Renovate 5 East_OKC VA_CD Specificatoins Final.pdf

DESIGN RENOVATION OF 5 EAST

OKLAHOMA CITY VA HEALTH CARE

SYSTEM

CONSTRUCTION DOCUMENTS

SPECIFICATIONS

CONTRACT NO.: VA259-16-D-021736C2592N0083

PROJECT NO.: 15-2226.A26

NOVEMBER 10, 2021

U.S. DEPARTMENT OF

VETERANS AFFAIRS

OKLAHOMA VA HEALTH CARE SYSTEM

DEPARTMENT OF VETERANS AFFAIRS

OKLAHOMA CITY, OK

NOVEMBER 10, 2021

ARCHITECT

FourFront Design, Inc.

517 Seventh Street

Rapid City, SD 57701

(605) 342-9470

James Lushbough, NCARB, AIA

MECHANICAL/ELECTRICAL ENGINEER

FourFront Design, Inc.

517 Seventh Street

Rapid City, SD 57701

(605) 342-9470

Ray Dawes, PE

FIRE PROTECTION/ALARM ENGINEER

Summit Fire Consulting

575 Minnehaha Ave. Suite 200

St. Paul, Minnesota 55103

(612) 387-7050

Mark A. Sornsin, PE

11.10.21

01-01-21

OKLAHOMA CITY VA HEALTH CARE SYSTEM

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

CONSTRUCTION DOCUMENTS 00 01 10-1 NOVEMBER 10, 2021

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 01-21

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 03-20

01 33 23 Shop Drawings, Product Data, and Samples 05-17

01 35 26 Safety Requirements 07-20

01 42 19 Reference Standards 11-20

01 45 00 Quality Control 02-21

01 45 29 Testing Laboratory Services 11-18

01 57 19 Temporary Environmental Controls 01-21

01 58 16 Temporary Interior Signage 07-15

01 74 19 Construction Waste Management 01-21

01 81 13 Sustainable Construction Requirements 10-17

01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE

DIVISION 04 – MASONRY

DIVISION 05 – METALS

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 13 00 Sheet Waterproofing 01-21

07 21 13 Thermal Insulation 01-21

07 84 00 Firestopping 01-21

07 92 00 Joint Sealants 10-17

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 01-21

08 14 00 Interior Wood Doors 01-21

OKLAHOMA CITY, OKLAHOMA

CONSTRUCTION DOCUMENTS 00 01 10-2 NOVEMBER 10, 2021

08 41 13 Aluminum-Framed Entrances and Storefronts 01-21

08 32 13 Intensive Care Unit/Critical Care Unit Entrances

08 71 00 Door Hardware 01-21

08 71 13.11 Low Energy Power Assist Door Operators 01-21

08 80 00 Glazing 01-21

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 01-21

09 06 00 Schedule for Finishes 01-21

09 22 16 Non-Structural Metal Framing 06-18

09 29 00 Gypsum Board 04-20

09 30 13 Ceramic/Porcelain Tiling 01-21

09 51 00 Acoustical Ceilings 12-18

09 65 13 Resilient Base and Accessories 01-21

09 65 16 Resilient Sheet Flooring 05-18

09 65 19 Resilient Tile Flooring 05-18

09 91 00 Painting 01-21

DIVISION 10 – SPECIALTIES

10 11 13 Chalkboards and Markerboards 01-21

10 11 33 Glassboards (Magnetic & Non-Magnetic) 01-21

10 14 00 Signage 01-21

10 21 23 Cubicle Curtain Tracks 01-21

10 25 13 Patient Bed Service Walls 01-20

10 26 00 Wall and Door Protection 01-21

10 28 00 Toilet, Bath, and Laundry Accessories 01-21

10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 11 – EQUIPMENT

11 73 00 Ceiling Mounted Patient Lift System 08-20

DIVISION 12 – FURNISHINGS

12 24 00 Window Shades 08-17

12 32 00 Manufactured Wood Casework 09-15

12 36 00 Countertops 12-18

DIVISION 13 - SPECIAL CONSTRUCTION

DIVISION 14– CONVEYING EQUIPEMENT

DIVISION 21- FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16

21 13 13 Wet-Pipe Sprinkler Systems 06-15

OKLAHOMA CITY, OKLAHOMA

CONSTRUCTION DOCUMENTS 00 01 10-3 NOVEMBER 10, 2021

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 09-20

22 05 19 Meters and Gages for Plumbing Piping 09-20

22 05 23 General-Duty Valves for Plumbing Piping 09-20

22 07 11 Plumbing Insulation 09-19

22 08 00 Commissioning of Plumbing Systems 11-16

22 11 00 Facility Water Distribution 11-19

22 13 00 Facility Sanitary and Vent Piping 09-20

22 40 00 Plumbing Fixtures 09-15

22 62 00 Vacuum Systems for Laboratory and Healthcare Facilities 09-15

22 63 00 Gas Systems for Laboratory and Healthcare Facilities 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 02-20

23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment

02-20

23 05 41 Noise and Vibration Control for HVAC Piping and

Equipment

02-20

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-20

23 07 11 HVAC and Boiler Plant Insulation 02-20

23 08 00 Commissioning of HVAC Systems 02-20

23 09 23 Direct-Digital Control System for HVAC 09-11

23 21 13 Hydronic Piping 02-20

23 31 00 HVAC Ducts and Casings 02-20

23 37 00 Air Outlets and Inlets 02-20

23 40 00 HVAC Air Cleaning Devices 03-20

23 82 00 Convection Heating and Cooling Units 03-20

23 82 16 Air Coils 03-20

DIVISION 25 – INTEGRATED AUTOMATION

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17

26 05 26 Grounding and Bonding for Electrical Systems 01-17

26 05 33 Raceway and Boxes for Electrical Systems 01-18

26 09 23 Lighting Controls 01-18

26 27 26 Wiring Devices 01-18

26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19

27 05 26 Grounding and Bonding for Communications Systems 06-15

OKLAHOMA CITY, OKLAHOMA

CONSTRUCTION DOCUMENTS 00 01 10-4 NOVEMBER 10, 2021

27 05 33 Raceways and Boxes for Communications Systems 10-18

27 10 00 Control, Communication and Signal Wiring 06-15

27 11 00 Communications Equipment Room Fittings 06-15

27 15 00 Communications Structured Cabling 01-16

27 31 31 Voice Communications Switching and Routing Equipment -

Extension

06-15

27 41 31 Master Antenna Television Equipment and Systems 06-15

27 52 23 Nurse Call and Code Blue Systems 10-18

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18

28 05 13 Conductors and Cables for Electronic Safety and

Security

10-18

28 05 26 Grounding and Bonding for Electronic Safety and

Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16

28 13 00 Physical Access Control System 10-11

28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK

DIVISION 32 – EXTERIOR IMPROVEMENTS

DIVISION 33 – UTILITIES

DIVISION 34 – TRANSPORTATION

DIVISION 48 – Electrical Power Generation

05-01-20

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 00 01 15 - 1 NOVEMBER 10, 2021

SECTION 00 01 15

LIST OF DRAWINGS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

GI-000 COVER SHEET

GI-001 PROJECT DIRECTORY, DRAWING INDEX AND GENERAL

NOTES

GI-002 LOCATION MAP / CONTRACTOR STAGING AREA AND

ACCESS

GI-003 ABBREVIATIONS, SYMBOLS, LEGENDS AND

ARCHITECTURE GENERAL NOTES

GI-010 NEW AREA PLAN

GI-200 CODE REVIEW PLAN

GI-201 LIFE SAFETY PLAN

GI-300 INFECTION CONTROL PLAN

ARCHITECTURE

AD-100 DEMOLITION PLAN

AD-101 DEMOLITION REFLECTED CEILING PLANS

AS-000 WALL TYPES

AS-001 PARTITION FRAMING DETAILS

AS-010 HEAD OF WALL DETAILS

AS-020 PLAN DETAILS

AS—021 PLAN DETAILS

AS-022 PLAN DETAILS

AS-100 ARCHITECTURAL FLOOR PLAN

AS-101 DIMENSION FLOOR PLAN

AS-102 REFLECTED DEILING PLAN

AS-103 CEILING DETAILS

AS-400 ENLARGED PLANS I

AS-401 ENLARGED PLANS II

AS-402 ENLARGED PLANS III

AS-403 ENLARGED PLANS IV

AS-404 ENLARGED PLANS V

AS-405 ENLARGED PLANS VI

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 00 01 15 - 2 NOVEMBER 10, 2021

AS-406 INTERIOR ELEVATIONS

AS-407 INTERIOR ELEVATIONS

AS-408 INTERIOR ELEVATIONS

AS-500 ROOM FINISH SCHEDULE

AS-501 FLOOR FINISH PLAN

AS-502 WALL PROTECTION PLAN

AS-600 DOOR SCHEDULE, ELEVATIONS, AND DETAILS

AS-601 DOOR DETAILS

EQUIPMENT

QH-100 MEDICAL EQUIPMENT PLAN

INTERIOR FURNISHINGS

IF-100 FURNISHINGS REFERENCE PLAN

MECHANICAL

M-000 SYMBOLS, LEGENDS AND ABBREVIATIONS

M-101 MECHANICAL FIRE BARRIER PLAN

MHD-101 MECHANICAL HVAC DEMO PLAN 5TH FLOOR PLAN

MPD-101 MECHANICAL PIPING DEMO PLAN 5TH FLOOR PLAN

MH-101 MECHANICAL HVAC PLAN 5TH FLOOR PLAN

MP-101 MECHANICAL PIPING PLAN 5TH FLOOR PLAN

M-501 MECHANICAL SCHEDULES AND DETAILS

PLUMBING

P-000 SYMBOLS, LEGENDS AND ABBREVIATIONS

PD-101 LEVEL 4 - PLUMBING DEMOLITION PLAN

PD-102 LEVEL 5 - PLUMBING DEMOLITION

P-103 LEVEL 4 - NEW SANITARY WASTE AND VENT PLAN

P-104 LEVEL 5 - NEW DOMESTIC WATER PLAN

P-105 LEVEL 5 - NEW SANITARY WASTE AND VENT PLAN

PG-106 LEVEL 5 - NEW MED GAS PLAN

P-201 WATER ISOMETRIC VIEW

P-202 SANITARY ISOMETRIC VIEW

PG-203 MED GAS ISOMETRIC VIEW

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 00 01 15 - 3 NOVEMBER 10, 2021

P-501 PLUMBING DETAILS

P-601 PLUMBING SCHEDULES

ELECTRICAL

E-000 ELECTRICAL LEGEND AND ABBREVIATIONS

E-001 ELECTRICAL SCHEDULE

E-002 ELECTRICAL DETAILS

ED-100 POWER DEMOLITION PLAN

ED-200 LIGHTING DEMOLITION PLAN

ED-300 SPECIAL SYSTEM DEMOLITION PLAN

E-100 POWER PLAN

E-200 LIGHTING PLAN

E-300 SPECIAL SYSTEMS PLAN

FIRE PROTECTION

FA-100 FIRE ALARM COVER SHEET

FA-101 FIRE ALARM - LEVEL 5 - DEMO

FA-102 FIRE ALARM - LEVEL 5 - NEW

FP-100 FIRE PROTECTION COVER SHEET

FP-101 FIRE PROTECTION – LEVEL 5 - DEMO

FP-102 FIRE PROTECTION - LEVEL 5 - NEW

- - - E N D - - -

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -1 NOVEMBER 10, 2021

SECTION 01 00 00

GENERAL REQUIREMENTS

GENERAL

1.1 SAFETY REQUIREMENTS

A. Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for new medical/surgical inpatient bed unit as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the Medical Center Engineering Officer.

C. Offices of FourFront Design, Inc., as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection.

Such prior notice shall be not less than three workdays unless otherwise designated by the COR.

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -2 NOVEMBER 10, 2021

of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes general construction, alterations, and certain other items.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at

Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -3 NOVEMBER 10, 2021

3. No photography of VA premises is allowed without written permission of the Contracting Officer. Patients and staff are not to be photographed at any time.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the

Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See

Section 08 71 00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub

Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or

“Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting

Officer upon request.

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -4 NOVEMBER 10, 2021

4. These security documents shall not be removed or transmitted from the project site without the written approval of

Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the

VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an

Engineering Document Management Software (EDMS).

a) Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

b) “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted

24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited (2 to 5) permits shall be issued for General

Contractor and its employees for parking in designated areas only. Contractor to coordinate with VA Medical Center Facility

Manager.

1.6 OPERATIONS AND STORAGE AREAS (FAR 52.236-10)

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -5 NOVEMBER 10, 2021

the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Working space and space available for storing materials shall be as determined by the COR.

C. Workers are subject to rules of Medical Center applicable to their conduct.

D. Execute work in such a manner as to interfere as little as possible with work being done by others. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times.

E. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by

Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to

Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -6 NOVEMBER 10, 2021

F. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

All such actions shall be coordinated with the COR or Utility

Company involved:

1.

G. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the

Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to ensure accomplishment of this work in successive phases mutually agreeable to Medical Center Director, COR and Contractor, as follows:

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -7 NOVEMBER 10, 2021

H. When a building and/or construction site is turned over to

Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C

(40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company

(Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from Contractor's employee or watchman.

I. Utilities Services: Maintain existing utility services for

Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR.

Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the

Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11

REQUIREMENTS FOR COMMUNICATIONS INSTALLATIONS and 28 05 00, OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -8 NOVEMBER 10, 2021

COMMON WORK RESULTS FOR ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical

Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, shall be removed back to their source. Those which are indicated to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

K. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -9 NOVEMBER 10, 2021

L. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF

ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR of areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the Contracting

Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of Building 5.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by

Contractor with new items in accordance with specifications which will be furnished by Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled

"DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4).

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -10 NOVEMBER 10, 2021

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by

Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of Contractor to restore damage caused by Contractor's workers in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are identified by attached tags or noted on drawings or in

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -11 NOVEMBER 10, 2021

specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -12 NOVEMBER 10, 2021

refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems

(including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4) and "DIFFERING SITE CONDITIONS"

(FAR 52.236-2).

1.11 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.12 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -13 NOVEMBER 10, 2021

1. Contractor makes all arrangements with the COR for use of elevators. The COR will ascertain that elevators are in proper condition. Contractor may use elevators for exclusive use and for special nonrecurring time intervals when permission is granted. Personnel for operating elevators will not be provided by the Department of Veterans Affairs.

2. Contractor covers and provides maximum protection of following elevator components:

a) Entrance jambs, heads soffits and threshold plates.

b) Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c) Finish flooring.

3. Government will accept hoisting ropes of elevator and rope of each speed governor if they are worn under normal operation.

However, if these ropes are damaged by action of foreign matter such as sand, lime, grit, stones, etc., during temporary use, they shall be removed and replaced by new hoisting ropes at the contractors expense.

4. If brake lining of elevators are excessively worn or damaged during temporary use, they shall be removed and replaced by new brake lining at the contractors expense.

5. All parts of main controller, starter, relay panel, selector, etc., worn or damaged during temporary use shall be removed and replaced with new parts at the contractors expense, if recommended by elevator inspector after elevator is released by Contractor.

6. Place elevator in condition equal, less normal wear, to that existing at time it was placed in service of Contractor as approved by Contracting Officer.

1.13 TEMPORARY TOILETS

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -14 NOVEMBER 10, 2021

A. Provide where directed, (for use of all Contractor's workers) ample temporary sanitary toilet accommodations with suitable sewer and water connections; or, when approved by COR, provide suitable dry closets where directed. Keep such places clean and free from flies and all connections and appliances connected therewith are to be removed prior to completion of contract, and premises left perfectly clean.

1.14 NEW TELEPHONE EQUIPMENT

A. The contractor shall coordinate with the work of installation of telephone equipment by others. This work shall be completed before the building is turned over to VA.

1.15 TESTS

A. As per specification section 23 05 93 the contractor shall provide a written testing and commissioning plan complete with component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the

Contracting Officer. Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -15 NOVEMBER 10, 2021

D. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

F. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

1.16 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc

(four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -16 NOVEMBER 10, 2021

periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment.

All such training will be at the job site. These requirements are more specifically detailed in the various technical sections.

Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed. This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage.

The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The Department of

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -17 NOVEMBER 10, 2021

Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the

COR, does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.17 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the drawings.

B. Equipment furnished by Government to be installed by Contractor will be furnished to Contractor at the Medical Center Cemetery.

C. Contractor shall be prepared to receive this equipment from

Government and store or place such equipment not less than 90 days before Completion Date of project.

D. Notify Contracting Officer in writing, 60 days in advance, of date on which Contractor will be prepared to receive equipment furnished by Government. Arrangements will then be made by the

Government for delivery of equipment.

1. Immediately upon delivery of equipment, Contractor shall arrange for a joint inspection thereof with a representative of the Government. At such time the Contractor shall acknowledge receipt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its condition or shortages.

2. Contractor thereafter is responsible for such equipment until such time as acceptance of contract work is made by the

Government.

E. Equipment furnished by the Government will be delivered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, fastenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the like) necessary to make the connection

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -18 NOVEMBER 10, 2021

between the Government furnished equipment item and the utility stub-up shall be furnished and installed by the contractor at no additional cost to the Government.

F. Completely assemble and install the Government furnished equipment in place ready for proper operation in accordance with specifications and drawings.

G. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.18 RELOCATED ITEMS

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated by symbol "R" or otherwise shown to be relocated by the

Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Suitably cap existing service lines, such as steam, condensate return, water, drain, gas, air, vacuum and/or electrical, at the main whenever such lines are disconnected from equipment to be relocated. Remove abandoned lines in finished areas and cap as specified herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

E. Contractor shall employ services of an installation engineer, who is an authorized representative of the manufacturer of this equipment to supervise assembly and installation of existing equipment, required to be relocated.

F. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -19 NOVEMBER 10, 2021

equipment ready for operation or use immediately after reinstallation.

1.19 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

A. Contractor shall complete approximately 10 (square feet) of space in building accessible from ground level without use of elevators for storage of certain materials and equipment by Department of

Veterans Affairs.

1. Provide such space with adequate light, ventilation and heat in season and lock for adequate security. Contractor shall also install and connect portion of nearest specified fire protection system including all apparatus for instant use to provide water for adequate fire protection of storage space.

2. Storage space shall be turned over to Contracting Officer ninety days prior to Completion Date of the buildings involved.

3. Forward two sets of drawings to Contracting Officer through the COR 120 days prior to Completion Date of building;

drawings shall indicate those areas which will be made available to Department of Veterans Affairs for temporary storage.

4. All cost for utility services for such storage space shall be borne by Contractor until entire building is turned over for occupancy.

B. "Completion Date" shall mean that date as established by

Contracting Officer upon which Contractor will turn over entire project or portions thereof to the Government.

1.20 CONSTRUCTION SIGN

A. Provide a Construction Sign where directed by the COR. All wood members shall be of framing lumber. Cover sign frame with 0.7 mm

(24 gage) galvanized sheet steel nailed securely around edges and

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 00 00 -20 NOVEMBER 10, 2021

on all bearings. Provide three 100 by 100 mm (4 inch by 4 inch) posts (or equivalent round posts) set 1200 mm (four feet) into ground. Set bottom of sign level at 900 mm (three feet) above ground and secure to posts with through bolts. Make posts full height of sign. Brace posts with 50 x 100 mm (two by four inch) material as directed.

B. Paint all surfaces of sign and posts two coats of white gloss paint. Border and letters shall be of black gloss paint, except project title which shall be blue gloss paint.

C. Maintain sign and remove it when directed by the COR.

D. Detail Drawing of construction sign showing required legend and other characteristics of sign shall be provided by the COR.

03-01-20

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 32 16.15 - 1 NOVEMBER 10, 2021

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COTR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the option of developing the project schedule within their organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification proposal to the COTR, within 10 days of bid acceptance. The qualification proposal shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph.

3. A representative sample of prior construction projects, which the proposed consultant has performed complete project scheduling

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 32 16.15 - 2 NOVEMBER 10, 2021

services. These representative samples shall be of similar size and scope.

B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision within seven calendar days from receipt of the qualification proposal.

In case of disapproval, the Contractor shall resubmit another consultant within 10 calendar days for renewed consideration. The

Contractor shall have their scheduling consultant approved prior to submitting any schedule for approval.

1.4 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Department of Veterans

Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly project updates. This monthly computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined reports of the scheduling software approved by the Contracting Officer; a hard copy listing of all project schedule changes, and associated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report. The COTR shall identify the five different report formats that the contractor shall provide.

B. The contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced reports to the

Contractor’s representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requested by the Contracting Officer’s representative, to correct errors which affect the payment and schedule for the project.

1.5 THE COMPLETE PROJECT SCHEDULE SUBMITTAL

A. Within 45 calendar days after receipt of Notice to Proceed, the

Contractor shall submit for the Contracting Officer's review; three

OKLAHOMA CITY, OKLAHOMA

PROJECT NUMBER:VA259-16-D-0217;36C25921N008

DESIGN RENOVATION OF 5 EAST

CONSTRUCTION DOCUMENTS 01 32 16.15 - 3 NOVEMBER 10, 2021

blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved

CPM schedule program. The submittal shall also include three copies of a computer-produced activity/event ID schedule showing project duration; phase completion dates; and other data, including event cost.

Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting

Officer identifying these date constraints and secure the Contracting

Officer’s written approval…