RFP W9128F20R0010 - TRSS 2 Final Draft 10MAR20.pdf

Tenant Renovations in Secures Spaces (TRSS) #2 $95M Indefinite Delivery/Indefinite Quantity (IDIQ) Unrestricted Multiple Aw ard Task Order (MATOC), Outside of the Contiguous United States (OCONUS)

Step 1 Solicitation: Return w ith offer: Information required by Section 00 10 00 (SF1442), and Section 00 21 00. Section 00 45 00 (Representations and Certif ications) are not required to be submitted w ith Step 1 information but w ill be required to be submitted w ith Step II information.

THIS SOLICITATION IS UNRESTRICTED AND IS OPEN TO BOTH LARGE AND SMALL BUSINESS PARTICIPANTS.

ERICKA T COLLINS 402-995-2116

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

10-Mar-2020

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______ calendar days and complete it w ithin ________ calendar days af ter receiving aw ard, notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________24 Mar 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______180 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U.S. ARMY CORPS OF ENGINEERS, OMAHA DIST

CONTRACTING OFFICE

1616 CAPITOL AVENUE

OMAHA NE 68102-4901

W9128F

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9128F20R0010 40

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W9128F20R0010

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 95,000,000 Job Base Period - UNR TRSS #2 - MATOC

FFP

Unrestricted (UNR) Indefinite Delivery, Indefinite Quantity (IDIQ) Tenant Renovations in Secure Spaces (TRSS) #2. The shared contract capacity of the MATOC is $95 million for an ordering period up to seven (7) years: four (4) years base and one three (3) year option period, with a possible six (6) month extension.

Contracting POC: Ericka Collins, 402-995-2116 FOB: Destination

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

1001 UNDEFINED Job OPTION Option Period - UNR TRSS #2 - MATOC

FFP

Unrestricted (UNR) Indefinite Delivery, Indefinite Quantity (IDIQ) Tenant Renovations in Secure Spaces (TRSS) #2. The shared contract capacity of the MATOC is $95 million for an ordering period up to seven (7) years: four (4) years base and one three (3) year option period, with a possible six (6) month extension.

UNIT UNIT PRICE MAX AMOUNT

2001 UNDEFINED Job OPTION 6- Month Option to Extend Services

FFP

6-Month Option to Extend Services - Unrestricted (UNR) Indefinite Delivery, Indefinite Quantity (IDIQ) Tennative Renovation of Secure Spaces (TRSS) #2 Multiple Award Task Order Contract (MATOC). The shared contract capacity of the MATOC is $95 million for an ordering period of seven (7) years: one (1) four

(4) year base and one (1) three (3) year option, with possible 6-month extension.

CONTRACT MINIMUM/MAXIMUM QUANTITY AND CONTRACT VALUE

The minimum quantity and contract value for all orders issued against this contract shall not be less than the minimum quantity and contract value stated in the following table. The maximum quantity and contract value for all orders issued against this contract shall not exceed the maximum quantity and contract value stated in the following table.

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

1.00 $2,500.00 95,000,000.00 $95,000,000.00

DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND ORDER VALUE

The minimum quantity and order value for each Delivery/Task Order issued shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for each Delivery/Task Order issued shall not exceed the maximum quantity and order value stated in the following table.

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

1.00 $2,500.00 1.00 $95,000,000.00

CLIN MINIMUM/MAXIMUM QUANTITY AND CLIN VALUE

The minimum quantity(s) and CLIN value(s) for all orders issued against the CLIN(s) on this contract shall not be less than the minimum quantity(s) and CLIN value(s) stated in the following table. The maximum quantity(s) and CLIN value(s) for all orders issued against the CLIN(s) on this contract shall not exceed the maximum quantity(s) and CLIN value(s) stated in the following table.

CLIN

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

0001 1.00 $2,500.00 95,000,000.00 $95,000,000.00

CLIN DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND CLIN ORDER VALUE

The minimum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not exceed the maximum quantity and order value stated in the following table.

CLIN

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

0001 1.00

$2,500.00

95,000,000.00

$95,000,000.00

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within the time give at the Task Order level calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the time given in the Task Order* The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

Section 00 21 00 - Instructions

00 21 00 STEP 1 INSTRUCTIONS

STEP I – SOLICITATION

INSTRUCTIONS TO OFFERORS

This procurement will be issued in accordance with FAR 4.403 and DFARS PGI 204.403.

Offerors must have a valid U.S. Facility Clearance Level (FCL) at the SECRET level or higher in order to respond to the RFP, because the RFP includes contract plans, specifications and drawings that are classified at a level which will be released only to Offerors possessing the appropriate clearance. All classified material must be handled in accordance with the National Industrial Security Program Operating Manual (NISPOM) (DoD 5220-22-M) and Industrial Security Regulation (DoD 5220.22-R).

The solicitation will be issued on an UNRESTRICTED basis under North American Industry Classification System (NAICS) code 236220. The corresponding SBA size standard is $39.5 million. The estimated cost range for the solicitation is a total contract capacity of $95,000,000.00. The procurement will result in a firm fixed price Multiple Award Contract for a target of five (5) firms.

The solicitation process for this RFP will occur in two steps: In Step I, the Government's objective is to receive and verify potential Offerors’ security clearances. In Step II, the Government will issue the amended solicitation and DD 254 only to those Offerors with a valid

FCL.

Procedures for Step I:

Offerors shall respond to Step I by providing verification of FCL. Offerors shall submit the SF 1442, completing blocks 14, 15, and 20, along with a memorandum on company letterhead, verifying the following:

1) Their firm has the required U.S. Facility Clearance level of SECRET;

2) Personnel who will perform on site at the embassy locations currently have U.S.

Security Clearances of TOP SECRET;

3) CAGE code;

4) The names of authorized individual(s) to speak on behalf of the firm and signature(s) of those individuals.

5) Contact Information for the Offeror’s Facility Security Officer.

6) If the Offeror is a Joint-Venture, they will also be required to submit their Joint-

Venture agreement.

NOTE: DD 254s will be accomplished prior to issuance of STEP II of the solicitation for all Offerors with a valid FCL.

Step I Proposals as described above are due NLT 2:00 PM, 24 March 2020. The preferred method of submission for Step I proposals is via e-mail to ericka.t.collins@usace.army.mil with courtesy copies to glenda.a.canty@usace.army.mil. If necessary and NLT than the 2:00PM, 24 March 2020 deadline, Step I proposals may be mailed to:

Omaha District Corps of Engineers CENWO-CT (AST) (Attn: Ericka Collins and/or Glenda Canty) 1616 Capitol Ave Omaha NE 68102-4901

After the Government confirms that the Offerors meet the required minimum U.S. Security Clearance and are otherwise eligible to receive the classified documents, the Government will issue the Step II solicitation to those firms who provided a timely response to the Step I Security Verification Process outlined under the solicitation. Offerors will have a minimum of 30 calendar days to provide a proposal in response to the Step II solicitation contract terms and conditions. Exact due date and time will be provided in the Step II solicitation.

The project will consist of construction activities for facility renovations and repair requirements located in U.S. diplomatic facilities worldwide, with a heavy emphasis on renovations in secure spaces. Work shall include, but not be limited to, repair, enhancement, maintenance, and incidental demolition of facilities, utilities, real property systems, and other infrastructure requirements. Projects will not be design-build, as each project will be fully designed.

The anticipated contract ordering period is seven (7) years.

Place of Performance: Overseas location to be disclosed to only those Offerors with the proper, verified clearances.

It is anticipated that the procurement will be evaluated in Step II on the following factors:

Previous Experience; Technical Approach to the Sample Project; Past Performance;

Organizational Capabilities; and Price. Proposals will be evaluated to determine which offer provides the best value to the Government utilizing trade-off selection procedures. Once proposals are received in response to Step II, all technical evaluation factors, when combined, are significantly more important than cost or price.

The contracting Point of Contact for this acquisition is Ericka T. Collins @ ericka.t.collins@usace.army.mil.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.216-27 Single or Multiple Awards OCT 1995 52.217-5 Evaluation Of Options JUL 1990 52.232-18 Availability Of Funds APR 1984 52.236-28 Preparation of Proposals--Construction OCT 1997

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Multiple Award Contract, consisting of Firm-fixed price Task Orders, resulting from this solicitation.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

US Army Corps of Engineers, Omaha District ATTN: CENWO-CT Glenda Canty, Contracting Officer 1616 Capitol Avenue Omaha, NE 68102

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits are scheduled per task order.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/content/regulations

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

None at this time.

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

00 45 00

SECTION 00 45 00

REPRESENTATIONS AND CERTIFICATIONS

02/20

1 PART 1 GENERAL

IMPORTANT NOTE:

Online Representations and Certifications Application per FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS is required to be completed.

Failure to complete applicable requirements contained herein and online representations and certifications and/or provisions may result in delay of contract award. Online Representations and Certifications are available at:

https://www.sam.gov/SAM/pages/public/index.jsf

Provide the following certifications and representations as a part of the proposal, check the appropriate boxes, fill in the appropriate information, and provide signatures on the attached pages, and submit with Standard Form 1442 (Section 00 10 00).

Failure to complete applicable requirements contained herein and online representations and certifications and/or provisions may result in delay of contract award.

-- End of Document –

52.209-7 Information Regarding Responsibility Matters OCT 2018 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2019)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

252.209-7998 REPRESENTATION REGARDING CONVICTION OF A FELONY CRIMINAL VIOLATION UNDER

ANY FEDERAL OR STATE LAW (DEVIATION 2012-O0007) (MAR 2012)

(a) In accordance with section 514 of Division H of the Consolidated Appropriations Act, 2012, none of the funds made available by that Act may be used to enter into a contract with any corporation that was convicted of a felony criminal violation under any Federal or State law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(b) The Offeror represents that it is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal or State law within the preceding 24 months.

252.209-7999 REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX

LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (DEVIATION 2012-O0004) (JAN 2012)

(a) In accordance with sections 8124 and 8125 of Division A of the Consolidated Appropriations Act, 2012,(Pub. L.

112-74) none of the funds made available by that Act may be used to enter into a contract with any corporation that—

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that—

(1) It is [ ___ ] is not [ ___ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability,

(2) It is [ ___ ] is not [ ___ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

252.225-7046 EXPORTS BY APPROVED COMMUNITY MEMBERS IN RESPONSE TO THE

SOLICITATION

(JUNE 2013)

(a) Definitions. The definitions of ``Approved Community'', ``defense articles'', ``Defense Trade Cooperation (DTC) Treaty'', ``export'', ``Implementing Arrangement'', ``qualifying defense articles'', ``transfer'', and ``U.S. DoD Treaty-eligible requirements'' in DFARS clause 252.225-7047 apply to this provision.

(b) All contract line items in the contemplated contract, except any identified in this paragraph, are intended to satisfy U.S. DoD Treaty-eligible requirements. Specific defense articles that are not U.S. DoD Treaty-eligible will be identified as such in those contract line items that are otherwise U.S. DoD Treaty-eligible.

CONTRACT LINE ITEMS NOT INTENDED TO SATISFY U.S. DoD TREATY-ELIGIBLE

REQUIREMENTS:

[Enter Contract Line Item Number(s) or enter ``None'' ___ ]

(c) Approved Community members responding to the solicitation may only export or transfer defense articles that specifically respond to the stated requirements of the solicitation.

(d) Subject to the other terms and conditions of the solicitation and the contemplated contract that affect the acceptability of foreign sources or foreign end products, components, parts, or materials, Approved Community members are permitted, but not required, to use the DTC Treaties for exports or transfers of qualifying defense articles in preparing a response to this solicitation.

(e) Any conduct by an offeror responding to this solicitation that falls outside the scope of the DTC Treaties, the Implementing Arrangements, and the implementing regulations of the Department of State in 22 CFR 126.16 (Australia), 22 CFR 126.17 (United Kingdom), and 22 CFR 126 Supplement No. 1 (exempted technologies list) is subject to all applicable International Traffic in Arms Regulations (ITAR) requirements, including any criminal, civil, and administrative penalties or sanctions, as well as all other United States statutory and regulatory requirements outside of ITAR.

(f) If the offeror uses the procedures established pursuant to the DTC Treaties, the offeror agrees that, with regard to the export or transfer of a qualifying defense article associated with responding to the solicitation, the offeror shall—

(1) Comply with the requirements and provisions of the applicable DTC Treaties, the Implementing Arrangements, and corresponding regulations (including the ITAR) of the U.S. Government and the government of Australia or of the United Kingdom, as applicable; and

(2) Prior to the export or transfer of a qualifying defense article—

(i) Mark, identify, transmit, store, and handle any defense articles provided for the purpose of responding to such solicitations, as well as any defense articles provided with or developed pursuant to their responses to such solicitations, in accordance with theDTC Treaties, the Implementing Arrangements, and corresponding regulations of the United States Government and the government of Australia or the government of the United Kingdom, as applicable, including, but not limited to, the marking and classification requirements described in the applicable regulations;

(ii) Comply with the re-transfer or re-export provisions of the DTC Treaties, the Implementing Arrangements, and corresponding regulations of the United States Government and the government of Australia or the government of the United Kingdom, as applicable, including, but not limited to, the re-transfer and re-export requirements described in the applicable regulations; and

(iii) Acknowledge that any conduct that falls outside or in violation of the DTC Treaties, Implementing Arrangements, and implementing regulations of the applicable government including, but not limited to, unauthorized re-transfer or re-export in violation of the procedures established in the applicable Implementing Arrangement and implementing regulations, remains subject to applicable licensing requirements of the government of Australia, the government of the United Kingdom, and the United States Government, as applicable, including any criminal, civil, and administrative penalties or sanctions contained therein.

(g) Representation. The offeror shall check one of the following boxes and sign the representation:

[ ___ ] The offeror represents that export(s) or transfer(s) of qualifying defense articles were made in preparing its response to this solicitation and that such export(s) or transfer(s) complied with the requirements of this provision.

Name/Title of Duly Authorized Representative Date

[ ___ ] The offeror represents that no export(s) or transfer(s) of qualifying defense articles were made in preparing its response to this solicitation.

Name/Title of Duly Authorized Representative Date

(h) Subcontracts. The offeror shall flow down the substance of this provision, including this paragraph (h), but excluding the representation at paragraph (g), to any subcontractor at any tier intending to use the DTC Treaties in responding to this solicitation.

Section 00 72 00 - General Conditions

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2019

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.215-1 Alt I Instructions to Offerors--Competitive Acquisition (Jan 2017) -

Alternate I

OCT 1997

52.215-2 Audit and Records--Negotiation OCT 2010 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-12 Subcontractor Certified Cost or Pricing Data OCT 2010 52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications OCT 2010 52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997 52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.216-4 Economic Price Adjustment-Labor and Material JAN 2017

52.219-9 Small Business Subcontracting Plan AUG 2018 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-29 Notification Of Visa Denial APR 2015 52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-50 Combating Trafficking in Persons JAN 2019 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-19 Contractor Personnel in a Designated Operational Area or Supporting a Diplomatic or Consular Mission Outside the United States

MAR 2008

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014 52.229-3 Federal, State And Local Taxes FEB 2013 52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984 52.243-1 Alt I Changes--Fixed Price (Aug 1987) - Alternate I APR 1984 52.243-4 Changes JUN 2007 52.245-9 Use And Charges APR 2012 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General DEC 2012 252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions OCT 2005 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.211-7007 Reporting of Government-Furnished Property AUG 2012 252.215-7002 Cost Estimating System Requirements DEC 2012 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7023 Drawings and Other Data to become Property of Government MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7005 Reimbursement Of Subcontractor Advance Payments--DOD Pilot Mentor--Protege Program

SEP 2001

252.232-7010 Levies on Contract Payments DEC 2006 252.233-7001 Choice of Law (Overseas) JUN 1997 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.239-7011 Special Construction And Equipment Charges DEC 1991 252.242-7005 Contractor Business Systems FEB 2012 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property DEC 2017 252.245-7003 Contractor Property Management System Administration APR 2012 252.245-7004 Reporting, Reutilization, and Disposal DEC 2017

52.216-19 ORDER LIMITATIONS (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $2,500.00, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor -

(1) Any order for a single item in excess of $95,000,000;

(2) Any order for a combination of items in excess of the maximum contract award amount; or

(3) A series of orders from the same ordering office within 30 days that together call for quantities exceeding the limitation in paragraph (b) (1) or (2) of this section.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs (b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 1 day after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after expiration of the applicable task order.

52.216-32 TASK-ORDER AND DELIVERY-ORDER OMBUDSMAN (SEPT 2019)

(a) In accordance with 41 U.S.C. 4106(g), the Agency has designated the following task-order and delivery-order Ombudsman for this contract. The Ombudsman must review complaints from the Contractor concerning all task-order and delivery-order actions for this contract and ensure the Contractor is afforded a fair opportunity for consideration in the award of orders, consistent with the procedures in the contract.

Reference task order.

(b) Consulting an ombudsman does not alter or postpone the timeline…