Pressure Washing Services for Fayette County Public Schools Request for Proposals No. 26-017-075

Georgia Procurement Registry Event No. PE-65615-NONST-2026-000000092

NOTICE TO VENDORS

Brief Description of NEED: Pressure washing services for school buildings, stadiums, sidewalks, and curbs.

Service Location(s): Multiple locations throughout the Fayette County School District

Complete solicitation documents may be obtained at www.fcboe.org. FCPS is not responsible for respondents and/or subcontractors not obtaining the information provided through the full set of contract documents.

Responses must be submitted via email, mail/parcel delivery, or hand delivery to the Fayette County Public Schools office located at Facilities Services and directed to Jamie Marrero, Purchasing Associate. Envelopes should be sealed and marked conspicuously on the front with the solicitation name and number above.

SUBMISSION - BY HAND, MAIL OR COMMON COURIER

Fayette County Public Schools

ATTN: Jamie Marrero, Purchasing Department

Facilities Services

939 Goza Road, Fayetteville, GA 30215

SUBMISSION - BY EMAIL to: marrero.jamie@fcboe.org

-1-http://www.fcboe.org mailto:marrero.jamie@fcboe.org

Pressure Washing Services for Fayette County Public Schools (RFP 26-017-075)

Objective

Fayette County Public Schools (hereinafter FCPS or the District) is soliciting proposals via this Request for Proposals (hereinafter RFP) from interested and qualified respondents to provide pressure washing services, as specified within this solicitation, for the Fayette County School District.

As is more fully explained in this RFP, an award, if made, will be made to the responsible and responsive respondent who provides the best solution to the described need, taking into consideration multiple evaluation factors as determined by the FCPS and defined herein.

It is the respondent’s responsibility to address all elements of this RFP. Any respondent failing to meet the terms and conditions herein may suffer a reduction in their evaluation score up to a complete rejection of their proposal.

Responses Due

Responses to this request for proposals are due no later than the date and time specified in the timeline of events either physically or electronically to the FCPS Purchasing Department located at Facilities Services, 939 Goza Road, Fayetteville, GA, 30215. Proposals received after the specified date and time will not be considered.

Section A: Instructions to Respondents

1. Designated Representative

1.1. The FCPS Purchasing Department has designated the following staff member as the representative of the Department and District during the solicitation process: Jamie Marrero

2. Communication Restriction

2.1. From the date of issuance of this RFP until an award is made all communications must be through the designated representative listed above.

2.1.1. Failure to comply with this restriction or attempts to communicate with other Fayette County Public Schools staff may result in rejection of your proposal.

3. Respondent Registration

3.1. Respondents are encouraged to register with the designated representative listed above via email after reviewing this solicitation.

3.2. Respondents who register will automatically receive an email update with additional documents such as addenda and be notified of award issuance, even if they choose not to submit a proposal.

-2-

4. Schedule of Events 4.1.

RFP Released Friday, January 23, 2026

Respondent Questions Due Tuesday, February 10, 2026

Addenda Issued (if applicable) Thursday, February 12, 2026

Proposals Due Before 9:00AM (EST), Friday, February 20, 2026

5. Georgia Open Records Act Compliance (O.C.G.A. § 50-18-70)

5.1. This solicitation and any resulting responses, evaluations, contracts, agreement, or purchase orders are subject to the Georgia Open Records Act and may be released publicly.

5.2. Pursuant to the act, for any records or documents marked as “confidential” or “trade secrets” the respondent must submit and attach to the records an affidavit affirmatively declaring that specific information in the records constitutes trade secrets according to O.C.G.A. § 10-1-761.

5.2.1. Failure to attach such an affidavit will result in the record being considered public and subject to release under the Georgia Open Records Act.

5.2.2. If FCPS determines that the specifically identified information does not constitute a trade secret, it shall notify the entity submitting the affidavit of its intent to disclose the information within ten days unless prohibited from doing so by an appropriate court order.

5.2.3. In the event the entity wishes to prevent disclosure of the requested records, the entity may file an action in superior court to obtain an order that the requested records are trade secrets exempt from disclosure. The entity filing such action shall serve the requestor with a copy of its court filing.

5.2.4. If the agency determines that the specifically identified information does constitute a trade secret, the agency shall withhold the records, and the requester may file an action in superior court to obtain an order that the requested records are not trade secrets and are subject to disclosure.

6. Solicitation Documents and Forms

6.1. Documents and forms required for submission as part of this RFP can be found on the FCPS Purchasing Department website.

6.2. Failure to include required submissions listed herein may result in a rejection of the proposal.

-3-https://advance.lexis.com/api/document/collection/statutes-legislation/id/61XD-TBX1-JN6B-S0Y8-00008-00?cite=O.C.G.A.%20%C2%A7%2050-18-70&context=1000516 http://www.open.georgia.gov/ https://advance.lexis.com/api/document/collection/statutes-legislation/id/61XD-TBV1-F06F-244V-00008-00?cite=O.C.G.A.%20%C2%A7%2010-1-761&context=1000516 https://www.fcboe.org/Page/2707

6.3. A list of required forms is contained herein and additional submissions may be required per the specifications contained herein.

7. Proposal Delivery

7.1. Proposals should be sent to the FCPS Purchasing Department and must be received before the proposal due date and time specified in the solicitation.

7.2. Proposals may be submitted electronically, by mail, or hand-delivered to Facilities Services, 939 Goza Road, Fayetteville, Georgia 30215, Attention:

Purchasing Department.

7.3. No faxed or telephone proposals will be accepted or considered.

7.4. Proposals may be emailed to the designated representative if meeting the following guidelines:

7.4.1. Emailed proposals must be in a consistent, clear, and readable format and complete. (Adobe PDF format is preferred unless specified otherwise)

7.4.2. All proposal documents should be bound in one document. Multiple separate documents may result in evaluation score reductions.

8. Attachments

8.1. Any specification listed with “Must Include Attachment” should include a document within the proposal conforming to standards set forth.

8.2. All attachments must be clearly marked and labeled using the following format: Attachment #, Solicitation Reference, Respondent Name, Solicitation Title, and Number.

9. Proposal Format Requirements

9.1. The proposal should be typed and legible as well as formatted to comply with accessibility standards (refer to ADA and Section 508 compliance).

9.2. The solicitation document has been carefully organized. All sections, specifications/requirements, and appendices are numbered; therefore proposals should be organized in the same manner referencing the solicitation document when necessary.

9.3. Proposals must be submitted with the following sections clearly identified and delineated:

9.3.1. Solicitation Response Form

9.3.2. Business Capability and Respondent Qualification Form

9.3.3. Reference Letters

9.3.4. E-Verfiy Documentation, W-9 Form, and Certificate of Insurance

-4-

9.3.5. Cost Proposal

10. Multiple Proposals from the Same Respondent

10.1. Respondents may submit more than one proposal when offering multiple alternatives.

10.2. Proposals must be separate and each should conform to all terms and conditions within the solicitation.

10.3. Proposals must be labeled separately so as to easily identify different proposals from the same respondent.

Section B: Scope of Work and Specifications

1. Background and Project Overview

1.1. The purpose and intent of this request for bid (RFP) is to secure firm prices to provide pressure washing services for Fayette County School District Facilities. Pressure washing services will apply to all locations within the Fayette County School District, during the term listed within this solicitation.

The areas to be serviced will include; concrete buildings, concrete sidewalks/curbs, concrete stadium seating, aluminum stadium seating, and other concrete/metal structures as assigned. Specified areas will be listed below in the specifications and outlined in the pricing sheet.

2. Technical/Service Requirements and Specifications

2.1. Respondent will provide all pressure washing equipment, chemicals, and labor for each project.

2.1.1. Any chemicals used must be approved by Facilities Coordinator, Beria

Orr, prior to start of project

2.2. Respondent will need to make sure that all equipment is in proper working condition.

2.2.1. Pressure washing machines are free of oil leaks and/or don't leave behind any oil residue that can stain concrete.

2.2.2. Water tanks are free of any leaks, to ensure large amounts of additional water is not needed to complete these projects.

2.3. Respondent will provide lift equipment for areas that are not accessible from the ground. Some schools will require a lift that can access 2-3 stories.

2.4. Respondent will be allowed to use onsite water to fill water tank for projects completed within the Fayette County School District.

2.4.1. If contractor is using a portable pressure washer on the sidewalks, water access at the site will be granted.

2.4.2. Fayette County Schools will not provide or authorize use of any school district equipment including water hoses. (Only water access when approved) Contractor is responsible for providing any water hose(s) that are needed to complete these projects.

2.4.3. At no time should a vendor fill a water tank onsite for unauthorized projects or work that is performed outside of the Fayette County School District.

-5-

2.5. Respondent will be responsible for the pressure washing of school buildings, sidewalks, concession stands, and stadium seating.

2.6. Respondent will be responsible for any prep work needed to complete these projects.

2.7. Respondent is responsible for providing all materials for each project without up front payment. Projects are paid out upon completion.

2.8. Respondents' working hours are flexible (work can be completed on the weekends and during the evening hours) with prior approval of Maintenance Coordinator, Beria Orr.

2.9. Inspections will be completed after the completion of each project. Once the inspection has been signed off on (to the satisfaction of Facilities Services member), invoices will be processed.

2.9.1. Fayette County Public Schools pays on thirty (30) day terms, per the General Terms and Conditions

2.10. Site visit(s) can be scheduled with Beria Orr, Facilities Coordinator, prior to the solicitation due date.

2.11. Respondent will be responsible for servicing their awarded area throughout the contract duration

2.11.1. Award can be issued for all project areas or can be divided into zones based on the solicitation responses and tabulations

2.11.2. Zones will be outlined on the cost proposal sheets

2.12. Cost proposal will be submitted with square foot pricing and daily rate

2.12.1. Respondent is responsible for providing square foot totals on each invoice for processing

2.12.2. Project pricing can be submitted (for review) after award, only if the completed project price will be less than square foot pricing submitted

2.12.2.1. Providing a project price (as a whole) may provide a cost break to the school system

3. Performance Requirements

3.1. Respondent will be required to wear a company logo shirt while onsite

3.2. Respondent will be required to check in with the front office, upon arrival, to inform staff of what area they will be working on

3.3. Respondent must adhere to the Fayette County Public Schools policies while onsite (Tobacco, drug, weapon, fighting, etc)

3.3.1. Respondent is responsible for conducting themselves in a professional manner

3.4. Respondent is responsible for providing a list of employees who will be onsite

3.4.1. Respondent is responsible for providing proof that a criminal background check has been processed and cleared for each employee

3.5. Respondent will be required to schedule all projects with Beria Orr, Facilities Coordinator, prior to site arrival.

3.6. Respondent will be responsible for reporting any damage and peeling paint that may occur during this project.

3.6.1. Included but not limited to; concrete breaking/crumbling, cracked/broken glass, paint that begins to peel when water pressure is

-6-applied. As, Facilities Services is responsible for making sure these items are addressed immediately.

3.6.2. If paint peeling occurs in an area, Beria Orr, Maintenance Coordinator, will need to be contacted immediately and the contractor will need to move on to another area, while the peeling is being accessed by the Maintenance Supervisor.

Section C: Evaluation of Proposals

1. Evaluation Committee

1.1. All proposals deemed responsive will be evaluated by a review committee composed of project administrators and end-users.

1.2. Criterions based on qualifications and experience, a submitted proposal, and price/cost will be used in the evaluation process.

2. Evaluation Methodology

2.1. The committee will perform a complete evaluation and verification process on a rating system of required proposal components contained herein based on an “Excellent”, “Good”, “Fair”, or “Poor” rating.

2.1.1. Excellent ratings will be issued four (4) points. Excellent ratings are issued when the proposed solution fully complies with the requirements of the specification and can be used as the high mark during the evaluation process.

2.1.2. Good ratings will be issued three (3) points. Good ratings are issued when the proposed solution partially complies with the requirements of the specification but meets the intended goals of the project.

2.1.3. Fair ratings will be issued either two (2) points or one (1) point. Fair ratings are issued when the proposed solution partially complies with the requirements of the specification but requires modification to meet the intended goals of the project.

2.1.4. Poor ratings will be issued zero (0) points. Poor ratings are issued when the proposed solution does not comply with the requirements of the specification or the specification is not addressed at all.

2.2. The committee will be the sole and final determiner of awarded points and whether or not a proposed solution complies with the specifications and intended goals of the project.

3. Interviews and Presentations

3.1. Post-proposal interviews and presentations may be required, in person at the committee’s direction or desire.

3.2. Submission of a proposal does not guarantee an interview or presentation.

3.3. Selection for interviews and presentations is at the sole discretion of the evaluation committee.

-7-

4. Contract Award and Negotiations

4.1. The evaluation committee will issue a recommendation to award following the outcome of its evaluation process.

4.2. The committee reserves the right to reject any or all bids.

4.3. A recommendation to award does not guarantee a contract. Final approval from the Superintendent and/or Board of Education may be required.

4.4. Following a recommendation to award, the Superintendent or their designee may engage in final negotiations with the selected respondent.

Section D: General Terms and Conditions

The FCPS General Terms and Conditions are posted on the Purchasing Department website under the heading of Vendor Terms, Conditions, and Forms and attached to this solicitation.

By submission of a proposal, the respondent acknowledges they have read and understood these General Terms and Conditions as well as any terms and conditions contained herein.

Section E: Special Terms and Conditions

1. Contract Incorporation

1.1. This solicitation will be incorporated into any resulting contract.

1.2. When this solicitation and any resulting contract are in conflict, Fayette County Public Schools will determine the controlling method.

1.3. Only the Superintendent or his direct designee may sign or enter into a contract on behalf of Fayette County Public Schools.

2. Term

2.1. The proposal term will begin from the time of award through June 30, 2026, with an option to renew for three (3) additional terms.

2.1.1. Terms are defined as the fiscal year from July 1st to June 30th of each calendar year.

3. Cooperative Purchasing

3.1. This solicitation allows for other Fayette County, Georgia government entities, including local municipalities, to purchase from the awarded contract at the same prices quoted during the effective term pending an agreement between the awarded respondent(s) and the government entity.

4. Substitutions and Alternates

4.1. Products similar to or other than specified may be acceptable if in compliance with all requirements of these specifications and are of the same or better quality.

4.2. The respondent must provide substantiation that proposed substitution or alternate does not violate any other manufacturer's patents, patents allowed, -8-http://www.fcboe.org/Page/2707 or patents pending and that the alternate proposed meets the same specifications contained herein.

4.3. The FCPS shall be the sole determiner of specification compliance and alternate acceptability.

4.4. No pre-proposal approval will be given for a proposed alternative.

5. Insurance Requirements

5.1. Respondents are required to submit a current and valid Certificate of

Insurance (COI) per the General Terms and Conditions and any specification contained herein.

5.2. Should the respondent choose to utilize subcontractors for installation or other matters, the respondent must provide a valid COI for the subcontractor per the requirements of the General Terms and Conditions.

Section F: Required Forms and Submissions

1. Required Respondent Submissions

1.1. Product Data: Fayette County School District must receive all product data that pertains to solicitations work scope, this includes but is not limited to;

1.2. Product Data Sheet: Chemicals that will be used throughout the contract duration

1.3. Product Certification: Submit manufacturer’s certification that products and materials comply with the requirements of the specifications.

1.4. Submit manufacturer's catalog cuts, material safety data sheets (MSDS), brochures, specifications;

1.5. Preparation, maintenance, and installation instructions and recommendations;

1.6. Storage, handling requirements, and recommendations.

1.7. Warranties: Submit warranty documents according to specifications (if applicable).

1.7.1. Include any and all manufacturer’s warranties for each item.

2. Cost Proposal

2.1. All respondents must include a separate cost proposal.

2.2. Pricing not entered in the cost proposal form will not be considered.

2.3. If pricing variations exist for different finishes/materials/options the respondent must include an attachment describing variations and associated costs.

-9-

2.4. Costs should be in line-item format detailing all costs applicable to the proposed solution and a grand total cost to execute the proposed solution fully.

3. Letters of Recommendation

3.1. The respondent must include a minimum of three (3) letters of recommendation dated within the previous two (2) calendar years.

3.2. Letters must be from clients/customers who have engaged the respondent in previous services and must include details such as a description/scope of work, timeline and budget parameters, and assessment of the respondent’s ability to complete work/service as specified.

3.3. Each letter must contain contact information including organization/firm, contact name, telephone, and email.

3.4. Letters from organizations and projects similar to the scope and size of Fayette County Public Schools are preferred.

4. Solicitation Response Form

4.1. Respondents must complete a Solicitation Response Form attached hereto and available online at the Purchasing Department website.

4.2. This form must be placed on top, or as the first page of your proposal.

4.3. Failure to attach could result in a reduction in score or a rejection of your proposal.

5. Business Capability Information Questionnaire

5.1. Respondents must complete a Business Capability Form attached hereto and available online at the Purchasing Department website.

5.2. Failure to attach could result in a reduction in score or a rejection of your proposal.

6. Certificate of Insurance

6.1. The respondent must submit a current certificate of insurance detailing coverage limits as defined in this RFP and the FCPS General Terms and Conditions.

6.2. Failure to attach could result in a reduction in score or rejection of your proposal.

6.3. The selected respondent will be required to submit a COI naming Fayette County Public Schools as an additional insured party.

7. W-9 Form

7.1. The respondent must submit a current Internal Revenue Service W-9 Form complete with proper signature.

-10-https://www.irs.gov/pub/irs-pdf/fw9.pdf

7.2. Failure to attach could result in a reduction in score or rejection of your proposal.

8. E-Verify Documentation

8.1. The respondent must submit a completed E-Verify Compliance Form and

Affidavit as attached below.

8.2. Failure to attach could result in a reduction in score or rejection of your proposal.

-11-

Cost Proposal Individual Rates and Fees

Description Rate/Cost

Pressure Wash Concrete Building $ Per Square Foot

Pressure Wash Concrete Sidewalk $ Per Square Foot

Pressure Wash Concrete Curb $ Per Square Foot

Pressure Wash Concrete Seating $ Per Square Foot

Pressure Wash Aluminum Seating $ Per Square Foot

Service Charge $ Per Visit

Travel Charge $ Per Trip

Fuel Surcharge $ Per Trip

Labor Rate $ Per Tech

Equipment Fee (Lift Rental/Usage) $ Per Project

Pressure Washing Daily Rate (8 Hours) $ Per Day **If Service, Travel, Fuel Surcharge, and Labor Rates are included in the square foot pricing, respondents will need to indicate in the space below. Additional information about equipment fees and daily rates must be provided as a separate attachment**

Respondent Notes: _____________________________________________________

Company Name:_____________________________ Date:_______________

Signature:____________________________________________

-12-

Cost Proposal: Zones

Zone #1 North Fayette Elementary School Fayetteville Elementary School FIS/Operations Fayette County High School LaFayette Educational Center (LEC) Fayette Life Academy Spring Hill Elementary School Bennett’s Mill Middle School Cleveland Elementary School

Zone #2 Oak Grove Elementary School Braelinn Elementary School Peeples Elementary School Rising Starr Middle School Starr’s Mill High School Goza Road Complex Whitewater High School Sara Harp Minter Elementary School Whitewater Middle School Inman Elementary School

Zone #3 Huddleston Elementary School Center of Innovations JC Booth Middle School McIntosh High School Peachtree City Elementary School Kedron Elementary School Crabapple Lane Elementary School Tyrone Elementary School Sandy Creek High School Robert J Burch Elementary School Flat Rock Middle School

-13-

Solicitation Response Form

RFP 26-017-075 Pressure Washing Services for Fayette County Public Schools

Place this form on top of your response.

Company Name:

Point of Contact:

Street Address:

City:

State:

Zip Code:

Telephone:

Email:

Website:

Authority to Act The undersigned states that he/she has the requisite authority to act on behalf of his/her employer in these matters and has offered to provide the products/services in accordance with the terms and conditions herein.

Terms, Conditions, and Specifications Through the submission of response and signature below, the respondent verifies that their solution, if applicable, complies fully, or complies with an exception, to all stated general and special terms, conditions, and specifications. See the FCPS General Terms and Conditions for further information and directions on notating exceptions to stated specifications.

Addenda Through the submission of response and signature below the respondent verifies that they have read and understood any addenda issued for this solicitation if issued.

Signature: ______________________________ Date:_____________________

RFP 26-017-075: Pressure Washing Services for Fayette County Public Schools

Business Capability and Respondent Qualification Questionnaire

Please answer all questions fully. Additional pages for responses must be clearly marked to identify the respondent’s name and solicitation number.

1) How long has your company been in business?

2) What was your annual gross revenue in 2025?

3) Please indicate current contracts in hand similar to the scope of this project and attach a separate document indicating the name, telephone, and email of each owner/controlling firm; and the status and completion date of each. (Must Include Attachment).

4) Does your company have experience in public school services? List all public school projects completed in Georgia since 2015.

5) Has your company ever completed a project more than one month behind schedule? If so, please identify the project and explain the circumstances. (If applicable, must include an attachment.)

6) Has your company ever failed to complete any work awarded to it? If so, please explain.

(If applicable, must include an attachment.)

7) Has your company ever defaulted on a contract? If so, please explain. (If applicable, must include an attachment.)

8) Please indicate your company’s bonding capacity.

9) Please indicate your company’s insurance carrier.

10)Please indicate whether any insurance claim has been made against or by your company in the past seven (7) years, the circumstances surrounding such claims, and the outcome.

(If applicable, must include an attachment.)

11)Please indicate whether any legal claim, administrative hearings and/or proceedings has been made against your company in the past seven (7) years (including state and federal Department of Labor as well as OSHA), the circumstances surrounding such claims, and the adjudicated outcome. (If applicable, must include an attachment.)

12)Please list bank reference:

13)Has your company ever had a bankruptcy petition, arbitration demand, or lien filed against it in the previous seven (7) years? If so, please explain. (If applicable, must include an attachment.)

14)Has your company, any principal officers, or project managers had any criminal investigations or proceedings brought against them in the previous ten (10) years? If so, please explain. (If applicable, must include an attachment.)

15)Please attach a separate list of all employees who will be assigned to work on the project described herein and include any professional licenses or certifications they hold. (Must Include Attachment)

The respondent attests that the information included as attachments and responses are true and accurate as of the date of submission. Respondent also agrees by submission to allow Fayette County Public Schools to review or investigate any response contained herein. Respondent may be required to submit recent financial statements/reports and should indicate any objection herein. Failure to indicate or answer questions may deem the proposal non-responsive.

Notarized

FAYETTE COUNTY PUBLIC SCHOOLS - PURCHASING DEPARTMENT

GEORGIA SECURITY & IMMIGRATION COMPLIANCE ACT FORM

GEORGIA SECURITY AND IMMIGRATION COMPLIANCE ACT OF 2006, AS AMENDED BY

THE ILLEGAL IMMIGRATION REFORM ACT OF 2011, OCGA 13-10-90, ET SEQ.

TO ALL PROSPECTIVE CONTRACTORS:

If you are providing services to Fayette County Public Schools, this completed document, as well as the applicable Georgia Security and Immigration Compliance forms and affidavits referenced herein must be completed, signed, notarized and submitted with your bid, proposal or contract.

Fayette County Public Schools shall comply with the Georgia Security and Immigration Compliance Act, as amended, O.C.G.A.,~13-10-90 et seq. In order to ensure compliance with the Immigration Reform and Control Act of 1986 (IRCA,P.L.99-603 and the Georgia Security and Immigration Compliance Act of 2006, as amended by the Illegal Immigration Reform Act of 2011,O.C.G.A ~ 13-10-90 et seq.

(collectively the “Act”) the contractor (“Contractor”) MUST INITIAL the statement applicable to Contractor below:

INITIAL ONLY ONE CHOICE BELOW

____ (Initial here) Contractor represents and warrants that Contractor has registered at https://e-verify.uscis.gov/enroll/ to verify information of all new employees in order to comply with the Act; Is authorized to use and uses the federal authorization program; and will continue to use the authorization program throughout the contract period. Contractor further represents, warrants and agrees that it shall execute and return any and all affidavits required by the Act and the rules and regulations issued by the Georgia Department of Labor as set forth at Rule 300-10-1-01 et.seq. In accordance with the terms thereof; (Complete and submit the Contractor Affidavit and Agreement); OR

____ (Initial here) Contractor represents and warrants that it has no employees and does not intend to hire employees to perform contractual services, and that Contractor has therefore provided a U.S. state-issued Driver’s license or ID card in lieu of an affidavit and that such license or ID card was issued by a State that verifies lawful Immigration status before issuing the license or ID card. If my status changes I will, before hiring any employees, immediately notify the School District in writing and provide all affidavits required under the Act; OR

____ (Initial here) Contractor represents and warrants that it does not physically perform any service within the State of Georgia as defined in the Act and thus does not have to comply with foregoing Georgia law; OR

_____(Initial here) Contractor is a foreign company and therefore not required to provide the affidavit as required by the Act. The Contractor must comply with any other laws required to perform services in the United States, including but not limited to having an appropriate visa.

USE OF SUBCONTRACTOR(S) and COMPLIANCE AS ABOVE

___(Initial here) Contractor will not employ or contract with any subcontractor in connection with a covered contract unless the subcontractor is registered, Is authorized to use, and uses the Federal Work Authorization Program and provides Contractor with all affidavits required by the Act and the rules and regulations issued by the Georgia Department of labor as set forth at Rule 300-10-01 et seq.

____(Initial here) Contractor covenants and agrees that, if Contractor employs or contracts with any Subcontractor in connection with the covered contract under the Act and DOL Rule 300-10-1-02, then in such event Contractor will secure from each subcontractor at the time of the subcontract, the subcontractor’s name and address, the employer identification number/taxpayer identification number applicable to the subcontractor; the date the authorization to use the Federal Work Authorization Program was granted to subcontractor; the subcontractor’s attestation of the subcontractor’s compliance with the Act and Georgia Department of Labor Rule 300-10-1-.2.; and the subcontractor’s agreement not to contract with subcontractors unless the subcontractor is registered, authorized to use, and uses the Federal Work Authorization Program; and provides subcontractor with all affidavits required by the Act and the rules and regulations issued by the Georgia Department of Labor as set forth at Rule 300-10-1-01 et seq.

(Complete and submit the Subcontractor Affidavit and Agreement)

_____(Initial here) Contractor agrees to provide Fayette County Public Schools with all affidavits of compliance as required by the Act and Georgia Department of Labor Rule 300-10-1-02, 300-10-1-03, 300-10-1-07 and 300-10-1-08 within five (5) business days of its receipt of any such documents.

Company Name: _____________________________________________________________

SIGNATURE: __________________________________________________________________

DATE: __________________________________________

CONTRACTOR AFFIDAVIT PROVIDED PURSUANT TO O.C.G.A. § 13-10-91(b)(2)

(Rev. 4/18/2019)

By executing this affidavit, the undersigned contractor verifies its compliance with O.C.G.A. § 13-10-91 stating affirmatively that the individual, firm or corporation which is engaged in the physical performance of services under a contract with Fayette County Public Schools, has registered with, is authorized to use, and uses the federal work authorization program commonly known as E-Verify, or any subsequent replacement program, in accordance with the applicable provisions and deadlines established in O.C.G.A. § 13-10-91. Furthermore, the undersigned contractor covenants that it will continue to use the federal work authorization program throughout the contract period, that the undersigned contractor will contract for the physical performance of services in the performance of such contract only with subcontractors who present an affidavit to the contractor with the information required by O.C.G.A. § 13-10-91(b), and that the contractor shall forward any subcontractor’s affidavit to the School District within five (5) days of its receipt of the same.

Contractor hereby attests that its federal work authorization user identification number and date of authorization are as follows:

EEV User Identification Number (4 to 6 Digit Number)

Date of Authorization

Contractor/Company

Email Address

Telephone Number

Name of Project

Project Number

Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on , 20 in (city), (state).

Signature of Authorized Officer or Agent

Printed Name of Authorized Officer or Agent Title of Authorized Officer or Agent

NOTARY INFORMATION

Sworn to before me this day of , 20 .

Notary Public Signature

My Commission Expires: ____________________________

SUBCONTRACTOR AFFIDAVIT PURSUANT TO O.C.G.A. § 13-10-91(b)(3)

(Rev. 4/18/2019)

By executing this affidavit, the undersigned subcontractor verifies its compliance with O.C.G.A. § 13-10-91 stating affirmatively that the individual, firm or corporation which is engaged in the physical performance of services under a contract with ___________________, which has a contract with Fayette County Public Schools, has registered with, is authorized to use and uses the federal work authorization program commonly known as E-Verify, or any subsequent replacement program, in accordance with the applicable provisions and deadlines established in O.C.G.A. § 13-10-91. Furthermore, the undersigned subcontractor covenants that it will continue to use the federal work authorization program throughout the contract period, that the undersigned subcontractor will contract for the physical performance of services in the performance of such contract only with sub-subcontractors who present an affidavit to the subcontractor with the information required by O.C.G.A. § 13-10-91(b), and that the subcontractor shall forward any sub-subcontractors affidavit to the contractor and School District within five (5) days of its receipt of the same.

Subcontractor hereby attests that its federal work authorization user identification number and date of authorization are as follows:

EEV User Identification Number (4 to 6 Digit Number)

Date of Authorization

Subcontractor/Company

Email Address

Telephone Number

Name of Project

Project Number

Name of Public Employer

I hereby declare under penalty of perjury that the foregoing is true and correct.

Executed on , 20 in (city), (state).

Signature of Authorized Officer or Agent

Printed Name of Authorized Officer or Agent Title of Authorized Officer or Agent

NOTARY INFORMATION

Sworn to before me this day of , 20 .

Notary Public Signature

My Commission Expires: ____________________________

Terms, Conditions, and Specifications

Addenda