RFP Elevator Courthouse.docx

REQUEST FOR PROPOSALS

Elevator Hydraulic Jack and Piston Assembly Replacement Elbert County Historic Courthouse Elberton, Georgia

Issue Date: June 29, 2026 Proposal Due Date: August 6, 2026 Awarded Date: August 10, 2026

1. Introduction Elbert County is soliciting sealed proposals from qualified and licensed elevator contractors to provide all labor, materials, equipment, supervision, permits, and incidentals necessary to replace the hydraulic jack and piston assembly for the hydraulic elevator located in the Historic Courthouse.

The selected contractor shall perform all work in accordance with applicable federal, state, and local codes, including all elevator safety regulations and manufacturer recommendations.

2. Project Overview The purpose of this project is to replace the existing hydraulic elevator jack and piston assembly to restore reliable and safe operation of the courthouse elevator.

The contractor shall furnish all labor, materials, equipment, transportation, supervision, disposal services, testing, and related services necessary to complete the project.

3. Scope of Work The contractor shall provide all labor and materials necessary to complete the following work, including but not limited to:

Removal

· Remove and properly dispose of or recycle the existing hydraulic jack and piston assembly.

· Drain and dispose of hydraulic fluid in accordance with all applicable environmental regulations.

· Remove any associated components necessary for installation of the new equipment.

Installation

· Furnish and install a new hydraulic jack and piston assembly compatible with the existing elevator system.

· Install all required seals, fittings, connections, hardware, and related components.

· Make all necessary hydraulic and mechanical connections.

· Restore disturbed finishes or surrounding construction as necessary.

Communication The contractor shall:

· Maintain timely communication with the County's designated project representative, Maintenance Director, Mr. Danny New at 762-994-7052 or dannynew@elbertga.us

· Notify the County immediately of unforeseen conditions affecting cost or schedule.

· Coordinate work to minimize disruption to courthouse operations.

· Schedule a site visit with our Maintenance Director Testing and Commissioning Following installation, the contractor shall:

· Perform all required operational testing.

· Verify proper hydraulic operation.

· Test all safety functions.

· Return the elevator to normal operating service.

· Coordinate inspections required by the Authority Having Jurisdiction (AHJ), if applicable.

· Provide documentation demonstrating successful testing and completion.

4. Contractor Qualifications Proposers shall:

· Be properly licensed to perform elevator work in the State of Georgia.

· Have a minimum of five (5) years of experience installing or replacing hydraulic elevator jack and piston assemblies.

· Demonstrate experience with similar public-sector or commercial projects.

· Have no unresolved safety violations or significant code violations within the past five years.

· Maintain adequate insurance coverage.

5. Contractor Responsibilities The selected contractor shall:

· Supply all labor, equipment, tools, materials, lifting equipment, and supervision.

· Obtain any required permits.

· Maintain a safe work environment.

· Protect County property during construction.

· Remove debris daily.

· Coordinate work with County staff.

· Comply with all OSHA regulations.

· Comply with all applicable state and local codes.

6. Warranty The contractor shall provide:

· A minimum one-year warranty on workmanship.

· Manufacturer's warranty on all new materials and equipment.

· Warranty service response procedures.

Longer warranty periods may be proposed.

7. Project Schedule The proposal shall include:

· Estimated lead time for materials.

· Estimated project duration.

· Proposed start date.

· Estimated completion date.

The County desires completion as soon as practicable following contract award.

8. Proposal Requirements Each proposal shall include:

Company Information

· Company name

· Business address

· Contact person

· Telephone number

· Email address Pricing Provide a lump-sum price that includes:

· Labor

· Materials

· Equipment

· Freight

· Permits

· Disposal

· Testing

· Mobilization

· Cleanup

· All other project costs Include any optional pricing separately.

10. Insurance Requirements The successful contractor shall provide certificates of insurance prior to beginning work, including:

· Commercial General Liability

· Workers' Compensation

· Automobile Liability

· Umbrella or Excess Liability (if applicable) Coverage limits shall meet County requirements.

11. Terms and Conditions The County reserves the right to:

· Reject any or all proposals.

· Waive informalities or technicalities.

· Request clarification of proposals.

· Negotiate with the selected proposer.

· Cancel the solicitation at any time.

· Award the contract in the best interest of the County.

12. Submission Instructions Submit one copy by mail: Each proposal must be submitted in a sealed envelope, addressed to the Owner. Each sealed envelope containing a proposal must be plainly marked on the outside as, "Proposal for Elevator Repair” Proposal Due Date: August 6, 2026

Time: 4:00 p.m.

Submit To:

Elbert County Board of Commissioners 45 Forest Ave Elberton, Georgia 30635 Attn: Ryan Wright

Proposals received after the deadline will not be considered.

13. Questions Questions regarding this solicitation shall be submitted by email to:

Contact: Ryan Wright

Title: Purchasing Manager

Email: rwright@elbertga.us

Phone: 706-283-2000

Questions must be received no later than July 27, 2026 at 5:00 p.m.

14. Acceptance By submitting a proposal, the proposer certifies that:

· They have examined the RFP.

· They understand the project requirements.

· They are capable of completing the work as specified.

· Their proposal shall remain valid for ninety (90) days following the submission deadline.