Solicitation_N6833519Q0086.pdf

N6833519Q0086

Section A - Solicitation/Contract Form

POINTS OF CONTACT

Contract Specialist Information: William Waterhouse, 2.5.2.5.1, 732.323.2243, william.waterhouse@navy.mil

Customer Information: TBD

Contractor Information: TBD

ACCELERATED DELIVERY

Accelerated delivery to the greatest extent possible in advance of the specified delivery schedule is desired. Any accelerated delivery will be at no additional cost(s) to the Government, unless specifically authorized by the

Procuring or Administrative Contracting Officer. Accelerated delivery will not result in any delay in payment to the

Contractor.

mailto:william.waterhouse@navy.mil

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 200 Each Jet Car Deadload Tires

FFP

200 each dead load tires for the Jet Car Test Site track operational testing.

The following are the minimum required salient characteristics:

- 32 x 8.8 Tire with the following requirements –

- Ply Rating >= 20

- Speed index >= 250 knots

- Max Load >= 23,700 lbs

- Inflation Pressure (unloaded) >= 100 psi

- Static Load Radius, at Rated Load - 13.3"

Tire will be mounted on a rim with the following dimensions:

- Width between Flanges – 7.00”

- Specified Rim Diameter – 16.00”

- Flange Height – 1.125”

- Outer Flange Diameter – 18.25”

FOB: Destination

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 30-APR-2019 200 NAVAIR LAKEHURST

JIM PARENTE

HIGHWAY 547 BLDG 398 TEST DEPT.

LAKEHURST NJ 08733

732-323-7893

FOB: Destination

N68335

Section G - Contract Administration Data

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through

WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

COMBO

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and

“Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in

WAWF, as specified by the contracting officer.

DESTINATION

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC TBD

Issue By DoDAAC N68335

Admin DoDAAC N68335

Inspect By DoDAAC N68335

Ship To Code N68335

Ship From Code TBD

Mark For Code N68335

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send

Additional Email Notifications” field of WAWF once a document is submitted in the system.

TBD

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Not applicable

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.211-17 Delivery of Excess Quantities SEP 1989

52.212-1 Instructions to Offerors--Commercial Items OCT 2018

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018

52.212-5 (Dev) Contract Terms and Conditions Required to Implement

Statutes or Executive Orders--Commercial Items (Deviation

2018-O0021)

OCT 2018

52.222-50 Combating Trafficking in Persons MAR 2015

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.247-34 F.O.B. Destination NOV 1991

52.252-6 Authorized Deviations In Clauses APR 1984

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7000 Buy American--Balance Of Payments Program Certificate--

Basic (Nov 2014)

NOV 2014

252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017

252.225-7008 Restriction on Acquisition of Specialty Metals MAR 2013

252.225-7009 Restriction on Acquisition of Certain Articles Containing

Specialty Metals

OCT 2014

252.225-7012 Preference For Certain Domestic Commodities DEC 2017

252.225-7036 Buy American--Free Trade Agreements--Balance of

Payments Program--Basic

DEC 2017

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.246-7000 Material Inspection And Receiving Report MAR 2008

252.247-7023 Transportation of Supplies by Sea APR 2014

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (OCT 2018)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by

Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(4) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(5) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19

U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_X__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct

1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

_X__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

____ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June

2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment

Act of 2009.)

_X__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub.

L. 109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div.

C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub.

L. 111-117, section 743 of Div. C).

_X__ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

_X__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (July 2013)

(41 U.S.C. 2313).

____ (10) [Reserved]

____ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

____ (ii) Alternate I (NOV 2011) of 52.219-3.

____ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014)

(if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (ii) Alternate I (JAN 2011) of 52.219-4.

____ (13) [Reserved]

____ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

____ (ii) Alternate I (NOV 2011).

____ (iii) Alternate II (NOV 2011).

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

____ (ii) Alternate I (Oct 1995) of 52.219-7.

____ (iii) Alternate II (Mar 2004) of 52.219-7.

_X__ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

_X__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (Nov 2016) of 52.219-9.

____ (iii) Alternate II (Nov 2016) of 52.219-9.

____ (iv) Alternate III (Nov 2016) of 52.219-9.

____ (v) Alternate IV (Nov 2016) of 52.219-9.

____ (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

____ (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

_X__ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C.

657f).

____ (22) 52.219-28, Post Award Small Business Program Rerepresentation (July 2013) (15 U.S.C. 632(a)(2)).

____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-

Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

____(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns

Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

_X__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X__ (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126).

_X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X__ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

_X__ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

____ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014) (29 U.S.C. 793).

____ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

____ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

_X__ (33)(i) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

____ (ii) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in

22.1803.)

____ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May

2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693).

____ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

(June, 2016) (E.O. 13693).

____ (38) (i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and

13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (39)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-14.

____ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

____ (41)(i) 52.223-16, Acquisition of EPEAT[supreg]-Registered Personal Computer Products (OCT 2015) (E.O.s

13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-16.

_X__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O.

13513).

____ (43) 52.223-20, Aerosols (June, 2016) (E.O. 13693).

____ (44) 52.223-21, Foams (June, 2016) (E.O. 13693).

____ (45)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

_X__ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

____ (47) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter

83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L.

103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I (May 2014) of 52.225-3.

____ (iii) Alternate II (May 2014) of 52.225-3.

____ (iv) Alternate III (May 2014) of 52.225-3.

____ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X__ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016)

(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

____ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150

____ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

____ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10

U.S.C. 2307(f)).

____ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

_X__ (55) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (July 2013) (31

U.S.C. 3332).

____ (56) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (July

2013) (31 U.S.C. 3332).

____ (57) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

_X__ (59) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

_X__ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

____ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_____(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

_____ (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

_____ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple

Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY

2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____(8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (E.O. 13658).

_____ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

_____ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

_____ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the

Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by

Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(v) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vii) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(viii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xiii) _____ (A) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvii)52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

(xviii) (A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xix) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section

862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx

1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

52.243-7 NOTIFICATION OF CHANGES (JAN 2017)

(a) Definitions. "Contracting Officer," as used in this clause, does not include any representative of the

Contracting Officer. "Specifically authorized representative (SAR)," as used in this clause, means any person the

Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the

Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing, within 7 calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state--

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including--

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Continued performance. Following submission of the notice required by (b) above, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in (b) above, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing and copies furnished to the

Contractor and to the Contracting Officer. The Contracting Officer shall countermand any action which exceeds the authority of the SAR.

(d) Government response. The Contracting Officer shall promptly, within 30 calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either--

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under (1), (2), or (3) above, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

(e) Equitable adjustments.

(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

NOTE: The phrases "contract price" and "cost" wherever they appear in the clause, may be appropriately modified to apply to cost- reimbursement or incentive contracts, or to combinations thereof.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/ or http://farsite.hill.af.mil

252.204-7012 SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER INCIDENT

INFORMATION (OCT 2016)

(a) Definitions. As used in this clause --

"Adequate security" means protective measures that are commensurate with the consequences and probability of loss, misuse, or unauthorized access to, or modification of information.

"Compromise" means disclosure of information to unauthorized persons, or a violation of the security policy of a system, in which unauthorized intentional or unintentional disclosure, modification, destruction, or loss of an object, or the copying of information to unauthorized media may have occurred.

"Contractor attributional/proprietary information" means information that identifies the contractor(s), whether directly or indirectly, by the grouping of information that can be traced back to the contractor(s) (e.g., program description, facility locations), personally identifiable information, as well as trade secrets, commercial or financial information, or other commercially sensitive information that is not customarily shared outside of the company.

"Controlled technical information" means technical information with military or space application that is subject to controls on the access, use, reproduction, modification, performance, display, release, disclosure, or dissemination. Controlled technical information would meet the criteria, if disseminated, for distribution statements

B through F using the criteria set forth in DoD Instruction 5230.24, Distribution Statements on Technical

Documents. The term does not include information that is lawfully publicly available without restrictions.

"Covered contractor information system" means an unclassified information system that is owned, or operated by or for, a contractor and that processes, stores, or transmits covered defense information.

https://www.acquisition.gov/far/ http://farsite.hill.af.mil/

"Covered defense information" means unclassified controlled technical information or other information, as described in the Controlled Unclassified Information (CUI) Registry at http://www.wrchives.gov/cui/registry/category-list.html, that requires safeguarding or dissemination controls pursuant to and consistent with law, regulations, and Governmentwide policies, and is --

(1) Marked or otherwise identified in the contract, task order, or delivery order and provided to the contractor by or on behalf of DoD in support of the performance of the contract; or

(2) Collected, developed, received, transmitted, used, or stored by or on behalf of the contractor in support of the performance of the contract.

"Cyber incident" means actions taken through the use of computer networks that result in a compromise or an actual or potentially adverse effect on an information system and/or the information residing therein.

"Forensic analysis" means the practice of gathering, retaining, and analyzing computer-related data for investigative purposes in a manner that maintains the integrity of the data.

"Information system" means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information.

"Malicious software" means computer software or firmware intended to perform an unauthorized process that will have adverse impact on the confidentiality, integrity, or availability of an information system. This definition includes a virus, worm, Trojan horse, or other code-based entity that infects a host, as well as spyware and some forms of adware.

"Media" means physical devices or writing surfaces including, but not limited to, magnetic tapes, optical disks, magnetic disks, large-scale integration memory chips, and printouts onto which covered defense information is recorded, stored, or printed within a covered contractor information system.

"Operationally critical support" means supplies or services designated by the Government as critical for airlift, sealift, intermodal transportation services, or logistical support that is essential to the mobilization, deployment, or sustainment of the Armed Forces in a contingency operation.

"Rapidly report" means within 72 hours of discovery of any cyber incident.

"Technical information" means technical data or computer software, as those terms are defined in the clause at

DFARS 252.227-7013, Rights in Technical Data - Non Commercial Items, regardless of whether or not the clause is incorporated in this solicitation or contract. Examples of technical information include research and engineering date, engineering drawings, and associated lists, specifications, standards, process sheets, manuals, technical reports, technical orders, catalog-item identifications, data sets, studies and analyses and related information, and computer software executable code and source code.

(b) Adequate security. The Contractor shall provide adequate security for all covered contractor information systems. To provide adequate security, the Contractor shall implement, at a minimum, the following information security protections:

(1) For covered contractor information systems that are part of an information technology (IT) service or system operated on behalf of the Government, the following security requirements apply:

(i) Cloud computing services shall be subject to the security requirements specified in the clause 252.239-

7010, Cloud Computing Services, of this contract.

(ii) Any other such IT service or system (i.e., other than cloud computing) shall be subject to the security requirements specified elsewhere in this contract.

(2) For covered contractor information systems that are not part of an IT service or system operated on behalf of the Government and therefore are not subject to the security requirement specified at paragraph (b)(1) of this clause, the following security requirements apply:

(i) Except as provided in paragraph (b)(2)(ii) of this clause, the covered contractor information system shall be subject to the National Institute of Standards and Technology (NIST) Special Publication (SP) 800-171, "Protecting Controlled Unclassified Information in Nonfederal Information Systems and Organizations," (available via the internet at http://dx.doi.org/10.6028/NIST.SP.800-171) that is in effect at the time the solicitation is issued or as authorized by the Contracting Officer.

(ii)(A) The Contractor shall submit requests to vary from NIST SP 800-171, as soon as practical, but not later than December 31, 2017. For all contracts awarded prior to October 1, 2017, the Contractor shall notify the DoD

Chief Information Officer (CIO), via email at osd.dibcsia@mail.mil, within 30 days of contract award, of any security requirements specified by NIST SP 800-171 not implemented at the time of contract award.

(B) The Contractor shall submit requests to vary from NIST SP 800-171 in writing to the Contracting

Officer, for consideration by the DoD CIO. The Contractor need not implement any security requirement adjudicated by an authorized representative of the DoD CIO to be nonapplicable or to have an alternative but equally effective, security measure that may be implemented in its place.

(C) If the DoD CIO has previously adjudicated the contractor's requests indicating that a requirement is not applicable or that an alternative security measure is equally effective, a copy of that approval shall be provided to the Contracting Officer when requesting its recognition under this contract.

(D) If the Contractor intends to use an external cloud service provider to store, process, or transmit any covered defense information in performance of this contract, the Contractor shall require and ensure that the cloud service provided meets security requirements equivalent to those established by the Government for the Federal Risk and Authorization Management Program (FedRAMP) Moderate baseline

(https://www.fedramp.gov/resources/documents/) and that the cloud service provider complies with requirements in paragraphs (c) through (g) of this clause for cyber incident reporting, malicious software, media preservation and protection, access to additional information and equipment necessary for forensic analysis, and cyber incident damage assessment.

(3) Apply other information systems security measures when the Contractor reasonably determines that information systems security measures, in addition to those identified in paragraph (b)(1) and (2) of this clause, may be required to provide adequate security in a dynamic environment or to accommodate special circumstances (e.g., medical devices) and any individual, isolated, or temporary deficiencies based on an assessed risk or vulnerability.

These measures may be addressed in a system security plan.

(c) Cyber incident reporting requirement.

(1) When the Contractor discovers a cyber incident that affects a covered contractor information system or the covered defense information residing therein, or that affects the contractor's ability to perform the requirements of the contract that are designated as operationally critical support, the Contractor shall --

(i) Conduct a review for evidence of compromise of covered defense information, including, but not limited to, identifying compromised computers, servers, specific data, and user accounts. This review shall also include analyzing covered contractor information system(s) that were part of the cyber incident, as well as other information systems on the Contractor's network(s), that may have been accessed as a result of the incident in order to identify compromised covered defense information, or that affect the Contractor's ability to provide operationally critical support; and

(ii) Rapidly report cyber incidents to DoD at http://dibnet.dod.mil.

(2) Cyber incident report. The cyber incident report shall be treated as information created by or for DoD and shall include, at a minimum, the required elements at http://dibnet.dod.mil.

(3) Medium assurance certificate requirement. In order to report cyber incidents in accordance with this clause, the Contractor or subcontractor shall have or acquire a DoD-approved medium assurance certificate to report cyber incidents. For information on obtaining a DoD-approved medium assurance certificate, see http://iase.disa.mil/pki/eca/Pages/index.aspx.

(d) Malicious software. When the Contractor or subcontractors discover and isolate malicious software in connection with a reported cyber incident, submit the malicious software to DoD Cyber Crime Center (DC#) in accordance with instructions provided by DC3 or the Contracting Officer. Do not send the malicious software to the

Contracting Officer.

(e) Media preservation and protection. When a Contractor discovers a cyber incident has occurred, the Contractor shall preserve and protect images of all known affected information systems identified in paragraph (c)(1)(i) of this clause and all relevant monitoring/packet capture data for at least 90 days from the submission of the cyber incident report to allow DoD to request the media or decline interest.

(f) Access to additional information or equipment necessary for forensic analysis. Upon request by DoD, the

Contractor shall provide DoD with access to additional information or equipment that is necessary to conduct a forensic analysis.

(g) Cyber incident damage assessment activities. If DoD elects to conduct a damage assessment, the Contracting

Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.

(h) DoD safeguarding and use of contractor attributional/proprietary information. The Government shall protect against the unauthorized use or release of information obtained from the contractor (or derived from information obtained from the contractor) under this clause that includes contractor attributional/proprietary information, including such information submitted in accordance with paragraph (c). To the maximum extent practicable, the

Contractor shall identify and mark attributional/proprietary information. In making an authorized release of such information, the Government will implement appropriate procedures to minimize the contractor attributional/proprietary information that is included in such authorized release, seeking to include only that information that is necessary for the authorized purpose(s) for which the information is being released.

(i) Use and release of contractor attributional/proprietary information not created by or for DoD. Information that is obtained from the contractor (or derived from information obtained from the contractor) under this clause that is not created by or for DoD is authorized to be released outside of DoD--

(1) To entities with missions that may be affected by such information;

(2) To entities that may be called upon to assist in the diagnosis, detection, or mitigation of cyber incidents;

(3) To Government entities that conduct counterintelligence or law enforcement investigations;

(4) For national security purposes, including cyber situational awareness and defense purposes (including with

Defense Industrial Base (DIB) participants in the program at 32 CFR part 236); or

(5) To a support services contractor ("recipient") that is directly supporting Government activities under a contract that includes the clause at 252.204-7009, Limitations on the Use or Disclosure of Third-Party Contractor

Reported Cyber Incident Information.

(j) Use and release of contractor attributional/proprietary information created by or for DoD. Information that is obtained from the contractor (or derived from information obtained from the contractor) under this clause that is created by or for DoD (including the information submitted pursuant to paragraph (c) of this clause) is authorized to be used and released outside of DoD for purposes and activities authorized by paragraph (i) of this clause, and for any other lawful Government purposes or activity, subject to all applicable statutory, regulatory, and policy based restrictions on the Government's use and release of such information.

(k) The Contractor shall conduct activities under this clause in accordance with applicable laws and regulations on the interception, monitoring, access, use, and disclosure of electronic communications and data.

(l) Other safeguarding or reporting requirements. The safeguarding and cyber incident reporting required by this clause in no way abrogates the Contractor's responsibility for other safeguarding or cyber incident reporting pertaining to its unclassified information systems as required by other applicable clauses of this contract, or as a result of other applicable U.S. Government statutory or regulatory requirements.

(m) Subcontracts. The Contractor shall --

(1) Include this clause, including this paragraph (m), in subcontracts, or similar contractual instruments, for operationally critical support, or for which subcontract performance will involve covered defense information, including subcontracts for commercial items, without alteration, except to identify the parties. The Contractor shall determine if the information required for subcontractor performance retains its identity as covered defense information and will require protection under this clause, and if necessary, consult with the Contracting Officer; and

(2) Require subcontractor to--

(i) Notify the prime Contractor (or next higher-tier subcontractor) when submitting a request to vary from a

NIST SP 800-171 security requirement to the Contracting Officer, in accordance with paragraph (b)(2)(ii)(B) of this clause; and

(ii) Provide the incident report number, automatically assigned by DoD, to the prime Contractor (or next higher-tier subcontractor) as soon as practicable, when reporting a cyber incident to DoD as required in paragraph

(c) of this clause.

252.225-7048 EXPORT CONTROLLED ITEMS (JUN 2013)

(a) Definition. “Export-controlled items,” as used in this clause, means items subject to the Export Administration

Regulations (EAR)(15 CFR Parts 730-774) or the International Traffic in Arms Regulations (ITAR)(22 CFR Parts

120-130). The term includes -- “Defense items,” defined in the Arms Export Control Act. 22 U.S.C. 2778(j)(4)(A), as defense articles, defense services, and related technical data, and further defined in the ITAR, 22 CFR Part 120;

and

“Items,” defined in the FAR as "commodities", "software", and "technology," terms that are also defined in the

FAR, 15 CFR 772.1.

(b) The Contractor shall comply with all applicable laws and regulations regarding export-controlled items, including, but not limited to, the requirement for contractors to register with the Department of State in accordance with the ITAR. The Contractor shall consult with the Department of State regarding any questions relating to compliance with the ITAR and shall consult with the Department of Commerce regarding any questions relating to compliance with the FAR.

(c) The Contractor's responsibility to comply with all applicable laws and regulations regarding export-controlled items exists independent of, and is not established or limited by, the information provided by this clause.

(d) Nothing in the terms of this contract adds, changes, supersedes, or waives any of the requirements of applicable Federal laws, Executive orders, and regulations, including but not limited to --

(1) The Export Administration Act of 1979, as amended (50 U.S.C. App. 2401, et seq.);

(2) The Arms Export Control Act (22 U.S.C. 2751, et seq.);

(3) The International Emergency Economic Powers Act (50 U.S.C. 1701, et seq.);

(4) The Export Administration Regulations (15 CFR Parts 730-774);

(5) The International Traffic in Arms Regulations (22 CFR Parts 120-130); and

(6) Executive Order 13222, as extended.

(e) The Contractor shall include the substance of this clause, including this paragraph (e), in all subcontracts.

5252.247-9508 PROHIBITED PACKING MATERIALS (NAVAIR)(JUN 1998)

The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hydroscopic or non-neutral material) is prohibited. In addition, loose fill polystyrene is prohibited for shipboard use.

5252.247-9509 PRESERVATION, PACKAGING, PACKING AND MARKING (NAVAIR)(JUL 1998)

(a) Preservation, packaging and packing shall conform to prevailing industry standards for the type of commodity purchased under this contract.

(b) All packages will be clearly marked with applicable contract number/delivery order number, and will contain appropriate packing slip. All deliveries will be marked for and/or consigned as follows:

Packaging, Preservation and Shipping shall be in accordance with best commercial practices available and shall provide protection from normal climatic / weather conditions and incidental mishandling during shipping. All deliverable items shall be shipped FOB Destination.

(c) In the event of any discrepancy in material shipped (overage, technical rejection, damage), the contractor shall, immediately upon request of the Contracting Officer, furnish disposition instructions. Normally, such disposition instruction shall be a properly completed Commercial Bill of Lading, which includes, but is not limited to, the mode of shipment, routing, special handling, and so forth.

(d) If the contractor is required to install equipment upon delivery, then the contractor shall inform the

Government of the date of…