations (including the requirements of material, prefectural, and local Government of Japan, and associated military installation) applicable to the performance of work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence. These damages shall be repaired or replaced by the Contractor at no cost to the Government. The Contractor shall take proper safety and health precautions to protect all work and workers.

Submit a schedule of planned road closures to the Contracting Officer with the initial project schedule. Notification of specific road closures shall be in writing to the Contracting Officer not less than thirty (30) calendar days in advance of the intended closure. The road closure request shall include the planned traffic control measures as well as the general information about the closure. All road closures shall be coordinated with base officials and are subject to base requirements. No road closure shall be permitted until the Contractor receives written approval from the Contracting Officer. Full road closures is generally not permitted (at least one way traffic shall always be provided).

1.8 SPECIAL CONTRACT REQUIREMENTS

1.8.1 Meetings

a. Post Award Orientation. A post award orientation (often referred to as a Preconstruction Conference) per FAR 42.503 shall be held. The chairperson shall be the Contracting Officer or his/her designee. The

SECTION 01 11 00.00 10 Page 6 chairperson shall be responsible for providing minutes of the meeting.

b. Weekly Progress Meetings. A weekly progress meeting shall be conducted, with the day, time, and location to be determined at the Preconstruction Conference. The Contractor's Project Manager, Superintendent, Interpreter, and Quality Control Manager shall attend.

Representatives from the Government may include, but are not limited to, Director of Public Works/Facilities Engineering personnel, Project's Resident Office personnel, and Project Manager. The Contractor shall be prepared to discuss work completed during the previous week, work currently in progress, and work forecasted for the following week, as well as the status of any construction issues and open action items. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the progress meeting for review.

c. Red Zone Meeting. A Red Zone meeting shall be conducted for Contracts with a value in excess of 55,000,000 JPY or those deemed sufficiently complex by the Contracting Officer to warrant one. The purpose of the Red Zone meeting is to discuss closeout requirements for the contract and to establish a timeline to get those items completed (see Section 01 78 00 CLOSEOUT SUBMITTALS for typical closeout requirements). The meeting is a good time for the Contractor to gain approval on format for items such as Operations and Maintenance manuals, the equipment-in-place list, the warranty plan, and any other items. The Initial Red Zone is typically scheduled when project reached 75 percent completion milestone. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the Red Zone meeting.

d. Safety and Quality Control Meetings. Safety and quality control meetings shall be held as needed and determined by the Contractor. See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and Section 01 45 00.00 10 USACE QUALITY CONTROL for specific requirements.

e. Construction Waste Management Meetings. See Section 01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT for requirements.

1.8.2 Conformed Drawings Submittal

Contractor shall submit one (1) hard copy Japanese-style folded and bound set of conformed A3 size drawings. Submittal shall be provided to the Resident Office at the Pre-Construction meeting. Conformed drawings are defined as the original advertised drawings with amended drawing sheets replaced in-kind with the corresponding original sheet number. If applicable, add new sheets and remove deleted sheets in accordance with amendment instructions. If multiple amendments are issued, supersede any previously amended drawing so that only the highest numbered amendment drawing is included.

1.9 PROGRESS AND COMPLETION PHOTOGRAPHS

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600 by 1200 by 24 bit true color 300 DPI minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of 10 digital photographs each week throughout the

SECTION 01 11 00.00 10 Page 7 entire project and 20 digital photographs at completion of project. Submit the Initial Site Conditions Photos, Monthly Progress Photos, and Construction Completion Photos. Indicate photographs demonstrating environmental procedures. Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Include a date designator in file names. Cross reference submittals in the appropriate daily report. Photographs provided are for unrestricted use by the Government.

1.10 BASE REGULATIONS

The Contractor and Subcontractor(s) shall become familiar with and obey all base regulations, including fire, traffic, safety, and security regulations. All Contractors shall keep within the limits of the work (and avenues of ingress and egress), and shall not enter any restricted areas unless required to do so and are cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.10.1 Request for Contractor's Employee Passes and Vehicle Passes

No employee or representative of the Contractor shall be admitted to the work site without a Contracting Officer's furnished authorized admittance.

Refer to USAG-J Regulation 190-13. Prior to the start of on-site work, submit applications for base passes to the Contracting Officer for key employees (project manager, site supervisor, interpreter, etc.) for long term DBIDS passes. The Contractor (through the employment of a Pass Coordinator), with assistance from the Resident Office, is responsible for securing sufficient passes for other workers, including subcontractor's employees and vehicles, required to access the base for the project duration. Additional personnel data shall also be furnished.

The Contractor shall use the USAG-J Form 1529 "EZ Pass" as the primary means of obtaining passes for all personnel who do not qualify for DBIDS passes. The USAG-J Form 1529 "EZ Pass" One Time/Multiple Access Roster must be complete and submitted to the Provost Marshall Pass and Vehicle Registration Office a minimum of three (3) U.S. workdays prior to access.

The use of the USAG-J "one day" pass (AJ Form 47) should be avoided, and used only for urgent situations. Applicants for a "one day" pass may be required to wait for several hours for their pass to be issued. Contractor personnel applying for more than one (1) "one-day" pass within any 15-day period will not be issued multiple one-day passes, and will instead be required to apply for access via the USAG-J Form 1529, and wait three or more days for approval.

Provide all information required for background checks to meet base access requirements to be accomplished by Base Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. The Government reserves the right to make changes to the Contractor security requirements or processes due to a change in the Force Protection Condition (FPCON).

Upon completion of this Contract, return all employee and vehicle passes to the base, and obtain a certification of receipt. Final payment shall be withheld until all passes have been returned.

1.10.2 No Smoking Policy

Smoking is prohibited on installations except in designated smoking

SECTION 01 11 00.00 10 Page 8 areas. This applies to existing buildings, buildings under construction, and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer shall identify designated smoking areas.

1.10.3 Munitions and Explosives of Concern (MEC)

Munitions and Explosives of Concern (MEC): Unexploded Ordnance (UXO), Material Presenting a Potential Explosive Hazard (MPPEH), Chemical Agents (CA), or Discarded Military Munitions (DMM) on jobsites shall be treated as extremely dangerous and must be reported immediately. Follow the 3Rs:

RECOGNIZE, RETREAT, and REPORT. In the event MEC are discovered or uncovered, immediately stop work in that area and immediately inform the Contracting Officer's Representative. Contractor shall provide dispatch and Contracting Officer's Representative with specific location of the item. Contractor personnel shall stop work in the immediate vicinity of the discovery and maintain a minimum distance of 300 meters from the item.

Contractor shall maintain flexibility in redirecting personnel and work effort in the event that items possessing an explosive hazard are discovered and construction personnel are excluded from areas during the destruction/removal process.

1.11 ORDER OF WORK

1.11.1 Schedule

Schedule all work to cause the least amount of interference with activity operations. Permission to interrupt any activity or roads shall be requested in writing a minimum of 30 calendar days prior to the desired date of interruption. Interruptions of activities, roads, and utility services shall be allowed only when they will not cause interference with the operations of the activity. The Contractor shall remove and dispose off Government property all Contractor generated debris at the end of each shift, or more frequently if required, to keep the space usable. Upon award of this Contract, the Contractor shall begin and complete all required work; ready for use and including cleanup, within the time period specified on this Contract. All work scheduled in occupied areas shall be accomplished in such a manner as to cause the least possible inconvenience to the occupants.

1.11.2 Working Hours

Normal Working Hours and Days are Monday through Friday, 0800 hours through 1700 hours. Saturday work is allowed on this contract and does not require additional approvals. Notify the Contracting Officer at least three days in advance when scheduling Saturday work.

1.11.3 Noise and Vibration

Noise greater than 70 decibels and vibration producing work in occupied buildings shall be conducted outside core school/business hours (0700 - 1430) unless written permission is given by the Contracting Officer.

1.11.4 Work Outside of Regular Hours

If the Contractor desires to carry on work outside the regular hours, on Sundays, or holidays, a written application shall be submitted to the Contracting Officer or his representative for approval. The Contractor shall allow three working days notice to enable satisfactory arrangements

SECTION 01 11 00.00 10 Page 9 to be made by the Government for inspecting the work in progress. If work is to be accomplished after daylight hours, the Contractor shall illuminate the area in a manner approved by the Contracting Officer or their representative and in accordance with EM 385-1-1. Unless directed by a Contracting Officer, work accomplished outside regular working hours shall be at no additional cost to the Government.

1.12 FIRE PREVENTION DURING CONSTRUCTION

1.12.1 General

Comply with all pertinent fire prevention provisions of the US Army Corps of Engineers Manual EM 385-1-1, NFPA 241 and shall follow the Installation fire regulations. Prior to commencement of welding or other hot work operations, obtain approval from the Installation Fire Chief.

1.12.2 Supply

No more than one day's supply of paint, paint materials, or compounds shall be allowed within the area of the building, and shall be removed from the job site after each working day. No gasoline or similar low flash point flammable liquid shall be allowed within the building area. After proper coordination with the Facility's Emergency Services (to confirm the maximum allowable quantities and location of storage), storage of additional product may be authorized.

1.12.3 Fire Extinguishers

Provide, as a minimum, the number, size, and type of fire extinguishers in accordance with the latest NFPA 10. The Contractor shall comply with the Installation Fire Chief's policies if they are more stringent than NFPA 10.

Fire extinguishers shall remain the property of the Contractor and shall be removed upon completion of the project.

1.12.4 Housekeeping

Accumulations of combustible material shall be removed from the building area on a daily basis.

1.12.5 Handling of Gasoline

Gasoline shall be stored in industry standard approved safety containers.

Adequate ventilation shall be provided to safely dispose of flammable vapors where flammable liquids are utilized. Gasoline powered equipment shall be refueled a minimum 6 meters away from the building area.

1.12.6 Notification of Fire

Be familiar with methods for notifying the Installation Fire Department.

The Installation's fire poster shall be posted in conspicuous locations and at telephones in construction shacks.

1.13 CONTRACTOR FURNISHED MATERIAL AND WORKMANSHIP

The Contractor shall furnish all materials necessary for performance of the work of this contract unless otherwise specified. Materials procured shall be new and shall meet any specifications and standards listed in these specifications. If no specification for a material needed to perform this contract are stated, the material shall be new, of acceptable industrial

SECTION 01 11 00.00 10 Page 10 grade and quality, equal to or better than the manufacturer's original equipment for equipment being repaired or replaced, and will be compatible with existing materials and systems. All materials provided under this contract shall be free of asbestos, lead in paint, and PCB. The Contracting Officer reserves the right to request submittal of any material being provided under this contract. The Contracting Officer shall make the final determination of the acceptability of any material used on this contract.

1.14 CORRESPONDENCE

All correspondence addressed to the Government shall be made through serialized letters furnished with one original and two copies. Serialized letters shall begin with the number S-0001 and shall be continuous without a break in numbering. Serialized letters shall include the contract title and number, date, subject, and shall be signed by an authorized representative of the Contractor.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 11 00.00 10 Page 11

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 GENERAL

1.2 SUBMITTALS

1.3 LINE ITEMS

1.3.1 CLIN 0001, Electrical Infrastructure

1.3.1.1 Payment

1.3.1.2 Unit of Measure

1.3.2 CLIN 0002, Cast-In-Place Concrete Mat Slabs

1.3.2.1 Payment

1.3.2.2 Unit of Measure

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION

3.1 PROGRESS PAYMENT INVOICE

3.2 TRANSPORTATION OF SUPPLIES BY SEA, BILL OF LADING

3.3 CONTRACT COST BREAKDOWN

3.4 CONTRACT ADMINISTRATION

3.4.1 Contracting Officer (KO)

3.4.2 Administrative Contracting Officer (ACO)

3.4.3 Contracting Officer's Representative (COR)

3.5 DESIGNATED BILLING OFFICE

-- End of Section Table of Contents --

SECTION 01 20 00 Page 1

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 GENERAL

Payment items for the work of this Contract for which payments shall be made are listed in the CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, topographic surveys, cost of bond premiums, and for performing all work required by drawings and specifications for which separate payment is not otherwise provided. Work paid for under one item shall not be paid for under any other item. No separate payment shall be made for the work, services, or operations required by the Contractor, as specified in DIVISION 01, GENERAL REQUIREMENTS, to complete the project in accordance with these specifications; all costs thereof shall be considered as incidental to the work.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-07 Certificates

Bill Of Lading; G

1.3 LINE ITEMS

1.3.1 CLIN 0001, Electrical Infrastructure

1.3.1.1 Payment

Payment shall be made at the Contract job price for CLIN 0001 "Electrical Infrastructure" for work completed including, but not limited to new power distribution to the Trailer and Shelter Pads and the HTT-M site and all the infrastructure for these including to U-Trenches, transformers, breakers, cables, conduit, switches, and disconnects. Payment for work completed shall constitute full compensation of CLIN 0001, complete.

1.3.1.2 Unit of Measure

Unit of measure: job.

SECTION 01 20 00 Page 2

1.3.2 CLIN 0002, Cast-In-Place Concrete Mat Slabs

1.3.2.1 Payment

Payment shall be made at the Contract job price for CLIN 0002 "Cast-In-Place Concrete Mat Slabs" for work completed including, but not limited to, cast-in-place concrete mat slabs for pads for the HTT-M site.

Payment for work completed shall constitute full compensation of CLIN 0002, complete.

1.3.2.2 Unit of Measure

Unit of measure: job.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION

3.1 PROGRESS PAYMENT INVOICE

Requests for payment shall be submitted in accordance with Federal Acquisition Regulations (FAR) Subpart 32.9, entitled "PROMPT PAYMENT", and Paragraphs 52.232-5 and 52.232-27, entitled "Payments Under Fixed-Price Construction Contracts", and "Prompt Payment for Construction Contracts", respectively. In addition each request shall be submitted in the number of copies and to the designated billing office as shown in the Contract.

When submitting payment requests, the Contractor shall complete Blocks 1 through 12 of the "PROGRESS PAYMENT INVOICE" Form as directed by the Contracting Officer (provided in RMS CM). The completed form shall then become the cover document to which all other support data shall be attached.

One additional copy of the entire request for payment, to include the "PROGRESS PAYMENT INVOICE" cover document, shall be forwarded to a separate address as designated by the Contracting Officer.

The Contractor shall submit with each pay request, a list of subcontractors that have worked during that pay period. The listing shall be broken down into weeks, identifying each subcontractor that has worked during a particular week, and indicate the total number of employees that have worked on site for each subcontractor for each week. The prime Contractor shall also indicate the total number of employees for its on site staff for each week.

Formal invoices shall be submitted every month between the first and the tenth of the month. Any invoice received after the tenth will be considered as not meeting the contract requirements and rejected. It may be resubmitted on the first of the following month.

3.2 TRANSPORTATION OF SUPPLIES BY SEA, BILL OF LADING

The Contractor shall, within 30 days after each shipment covered by Defense Federal Acquisition Regulation (DFAR) Subpart 252.247-7023, provide the Contracting Officer and the Maritime Administration (MARAD) one copy of the rated on board vessel operating carrier's ocean Bill of Lading. See DFAR 252.247-7023 for information required in the bill of lading. MARAD contact information: usarmy.scott.sddc.mbx.g3-ffw-team@mail.mil and msc.n101.ffw@navy.mil.

SECTION 01 20 00 Page 3

The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract. If U.S.-flag vessels are not available, the Contractor may submit a request for use of foreign-flag vessels in writing to the Contracting Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. Refer to DFAR 252.247-7023 for required documentation when making this request. The Contracting Officer will process requests submitted as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay. Failure to get approval prior to the use of foreign-flag vessels may result in monetary penalty.

3.3 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

3.4 CONTRACT ADMINISTRATION

3.4.1 Contracting Officer (KO)

This Contract shall be administered by a Contracting Officer (KO) assigned to the U.S. Army Corps of Engineers, Japan Engineer District, APO AP 96338-5010.

3.4.2 Administrative Contracting Officer (ACO)

In accordance with the USACE Acquisition Instruction (UAI) 5101.603-3-100, Appointment, Administrative Contracting Officer(s) (ACO's) may be delegated a part of the Contracting Officer's authority to modify this Contract and perform Contract administration functions under Federal Acquisition Regulation (FAR) Section 42.302, subject to the authority and limitations set forth in the appointment and delegation letter.

3.4.3 Contracting Officer's Representative (COR)

The Contracting Officer may designate one or more individuals as his/her authorized representatives in administering this Contract.

3.5 DESIGNATED BILLING OFFICE

The designated billing office for this Contract is:

Kanagawa Resident Office U.S. Army Corps of Engineers, Japan Engineer District Unit 45010

APO AP 96343-5010

USAED-J

Bldg. 250 Camp Zama Zama-City, Kanagawa

252-8511 JAPAN

SECTION 01 20 00 Page 4

The designated billing office for this Contract is:

Yokota Resident Office U.S. Army Corps of Engineers, Japan Engineer District Unit 5101

APO AP 96328-5101

USAED-J

Unit 5101, Bldg 445 Yokota Air Base Fussa-City, Tokyo

197-0001 JAPAN

-- End of Section --

SECTION 01 20 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

08/18

PART 1 GENERAL

1.1 SUBMITTALS

1.2 PRE-CONSTRUCTION SCHEDULE REQUIREMENT

1.3 SCHEDULE FORMAT

1.3.1 Network Analysis Schedule (NAS)

1.3.1.1 Activity Requirements

1.3.1.2 Anticipated Weather Lost Work Days

1.3.1.3 Activity Identification

1.3.1.4 Responsibility Code

1.3.1.5 Primavera P6 Settings and Parameters

1.3.1.6 Microsoft Project 2010 Settings and Parameters

1.3.1.7 Cost Loading Microsoft Project 2010 Schedules

1.3.1.7.1 Software Settings

1.3.1.7.2 Tabular Reports

1.3.1.7.2.1 Tracking Gantt Schedule with Cost Table

1.3.1.7.2.2 Earned Value Over Time Report

1.3.1.7.3 Pay Activity Data

1.3.2 Bar Chart Schedule

1.3.2.1 Schedule of Prices

1.3.3 Schedule Submittals and Procedures

1.4 PAYMENTS FOR STORED MATERIALS

1.5 COST LOADING OF CLOSEOUT ACTIVITES

1.6 SCHEDULE MONTHLY UPDATES

1.7 CONTRACT MODIFICATION (applicable when use of NAS is specified)

1.8 3-WEEK LOOK AHEAD SCHEDULE

1.9 CORRESPONDENCE AND TEST REPORTS:

1.10 ADDITIONAL SCHEDULING REQUIREMENTS

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 32 16.00 20 Page 1

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

08/18

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Baseline Construction Schedule; G

Monthly Updates; G

1.2 PRE-CONSTRUCTION SCHEDULE REQUIREMENT

Prior to the start of work, prepare and submit to the Contracting Officer a Baseline Construction Schedule in the form of a Network Analysis Schedule (NAS) or Bar Chart Schedule in accordance with the terms in Contract Clause FAR 52.236-15 Schedules for Construction Contracts, except as modified in this contract.

The approval of a Baseline Construction Schedule is a condition precedent to:

a. The Contractor starting demolition work or construction stage(s) of the contract.

b. Processing Contractor's invoice(s) for construction activities/items of work.

c. Review of any schedule updates.

Submittal of the Baseline Construction Schedule, and subsequent schedule updates, is understood to be the Contractor's certification that the submitted schedule meets the requirements of the Contract Documents, represents the Contractor's plan on how the work will be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).

1.3 SCHEDULE FORMAT

Provide schedule in either NAS or Bar Chart format as specified in the task order.

1.3.1 Network Analysis Schedule (NAS)

Use the critical path method (CPM) to schedule and control project activities. Prepare and maintain project schedules using Primavera P6 or Microsoft Project 2010.

Within 15 calendar days after approval of the Initial Schedule , submit to

SECTION 01 32 16.00 20 Page 2 the Contracting Officer a final NAS schedule.

1.3.1.1 Activity Requirements

a. At a minimum, identify the following in the schedule:

(1) Construction time for major systems and components

(2) Each activity assigned with its appropriate Responsibility Code

(3) Each activity assigned with its appropriate Phase and Area Codes

(4) Major submittals and submittal processing time

(5) Major equipment lead time

b. Build the Schedule as follows:

(1) Show submittals, Government review periods, material/equipment delivery, utility outages, on-site construction, inspection, testing, and closeout activities.

(2) With the exception of the Contract Award and End Contract milestone activities, use of open-ended activities is not allowed;

each activity must have predecessor and successor ties. No activity must have open start or open finish (dangling) logic.

Minimize redundant logic ties. Once an activity exists on the schedule it must not be deleted or renamed to change the scope of the activity and must not be removed from the schedule logic without approval from the Contracting Officer. While an activity cannot be deleted, where said activity is no longer applicable to the schedule but must remain within the logic stream for historical record, it can be changed to a milestone. Document any such change in the milestone's "Notebook," including a date and explanation for the change. The ID number for a deleted activity must not be re-used for another activity.

(3) Assign each activity its appropriate Responsibility Code and Area Code, indicating location and responsibility to accomplish the work indicated by the activity, Phase Code, and Work Location Code. Include anticipated tasks to be assigned Government responsibility.

(4) Date/time constraints or lags, other than those required by the contract, are not allowed unless approved by the Contracting Officer. Include as the last activity in the contract schedule, a milestone activity named "Contract Completion Date".

(5) Include the following Contract Milestones:

(a) Include as the first activity on the schedule a start milestone titled "Contract Award", which must have a Mandatory Start constraint equal to the Contract Award Date;

(b) Include Interim or Phased Completion Milestones required by the Contract or as approved by the Contracting Officer;

(c) Include Facility Turnover Planning Meeting Milestones;

SECTION 01 32 16.00 20 Page 3

(d) Include an unconstrained finish milestone on the schedule titled "Substantial Completion". Substantial Completion is defined as the point in time the Government would consider the project ready for beneficial occupancy wherein by mutual agreement of the Government and Contractor. Government use of the facility is allowed while construction access continues in order to complete remaining items (e.g. punch list and other close out submittals).

(e) Include an unconstrained finish milestone on the schedule titled "Projected Completion". Projected Completion is defined as the point in time the Government would consider the project complete. This milestone must have the Contract Completion Date (CCD) milestone as its only successor.

(f) Include as the last activity on the schedule a finish milestone titled "Contract Completion (CCD)" with constraint type "Must Finish No Later Than". Calculation of schedule updates must be such that if the finish of the "Projected Completion" milestone falls after the contract completion date, then negative float will be calculated on the longest path and if the finish of the "Projected Completion" milestone falls before the contract completion date, the float calculation must reflect positive float on the longest path. This milestone must be set to 5:00 pm.

(6) Provide lead time for major equipment.

1.3.1.2 Anticipated Weather Lost Work Days

Refer to Section 01 11 00.00 10 GENERAL CONTRACT REQUIREMENTS, paragraph

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER.

Assign the Weather Calendar to any activity that could be impacted by adverse weather. The Contracting Officer will issue a modification in accordance with the contract clauses, giving the Contractor a time extension for the difference of days between the anticipated and actual adverse weather delay if the number of actual adverse weather delay days exceeds the number of days anticipated for the month in which the delay occurs and the adverse weather delayed activities are critical to contract completion. A lost workday due to weather conditions is defined as a day in which the Contractor cannot work at least 50 percent of the day on the impacted activity.

1.3.1.3 Activity Identification

a. Identify Government, Construction Quality Management (CQM), Construction activities planned for the project and other activities that could impact project completion if delayed.

b. Identify administrative type activity/milestones including pre-construction submittal and permit requirements prior to demolition or construction stage.

c. Create separate activities for each Phase, Area, Floor Level, and Location the activity is occurring.

d. Do not use construction category activity to represent non-work type reference (Such as, Serial Letter or Request for Information) in NAS.

SECTION 01 32 16.00 20 Page 4

e. Place non-work reference within P6 activity details notebook. Activity categories included in the schedule are specified below.

1.3.1.4 Responsibility Code

Assign each activity its appropriate Responsibility Code indicating responsibility to accomplish the work indicated by the activity, Phase Code and Work Location Code.

1.3.1.5 Primavera P6 Settings and Parameters

Use the following Primavera P6 settings and parameters in preparing the Baseline Schedule. Deviation from these settings and parameters, without prior consent of the Contracting Officer, is cause for rejection of schedule submission.

a. General: Define or establish Calendars and Activity Codes at the "Project" level, not the "Global" level.

b. Admin Drop-Down Menu, Admin Preferences, Time Periods Tab:

(1) Set time periods for P6 for Hours/Day, Hours/Week, Hours/Month and Hours/Year based on Section 01 11 00.00 10 Paragraph "WORKING

HOURS".

(2) Use assigned calendar to specify the number of work hours for each time period: Must be checked.

c. Admin Drop-Down Menu, Admin Preferences, Earned Value Tab: Earned Value Calculation: Use "Budgeted values with current dates".

d. Project Level, Dates Tab: Set "Must Finish By" date to "Contract Completion Date", and set "Must Finish By" time to 05:00pm.

e. Project Level, Defaults Tab:

(1) Duration Type: Set to "Fixed Duration & Units".

(2) Percent Complete Type: Set to "Physical".

(3) Activity Type: Set to "Task Dependent".

(4) Calendar: Set to "Standard 5 Day Workweek". Calendar must reflect Saturday, Sunday and all Federal…