RFQ.pdf

4.3.4.3

KRISTEN MESMER

48066 SHAW RD

BUILDING 2188, UNIT 5

PATUXENT RIVER MD 20670

TEL: 301-757-8315 FAX:

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

N0042123Q0317 31-May-2023 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. % NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and

ZIP Code) 14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA

FAR (48 CFR) 53.215-1(a)

THIS RFQ [ ] IS X [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF. 3. REQUISITION/PURCHASE

REQUEST NO.

NAWCAD PROCUREMENT GROUP

21983 BUNDY ROAD, BLDG 441

PATUXENT RIVER MD 20670

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ] X FOB

DESTINATION

[ ] OTHER

(See Schedule)

02-Jun-2023 (Date) PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS: 10.

ANNIE N BOHMANN

(Name and Telephone no.) (No collect calls) 5b. FOR INFORMATION CALL:

d. CALENDAR DAYS c. 30 CALENDAR DAYS b. 20 CALENDAR DAYS 12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

N0042123Q0317

Section A - Solicitation/Contract Form

SECTION A

U.S Government ~ Tax Exempt

ISSUED BY:

Name: Annie Bohmann Phone Number: 240-572-9625 Email: annie.n.bohmann.civ@us.navy.mil

VENDOR CONTACT:

CAGE:

Company Phone:

Email:

Reference Your Quote:

TECHNICAL POC:

Name:

Email:

ALTERNATE TECHNICAL POC:

Name:

Email:

PAYMENT/INVOICING ISSUES: PLEASE CONTACT COMPTROLLER BELOW.

DEPARTMENT OF THE NAVY

COMPTROLLER GROUP

INTERNAL ENTITLEMENTS TEAM CODE A823 BLDG 2185

NAWCAD

22347 CEDAR POINT ROAD STE 1190

PATUXENT RIVER MD 20670 1161

Email: PAXR_ACCT_INTERNAL_ENTITLEMENTS@NAVY.MIL

WAWF Invoicing Help & Instructions:

Visit the website at https://wawf.eb.mil/ and you can find help via the link "Vendors - Getting Started Help" under the New User section.

EARLY AND PARTIAL SHIPMENTS ARE ACCEPTABLE

VENDOR – IF ELECTRONIC EQUIPMENT, PLEASE MARK BOX/PACKAGE CONTAINING ELECTRONIC

EQUIPMENT WITH THE “DO NOT SCAN” STICKER

RECEIVING DOC HOURS ARE MONDAY THROUGH FRIDAY, 0630-1500 EST.

mailto:PAXR_ACCT_INTERNAL_ENTITLEMENTS@NAVY.MIL https://wawf.eb.mil/

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each

VEO3 PHASED ARRAY INSTRUMENT TFM PACKAGE

FFP

VEO3 PHASED ARRAY INSTRUMENT TFM PACKAGE Delivery Date 7/31/2023 Veo3 Phased Array Instrument, 32:128, TFM Package

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

MFR PART NR: VEO3 PHASE ARRAY INSTRUMENT TFM PACKAGE

PURCHASE REQUEST NUMBER:

ADDITIONAL MARKINGS: TPOC: KRISTEN.MESMER@NAVY.MIL

PSC CD: 6635

NET AMT

0002 1 Each

X3A-001 LONG ARRAY PROBES

FFP

X3A-001 LONG ARRAY PROBES Delivery Date 7/31/2023 X3A-001 - X3A-2.25M48E-0.8x10-SQX2.5 Long Array Probes for Electric Scanning

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0003 1 Each

X3A-003 LONG ARRAY PROBES

FFP

X3A-003 LONG ARRAY PROBES Delivery Date 7/31/2023 X3A-003 - X3A-5M64E-0.6x10-SQX2.5 Long Array Probe for Electric Scanning

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0004 1 Each

X3A-004 LONG ARRAY PROBES

FFP

X3A-004 LONG ARRAY PROBES Delivery Date 7/31/2023 X3A-004X3A-10M64E-0.6X7-SQX2.5 Long Array Probe for Electric Scanning

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0005 1 Each

X2A-005 GEN PURPOSE PA PROBE

FFP

X2A-005 GEN PURPOSE PA PROBE Delivery Date 7/31/2023 X2A-005X2A- 10M32E-0.3x10-SQX2.5 - General Purpose PA Probe

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0006 1 Each

X2B-003 GEN PURPOSE PA PROBE

FFP

X2B-003 GEN PURPOSE PA PROBE Delivery Date 7/31/2023 X2B-003X2B- 5M32E-0.6x10-SQX5 General Purpose PA Probe

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0007 1 Each

X3AG-001 X3 GLIDE WEDGE DELAY

FFP

X3AG-001 X3 GLIDE WEDGE DELAY Delivery Date 7/31/2023 X3AG-001 - X3 Glide Wedge Delay - X3AG-0LW25

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0008 1 Each

X3AG-002 X3 GLIDE WEDGE DELAY

FFP

X3AG-002 X3 GLIDE WEDGE DELAY Delivery Date 7/31/2023 X3AG-002 - X3 Glide Wedge Delay - X3AG-0LW6.35

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0009 1 Each

AXYS CLAMP AND ENCODER

FFP

AXYS CLAMP AND ENCODER Delivery Date 7/31/2023 AXYS Clamp & Encoder 5M (AXYS-002)

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0010 1 Each

0 DEGREE WEDGE 25 MM DELAY

FFP

0 DEGREE WEDGE 25 MM DELAY Delivery Date 7/31/2023 X3AW-001 0-Deg wedge 25mm delay

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0011 1 Each

55 DEGREE WEDGE

FFP

55 DEGREE WEDGE Delivery Date 7/31/2023 X3AW-003 - X3-SB57-N55S Wedge, 55 degree

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0012 1 Each

WEDGE

FFP

WEDGE NWCF SCC Delivery Date 7/31/2023 X2AW-0L25 Wedge (X2AW-001)

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0013 1 Each

WEDGE

FFP

WEDGE Delivery Date 7/31/2023 X2AW-N55S Wedge (X2AW-003)

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0014 1 Each

WEDGE

FFP

WEDGE Delivery Date 7/31/2023 X2BW-0L25 Wedge (X2BW-001)

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0015 1 Each

WEDGE

FFP

WEDGE Delivery Date 7/31/2023 X2BW-N60S Wedge (X2BW-003)

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

0016 1 Each

TFM LW DEMO BLOCK

FFP

TFM LW DEMO BLOCK Delivery Date 7/31/2023

*SEE SECTION C FOR MORE INFORMATION*

FOB: Destination

PURCHASE REQUEST NUMBER:

Section C - Descriptions and Specifications

SEE SECTION C

Statement of Work Phased Array UT System with Total Focusing Method (TFM) Production and delivery of TFM system with the following minimum capabilities:

Shall have phased array (PA), TOFD, and live TFM views Shall have multi-technique functionality, simultaneously showing a PA and several live TFM scans to identify and size flaws Shall be capable of generating up to six live TFM scans, produced from multiple full matrix capture (FMC) sources on different probes Shall be capable of generating TFM images of up to 500K pixels with a maximum resolution of at least 100 pixel per mm without limiting the number of pixel per axis Shall be capable of combining time corrected gain on the TFM image to inspect thicker parts in a single scan Shall record all of the data received during Full Matrix Capture (FMC) scanning on the unit for analysis and comparison with previous inspection data to identify trends and growth rates Shall be capable of generating high-resolution, color C-scans Shall have at least 32 pulser channels and 128 receiver channels (i.e., 32:128 PR) in the base system Shall have a minimum screen refresh rate of 60 Hz Shall be a unit with a maximum weight of 4.6 kg (10 lbs.) without a battery and a maximum of 5.5 kg (12 lbs.) with two hot swappable batteries installed Shall be portable and come with rechargeable hot-swappable batteries Shall be able to operate on rechargeable hot-swappable battery power for up to 6 hours under normal conditions Shall be compatible with existing Evident Scientific phased array probes and encoders Shall have an onboard PDF reader integrated to load and read PDF documents Shall be able to generate PDF auto-report, export data to CSV file, and save screen captures Shall have the ability to save and store data files beyond screen capture for analysis and archival purposes with an internal storage capacity of at least 128GB Shall be able to save data and setup files on an SD card or an external USB 3.0 hard drive Shall include software capable of data viewing and post processing that has an open or portable license, does not require a recurring license fee, and is capable of functioning without an internet connection Shall have supporting analysis software capable of stitching C-Scan images together to form a tiled scan that represents the part geometry and the ability to import drawings and outlines as images to overlay on the tiled scan to provide precise flaw data and dimensions Shall have software updates made available to Licensee for download at no additional cost

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government 0012 Destination Government Destination Government 0013 Destination Government Destination Government 0014 Destination Government Destination Government 0015 Destination Government Destination Government 0016 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 31-JUL-2023 1 4.3.4.3

KRISTEN MESMER

48066 SHAW RD

BUILDING 2188, UNIT 5

PATUXENT RIVER MD 20670

301-757-8315 FOB: Destination

N00421

0002 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0003 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0004 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0005 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0006 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0007 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0008 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0009 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0010 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0011 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0012 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0013 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0014 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0015 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

0016 31-JUL-2023 1 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.247-34 F.O.B. Destination NOV 1991

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (DEC 2018)

(a) Definitions. As used in this clause--

Contract financing payment means an authorized Government disbursement of monies to a contractor prior to acceptance of supplies or services by the Government.

(1) Contract financing payments include--

(i) Advance payments;

(ii) Performance-based payments;

(iii) Commercial advance and interim payments;

(iv) Progress payments based on cost under the clause at Federal Acquisition Regulation (FAR) 52.232-16, Progress Payments;

(v) Progress payments based on a percentage or stage of completion (see FAR 32.102(e)), except those made under the clause at FAR 52.232-5, Payments Under Fixed-Price Construction Contracts, or the clause at FAR 52.232-10, Payments Under Fixed-Price Architect-Engineer Contracts; and

(vi) Interim payments under a cost reimbursement contract, except for a cost reimbursement contract for services when Alternate I of the clause at FAR 52.232-25, Prompt Payment, is used.

(2) Contract financing payments do not include--

(i) Invoice payments;

(ii) Payments for partial deliveries; or

(iii) Lease and rental payments.

Electronic form means any automated system that transmits information electronically from the initiating system to affected systems.

Invoice payment means a Government disbursement of monies to a contractor under a contract or other authorization for supplies or services accepted by the Government.

(1) Invoice payments include--

(i) Payments for partial deliveries that have been accepted by the Government;

(ii) Final cost or fee payments where amounts owed have been settled between the Government and the contractor;

(iii) For purposes of subpart 32.9 only, all payments made under the clause at 52.232-5, Payments Under Fixed- Price Construction Contracts, and the clause at 52.232-10, Payments Under Fixed-Price

Architect-Engineer Contracts; and

(iv) Interim payments under a cost-reimbursement contract for services when Alternate I of the clause at 52.232-25, Prompt Payment, is used.

(2) Invoice payments do not include contract financing payments.

Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract or task or delivery order.

Receiving report means the data prepared in the manner and to the extent required by Appendix F, Material Inspection and Receiving Report, of the Defense Federal Acquisition Regulation Supplement.

(b) Except as provided in paragraph (d) of this clause, the Contractor shall submit payment requests and receiving reports in electronic form using Wide Area WorkFlow (WAWF). The Contractor shall prepare and furnish to the Government a receiving report at the time of each delivery of supplies or services under this contract or task or delivery order.

(c) Submit payment requests and receiving reports to WAWF in one of the following electronic formats:

(1) Electronic Data Interchange.

(2) Secure File Transfer Protocol.

(3) Direct input through the WAWF website.

(d) The Contractor may submit a payment request and receiving report using methods other than WAWF only when-

(1) The Contractor has requested permission in writing to do so, and the Contracting Officer has provided instructions for a temporary alternative method of submission of payment requests and receiving reports in the contract administration data section of this contract or task or delivery order;

(2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System);

(3) DoD makes payment on a contract or task or delivery order for rendered health care services using the TRICARE Encounter Data System; or

(4) The Governmentwide commercial purchase card is used as the method of payment, in which case submission of only the receiving report in WAWF is required.

(e) Information regarding WAWF is available at https://wawf.eb.mil/.

(f) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payment requests.

(End of clause)

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232- 7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

____2IN1________________________________________________________

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

https://www.sam.gov/

____SEE SECTION E________________________________________________________

(Contracting Officer: Insert either “Invoice 2in1” or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC N64142 Issue By DoDAAC N00421 Admin DoDAAC** N00421 Inspect By DoDAAC N00421 Ship To Code N00421 Ship From Code N00421 Mark For Code N/A Service Approver (DoDAAC) N00421 Service Acceptor (DoDAAC) N00421 Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert “See Schedule” or “Not applicable.”)

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

___william.l.milan.civ@us.navy.mil

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

mailto:___william.l.milan.civ@us.navy.mil

Section I - Contract Clauses

52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

NOV 2021

52.212-4 Contract Terms and Conditions--Commercial Products and Commercial Services

DEC 2022

52.213-2 Invoices APR 1984 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 252.204-7000 Disclosure Of Information OCT 2016 252.204-7009 Limitations on the Use or Disclosure of Third-Party

Contractor Reported Cyber Incident Information

JAN 2023

252.204-7016 Covered Defense Telecommunications Equipment or Services -- Representation

DEC 2019

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services -- Representation

MAY 2021

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2023

252.225-7048 Export-Controlled Items JUN 2013 252.239-7010 Cloud Computing Services JAN 2023

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

(a) Definitions. As used in this clause--

Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Registered in the System for Award Management (SAM) means that--

(1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into SAM;

(2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

System for Award Management (SAM) means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes—

(1) Data collected from prospective Federal awardees required for the conduct of business with the Government;

(2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12;

and

(3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) If the solicitation for this contract contained the provision 52.204-7 with its Alternate I, and the Contractor was unable to register prior to award, the Contractor shall be registered in SAM within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first.

(c) The Contractor shall maintain registration in SAM during contract performance and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement. The Contractor is responsible for the currency, accuracy and completeness of the data within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in SAM after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in SAM to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(d)(1)(i) If a Contractor has legally changed its business name or ``doing business as'' name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to--

(A) Change the name in SAM;

(B) Comply with the requirements of subpart 42.12 of the FAR; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (d)(1)(i) of this clause, or fails to perform the agreement at paragraph (d)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the ``Suspension of Payment'' paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims). Assignees shall be separately registered in SAM. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the ``Suspension of Payment'' paragraph of the EFT clause of this contract.

(3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished.

http://www.sam.gov/ http://www.sam.gov/

(e) Contractors may obtain additional information on registration and annual confirmation requirements at https://www.sam.gov.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (MAR 2023)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

___ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L.

109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved] https://www.sam.gov/

___ (6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div.

C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub.

L. 111-117, section 743 of Div. C).

___ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) (31 U.S.C. 6101 note).

___ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) (41 U.S.C. 2313).

____ (10) [Reserved]

____ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) (15 U.S.C. 657a).

____ (12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (13) [Reserved]

____ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-6.

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-7.

____ (16) 52.219-8, Utilization of Small Business Concerns (OCT 2022) (15 U.S.C. 637(d)(2) and (3)).

____ (17)(i) 52.219-9, Small Business Subcontracting Plan (OCT 2022) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (NOV 2016) of 52.219-9.

____ (iii) Alternate II (NOV 2016) of 52.219-9.

____ (iv) Alternate III (JUN 2020) of 52.219-9.

____ (v) Alternate IV (SEP 2021) of 52.219-9.

____ (18) (i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) (15 U.S.C. 644(r)).

____ (ii) Alternate I (MAR 2020) of 52.219-13.

____ (19) 52.219-14, Limitations on Subcontracting (OCT 2022) (15 U.S.C. 657s).

____ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (OCT 2022) (15 U.S.C.

657f).

____ (22) (i) 52.219-28, Post-Award Small Business Program Rerepresentation (MAR 2023) (15 U.S.C. 632(a)(2)).

____ (ii) Alternate I (MAR 2020) of 52.219-28.

____ (23) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (OCT 2022) (15 U.S.C. 637(m)).

____ (24) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) (15 U.S.C. 637(m)).

____ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) (15 U.S.C. 644(r)).

____ (26) 52.219-33, Nonmanufacturer Rule (SEP 2021) (15 U.S.C. 657s).

x (27) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

x (28) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (DEC 2022) (E.O. 13126).

x (29) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

x (30)(i) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

____ (ii) Alternate I (FEB 1999) of 52.222-26.

x (31)(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

____ (ii) Alternate I (JUL 2014) of 52.222-35.

x (32)(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

____ (ii) Alternate I (JUL 2014) of 52.222-36.

x (33) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

____ (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O.

13496).

x (35)(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (36) 52.222-54, Employment Eligibility Verification (MAY 2022). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

____ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (MAY 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693).

____ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

(JUN 2016) (E.O. 13693).

____ (40)(i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (41)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-14.

____ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b).

____ (43)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-16.

x (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O. 13513).

____ (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

____ (46) 52.223-21, Foams (JUN 2016) (E.O. 13693).

____ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

x (48) (i) 52.225-1, Buy American--Supplies (OCT 2022) (41 U.S.C. chapter 83).

____ (ii) Alternate I (OCT 2022) of 52.225-1.

____ (49)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (DEC 2022) (19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I [Reserved].

____ (iii) Alternate II (DEC 2022) of 52.225-3.

____ (iv) Alternate III (JAN 2021) of 52.225-3.

____ (v) Alternate IV (OCT 2022) of 52.225-3.

____ (50) 52.225-5, Trade Agreements (DEC 2022) 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

x (51) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150

____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C.

5150).

____ (55) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

____ (56) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

____ (57) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

x (58) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (OCT 2018) (31 U.S.C.

3332).

____ (59) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (JUL 2013) (31 U.S.C. 3332).

____ (60) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

____ (62) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(13)).

____ (63)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C.

55305 and 10 U.S.C. 2631).

____ (ii) Alternate I (APR 2003) of 52.247-64.

____ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

_____ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67).

_____ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (E.O.

13658).

_____ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

_____ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(v) 52.219-8, Utilization of Small Business Concerns (OCT 2022) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vi) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vii) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

(viii) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xxii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xiii) 52.222-41, Service Contract Labor Standards (AUG 2018), (41 U.S.C. chapter 67).

(xiii) _____ (A) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xvi) 52.222-54, Employment Eligibility Verification (MAY 2022) (E. O. 12989).

(xvii) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (E.O. 13658).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(xix) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (JUN 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxiii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.227-19 COMMERCIAL COMPUTER SOFTWARE LICENSE (DEC 2007)

https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_222_62 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3

(a) Notwithstanding any contrary provisions contained in the Contractor's standard commercial license or lease agreement, the Contractor agrees that the Government will have the rights that are set forth in paragraph (b) of this clause to use, duplicate or disclose any commercial computer software delivered under this contract. The terms and provisions of this contract shall comply with Federal laws and the Federal Acquisition Regulation.

(b)(1) The commercial computer software delivered under this contract may not be used, reproduced, or disclosed by the Government except as provided in paragraph (b)(2) of this clause or as expressly stated otherwise in this contract.

(2) The commercial computer software may be--

(i) Used or copied for use with the computer(s) for which it was acquired, including use at any Government installation to which the computer(s) may be transferred;

(ii) Used or copied for use with a backup computer if any computer for which it was acquired is inoperative;

(iii) Reproduced for safekeeping (archives) or backup purposes;

(iv) Modified, adapted, or combined with other computer software, provided that the modified, adapted, or combined portions of the derivative software incorporating any of the delivered, commercial computer software shall be subject to same restrictions set forth in this contract;

(v) Disclosed to and reproduced for use by support service Contractors or their subcontractors, subject to the same restrictions set forth in this contract; and

(vi) Used or copied for use with a replacement computer.

(3) If the commercial computer software is otherwise available without disclosure restrictions, the Contractor licenses it to the Government without disclosure restrictions.

(c) The Contractor shall affix a notice substantially as follows to any commercial computer software delivered under this contract:

Notice--Notwithstanding any other lease or license agreement that may pertain to, or accompany the delivery of, this computer software, the rights of the Government regarding its use, reproduction and disclosure are as set forth in Government Contract No. _________.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: https://www.acquisition.gov/browse/index/far

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (DEC 2022)

(a) The Contractor shall inform its employees in writing, in the predominant native language of the workforce, of contractor employee whistleblower rights and protections under 10 U.S.C. 4701, as described in subpart 203.9 of the Defense Federal Acquisition Regulation Supplement.

(b) The Contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts.

252.204-7012 SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER INCIDENT

REPORTING (JAN 2023)

https://www.acquisition.gov/browse/index/far

(a) Definitions. As used in this clause--

Adequate security means protective measures that are commensurate with the consequences and probability of loss, misuse, or unauthorized access to, or modification of information.

Compromise means disclosure of information to unauthorized persons, or a violation of the security policy of a system, in which unauthorized intentional or unintentional disclosure, modification, destruction, or loss of an object, or the copying of information to unauthorized media may have occurred.

Contractor attributional/proprietary information means information that identifies the contractor(s), whether directly or indirectly, by the grouping of information that can be traced back to the contractor(s) (e.g., program description, facility locations), personally identifiable information, as well as trade secrets, commercial or financial information, or other commercially sensitive information that is not customarily…