Performance_Bond_QB.pdf

CONSTRUCTION PERFORMANCE BOND

KNOW ALL PERSONS BY THESE PRESENTS:

1. THAT WHEREAS, City of Watsonville, a political subdivision of the State of California (Owner) has awarded to [Name of Contractor)____________________________, as Principal, a Purchase Order Agreement, dated the ___________ day of ___________, 20___ (Agreement), titled THE ___________________________ PROJECT in the amount of $______________, which Agreement is by this reference made a part hereof, for the work described as follows:

2. (Describe Agreement Work)

3. AND WHEREAS, Principal is required to furnish a bond in connection with the Agreement, guaranteeing the faithful performance thereof;

4. NOW, THEREFORE, we, the undersigned Principal and _________________________ as Surety are held and firmly bound unto Owner in the sum of 100% OF THE CONTRACT SUM to be paid to Owner or its successors and assigns; for which payment, well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents.

5. THE CONDITION OF THIS OBLIGATION IS SUCH, that if Principal, or its heirs, executors, administrators, successors, or assigns approved by Owner, shall promptly and faithfully perform the covenants, conditions, and agreements of the Agreement during the original term and any extensions thereof as may be granted by Owner, with or without notice to Surety, and during the period of any guarantees or warranties required under the Agreement, and shall also promptly and faithfully perform all the covenants, conditions, and agreements of any alteration of the Agreement made as therein provided, notice of which alterations to Surety being hereby waived, on Principal’s part to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify, defend, protect, and hold harmless Owner as stipulated in the Agreement, then this obligation shall become and be null and void;

otherwise it shall be and remain in full force and effect.

6. No extension of time, change, alteration, modification, or addition to the Agreement, or of the work required thereunder, shall release or exonerate Surety on this bond or in any way affect the obligation of this bond; and Surety does hereby waive notice of any such extension of time, change, alteration, modification, or addition.

7. Whenever Principal shall be and declared by Owner in default under the Agreement, Surety shall promptly remedy the default, or shall promptly:

7.01 Undertake through its agents or independent contractors, reasonably acceptable to Owner, to complete the Agreement in accordance with its terms and conditions and to pay and perform all obligations of Principal under the Agreement including, without limitation, all obligations with respect to warranties, guarantees, indemnities, and the payment of liquidated damages; or

7.02 Obtain a bid or bids for completing the Agreement in accordance with its terms and conditions, and, upon determination by Owner of the lowest responsible bidder, reasonably acceptable to Owner, arrange for a contract between such bidder and Owner and make available as work progresses (even though there should be a default or a succession of defaults under the contract or contracts of completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the Contract Sum, and to pay and perform all obligations of Principal under the Agreement including, without limitation, all obligations with respect to warranties, guarantees, and the payment of liquidated damages; but, in any event, Surety’s total obligations hereunder shall not exceed the amount set forth in the third paragraph hereof. The term “balance of the Contract Sum,” as used in this paragraph, shall mean the total amount payable by Owner to the Principal under the Agreement and any amendments thereto, less the amount Owner paid to Principal.

8. Surety’s obligations hereunder are independent of the obligations of any other surety for the performance of the Agreement, and suit may be brought against Surety and such other sureties, jointly and severally, or against any one or more of them, or against less than all of them without impairing Owner’s rights against the others. Surety may not use Contractor to complete the Agreement absent Owner’s written consent.

9. No right of action shall accrue on this bond to or for the use of any person or corporation other than Owner or its successors or assigns.

10. Surety may join in any proceedings brought under the Agreement and shall be bound by any judgment.

11. Correspondence or claims relating to this bond shall be sent to Surety at the address set forth below.

IN WITNESS WHEREOF, we have hereunto set our hands this _________ day of ________________, 20___.

CONTRACTOR AS PRINCIPAL

Company: (Corp. Seal)

Signature

Name

Title

Street Address

City, State, Zip Code

SURETY

Company: (Corp. Seal)

Signature

Name

Title

Street Address

City, State, Zip Code

(End of Appendix D)