RFA 2027-02PRE QUALIFICATIONS CTE ADDITION AND IMPROVEMENTS CONTRACTOR.pdf

GOOCHLAND COUNTY SCHOOL BOARD

APPLICATION FOR PREQUALIFICATION

for

GENERAL CONTRACTORS FOR CTE ADDITION AND SECONDARY

IMPROVEMENTS PROJECT

ISSUE DATE: September 22, 2026

DUE DATE: October 20, 2026

TIME: 2:00 PM

REQUEST#: 2027-02

ISSUING CONTACT: Tandra Harris, VCO AP/Purchasing Supervisor Email: tharris@glnd.k12.va.us Physical/Delivery Address:

2938-I River Rd West Goochland, VA 23063

Mailing Address:

P. O. Box 169 Goochland, VA 23063-0169

TITLE SHEET: #2027-02

APPLICATION FOR PREQUALIFICATION

GENERAL CONTRACTOR FOR CTE ADDITION AND SECONDARY

IMPROVEMENTS PROJECT

(This page is to be used as Bidder’s Cover Page.)

OBLIGATION OF APPLICANT: By submitting an application, the Applicant covenants and agrees that it has satisfied itself, from its own investigation of conditions to be met, that it fully understands its obligation and that it will not make any claim because of any misunderstanding or lack of information.

Applicant further agrees that conditions herein have been carefully read and this proposal is submitted subject to all requirements stated herein

NAME OF FIRM

ADDRESS OF FIRM

DATE

BY

(Signature in Ink)

NAME

(Printed Name)

TITLE

(Printed Title) eVA VENDOR or DUNS NO.

STATE CORPORATION COMMISSION (SCC) NO.

VA CONTRACTOR CLASS CLASS A ☐ CLASS B ☐ CLASS C ☐

VA CONTRACTOR LICENSE NO.

FEI/FIN NO.

PHONE FAX

EMAIL

Indicate the length of time you have been in business as a company providing the type of good(s) and/or service(s) required for this contract.

YEARS MONTHS

General Contractor shall ascertain prior to submitting an application that all Addenda issued have been received and shall acknowledge receipt and inclusion of all addenda here:

Addendum No. _____ Date: ________ Addendum No. _____ Date: ________ Addendum No. _____ Date: ________ Addendum No. _____ Date: ________

The Goochland County School Board does not discriminate against faith-based organizations.

This is Goochland County Public Schools (GCPS) Request for Applications for Prequalification (Request) #2027-02, issued on September 22, 2026. Sealed applications must be received in hand by the Goochland County Public Schools Purchasing Office prior to the date and time stated on the cover page. The time will be written on the application, by hand, by Purchasing Office personnel. Applications received after 2:00 p.m. (Local Prevailing Time) on Tuesday, October 20, 2026, shall not be considered.

SECTION 1 PURPOSE

1.1 Goochland County Public Schools is soliciting applications for General Contractors for the CTE Addition and Secondary Improvements Project, which will be constructed on Bulldog Way in Goochland, Virginia 23063 (the Project).

1.2 Only those General Contractors who have been prequalified in accordance with the procedures herein will be allowed to submit bids for the Project.

1.3 The project will be accomplished through the efforts and cooperation of Goochland County Public Schools, in accordance with plans and specifications prepared by Stantec located at 609 E. Market Street, Suite 202, Charlottesville, VA 22902.

1.4 All materials submitted by General Contractors in response to this Request shall become the property of Goochland County Public Schools and will not be returned.

1.5 At the time of submitting their applications, General Contractors must possess a valid Class A Virginia Contractor's License.

SECTION 2 QUESTIONS

All questions shall be submitted in writing to the GCPS Purchasing Office, Attention:

Tandra Harris, AP/Purchasing Supervisor, via email: tharris@glnd.k12.va.us; with a copy to Ryan Waldrop, Project Manager, via email: rwaldrop@mbpce.com. To be assured of consideration, all questions must be received prior to 2:00 P.M. on Tuesday, October 6, 2026. After reviewing any questions submitted, the GCPS Purchasing Office will issue an Addendum to respond to any question it deems necessary.

Modification or changes to this Request will be made only by written addendum issued by the GCPS Purchasing Office. A copy of the Request and all Addenda will be posted on the Goochland County Public Schools website:

https://www.goochlandschools.org/page/bids-and-proposals; and on eVA:

https://eva.virginia.gov/index.html.

SECTION 3 SCOPE OF WORK

3.1 Project: A new two-story building addition (roughly 40,000 gross square feet) and associated improvements to the existing secondary high/middle school campus.

The project will expand the current Career and Technical Educational program, including but not limited to the following programs: heavy equipment, agricultural education, health sciences, culinary arts, construction, robotics, and MCJROTC.

Additionally, the project will include athletic improvements, including a new auxiliary gymnasium and wrestling support area.

Associated work is anticipated to include the following:

● Selective demolition and modifications to existing building areas as required to accommodate new construction and tie-ins.

● Site development, grading, drainage, stormwater management, utilities, paving, sidewalks, landscaping, and other associated site improvements.

● Structural, architectural, mechanical, electrical, plumbing, fire protection, fire alarm, technology, security, communications, and building automation systems associated with the new construction and potential modifications to existing facilities.

● Specialized infrastructure and equipment required to support the various CTE instructional programs, including shop, laboratory, culinary, technology, and hands-on instructional environments.

● Gymnasium/wrestling support areas and related recreational improvements.

● Coordination and modification of existing utilities and building systems necessary to support the additions and maintain operation of existing facilities.

● Coordination of utility relocations, connections, temporary services, and shutdowns required for construction.

● Associated roadway, access, parking, pedestrian, and site circulation improvements, including improvements in the vicinity of Bulldog Way.

Construction will occur on an active and occupied school campus and will require phasing and coordination to maintain safe and continuous school operations. The General Contractor will be responsible for coordinating construction access, deliveries, temporary facilities, pedestrian and vehicular circulation, utility interruptions, site security, and separation of construction activities from students, staff, and the public. Certain activities may be required during school breaks, summer periods, evening, or weekends to minimize impacts to school operations.

The final scope of construction will be established by the Contract Documents issued for bidding. The description provided herein is intended to communicate the anticipated nature and complexity of the project for purposes of General Contractor prequalification and should not be considered an exhaustive description of all work required under the future construction contract.

3.2 Schedule: The current anticipated construction period is approximately fifteen months with construction estimated to commence in the first quarter of 2027 and finish in May/June 2028. The actual bid documents will establish the schedule.

3.3 Budget: The estimated total project cost of the CTE Addition and Secondary Improvements Project is $30,000,000.00 (thirty million dollars).

3.4 Location: The CTE Addition will be built on Bulldog Way end of the current Secondary Complex in Goochland, Virginia, which is between U.S. Route 6 and Route 522.

SECTION 4 PROJECT SOLICITATION PROCESS AND EVALUATION OF

GENERAL CONTRACTORS

4.1 General Contractors shall submit qualification information in accordance with the requirements identified herein. The Purchasing Agent, or assigned designee, may contact General Contractors during the evaluation process seeking clarification and additional information of any qualifications received in response to this solicitation. Such additional information must be submitted to GCPS no later than the end of the fifth (5) business day after the applicant's receipt of the request for the additional information. Applicants meeting all of the mandatory requirements are prequalified. Prequalified applicants will be notified by November 2, 2026.

4.2 The decision to prequalify a General Contractor shall not, however, constitute a determination that the General Contractor is responsible; and such General Contractor may be subsequently rejected as non-responsible on the basis of subsequently discovered information.

4.3 GCPS may deny pre-qualification to any General Contractor if the Purchasing Agent or assigned designee finds any of the following:

4.3.1 The General Contractor does not have sufficient financial ability to perform the contract that would result from such procurement.

4.3.2 The General Contractor is not able to acquire bid, performance or payment bonds from a corporation included in the United States Treasury list of acceptable surety corporations in the amount of $30,000,000 (Thirty million dollars). If the General Contractor can acquire bid, performance or payment bonds from a corporation included in the United States Treasury list of acceptable surety corporations in the amount and type required by GCPS, this shall be sufficient to establish the financial ability of such General Contractor to perform the contract resulting from such procurement. See attachment G

4.3.3 The General Contractor does not have the appropriate experience to perform this project, as determined by GCPS:

4.3.3.1 Contractor’s License: The General Contractor must hold a Virginia Commonwealth Class A license at the time of submitting its qualifications.

Note: An active copy of the Contractor’s license issued by the Department of Professional and Occupational Regulation Commonwealth of Virginia must be provided.

4.3.3.2 Firm Experience: The contractor shall be a firm with experience and expertise in new school construction or equivalent institutional buildings. The General Contractor must have been established as a full-time construction contractor for a minimum of eight (8) years prior to the date set for receipt of the qualifications. If the General Contractor or its principals operated under another name or entity within the past eight (8) years prior to the date set for receipt of the qualifications, the General Contractor shall provide the same level of information on the other name or entity.

4.3.3.3 Demonstrated Performance on Relevant Projects: The General Contractor must have demonstrated satisfactory performance, as judged by Goochland County Public Schools, on at least three (3) new school construction projects, new construction projects or equivalent institutional buildings such as higher education, healthcare or public safety. Each project must have consisted of a minimum gross building square footage of 40,000 sq. ft. and have a minimum total disturbed site area of ten (10) acres. Renovation work does NOT qualify as new construction work; however, should a project consist of renovations and additions the amount of square footage associated with the additions will qualify as new construction work if the minimum gross building square footage addition is 40,000. Specifically, the projects submitted shall have been substantially completed within ten (10) years prior to the date set for receipt of the qualifications. The owner and design architect/engineer of each project shall be named in Attachment B as references.

4.3.3.4 Budget Control: The General Contractor must demonstrate the capacity and competence in fiscal and construction management as necessary for a project of this size given existing commitments. On Attachment B, the General Contractor shall provide the original contract amount, final contract amount, total value of approved changes orders, and a brief explanation of significant changes in contract value for the three (3) projects listed in 4.3.3.3 above. The General Contractor shall identify, to the extent applicable, changes resulting from Owner-directed scope, design changes, unforeseen conditions, and contractor-attributable issues.

4.3.3.5 Schedule Control: The General Contractor must demonstrate the ability to complete projects on schedule given existing commitments. On Attachment B, the General Contractor shall provide schedule information for the three (3) projects listed in 4.3.3.3 above.

4.3.3.6 Provide information regarding the experience of Key Personnel proposed for this project using Attachment D. That information must include the following: The designated Project Manager AND the Site Superintendent must have worked on a minimum of three (3) similar construction projects, including at least one project of comparable size and complexity. General Contractors will be required to indicate Project Manager and Site Superintendent proposed for management of the project, their roles for this project, their past experience, references and the percentage of time proposed for this project.

4.3.4 The General Contractor or any officer, director, or owner thereof has had judgments entered against him/her within ten (10) years of the date set for receipt of the qualifications for the breach of contracts for governmental or nongovernmental projects, including, but not limited to, design-bid-build, design-build or construction management.

4.3.5 The General Contractor has been in substantial noncompliance, as determined by GCPS, with the terms and conditions of prior construction contracts with GCPS or Goochland County without good cause. If GCPS has not contracted with the General Contractor in any prior construction contracts, the Purchasing Agent may deny prequalification if the General Contractor has been in substantial noncompliance with the terms and conditions of comparable construction contracts with another public body without good cause.

4.3.6 The General Contractor or any owner, officer, director, project manager, superintendent, procurement manager or chief financial official thereof has been convicted within ten (10) years of the date set for receipt of the qualifications of a crime related to governmental or nongovernmental construction or contracting, including, but not limited to a violation of the Virginia Governmental Frauds Act (§18.2-498 et seq.), Chapter 4.2 (§59.1-

68.6 et seq.) of Title 59.1, or any substantially similar law of the United States or another state.

4.3.7 The General Contractor or any officer, director or owner thereof is currently debarred pursuant to an established debarment procedure from bidding or contracting by any public body, agency of another state or agency of the federal government.

4.3.8 The General Contractor failed to provide to GCPS within the established time frame any information requested in this solicitation relevant to items

4.3.1 through 4.3.7 above.

SECTION 5 APPLICATION REQUIREMENTS

Application Forms and Supplemental Information must be typed or printed. Information presented therein shall be clear, complete and concise. The following forms and attachments comprise the Application for Prequalification:

5.1 General Contractor’s Prequalification Statement: The General Contractor shall provide the information required. The form at Attachment A shall be used.

5.2 Similar Projects: The General Contractor shall provide: A list and description of at least three (3) new school construction projects or equivalent institutional buildings each consisting of a minimum gross building square footage of 40,000 and have a minimum total disturbed site area of ten (10) acres. Each project shall be submitted on the form at Attachment B. One form is to be completed for each project. The list of all similar projects shall have been substantially completed within ten (10) years of the date set for receipt of the qualifications. For each project provide the project name, location, owner, architect, dates started/completed, cost information, and other information required on Attachment B.

5.3 Affidavit of Accuracy: Certification that the information contained in the Application for Prequalification is true and accurate. The form in Attachment C shall be used.

5.4 Management Plan: The General Contractor shall describe the general plan for meeting specific management requirements of the total project as described herein. The form in Attachment D shall be used.

5.5 Subcontracting Plan: The General Contractor shall provide a subcontracting plan intended to meet the requirements of this project as described herein. The form in Attachment E shall be used.

5.6 Contractor's License: A statement from the General Contractor confirming they possess a Virginia Class A Contractor's License, at the time of submitting their qualifications, and a commitment to ensure that all affected subcontractors carry a Virginia Contractor's license, Class A, B, or C, as applicable. The form in Attachment F shall be used. General Contractors are to confirm at Attachment A whether there are any pending actions against Contractor’s license.

5.7 Surety Statement: General Contractor's ability to acquire bid, performance, and payment bonds for this project. The form in Attachment G shall be used.

5.8 Credit Worthiness: A copy of a current Dun & Bradstreet Business Information Report (BIR) applicable to the General Contractor shall be provided as Attachment H.

5.9 Trade Secrets or Proprietary Information: General Contractor shall identify the data or other materials which are considered to be a Trade Secret or Proprietary Information and which are to be protected on Attachment I. General Contractors are required to state why protection is necessary.

REQUEST FOR APPLICATIONS FOR PREQUALIFICATION (“REQUEST”)

SUBMITTAL:

Submit Qualifications: BY MAIL, HAND DELIVERY OR EXPRESS CARRIER TO:

Goochland County Public Schools Purchasing Dept., 2938 I River Road West, Goochland Va. 23063.

One original, so marked, with all signatures in blue ink and two (2) copies of the original of the entire submission, and one (1) electronic copy on separate USB Flash Drive, so marked, for a total of three (3) hard copy sets and one (1) electronic copy are required. General Contractors are responsible for ensuring each copy is marked with the name of their firm. All qualifications must be submitted in a sealed package, with the REQUEST number, title, due date and time on the outside of the package. GCPS will not assume responsibility for reproduction where an insufficient number of copies have been supplied. In any such case, GCPS shall notify the General Contractor of the deficiency and request that the appropriate number of copies is delivered by no later than the end of the second (2) business day following receipt of the request for additional information. Failure to comply with this or other requirements of this Request shall be grounds for GCPS to reject such applications. Email or facsimile submissions of applications are not acceptable and any such applications shall not be considered. Nothing herein is intended to exclude any responsible General Contractor or in any way restrain or restrict competition. All responsible General Contractors are encouraged to submit applications.

FORMAT AND CONTENT:

The General Contractors shall submit the qualification information in accordance with the requirements identified herein. Each copy of the applications shall be tabbed and submitted in a securely bound or contained binder with all documentation in a single volume if practical.

Incomplete applications may be determined to be non-responsive; and as such, the Purchasing Agent reserves the right to reject the incomplete applications.

General Contractors must organize their applications using the following format:

Title Sheet (TAB 1) General Contractor’s Prequalification Statement (Attachment A) (TAB 2) Record of Similar Projects (Attachment B) (TAB 3) Affidavit of Accuracy (Attachment C) (TAB 4) Management Plan (Attachment D) (TAB 5) Subcontracting Plan (Attachment E) (TAB 6) Virginia Class A Contractor’s License Statement (Attachment F) (TAB 7) Suggested Surety Statement (Attachment G) (TAB 8) Credit Worthiness (Attachment H) (TAB 9) Trade Secrets or Proprietary Information (by General Contractor) (Attachment I) (TAB 10)

ATTACHMENT – A

GENERAL CONTRACTOR’S PREQUALIFICATION STATEMENT

Project Name:

Submitted By:

General Contractor Name and Address:

General Contractor telephone No.: (__) _____________ Fax No.: (__) _____________

General Contractor's Virginia Contractor's License Number: _________________ Class: _____

Does the General Contractor have any pending actions against its Contractor’s license?

____YES ____NO

If yes, provide details:

Tax ID No. (Soc. Sec. No. If Sole Proprietor) ________________________________________

Person who can respond authoritatively to any questions about this statement:

Name: _____________________________ Title: _____________________ Tel.: ___________

Indicate if: Corporation ____ Sole Proprietor _____ Partnership _____ Joint Venture _____

Other (Indicate) ____________________________________________

The General Contractor may attach additional information deemed appropriate to respond. Do not attach additional information not relevant to the response.

1.0 Organization

1.1 How many years has your organization been in business as a General Contractor? ____

1.2 How many years has your organization been in business under its present business name? __________

ATTACHMENT – A (Continued)

1.3 Provide previous names (s) of your organization within the last eight (8) years, if applicable.

1.4 If your organization is a corporation, please indicate:

Date of incorporation: _________________________

State of incorporation: _________________________

President's name: _________________________

Vice President's name(s): _________________________

Secretary's name: _________________________

Treasurer's name: _________________________

1.5 If your organization is a partnership, please indicate:

Date of organization: _________________________

Type of partnership: _________________________

Name(s) of general partners: _________________________

1.6 If your organization is a sole proprietorship, please indicate:

Date of organization: _________________________

Name of owner: _________________________

1.7 If the form of your organization is other than those listed above, describe it and name the principals:

1.8 Submit a copy of the General Contractor's current organization chart showing numbers of employees by discipline (field total, field supervisory, office total, office supervisory) and project including names and titles of Executives and Managers.

1.9 Is the General Contractor related to another firm as a parent, subsidiary or affiliate?

Yes _____ No _____

If yes, give names and addresses of all affiliated parent and/or subsidiary companies.

Indicate which companies are subsidiaries.

1.10 Provide a history of the General Contractor’s total annual volume of work for the last five (5) years, including the size (both in dollar value and gross square footage) of the single largest project completed.

2.0 Judgments

Has the General Contractor or any officer, director or owner thereof had any judgments entered against him within the past ten (10) years for breach of contracts for governmental or non-governmental construction, including, but not limited to, design-build or construction management? Yes _____ No _____

If yes, provide details on any such judgment.

3.0 Contract Compliance

Has the General Contractor been found to be in substantial noncompliance with the terms and conditions of prior construction contracts with any public body without good cause?

Yes _____ No _____

If yes, provide details on any such instance.

4.0 Convictions

Has the General Contractor, or any officer, director, owner, project manager, procurement manager, or chief financial officer thereof, been convicted within the past ten (10) years of a crime related to governmental or nongovernmental construction or contracting, including, but not limited to, a violation of:

1. Article 6 (§ 2.2-4367 et seq.) of Chapter 43, Title 2.2 of the Virginia Public Procurement Act;

2. The Virginia Governmental Frauds Act (§ 18.2-498.1 et seq.);

3. Chapter 4.2 (§ 59.1-68.6 et seq.) of Title 59.1; or

4. Any substantially similar law of the United States or another state?

Yes _____ No _____ If yes, provide details.

5.0 Debarment

Is the General Contractor or any officer, director or owner thereof currently debarred pursuant to an established debarment procedure from bidding or contracting by any public body, agency of another state or agency of the federal government?

Yes _____ No _____

If yes, provide details.

6.0 Workers Compensation Experience

List your Experience Modification Rate for workers compensation for the past three (3) years:

2023: _____________ 2024: _____________ 2025: _____________

7.0 Contractor Certification Regarding Criminal Convictions

This form must be completed by an authorized official for any organization contracting to provide services to the GCPS or any of its schools or departments at the contract award date.

As the official authorized to enter into this contract on behalf of my organization, I certify that no employee of the organization:

● Has been convicted of any violent felony set forth in the definition of barrier crime in subsection A of Va. Code 19.2-392.02; any offense involving the sexual molestation, physical or sexual abuse or rape of a child; and/or any crime of moral turpitude, except for the following:

Date of Crime

Name of Person Description of Crime Court Jurisdiction

I understand that a materially false statement regarding this certification is a Class 1 misdemeanor and that conviction of such misdemeanor may result in the revocation of the contract with GCPS and of any related license that I may hold. I declare under penalty of perjury that the foregoing statement is true and correct.

Name of General Contractor Signature Address of General Contractor Name and Title (please type or print) Telephone Date

7.1 By signing this qualification, the General Contractor and his sub-contractors agree that:

General Contractor and his subcontractors nor any employee of the General Contractor and his subcontractors who will have contact with students has been convicted of a felony or any offense involving the sexual molestation or physical or sexual abuse or rape of a child; and (b) unless expressly disclosed in an attachment to this qualification on the General Contractor’s or subcontractor’s official letterhead stationery, neither the General Contractor and his subcontractors nor any employee of the General Contractor and his subcontractors who will have contact with students has been convicted of a crime of moral turpitude (Submit Forms provided below).

7.2 The General Contractor and his subcontractors further agree that if any employee who has not previously submitted a certification is assigned to the work under the contract, that the employee signed certification will be kept with the General Contractor and his subcontractors and provided to Goochland County Public Schools, upon demand.

ATTACHMENT B

SIMILAR PROJECTS FORM

Provide the information requested in Section 4.3.3.3 on this form.

(USE SEPARATE FORM FOR EACH OF THE THREE (3) PROJECTS)

DETAILS OF PROJECTS

1. General Contractor Name: _______________________________________________

Project Manager Name: _______________________________________________

Superintendent Name: _______________________________________________

Other On-Site Staff: _______________________________________________

Name of Project: _______________________________________________

Owner Name: _______________________________________________

Address: _______________________________________________

Contact Person: _______________________________________________

Telephone Number (____)_________________________________________

Design Architect/Engineer Name: _________________________________________

Address: _______________________________________________

Contact Person: _______________________________________________

Telephone Number (____)_________________________________________

Contact Dates – Attach additional information if the project was not on schedule.

Started: __________________________

Original Contractual Completion: a) Substantial Completion ____________________

b) Final Completion _________________________

Extended Contractual Completion: a) Substantial Completion ____________________

b) Final Completion _________________________

Actual Completion: a) Substantial Completion ____________________

b) Final Completion _________________________

ATTACHMENT B (Continued)

Original Contract Value $ __________________________________________________

Final Contract Value $ ____________________________________________________

Value of: Change Orders to Date $ __________________________________________

Outstanding Claims to Date $ ______________________________________________

Name of Bonding Company ______________________________________________

Address: _______________________________________________________________

Contact Person: _________________________________________________________

Telephone Number (____)_________________________________________________

Major Subcontractor(s):

Name: ________________________________________________________________

Address: ______________________________________________________________

Contact Person: ________________________________________________________

Telephone Number: (____)________________________________________________

Trade: ________________________________________________________________

Name: ________________________________________________________________

Address: ______________________________________________________________

Contact Person: ________________________________________________________

Telephone Number: (____)________________________________________________

Trade: ________________________________________________________________

ATTACHMENT – C

AFFIDAVIT OF ACCURACY

The undersigned swears or affirms under the penalty of perjury and upon personal knowledge that the contents of the Application for Prequalification are true and correct.

The undersigned swears or affirms under the penalty of perjury that the General Contractor, its agents, servants and/or employees, to the best of his/her knowledge and belief, have not in any way colluded with anyone for and on behalf of the General Contractor an unfair advantage over others, nor have they colluded with anyone for and on behalf of the General Contractor, or themselves, to gain any favoritism in the award of any contract resulting from this prequalification.

NAME OF GENERAL CONTRACTOR SIGNATURE

REPRESENTATIVE/TITLE (PRINT)

ADDRESS

TELEPHONE NUMBER DATE

NOTARY:

The foregoing instrument was acknowledged before me this ______ day of___________, 2022, by ____________________________ on behalf of ___________________________________.

My commission expires: ___________ ____________________________________

Date Notary Public

Commission Number: ______________________________

ATTACHMENT - D

MANAGEMENT PLAN

The Management Plan will identify key personnel proposed to be assigned to the project and their roles, responsibilities, and percentage of time expected to be devoted to this project including the proposed Project Manager and Site Superintendent.

ATTACHMENT - E

SUBCONTRACTING PLAN

1. The General Contractor shall describe the major scopes of work anticipated to be subcontracted, identifying major subcontractors that it may solicit bids from on this project.

2. The General Contractor shall include a statement identifying which items of work are expected to be self- performed, including the approximate percentage of the total cost of work, exclusive of general conditions.

ATTACHMENT - F

VIRGINIA CLASS A CONTRACTOR’S LICENSE STATEMENT

Statement from General Contractor confirming they possess a Virginia Class A Contractor's License at the time of submitting its qualifications, and a commitment to ensure that affected subcontractors have the applicable Virginia Contractor's Licenses. Any Contractor or subcontractor who does not possess a valid Contractor’s License at the time when qualifications are received will not be deemed to be qualified. Please attach hereto a Copy of the Virginia Class A Contractor’s License, which has been issued by the Department of Professional and Occupational Regulation of the Commonwealth of Virginia.

ATTACHMENT - G

SURETY STATEMENT

(to be completed on Surety’s letterhead)

(Name of General Contractor) has been a client of (Name of Surety Company___) for over (_____ ) years. During that time, we have supported this General Contractor in their pursuit of projects in the $ _______________ dollars range and total programs in excess of $ ______________________dollars.

We know of no reason at this time why we would not be able to provide Bid, Performance, and Payment Bonds for an amount of up to and exceeding $30,000,000 (thirty million dollars) on the aforementioned project, provided (Name of General Contractor) accepts an award of the contract and makes application to us on or about the time the work is to commence, and we are satisfied with the prevailing underwriting conditions, including but not limited to, acceptable contract terms and job specifications, acceptable bond forms, and confirmation of full financing.

We also possess certificates of authority as an acceptable surety authorized to do business in the Commonwealth of Virginia as published annually in the Federal Register, Department of Treasurer, Fiscal Service, Department Circular 570.

Sincerely, Attorney-In-Fact (Name of Surety Company)

Name of Surety: ______________________________________________________________

Signature: ___________________________________________________________________

Printed Signature: ____________________________________________________________

Date: _______________________________________________________________________

Address: ____________________________________________________________________

Telephone: __________________________________________________________________

ATTACHMENT – H

CREDIT WORTHINESS:

The bidder shall submit a current Dun & Bradstreet Business Information Report (BIR) as evidence of the bidder’s financial responsibility and creditworthiness. The Owner may consider the information contained in the report, along with other relevant information available to the Owner, in determining whether the bidder is a responsible bidder.

ATTACHMENT – I

TRADE SECRETS OR PROPRIETARY INFORMATION:

Applicants shall specifically identify each page, section, or item claimed to contain trade secrets or proprietary information and shall provide a written explanation of the basis for each designation. Blanket designations of an entire submission or broad categories of information shall not be accepted.