PW24_A003 INSTALLATION OF ROADWAY RE_STRIPING.pdf

INVITATION TO BID

Solicitation PW24-A003

INSTALLATION OF ROADWAY

RE-STRIPING AND PAVEMENT MARKINGS

FOR CARROLL COUNTY

The Carroll County Board of Commissioners is currently soliciting bids for the purpose of installation of Roadway Re-Striping and Pavement Markings on approximately 207.72 miles of various roadways throughout Carroll County.

All bids submitted become the property of the County and will not be returned. The County is not responsible for any costs incurred by the bidder in the preparation of bids or presentations given. All expenses incurred by the bidder’s pursuit of this award shall be borne by the bidder.

All bids should be based on but not limited to the following specifications:

A. Installation of roadway re-striping and pavement markings on approximately 207.72 miles of various roadways throughout Carroll County.

B. Regular and Uniform Bid: Each contractor must comply with all requirements as directed or required by this notice. Notice is hereby given to all contractors that if their bids are defective or irregular;

the same may be rejected immediately. To facilitate comparative analysis and evaluation of bids, it is desired that a uniform format be employed in structuring each bid. All instructions are to be considered an integral part of this Invitation to Bid.

C. Firm Price: Prices quoted by contractor shall be firm prices, and not subject to increase during the schedule hereinafter set-forth and shall not include Federal or State Tax.

D. Security: Accompany bid with a bid security in the amount of five percent (5%) of the bid. The successful bidder will be required to submit to Carroll County a performance bond and a payment bond in the amount equal to one hundred percent (100%) of the total contract amount in the form attached hereto. Surety companies executing Bonds must appear on the Treasury Department’s most current list (Circular 570 as amended) and be authorized to transact business in the State of Georgia.

E. All bidders must be DOT approved contractors.

SCOPE AND PROCEDURE

The Scope and Procedure for this Project shall be the installation of the safety elements consisting of the placement of roadway re-striping of centerlines and edge lines and pavement markings on approximately 207.72 miles of County road. The pricing is to include up to 260 stop crossbars as designed by the County. The

Contractor shall be responsible for providing all material and labor necessary for the completion of the Project as proposed.

The Contractor shall supply weekly quality control reports to verify thickness of Thermoplastic and road completions.

The Contractor shall be responsible for assuring that all re-striping and markings are installed per the current

GDOT Signing & Marking and/or Manual on Uniform Traffic Control Devices (MUTCD) guidelines.

The Contractor shall be responsible for assuring that all material and labor used for this project in in compliance with current GDOT Construction Standards, Details, Specifications and Special Provisions.

Per Section 653 – Thermoplastic Traffic Stripe, of the GDOT Standard Specifications Construction of

Transportation Systems, all thermoplastic striping shall be reflectorized pavement marking compound.

The Contractor shall be responsible for assuring that all Traffic Control complies with Section 150 of the current

GDOT Standard Specifications Construction of Transportation Systems, The Manual on Uniform Traffic

Control Devices (current edition) and/or GDOT Special Provisions and Standards & Details as they apply.

The Contractor shall work with and coordinate with the County Public Works Department for this Project. A

Pre-Construction Conference shall be held for this project before any work is started by the Contractor. The Pre-

Construction Conference shall include a County representative and a Contractor representative. Contractor must provide a schedule and timeline for project completion.

The County shall be responsible for scraping the pavement edges if necessary before the Contractor stripes the white edge lines.

The Contractor will be responsible for signage and traffic control during the project.

The Contractor must attend a mandatory Prebid Meeting held at Carroll County Public Works, 34 Horsley Mill Rd., Carrollton, GA 30117 at 10am on Thursday, June27th, 2024.

Sealed bids must be received no later than Monday, July 15, 2024 at 2:00PM. Any bid received after 2:00 PM on that date will not be accepted or considered.

The Carroll County Board of Commissioners reserves the right, in its sole discretion, to waive irregularities in any bid, to reject any and all, or parts of any and all, bids with or without cause, and/or to re-advertise this Invitation to Bid or postpone or cancel this Invitation to Bid. The County also reserves the right to request additional information or clarification from the bidder.

Instructions to Bid

A. How to Prepare Bid Proposals: All bid proposals shall be:

1. Bidders should prepare a detailed quote for Installation Re-Striping and Pavement Markings they are willing to provide the County.

2. Typewritten or completed with pen and ink, signed by the vendor or their authorized representative, with all erasures or corrections initialed and dated by the official signing the proposal. Bidders are encouraged to review carefully all provisions and attachments of this document prior to completion. Each bid constitutes an offer and may not be withdrawn except as provided herein. Also, prices are to remain firm for the period stated herein.

B. How to Submit Bid Proposals: All bid proposals shall be:

1. Submitted in a sealed envelope, plainly marked with Sealed Proposal -

INSTALLATION OF ROADWAY RE-STRIPING AND PAVEMENT MARKINGS,

SOLICITATION PW24-A003

2. Mailed, Express Delivery or delivered as follows in sufficient time to ensure receipt by the

Purchasing Manager on/before 2:00 P.M. Monday, July 15, 2024.

(a) Mailing Address: Carroll County Public Works

Attn: Sunday Cook

34 Horsley Mill Rd.

Carrollton, GA 30117

(b) Hand or Express Delivery Address:

Carroll County Public Works

34 Horsley Mill Rd.

(c) Late proposals will be not received, accepted or considered after 2:00 P.M. ET July 13, 2024

(the “Bid Deadline”). Proposals submitted after the designated date and time will be deemed invalid and returned unopened to the proponent. Carroll County is not responsible for lost or misdirected mail. It is the bidder’s responsibility to ensure no late bid is submitted. No proposal may be withdrawn within thirty days after the proposal opening and shall remain firm through the period.

C. How to Submit an Objection: Objections from bidders to the invitation to bid and/or these specifications should be brought to the attention of the Purchasing Manager in the following manner.

1. Written objections may be submitted at least 3 days prior to the opening of the bid.

2. Failure to object in accordance with the above procedure shall constitute a waiver on the part of the vendor to protest the solicitation.

D. Submittal of Questions and Requests for Clarification:

It is the responsibility of each proposer to examine the entire instructions, to seek clarification in writing, and review their submittal for accuracy before submitting the document. Once the submission deadline has passed, all submissions will be final. Carroll County reserves the right to ask for additional information from all bidders. Questions about any aspect of the instructions, or the project, shall be submitted in writing via e-mail to:

Sunday Cook

Public Works Purchasing Analyst

Carroll County Public Works Office

34 Horsley Mill Road

Carrollton, Georgia 30117 scook@carrollcountyga.gov

The deadline for submission of questions relating to the instructions is at least 72 hours prior to the

Bid Deadline. All relevant and significant questions that have been submitted in writing prior to the deadline will be compiled, and answers will be delivered to all proposers.

E. Standards for Acceptance of Bid for Awarded Contract: Carroll County reserves the right to waive any informality, to reject any and all bids, to evaluate all bids, to accept portions of any bid and to accept any bid which in its opinion may be in the best interest of the County.

The County reserves the right to modify the contract after its award.

F. Compliance with laws: The bidder shall obtain and maintain all licenses, permits, liability insurance, workman’s compensation insurance and comply with any and all other standards or regulations required by federal, state or County statute, ordinances and rules during the performance of any contract between the bidder and the County. Any such requirement specifically set forth in any contract document between the bidder and the County shall be supplementary to this section and not in substitution thereof.

II. General Terms and Conditions

A. Specifications: Any obvious error or omission in specifications shall not inure to the benefit of the bidder but shall put the bidder on notice to inquire of or identify the same from the

County. Whenever mention is made of any article, material, or workmanship to be in accordance with laws, ordinances, building codes, underwriter’s codes, A.S.T.M. regulations or similar expressions, the requirements of these laws, ordinances, etc., shall be construed to be the minimum requirements of these specifications.

B. Delivery Point: All items shall be quoted and delivered to the assigned destination

Delivery cost and charges (if any) will be included in bid price.

C. Delivery Time: Estimated completion dates will be scheduled. Work shall begin within thirty (30)

Day of notification of acceptance, and be completed no later than 180 days from the notice to proceed date. Delivery time may be considered by the County when selecting most responsible bidder.

D. Bids for All or Part: Unless otherwise specified by the County or by the bidder, CARROLL COUNTY RESERVES THE RIGHT TO MAKE AWARD ON ALL

ITEMS, OR ON ANY OF THE ITEMS ACCORDING TO THE BEST

INTEREST OF THE COUNTY. Bidder may restrict his bid consideration in the aggregate by so stating, but must name a unit price on each item bid upon.

E. Prices to be Firm: Bidder warrants that bid prices, terms and conditions quoted in their bid will be firm for acceptance for a period of sixty (60) days from opening date.

F. Completeness: All information required by Invitation to Bid must be completed and submitted to constitute a proper bid.

G. Guarantee/Warranty: The bidder shall state the warranty period in their proposal.

H. “OR EQUAL” Interpretation: It is the vendor’s responsibility to prove to the County that each bid item is equal to the grade or quality of material specified.

I. Award of Contract/Purchase Order: The contract/Purchase Order, if awarded, will be awarded to the most responsive and responsible bidder whose bid will be most advantageous to the County, price, estimated delivery, warranty and other factors considered. The County will make the determination.

J. Qualified Vendor: A “Qualified Vendor” is defined for this purpose as one who meets, or by the date of bid acceptance can meet, all requirements for licensing, insurance and service contained within these specifications.

K. Compliance with Specifications – Terms and Conditions: The Invitation to Bid, Legal Advertisement, General Conditions and Instructions to Bidder, Specifications, Special

Conditions, Vendor’s Bid, Addendum, and/or any other pertinent documents form a part of this proposal and by reference are made a part hereof.

L. Signed Bid Considered Offer: The signed bid shall be considered an offer on the part of the bidder, which offer shall be deemed accepted upon approval by the Carroll County Board of

Commissioners. In case of a default on the part of the bidder after such acceptance, Carroll County

Board of Commissioners may take such actions as it deems appropriate including legal action for damages or specific performance.

M. Invoices – Invoices should be mailed to the following address:

Carroll County Board of Commissioners

P.O. Box 338

Carrollton, GA 30112

Attn: Accounts Receivable

N. Payment Terms- Net 30 Days.

O. Point of Contact – Sunday Cook, Purchasing Agent (770) 830-5985

P. Certification of Independent Price Determination: By submission of this bid, the bidder certifies that in connection with this Invitation to Bid:

1. The prices in the bid have been arrived at independently, without consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any bidder or with any competitor;

2. Unless otherwise required by law, the prices which have been quoted in this bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed by the bidder prior to opening, directly or indirectly to any other bidder or to any competitor.

3. No attempt has been made or will be made by the bidder to induce any other person or firm to submit or not to submit a bid for the purpose of restricting competition; and

4. No agent or employee of Carroll County Government has been provided any compensation, goods, or promise in connection with this bid solicitation.

Q. Bidders shall furnish a list of references to include the following information:

1. Company Name

2. Principle Owner(s)

3. Business Address

4. List of completed contracts with governmental organizations during the last five (5) years with client’s address, telephone and contact person

5. List of contracts with governmental organizations in progress with client’s address, telephone number and contact person.

6. Statement listing any and all differences between your bid and the work specified in the

Invitation to Bid.

7. Sample contract agreement for the proposed work, which shall be subject to the review

R. And revision of the county. Bids must be typed. All corrections made by the bidder prior to submitting must be initialed and dated by the bidder. No changes or corrections will be allowed after bids are submitted.

S. All respondents should furnish the County with two (2) complete copies of the bid. Each copy must contain a manual signature of an authorized representative of the proposing firm.

T. Time is of the essence. The successful bidder will have thirty (30) days from the Date of Award to enter a contract with the County.

At the time the contract with the successful bidder is entered, the successful bidder must provide the Board of

Commissioners with Certificates of Insurance demonstrating General Liability Coverage in the amount of at least $1,000,000 per occurrence and $2,000,000 in aggregate; automobile insurance in the amount of

$1,000,000 per occurrence and $ 1,000,000 in aggregate; commercial umbrella/excess liability coverage of

$1,000,000; and workers ‘compensation coverage as required by law. Carroll County and Carroll County Board of Commissioners must be listed as additional insured on the policies for the duration of the project. The company shall assume all liability and risks for all damages and injuries to persons or property which shall or may arise or accrue out of the conduct of any activity relating to the performance of the Agreement by the company, its officials, employees, agents or servants and shall indemnify and hold harmless Carroll County and the Carroll County Board of Commissioners from any and all liability, actions causes of actions, suits, damages, attorney’s fee, and costs which may arise or accrue due to the conduct of any activity relating to the performance of the Agreement by the company, its officers, employees, agents or servants.

U. The successful bidder must provide proof of compliance with E-Verify and affidavits as required by

Georgia’s Immigration laws.

V. The bidder must certify that there are no circumstances which will cause a conflict of interest in performing the services required.

W. Work shall begin within thirty (30) days of notification of acceptance, and be completed no later than 180 days from the notice to proceed date.

X. Submission on bid indicates acceptance by the bidder of the terms, conditions and requirements described in the Invitation to Bid unless clearly and specifically noted in the submittal.

All bids should be returned to:

34 Horsley Mill Road

Re: PW24-A003

Any questions regarding the scope of work should be directed in writing to:

Danny Yates

Email: dyates@carrollcountyga.gov

SEE ATTACHMENTS

Attachment A - Payment Bond

Attachment B - Performance Bond

Attachment C - Contractor Affidavit and Agreement (E-Verify)

Attachment D - Subcontractor Affidavit and Agreement (E-Verify)

Attachment E- Non-Collusion Agreement

Attachment F – Carroll County Road Striping List

Attachment A

CONSTRUCTION PAYMENT BOND

KNOW ALL MEN BY THESE PRESENTS that contractor] (hereinafter called the "Principal") and

[Insert name of

[Insert name of

Surety (hereinafter called the "Surety"), are held and firmly bound unto Carroll County, Georgia, Acting by and through its Board of Commissioners (hereinafter called the "Owner"), its successors and assigns as oblige, in the penal sum of [Insert contract amount], lawful money of the United States of America, for the payment of which the Principal and the Surety bind themselves, their administrators, executors, successors, and assigns, jointly and severally, firmly by these presents.

WHEREAS, the Principal has entered, or is about to enter, into a certain written contract with the

Owner, dated [Insert date of contract], which is incorporated herein by reference in its entirety (hereinafter called the "Construction Contract"), for the construction of a project known as [Insert name of project], as more particularly described in the Construction Contract (hereinafter called the "Project");

NOW, THEREFORE, the condition of this obligation is such that if the Principal shall promptly make payment to all persons working on or supplying labor or materials under the Construction Contract, and any amendments thereto, with regard to labor or materials furnished and used in the Project, and with regard to labor or materials furnished but not so used, then this obligation shall be void; but otherwise it shall remain in full force and effect.

1. A "Claimant" shall be defined herein as any subcontractor, person, party, partnership, corporation or other entity furnishing labor, services, or materials used, or reasonably required for use, in the performance of the Construction Contract, without regard to whether such labor, services, or materials were sold, leased, or rented, and without regard to whether such Claimant is or is not in privity of contract with the Principal or any subcontractor performing work on the Project, including, but not limited to, the following labor, services, or materials: water, gas, power, light, heat, oil, gasoline, telephone service, or rental of equipment directly applicable to the Construction Contract.

2. I n the event a Claimant files a claim against the Owner, or the property of the

Owner and the Principal fails or refuses to satisfy or discharge it promptly, the Surety shall satisfy or discharge the claim promptly upon written notice from the Owner, either by bond or as otherwise provided in n the Construction Contract.

3. The Surety hereby waives notice of any and all modifications, omissions, additions, changes, alterations, extensions of time, changes in n payment terms, and any other amendments in or about the Construction Contract and agrees that the obligations u ndertaken by this bond shall not be impaired in any manner by reason of any such modifications, omissions, additions, changes, alterations, extensions of time, changes in payment terms, and amendments.

4. The Surety hereby agrees that this Bond shall be deemed amended automatically and immediately, without formal or separate amendments hereto, u p o n any amendment or modification to the Construction Contract, so as to bind the

Principal and Surety, jointly and severally, to the full payment of any Claimant u under the Construction Contract, as amended or modified, provided only that the

Surety shall not be liable for more than the penal sum of the Bond, as specified in n the first paragraph hereof.

5. This Bond is made for the use and benefit of all persons, firms, and corporations who or which may furnish any materials or perform any labor for or on account of the construction to be performed or supplied u under the Construction Contract, and any amendments thereto, and they and each of them may sue hereon.

6. No action may be maintained on this Bond after one (1) year from the date the last services, labor, or materials were provided under the Construction Contract by the Claimant prosecuting said action.

7. This Bond in intended to comply with O.C.G.A. § 36-91-90, and shall be interpreted so as to comply with the minimum requirements thereof. However, in the event the express language of this Bond extends protection to the Owner beyond that contemplated by O.C.G.A. § 36-91-90, or any other statutory law applicable to this

Project, then the additional protection shall be enforced in favor of the Owner, whether or not such protection is found in the applicable statutes.

IN WITNESS WHEREOF, the Principal and Surety have hereunto affixed their corporate seals and caused this obligation to be signed by their duly authorized representatives this of , 2024.

day

PRINCIPAL:

By:

Name:

Title:

(SEAL)

Attest:

(CORPORATE SEAL)

SURETY:

Attachment B

CONSTRUCTION PERFORMANCE BOND

KNOW ALL MEN BY THESE PRESENTS [Insert name of contractor] hereinafter called the "Principal") and [Insert name of surety] (hereinafter called the "Surety"), are held and firmly bound unto Carroll County, Georgia, acting by and through its Board of Commissioners (hereinafter called the "Owner") and their successors and assigns, in the penal sum of Dollars ($ ), lawful money of the United States of America, for the payment of which the Principal and the Surety bind themselves, their administrators, executors, successors and assigns, jointly and severally, firmly by these presents.

WHEREAS, the Principal has entered, or is about to enter, into a certain n written contract with the Owner, dated which is incorporated herein n by reference in its entirety (hereinafter called the "Construction Contract"), for the [description of the project], more particularly described in n the Construction Contract (hereinafter called the "Project"); and

NOW, THEREFORE, the conditions of this obligation are as follows, that if the Principal shall fully and completely perform all the undertakings, covenants, terms, conditions, warranties and guarantees contained in the Construction Contract, including all modifications, amendments, changes, deletions, additions and alterations thereto that may hereafter be made, then this obligation shall be void; otherwise, it shall remain in full force and effect.

Whenever the Principal shall be, and declared by the Owner to be, in n default u under the

Construction Contract, the Surety shall promptly remedy the default as follows:

1) Complete the Construction Contract in accordance with the terms and conditions;

or

2) Obtain a bid or bids for completing the Construction Contract in accordance with its terms and conditions, and upon determination by the Surety and the

Owner of the lowest responsible bidder, arrange for a contract between such bidder and Owner and make available as the work progresses (even though there should be a default or succession of defaults u under the Construction

Contract or contracts of com platoon arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not exceeding, include ng other costs and damages for which the

Surety may be liable hereunder, the penal sum set forth in the first paragraph hereof, as may be adjusted, and the Surety shall make available and pay to the

Owner the funds required by this Paragraph prior to the payment of the

Owner of the balance of the contract price, or any portion thereof. The term

"balance of the contract price," as used in this paragraph, shall mean the total amount payable by the Owner to the Contractor u under the Construction

Contract, and any amendments thereto, less the amount paid by the Owner to the Contractor; or, at the option of the Owner;

3) Allow Owner to compute the work and reimburse the Owner for all reasonable costs incurred in completing the work.

In addition to performing as required in the above paragraphs, the Surety shall indemnify and hold harmless the Owner from any and all losses, liability and damages, claims, judgments, liens, costs, and fees of every description, including reasonable attorney's fees, litigation costs and expert witness fees, which the Owner may incur, sustain or suffer by reason of the failure or default on the part of the Principal in the performance of any or all of the terms, provisions, and requirements of the Construction Contract, including any and all amendments and modifications thereto, or incur red by the Owner in n making good any such failure to performance on the part of the Principal.

The Surety shall commence performance of its obligations and undertakings under this Bond promptly and without delay, after written notice from the Owner to the Surety.

The Surety hereby waives notice of any and all modifications, omissions, additions, changes, alterations, extensions of time, changes in payment terms, and any other amendments in or about the

Construction Contract, and agrees that the obligations undertaken by this bond shall not be impaired in any manner by reason of any such modifications, omissions, additions, changes, alterations, extensions of time, change in payment terms, and amendments.

The Surety hereby agrees that this bond shall be deemed amended automatically and immediately, without formal or separate amendments hereto, upon any amendment to the Construction Contract, so as to bind the Principal and the Surety to the full and faithful performance of the Construction Contract as so amended or modified, and so as to increase the penal sum to the adjusted Contract Price of the

Construction Contract.

No right of action shall accrue on this bond to or for the use of any person, entity, or corporation other than the Owner and any other oblige named herein, or their executors, administrators, successors or assigns.

This Bond is intended to comply with O.C.G.A. § 36-91-70, and shall be interpreted so as to comply with the minimum requirements thereof. However, in the event the express language of this bond extends protection to the Owner beyond that contemplated by O.C.G.A. § 36-91-70, or any other statutory law applicable to this Project, then the additional protection shall be enforced in favor of the Owner, whether or not such protection is found in the applicable statutes.

IN WITNESS WHEREOF the undersigned have caused this instrument to be executed and their respective corporate seals to be affixed and attested by their duly authorized representatives this day of , 2024.

PRINCIPAL: SURETY:

Title:

(SEAL) By:

Name:

Title:

(SEAL) Attest:

Name:

[Attach Power of Attorney]

Attachment C E-verify Contractor Affidavit under O.C.G.A. § 13-10-91(b)(l)

The undersigned contractor ("Contractor") executes this Affidavit to comply with O.C.G.A § 13-10-91 related to any contract to which Contractor is a party that is subject to O.C.G.A. § 13-10-91 and hereby verifies its compliance with O.C.G.A. § 13-10-91, attesting as follows:

a) The Contractor has registered with, is authorized to use and uses the federal work authorization program commonly known as E-Verify, or any subsequent replacement program;

b) The Contractor will continue to use the federal work authorization program throughout the contract period, including any renewal or extension thereof;

c) The Contractor will notify the public employer in the event the Contractor ceases to utilize the federal work authorization program during the contract period, including renewals or extensions thereof;

d) The Contractor understands that ceasing to utilize the federal work authorization program constitutes a material breach of Contract;

e) The Contractor will contract for the performance of services in satisfaction of such contract only with subcontractors who present an affidavit to the Contractor with the information required by O.C.G.A. § 13-10-91(a), (b), and (c);

f) The Contractor acknowledges and agrees that this Affidavit shall be incorporated into any contract(s) subject to the provisions of O.C.G.A. § 13-10- 91 for the project listed below to which Contractor is a party after the date hereof without further action or consent by

Contractor; and

g) Contractor acknowledges its responsibility to submit copies of any affidavits, drivers' licenses, and identification cards required pursuant to O.C.G.A. § 13-10-91 to the public employer within five business days of receipt.

Federal Work Authorization User Identification Number Date of Authorization

Name of Contractor Name of Project

______CARROLL COUNTY, GEORGIA___________

Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on _________, _____, 20_____ in _______________ (city), __________ (state).

Signature of Authorized Officer or Agent

Printed Name and Title of Authorized Officer or Agent

SUBSCRIBED AND SWORN BEFORE ME

ON THIS THE _______ DAY OF _____________, 20______.

NOTARY PUBLIC

My Commission Expires: _______________________

Attachment D E-verify Subcontractor Affidavit under O.C.G.A. § 13-10-91(b)(l)

The undersigned contractor ("Contractor") executes this Affidavit to comply with O.C.G.A § 13-10-91 related to any contract to which Contractor is a party that is subject to O.C.G.A. § 13-10-91 and hereby verifies its compliance with O.C.G.A. § 13-10-91, attesting as follows:

g) The Contractor has registered with, is authorized to use and uses the federal work authorization program commonly known as E-Verify, or any subsequent replacement program;

h) The Contractor will continue to use the federal work authorization program throughout the contract period, including any renewal or extension thereof;

i) The Contractor will notify the public employer in the event the Contractor ceases to utilize the federal work authorization program during the contract period, including renewals or extensions thereof;

j) The Contractor understands that ceasing to utilize the federal work authorization program constitutes a material breach of Contract;

k) The Contractor will contract for the performance of services in satisfaction of such contract only with subcontractors who present an affidavit to the Contractor with the information required by O.C.G.A. § 13-10-91(a), (b), and (c);

l) The Contractor acknowledges and agrees that this Affidavit shall be incorporated into any contract(s) subject to the provisions of O.C.G.A. § 13-10- 91 for the project listed below to which Contractor is a party after the date hereof without further action or consent by

Contractor; and

g) Contractor acknowledges its responsibility to submit copies of any affidavits, drivers' licenses, and identification cards required pursuant to O.C.G.A. § 13-10-91 to the public employer within five business days of receipt.

Federal Work Authorization User Identification Number Date of Authorization

Name of Contractor Name of Project

______CARROLL COUNTY, GEORGIA___________

Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on _________, _____, 20_____ in _______________ (city), __________ (state).

Signature of Authorized Officer or Agent

Printed Name and Title of Authorized Officer or Agent

SUBSCRIBED AND SWORN BEFORE ME

ON THIS THE _______ DAY OF _____________, 20______.

NOTARY PUBLIC

My Commission Expires: _______________________

Attachment E

Attachment F

2024 STRIPING LIST

CARROLL COUNTY

Road Name Beginning Ending Length

Reavesville Road SR 5 SR 100 3.65

State Line Road SR 5 Ala. State Line 2.59

Rainey Road Temple City Limits Morgan Road 1.78

Rainey Road Morgan Road SR 101 3.35

Centerpoint Road SR 113

Old Centerpoint Road 4.92

Temple Centerpoint Road

Old Centerpoint Road

Temple City Limits 2.42

Levans Road Old Centerpoint Road

Haralson County Line 1.74

Lovell Road Oak Grove Road SR 113 1.47

Tumlin Lake Road SR 101

Taylor's Gin Road 1.53

Bowdon Junction Road

Mt. Zion City Limits SR 1 0.83

Bar J Road SR 78 Spruill Bridge Road 3.16

Spruill Bridge Road SR 113 Buckhorn Drive 0.94

Stateline Road SR 166 Alabama State Line 0.58

Wayside Road SR 166 Horsley Mill Road 2.41

East Wayside Road Wayside Road End of Pavement 0.87

Harris Road Pleasant Hill Road

West Wayside Road 0.76

Maple Hill Road Pleasant Hill Road SR 166 1.04

Central High Road

Central High Spur

Blandenburg Road 0.97

Whooping Creek Church Road SR 16 Lowell Road 4.71

Hays Mill Road Oak Grove Church Road Oak Grove Road 1.84

Oak Grove Church Road Oak Grove Road

Bonner Goldmine Road 2.83

Nugget Road Bonner Goldmine Road

Oak Grove Church Road 1.18

Mashburn Road Bonner Goldmine Road SR 1 0.8

Stoney Point Road

Roopville Veal Road

Heard County Line 1.16

Rance Foster Road

New Mexico Road SR 5 1.44

Black Mountain Road

New Mexico Road SR 100 1.36

Sardis Bethel Road SR 100

Alabama State Line 1.4

Mitchell Road SR 100 Alabama State Line 0.81

Dot Road SR 100 Stateline Road 2.19

Rogers Road SR 100 Watts Road 0.63

New Hope Road SR 100 Sandy Flat Road 1.09

Brickyard Road Stateline Road End of Pavement 1.55

Ayers Road Brickyard Road SR 166 0.93

Tom Fletcher Road Old Antioch Road

Antioch Church Road 0.52

Antioch Church Road Old Antioch Road End of Pavement 1.2

Needmore Road SR 5 Roopville Veal Road 2.01

Thomas Wilson Road

Bonner Goldmine Road SR 5 2.09

Blackwelder Road Hilltop Road

Shirey Dairy Road 0.77

Black Dirt Road SR 5 The Bridge 2.34

Old Boy Scout Road SR 5 Dead End 0.58

Cavender Creek Road SR 5

Liberty Church Road 1.9

Coleman Mill Road

Clem Lowell Road

Whooping Creek Road 1.61

Howard Road Whooping Creek Road End of Pavement 0.51

Ringer Road SR 1 SR 5 2.62

Hester Road SR 1 Ringer Road 0.74

Old Villa Rica Road SR 78

Taylor's Gin Road 2.09

Kansas Road SR 100 Haralson County Line 1.29

Johnson Road Lovvorn Mill Road Teague Road 1.13

Kansas Jake Road SR 100

Jake Buncombe Road 3.13

New Hope Church Road SR 16

Bethel Church Road 2.31

South Little New York Trail Happy Hill Road End of Pavement 2.19

Salem Church Road

Farmers High Road

Tyus Carrollton Road 2.67

Buttercup Lane Salem Church Road

Farmers High Road 1.13

Mountain Creek Road SR 5

Old Columbus Road 1

Maddox Road Bethesda Church Road

Tyus Carrollton Road 1.63

Walker Road Bethesda Church Road

Thomas Wilson Road 1.3

Jackson Road Bonner Goldmine Road

Thomas Wilson Road 0.84

McClendon Circle Oak Grove Road Oak Grove Road 2.09

Shadinger Road Gray Road SR 1 0.42

Willie Walker Road

Tyus Carrollton Road

Old Camp Church Road 0.95

Brock Road Tyus Carrollton Road

Farmers High Road 2.5

Horton Road Tyus Carrollton Road

Bethesda Church Road 0.77

Piney Grove Road

Tyus Carrollton Road End of Pavement 0.6

McGuire Road Tyus Carrollton Road Bonner Road 0.28

Legion Lake Road SR 101 Tapley Road 1.8

Sandhill Shady Grove Road SR 61

Shady Grove Road 2.74

Whitworth Road SR 61 Daniel Road 0.87

Little Vine Church Road

North Hulett Road Dead End 2.45

Fairfield Road Sandhill Hulett Road Dead End 0.51

North Helton Road

Little Vine Church Road

Douglas County Line 0.4

Burwell Road SR 166 North Jonesville Road 4.74

Indian Creek Road

Alabama State Line

Lovvorn Mill Road 3.1

Davenport Mill Road Garrett Circle Lovvorn Road 1.26

Lambert Lane Burwell Road Lovvorn Road 0.85

Kuglar Road SR 166 Burwell Road 1.33

Melear Road Smith’s Chapel Road SR 16 5.08

Jake Buncombe Road SR 16 End of Pavement 0.45

Wynn Drive Lovvorn Road Bethel Church Road 0.31

Bethel Church Road Lovvorn Road

Burwell Mt. Zion Road 1.85

West Mandeville Road SR 1 Hog Liver Road 0.98

Hog Liver Road SR 1 Regional Airport Road 1.69

Bear Creek Road Hog Liver Road End of Pavement 2.25

Little River Road Smyrna Church Road Bear Creek Road 0.96

Staples Dairy Road

Liberty Church Road

End of County Road 1.39

Larry Keaton Road SR 166

Sandhill Hulett Road 0.83

Mooyn Road Larry Keaton Road

Sandhill Hulett Road 1.41

Mandeville Road SR 1 Pleasant Ridge Road 4.21

Miller Academy Road SR 1

Bremen City Limits 4.49

Goolsby Road Pleasant Ridge Church Road End of Pavement 0.5

Happy Hollow Road Ithica Gin Road

N. E. Hickory Level Road 0.7

Old Draketown Road Rainey Road

Paulding County Line 0.5

Mt. Carmel Church Road Rainey Road

Paulding County Line 1.95

Asbury Road Temple City Limits Morgan Road 2.03

Morgan Road Rainey Road Haralson County Line 1.81

McGukin Road Levans Road Mandeville Road 1.44

Ithica Gin Road Sandhill Hickory Level Road SR 61 2.7

Old Word Road Tyus Carrollton Road End of Pavement 0.77

Old Roanoke Road

Heard County Line

New Mexico Road 2.66

Bethlehem Church Road SR 1

West Mandeville Road 0.72

Victory Church Road

Bowdon Tyus Road Rowland Road 2.49

Holland Road Jones Mill Road Clara Bell Way 0.4

West Carroll Road Holland Road End of Pavement 0.62

Ballard Bridge Road SR 166

Carrollton City Limits 0.57

Holmes Road SR 16 Lovvorn Road 0.9

Ingram Road Lovvorn Road New Hope Church Road 1.01

Hamp Jones Road Walnut Hill Road

Lovvorn Farm Road 1.18

Holly Springs Road SR 1 Dead End 1.25

Holly Springs Drive SR 1

Holly Springs Road 0.2

Walnut Hill Road SR 1 Dead End 0.77

Union Road Five Points Road Campground Road 0.43

Prater Road Haralson County Line Lively Road 1.09

Lively Road Five Points Road Prater Road 0.92

Five Points Road SR 16 Haralson County Line 3.24

New Brooklyn Church Road

Old Villa Rica Road

Taylor's Gin Road 1.11

Pleasant Grove Church Road

N. E. Hickory Level Road SR 8 3.69

Primary School Road

Stripling Chapel Road

Whooping Creek Road 0.32

Primary School Road SR 1

Stripling Chapel Road 0.26

Bagwell Road SR 1 End of Pavement 0.97

Brooks Road SR 61 Hominy Creek Road 0.4

Sales Barn Road SR 166 SR 166 0.53

South Lake Road Laurel Road

Old Camp Church Road 0.34

Hutcheson Ferry Road SR 5 End of Pavement 1.35

Lambert Road Hutcheson Ferry Road Wilson Road 1.15

Wilson Road Lambert Road Old Five Notch Road 1.08

Crews Road Old Newnan Road Dead End 1.96

Caney Creek Road Davis Road Shoemake Road 1.32

Shoemake Road Happy Hill Road Caney Creek Road 1.28

Adamson Road Highpoint Road End of Pavement 1.06

Downs Road Highpoint Road Dead End 0.86

Heath Road Old Driver Road SR 16 0.43

Old Bowdon Road SR 166 SR 166 0.75

Fletcher Road SR 166 Alabama State Line 0.85

Garrett Circle SR 166 Burwell Mt. Zion Road 0.41

Garrett Circle SR 166 Garrett Circle 0.5

Bill Hearn Road Burwell Mt. Zion Road Davenport Road 0.35

Happy Hill Road SR 16 Happy Hill Road 1.05

Happy Hill Road Happy Hill Road Happy Hill Road 0.76

Happy Hill Road Happy Hill Road Ephesus Church Road 1.48

Davis Road Happy Hill Road Davis Road 1.28

Davis Road Davis Road Clem Lowell Road 1.24

Total Miles: 207.72

DETAILED ESTIMATE

ITEM NO. DESCRIPTION UNIT QUANTITY

653-2501 5 in. Solid White Thermoplastic LM 415.44

653-2502 5 in. Solid Yellow Thermoplastic LM 415.44

654-1001 Raised Pavement Marker Type 1 EA 13,662

653-1704 24 in. Soid White Thermoplastic LF 3,108