Payment_Bond.docx
DOCX document 28 KB Posted
- Solicitation number
- 4514
- Issued by
- Los Angeles County, San Francisco City, California
About this file
This is a Payment Bond document for the City of Santa Monica, California, required under Civil Code Section 9550 for a five-year firm-fixed contract to provide periodic sewer diversion unit cleaning and hazardous waste disposal services at various locations throughout the city's Wastewater Division. The bond is executed by a principal contractor and surety to secure payment claims from all persons named under California Civil Code Section 9100, including contractors, subcontractors, laborers, materialmen, and other parties involved in contract performance. The bond amount equals 100 percent of the proposal amount and covers all materials, equipment, labor, and amounts due under the Unemployment Insurance Act related to contract performance. The document is dated 2017 and requires execution by authorized representatives of both the principal and surety, accompanied by notarial acknowledgment of the surety and power of attorney documentation.
The surety's obligations remain binding regardless of any changes, extensions of time, alterations, or modifications to the contract or work, with the surety waiving notice of such modifications. The bond provides protection for all persons with a right of action against the surety in an amount not exceeding the stated bond value. In the event suit is brought upon the bond, the surety agrees to pay reasonable attorney's fees as fixed by the court and assessed as costs within any judgment rendered. The bond obligations bind the surety and its successors and assigns jointly and severally, creating comprehensive protection for all claimants entitled to payment under California law.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| Sewer_Diversion_Unit_Cleaning_and_Hazardous_Waste_Disposal_(Addendum_#1_Revision).pdf | ||
| Sewer_Diversion_Unit_Cleaning_and_Hazardous_Waste_Disposal.pdf | ||
| CSA-PO_with_Pollution.docx | DOCX document | |
| CSA_Template.docx | DOCX document | |
| PW_Determination_(Hazardous_Waste).pdf |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PAYMENT BOND
(Civil Code Section 9550)
KNOW ALL PERSONS BY THESE PRESENTS:
WHEREAS, the City of Santa Monica, hereinafter called City by motion adopted on the
_______day of _______________, 2017, has awarded to______________________________, hereinafter called Principal, with its principal office in the City of _________________________, State of ______, a Contract for _________________________________________________, including without limitation all incorporated documents, exhibits and other documents defined for the Contract.
WHEREAS, Principal is required under the terms of the agreement to furnish a good and sufficient payment bond to secure the claims to any of the persons named in Section 9100 Civil Code of the State of California.
THAT we _ , as Principal, and, _____________________ , hereinafter called Surety, are held and firmly bound unto the City all contractors, subcontractors, laborers, materialmen and all other persons employed in the performance of the Contract and referred to in the aforesaid portion of the Civil Code, in the sum of
______________________________________________Dollars ($_____________________), (100% of amount in proposal) for materials and equipment furnished and labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect thereto, and that said Surety will pay the same in or to an amount not exceeding the amount herein above set forth, and also will pay in case suit is brought upon this bond, such reasonable attorney’s fees as shall be fixed by the Court, awarded and taxed as costs and included in the judgment therein rendered.
This bond shall inure to the benefit of any and all persons, named in Civil Code Section 9100 so as to give a right of action to them or their assigns in any suit upon this bond.
Should the condition of this bond be fully performed, then this obligation shall be void, otherwise it shall remain in full force and effect.
Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or modification of the Contract or of the work to be performed thereunder shall in any way affect its obligations on this bond and it does hereby waive notice of such change, extension of time, alteration or modification of the Contract or of work to be performed thereunder.
The obligations set forth herein shall be binding upon Surety and its heirs, executors, administrators, successors, and assigns, jointly and severally.
PAYMENT BOND
(Civil Code Section 9550)
IN WITNESS WHEREOF one (1) identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety named herein, on the _______day of _______________, 2017, the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative pursuant to authority of its governing body.
SIGNED AND SEALED on this _________ day of __________________, 2017
| ________________________________ | ||
| Seal | Principal |
By________________________________ Signature
| ________________________________ | |
| Seal | Surety |
By________________________________ Signature ________________________________
Surety’s Mailing Address
Telephone Number
(Attach both Notarial Acknowledgement of Surety and Power of Attorney) image1.jpeg
File details come from the government source that posted it. Updated .